Home

Document A101TM - Morlando Construction LLC

1. TI PIEDMONT TRIAD AIRPORT AUTHORITY SPECIFICATIONS AND BID DOCUMENT FOR PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport Greensboro North Carolina January 14 2013 LINDSEY ARCHITECTURE Project No 12 040 000 125 S Elm Street Suite 300 Greensboro NC 27401 336 617 4402 Fax 336 617 4434 PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport Ticket Counter Ceiling Renovation TABLE OF CONTENTS 12 001 000 BIDDING REQUIREMENTS CONTRACT FORMS AND CONDITIONS OF THE CONTRACT 00020 Invitation to Bid 00100 Instructions to Bidders 00310 Bid Form for General Construction 00500 Agreement 00700 General Conditions 00800 Supplementary Conditions DIVISION 1 GENERAL REQUIREMENTS 01010 Summary of Work 01040 Coordination 01300 Submittals 01720 Project Record Documents DIVISION 2 SITE WORK NOT USED DIVISION 3 CONCRETE NOT USED DIVISION 4 MASONRY NOT USED DIVISION 5 METALS NOT USED DIVISION 6 WOOD AND PLASTICS 06202 Interior Finish Carpentry DIVISION 7 THERMAL AND MOISTURE PROTECTION NOT USED DIVISION 8 DOORS AND WINDOWS NOT USED DIVISION 9 FINISHES 09290 Gypsum Board Assemblies 09512 Acoustical Tile Ceilings 09514 Custom Metal Ceilings 09912 Interior Painting DIVISION 10 SPECIALTIES NOT USED DIVISION 11 EQUIPMENT NOT USED TABLE OF CONTENTS PAGE TC 1 PTIA Ticket Counter Ceiling Reno
2. A Submit four 4 typed copies of proposed test procedures for approval in accordance with shop drawing requirements of Section 15010B Mechanical General Provisions Include description of procedures instruments and equipment to be used catalog data on instrumentation planned manpower required and proposed schedule Provide this information for each type of test and for each system to be tested Submit four 4 typed copies of test schedules of readings taken during testing and balancing operations indicating the required reading the first reading taken and the final balance reading for the items listed in Part 3 Execution of this section in accordance with shop drawing requirements of Section 15010B Mechanical General Provisions Readings shall be taken with clean operating strainers and filters in place but with start up strainers removed Submit instrument calibration report along with the test schedules of readings taken during testing and balancing operations Submit Component Deficiency Report s as required to provide information helpful in determining the cause of the problem s and to provide feedback to the equipment manufacturer designer or installer Submit such reports as soon as the problem becomes evident and where practical provide recommendations for correcting the apparent system component failure Furnish documentation of confirming test data and observations as required to substantiate the reported prob
3. Maintain clean and safe working conditions for Contractor s personnel Owner s representative s personnel and Owner s personnel Contractor shall cooperate fully with Owner s representative in this matter Daily During construction execute daily cleaning to keep the work the site and adjacent properties free from accumulations of waste materials rubbish and windblown debris resulting from construction operations Waste Containers Provide on site containers for the collection of waste materials debris and rubbish Waste Removal Remove waste materials debris and rubbish from the site periodically and dispose of at legal disposal areas away from the site Dust Control Schedule operations so that dust and other contaminants resulting from work will not interfere with other operations Final Cleaning 1 Execute prior to Substantial Completion and again prior to Final Inspection 2 Employ skilled workmen for final cleaning 3 Remove grease mastic adhesive dust dirt stains fingerprints labels and other foreign materials from sight exposed interior and exterior surfaces 4 Clean or replace all filters 5 Remove waste and surplus materials rubbish and construction facilities from the Project and from the site 6 Prior to final completion Contractor shall conduct an inspection of sight exposed interior and exterior surfaces and all work areas to verify that the entire work is clean 3 13 PAINTING Touch up or
4. Perform testing specified in this section in the presence of the Owner s authorized representative Local or state authorities having jurisdiction shall be given due notice of the tests as may be required by them and acceptance of the work by the Owner s representative will be contingent upon acceptance by the public authority All system equipment shall be inspected adjusted and tested after installation Adjustments shall be made and tests shall be repeated as often as necessary to insure that the equipment operates as specified Furnish all necessary equipment and assume all costs involved to perform all testing and balancing Tests of piping systems shall be conducted before connections to equipment are made and before piping is insulated and or concealed Systems found to have leaks shall be retested after leaks have been repaired Duct systems shall be tested under two 2 times the normal fan pressure with all air handling equipment connecting ductwork dampers accessories and air outlet and inlet taps in place Cover securely with plastic Balancing of each system shall not be done until the system has been completed and is fully operational Take all balancing readings with clean strainers and filters in place Instruments shall be calibrated prior to balancing Types serial numbers and dates of calibration of all instruments shall be listed in the final balance reports After cleaning and testing of individual equipme
5. 2 Alkyd over Latex Primer System Prime Coat Primer sealer latex interior MPI 50 Intermediate Coat Alkyd interior matching topcoat Topcoat Alkyd interior flat Gloss Level 1 MPI 49 Topcoat Alkyd interior Gloss Level 3 MPI 51 Topcoat Alkyd interior semi gloss Gloss Level 5 MPI 47 Topcoat Alkyd interior gloss Gloss Level 6 MPI 48 Papp END OF SECTION 09912 INTERIOR PAINTING 09912 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15010B MECHANICAL GENERAL PROVISIONS PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 CODES REGULATIONS TAXES PERMITS amp FEES A Work under this Division shall meet the applicable requirements of the following codes and standards 1 Federal laws and regulations 2 North Carolina State Building Code all volumes and parts 3 Health agencies having jurisdiction 4 Applicable code requirements shall govern where code requirements exceed the requirement of the Drawings and Specifications The Drawings and Specifications shall govern where the work and materials specified exceed applicable code requirements B The Contractor shall give all necessary notices obtain all permits and pay all sales taxes fees and other costs including utility connections or extensions in connection with his work file all necessary plans prepare all documents and obtain all necessary approvals of
6. A General Requirements Installation testing and calibration of all sensors transmitters and other input devices shall be provided to meet the system requirements FMS CONTROLS AND INSTRUMENTATION 15900B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B Temperature Sensors 1 General Requirements a Sensors and transmitters shall be provided as outlined in the input output summary and sequence of operations b The temperature sensor shall be of the resistance type and shall be either two wire 1000 ohm nickel RTD or two wire 1000 ohm platinum RTD c The following point types and the accuracy of each are required and their associated accuracy values include errors associated with the sensor lead wire and A to D conversion Point Type Chilled Water Duct Temperature All Others Room Temperature Sensors Room sensors shall be constructed for recessed mounting Thermowells a When thermowells are required the sensor and well shall be supplied as a complete assembly including well head and Greenfield fitting b Thermowells shall be pressure rated and constructed in accordance with the system working pressure c Thermowells and sensors shall be mounted in a threadolet or 1 2 NFT saddle and allow easy access to the sensor for repair or replacement d Thermowells shall be constructed of 316 stainless steel 4 Duct Mount Sensors a Duct mount sensors shall mou
7. INSTALL where shown on Drawings Provide required clearances for access maintenance and safety TEST and obtain specified performance as required by Section 15042B Tests ADJUST settings as necessary to obtain required performance PROVIDE all appurtenance items as required for installation per manufacturer s recommendations INSULATE in accordance with Sections 15060SB and 15250B END OF SECTION HYDRONIC SPECIALTIES 15080B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15090B SUPPORTS ANCHORS AND SEALS PART 1 GENERAL 1 1 1 2 1 5 CONTRACT DOCUMENTS The Contract Documents apply to this section PIPING SYSTEMS Supports and anchors for piping systems shall be in accordance with ANSI B31 1 Power Piping to maintain required pitch of lines prevent vibration and provide for expansion and contraction movement REFERENCES A ASME B31 1 Power Piping B MSS SP 58 Pipe Hangers and Supports Materials Design and Manufacture C MSS SP 69 Pipe Hangers and Supports Selection and Application D MSS SP 89 Pipe Hangers and Supports Fabrication and Installation Practices SUBMITTALS A Submit shop drawings in accordance with Section 15010B Mechanical General Provisions B Submittals shall be provided for hanger and support types according to pipe size pipe service type and exposure classification C Submittals shall include manufacturer s product data
8. User Notes 1162824017 8 4 The Contractor s representative Name address and other information 8 5 Neither the Owner s nor the Contractor s representative shall be changed without ten d other party 8 6 Other provisions ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS 9 1 The Contract Documents except for Modifications issued after execution of this Agree the sections below 9 1 1 The Agreement is this executed AIA Document A101 2007 Standard Form of Agree and Contractor 9 1 2 The General Conditions are AIA Document A201 2007 General Conditions of the Contract for Construction 9 1 3 The Supplementary and other Conditions of the Contract Document Title Date 9 1 4 The Specifications Either list the Specifications here or refer to an exhibit attached to this Agreement Section Title Date 9 1 5 The Drawings Either list the Drawings here or refer to an exhibit attached to this Agreement Number 9 1 6 The Addenda if any Number Date Portions of Addenda relating to bidding requirements are not part of the Contract Docume requirements are also enumerated in this Article 9 ess the bidding 9 1 7 Additional documents if any forming part of the Contract Documents AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects Al
9. 4 Install sound absorptive pads in perforated metal units over metal spacer grids 5 Install sound attenuation panels in areas indicated by reflected ceiling plans or room finish schedules Lay panels directly on ceiling system in manner indicated and close major openings to form complete coverage in required areas 3 4 CLEANING A Clean exposed surfaces of metal ceiling including trim and edge moldings Comply with manufacturers instructions for cleaning and touchup of minor finish damage Remove and replace work that cannot be successfully cleaned and repaired to permanently eliminate evidence of damage including dented and bent units END OF SECTION 09513 CUSTOM METAL CEILINGS 09514 7 PTIA Ticket Counter ceiling Renovation 12 001 000 SECTION 09912 INTERIOR PAINTING PART 1 GENERAL 1 1 A 1 2 1 3 1 4 SUMMARY Section includes surface preparation and the application of paint systems on interior substrates 1 Wood 2 Gypsum board DEFINITIONS Gloss Level 1 Not more than 5 units at 60 degrees and 10 units at 85 degrees according to ASTM D 523 Gloss Level 2 Not more than 10 units at 60 degrees and 10 to 35 units at 85 degrees according to ASTM D 523 Gloss Level 3 10 to 25 units at 60 degrees and 10 to 35 units at 85 degrees according to ASTM D 523 Gloss Level 4 20 to 35 units at 60 degrees and not less than 35 units at 85 degrees according to ASTM D 523 Gloss Level 5 35 to 70 unit
10. FAN COIL UNITS 15767B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15840B DUCTWORK PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 REFERENCES Latest edition for listed references shall apply zg ASTI O NMOOWS ASHRAE Handbook Fundamentals latest edition Duct Design chapter ASHRAE Handbook Equipment latest edition Duct Construction chapter ASTM A90 Weight of Coating on Zinc Coated Galvanized Iron or Steel Articles ASTM A167 Stainless and Heat Resisting Chromium Nickel Steel Plate Sheet and Strip ASTM A480 Standard Specification for Stainless Steel Sheet Plate and Strip ASTM A525 General Requirements for Steel Sheet Zinc Coated Galvanized by the Hot Dip Process ASTM A527 Steel Sheet Zinc Coated Galvanized by Hot Dip Process Lock Forming Quality ASTM B209 Aluminum Alloy Sheet and Plate NFPA 90A Installation of Air Conditioning and Ventilating Systems NFPA 90B Installation of Warm Air Heating and Air Conditioning Systems NFPA 96 Standard for Ventilation Control and Fire Protection of Commercial Cooking Operations SMACNA Duct Construction Standards SMACNA Fire Smoke and Radiation Damper Guide for HVAC Systems UL 181 Factory Made Air Ducts and Connectors 1 3 STANDARDS Duct systems shall be in accordance with SMACNA Duct Construction Standards the National Fire Protection Associatio
11. HP 1 6 1 3 1 2 3 4 1 5 150 3600 RPM 1 35 1 25 1 25 1 25 1 15 END OF SECTION 15045B MOTORS 1800 RPM 1 35 1 25 1 25 1 15 1 15 1200 RPM 1 35 1 25 1 15 1 15 1 15 2 Pole 88 5 88 5 90 2 91 0 91 7 91 7 93 0 93 0 94 1 94 1 95 0 95 0 95 0 95 4 96 2 96 2 900 RPM TEFC Enclosure 1 35 1 15 1 15 1 15 1 15 4 Pole 88 5 88 5 90 2 90 2 92 4 92 4 93 6 93 6 94 1 94 5 95 0 95 0 95 4 95 8 96 2 96 2 6 Pole 89 5 89 5 90 2 91 0 92 4 92 4 93 0 93 6 94 1 94 1 95 0 95 0 95 0 95 4 96 2 96 2 15045B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15060B PIPE PIPE FITTINGS AND VALVES PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 DRAWINGS Drawings show the approximate routing of piping however execution of the work shall be coordinated more precisely as described in Part 3 of this section 1 3 REFERENCES A ASTM B 828 Standard Practice for Making Capillary Joints by Soldering of Copper and Copper Alloy Tube and Fittings ASTM B 813 Standard Specification for Liquid Paste Fluxes for Soldering Applications of Copper and Copper Alloy Tube 1 4 DEFINITIONS A Design pressure of a zone of piping is the maximum pressure that can be predicted to occur in that zone from an analysis of Drawings Design pressure is not normally indicated on Drawings Cons
12. PTIA Ticket Counter Ceiling Renovation 12 001 000 3 2 PREPARATION A Coordination Furnish layouts for preset inserts clips and other ceiling anchors whose installation is specified in other sections Measure each ceiling area and establish layout of metal units to balance border widths at opposite edges of each ceiling Avoid use of less than half width units at borders and comply with reflected ceiling plans 3 3 INSTALLATION A General Install custom metal ceiling system in accordance with manufacturer s instructions and CISCA Ceiling Systems Handbook to comply with requirements indicated Standards for Installation of Ceiling Suspension Systems Comply with ASTM C 636 and ASTM E 580 as applicable to metal ceilings Suspend ceiling hangers from building structural members and as follows 1 Install hangers plumb and free from contact with insulation or other objects within ceiling plenum that are not part of supporting structural or ceiling suspension system Splay hangers only where required to miss obstructions and offset resulting horizontal forces by bracing countersplaying or other equally effective means 2 Where width of ducts and other construction within ceiling plenum produces hanger spacings that interfere with the location of hangers at spacings required to support standard suspension system members install supplemental suspension members and hangers in form of trapezes or equivalent devices Size suppleme
13. Same as System A Calcium silicate Provide finish jacket as scheduled Polystyrene with vapor retarder all service jacket Continuous vapor retarder including sealing of joints seams staples and the like is required Provide finish jacket as scheduled Molded or sheet foamed plastic Continuous vapor retarder including sealing of joints seams and the like is required Provide finish jacket and or finish as scheduled Cellular glass with factory applied vapor retarder all service jacket Seal jacket with 2 coat vapor retarder sealant Smooth finish on finished jacket required Continuous vapor retarder including sealing of joints seams and the like is required Provide finish jacket as scheduled Cellular glass with all service jacket Continuous vapor retarder not required Provide finish jacket as scheduled 12 0001 000 1 amp Smaller 1 0 Thick 1 1 4 2 1 5 Thick 2 1 2 4 2 0 Thick 5 6 2 0 Thick 8 amp Larger 2 0 Thick 1 amp Smaller 1 5 Thick 1 1 4 2 1 5 Thick 2 1 2 4 2 0 Thick 5 6 2 5 Thick 8 amp Larger 3 0 Thick 1 amp Smaller 1 0 Thick 1 1 4 2 1 0 Thick 2 1 2 4 1 5 Thick 5 6 1 5 Thick 8 amp Larger 1 5 Thick Note Not Allowed in plenums in NC fire smoke 25 50 required 1 amp Smaller 75 Thick 1 1 4 1 1 2 1 0 Thick 2 3 1 0 Thick 4 amp Larger 1 0 Thick Note Not Allowed 4 amp larger in plenums in NC
14. 2 1 A Q MATERIALS GENERAL Certified Wood The following wood products shall be produced from wood obtained from forests certified by an FSC accredited certification body to comply with FSC STD 01 001 FSC Principles and Criteria for Forest Stewardship 1 Interior trim 2 Interior plywood hardboard board paneling Low Emitting Materials Composite wood products shall comply with the testing and product requirements of the California Department of Health Services Standard Practice for the Testing of Volatile Organic Emissions from Various Sources Using Small Scale Environmental Chambers Lumber DOC PS 20 Softwood Plywood DOC PS 1 Hardboard AHA A135 4 MDF ANSI A208 2 Grade 130 made with binder containing no urea formaldehyde resin Particleboard ANSI A208 1 Grade M 2 made with binder containing no urea formaldehyde resin INTERIOR FINISH CARPENTRY 06202 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 2 2 2 3 A INTERIOR TRIM Softwood Lumber Trim 1 Species and Grade Douglas fir larch or Douglas fir south Superior or C amp Btr Prime or D finish NLGA WCLIB or WWPA 2 Species and Grade Southern pine C amp Btr finish SPIB 3 Maximum Moisture Content 19 percent Hardwood Lumber Trim 1 Species and Grade Aspen basswood cottonwood sap gum sycamore white maple or yellow poplar NHLA 2 Maximum Moisture Content 10 percent Moldings for Opaque Finish Paint
15. A Material and finish for hangers and supports shall be the same as the hanger type required for each location in the project Use Type A hangers for all indoor applications and Type B hangers in Mechanical Rooms and outdoors Where piping or ductwork cannot be suspended from overhead supports use substantial cast iron or welded steel wall brackets or trapeze supports to support the hangers pipe seats or roll stands as conditions demand and as approved by the Owner s Representative Construct fabricated supports and brackets of structural grade miscellaneous steel and fasteners Black or plain steel components which are not specified to have a special finish shall be delivered to the job site with a prime coat of paint Touch up primer after fabrication and after installation All exposed miscellaneous support steel shall as a minimum be prime coated with paint to minimize the potential for rusting SUPPORTS ANCHORS AND SEALS 15090B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 D Provide all miscellaneous steel bridging brackets anchors frames bracing plates bolts nuts washers and the like necessary to properly support piping or ductwork All steel hangers and attachments shall be mounted to the building structural steel frame concrete or masonry walls structural concrete floors or concrete structural members No attachments of any kind shall be made to the roof deck metal Refer to
16. At each item of equipment At each side of penetration of structure or enclosure At each control device On all straight conduit runs every 25 feet At each passage to underground Daang F Miscellaneous Provide screw mounted nameplates on access doors in all building construction identifying items behind door such as valves controls equipment etc END OF SECTION 15035B MECHANICAL IDENTIFICATION 15035B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15042B TESTS PART 1 GENERAL 1 1 1 2 TESTS CONTRACT DOCUMENTS The Contract Documents apply to this section REFERENCES Latest edition for listed references shall apply A ASHRAE Handbook Fundamentals latest edition Chpt 7 Sound and Vibration Fundamentals and Chpt 13 Measurement and Instruments ASHRAE Handbook 1991 HVAC Applications Chpt 34 Testing Adjusting and Balancing ASHRAE Standard 111 1988 Practices for Measurement Testing Adjusting and Balancing of Building Heating Ventilation Air Conditioning and Refrigeration Systems AABC National Standards for Total System Balance 4th edition NEBB Procedural Standards for Testing Adjusting and Balancing of Environmental Systems SMACNA HVAC Systems Testing Adjusting amp Balancing SMACNA HVAC Air Duct Leakage Test Manual SMACNA HVAC Duct Construction Standards Metal and Flexible SUBMITTAL REQUIREMENTS
17. The independent TAB Contractor shall test adjust and balance all systems until design function and operation are achieved All work shall be performed in strict accordance with appropriate sections of the AABC or NEBB Standards the ASHRAE Handbooks and these Specifications The TAB Contractor shall perform a pre construction review of the Contract Documents in order to become familiar with the project and advise the Mechanical Contractor regarding potential problems that may impact TAB services The TAB Contractor shall also be available to observe construction progress to identify and minimize TAB or operation problems witness and certify Contractor s leak tests and manufacturer s performance tests as required The TAB Contractor shall participate in the instruction and training of the Owner s operating personnel The TAB Contractor shall correct any deficiencies for a period of one year following substantial completion and Owner acceptance of final balancing reports TESTING ADJUSTING AND BALANCING GENERAL A Testing Contractor shall test adjust and balance all systems until design function and operation are achieved Testing Contractor shall demonstrate performance of design function and operation for each system to Owner s representative Testing adjusting and balancing shall be performed in accordance with the recommended procedures of the Associated Air Balance Council AABC or the National Environmental Balancing Bureau NEBB
18. ducts having velocities of less than 1000 feet per minute shall be measured with micromanometers hook gages or similar low pressure instruments Openings in ducts for pitot tube insertion shall be accomplished by installation of instrument ports When not in use ports shall be sealed with plastic snap plugs Diffuser grille and register air quantities shall be determined by direct reading velocity meters 3 Obtain design air quantities in main ducts by adjusting fan speeds Then adjust branch duct air quantities by volume or splitter dampers 4 Adjust minimum and maximum flow setpoint at each variable air volume terminal unit using methods and instruments recommended by terminal unit manufacturers 5 Adjust extractors at supply grilles and branch ducts Opposed blade dampers at diffusers and registers may be used to balance air quantities providing final adjustments do not produce objectionable drafts or sound levels Final air quantities shall be within 10 percent of design requirements 6 In cooperation with the Control Contractor s representative set adjustment of automatically operated dampers and valves to operate as specified 7 After testing and adjusting branch ducts terminal units grilles and the like retest main duct air quantities Re adjust if required 8 Permanently and legibly scribe punch or paint mark dampers after air balance is complete to enable them to be restored to their correct position if disturbed at
19. fire smoke of 25 50 required 1 amp Smaller 1 5 Thick 1 1 4 2 1 5 Thick 2 1 2 4 1 5 Thick 5 6 2 0 Thick Note Minimum thickness 1 5 to avoid breakage because of brittle material All Sizes 2 0 Thick 15060SB 2 Ticket Counter Ceilings Piedmont Triad International Airport PIPING SCHEDULE MATERIAL SYSTEM CP 1 Pressure Design 100 psig ITEM Pipe Fittings Flanges Unions Valves Gate Valves Globe Valves Check Valves Ball Strainers SIZES ALL ALL ALL 1 1 4 amp Larger 1 amp Smaller 4 amp Larger 3 amp Smaller 4 amp Larger 3 amp Smaller 4 amp Larger 3 amp Smaller 2 amp Smaller 2 amp Smaller 4 amp Larger 3 amp Smaller 12 0001 000 Temperature Design 210 F MATERIALS ASTM B 88 Type L Seamless Hard Drawn Copper Tubing above grade ASTM B 88 Type K Seamless Hard Drawn or Soft Annealed Copper Tubing below grade ASTM B 75 and ANSI B16 22 Wrought Copper Solder Joint or ASTM B 62 and ANSI B16 18 Cast Brass Solder Joint ASTM B 62 and ANSI B16 18 Cast Brass 125 Ib Flat Face Socket Type Solder Joint ASTM B 62 and ANSI B16 18 Cast Brass Threaded Ends ASTM B 62 and ANSI B16 18 Cast Brass Solder Joint Crane No 465 1 2 Flanged 125 Cast Iron OS amp Y Bronze Trim and Stem Crane No 428 Threaded End or No 1334 Solder End Bronze Rising Stem Screwed Bonnet Soli
20. for maximum moisture content and other conditions affecting performance of the Work Maximum Moisture Content of Substrates When measured with an electronic moisture meter as follows 1 Wood 15 percent 2 Gypsum Board 12 percent Verify suitability of substrates including surface conditions and compatibility with existing finishes and primers INTERIOR PAINTING 09912 3 PTIA Ticket Counter ceiling Renovation 12 001 000 D Proceed with coating application only after unsatisfactory conditions have been corrected 1 Application of coating indicates acceptance of surfaces and conditions 3 2 PREPARATION A Comply with manufacturer s written instructions and recommendations in MPI Manual applicable to substrates indicated B Remove hardware covers plates and similar items already in place that are removable and are not to be painted If removal is impractical or impossible because of size or weight of item provide surface applied protection before surface preparation and painting 1 After completing painting operations use workers skilled in the trades involved to reinstall items that were removed Remove surface applied protection if any C Clean substrates of substances that could impair bond of paints including dust dirt oil grease and incompatible paints and encapsulants 1 Remove incompatible primers and reprime substrate with compatible primers or apply tie coat as required to produce paint systems indi
21. if any which are described inthe Contract Documents and are hereby accepted by the Owner State the numbers or other identification of accepted alternates If the bidding or proposal documents permit the Owner to accept other alternates subsequent to the execution of this Agreement attach a schedule of such other alternates showing the amount for each and the date when that amount expires 4 3 Unit prices if any Identify and state the unit price state quantity limitations if any to which the unit price will be applicable Item Units and Limitations Price Per Unit 0 00 4 4 Allowances included in the Contract Sum if any Identify allowance and state exclusions if any from the allowance price Item Price ARTICLE5 PAYMENTS 5 1 PROGRESS PAYMENTS 5 1 1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents 5 1 2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month or as follows OP 5 1 3 Provided that an Application for Payment is received by the Architect not later than the 23rd Day of the Month day of a month the Owner shall make payment of the certified amount to the Contractor not later than the twen
22. to use the following Subcontractors on this project List below all proposed Subcontractors and trade specialties List only one Subcontractor for each item The Bidder shall obtain prior written permission of the Owner should he choose to add or substitute other Subcontractor s not shown herein Items Subcontractors Estimated total cost of items that Bidder states will be performed by Subcontractor BID FORM 00310 9 PTIA Visitor Information Booths 12 040 000 This Affidavit is Part of Bid CERTIFICATION REGARDING FAIR TRADE The contractor or subcontractor by submission of an offer and or execution of a contract certified that it A is not owned or controlled by one or more citizens or nationals of a foreign country included in the list of countries that discriminate against U S firms published by the Office of the United States Trade Representative USTR B has not knowingly entered into any contract or subcontract for this project with a contractor that is a citizen or national of a foreign country on said list or is owned or controlled directly or indirectly by one or more citizens or nationals of a foreign country on said list and C has not procured any product nor subcontracted for the supply of any product for use on the project that is produced in a foreign country on said list Unless the restrictions of this clause are waived by the Secretary of Transportation in accorda
23. 1 5 Ib cu ft minimum density wrapped firmly under compression and wired in place Finish with 1 4 inch layer of hydraulic insulating cement to a thickness equal to adjoining insulation 4 Fastening Secure insulation jacket with lagging adhesive Childers CP 50A or Foster 30 36 if not provided with self sealing pressure sensitive adhesive In areas not accessible after construction also secure insulation with aluminum bands on 12 to 18 inch centers 5 Cover fittings standard or Victaulic type with one piece PVC premolded fitting covers stapled or tacked in place Apply over proper shape factory precut insulation blanket Before applying fitting cover on piping requiring a vapor barrier apply two vapor barrier mastic beads 1 8 in diameter around pipe covering close to end of covering before applying PVC cover Wrap circumferential edges of cover with vapor barrier pressure sensitive color matching tape Overlap tape 2 inches on adjacent insulation and on cover B Foamed Plastic Insulation Apply thickness shown in insulation schedule 1 Piping Applications a Unslit tubular insulation shall be slipped onto piping before it is connected b Preslit tubular insulation shall be rolled onto piping after fabrication INSULATION 15250B 9 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 C Tightly butt adjacent sections and seal with a contact adhesive specifically approved by the insulation manufacturer Ar
24. 1 Where reference is made in this Agreement to a provision of AIA Document A201 2007 or another Contract Document the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents 8 2 Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below or in the absence thereof at the legal rate prevailing from time to time at the place where the Project is located Insert rate of interest agreed upon if any 0 00 per annum 8 3 The Owner s representative Name address and other information Mr J Alex Rosser P E Piedmont Triad Airport Authority 1000A Ted Johnson Parkway Greensboro NC 27409 Telephone Number 336 665 5600 Email Address rossera gsoair org AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale
25. 16060 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16070 HANGERS AND SUPPORTS PART 1 GENERAL 1 1 WORK INCLUDED A B Conduit and equipment supports Fastening hardware 1 2 QUALITY ASSURANCE Support systems shall be adequate for weight of equipment and conduit including wiring which they carry PART 2 PRODUCTS 2 1 MATERIAL A B Support Channel Galvanized Hardware Corrosion resistant PART 3 EXECUTION 3 1 INSTALLATION A C D E F G Fasten hanger rods conduit clamps and outlet and junction boxes to building structure using expansion anchors beam clamps and spring steel clips Use toggle bolts or hollow wall fasteners in hollow masonry plaster or gypsum board partitions and walls expansion anchors or preset inserts in solid masonry walls self drilling anchors or expansion anchor on concrete surfaces sheet metal screws in sheet metal studs Do not fasten supports to piping ductwork mechanical equipment or conduit Do not use powder actuated anchors Do not drill structural steel members Fabricate supports from structural steel or steel channel rigidly welded or bolted to present a neat appearance Use hexagon head bolts with spring lock washers under all nuts Install surface mounted cabinets and panelboards with minimum of four anchors END OF SECTION 16070 HANGERS AND SUPPORTS 16070 1 Ticket Counter Ceilings Piedmon
26. 5 VDC 0 to 10 VDC or 4 to 20 mA output signal C Differential pressure transmitters used for flow measurement shall be sized to the flow sensing device and shall be supplied with Tee fittings and shut off valves in the high and low sensing pick up lines to allow the balancing Contractor and Owner permanent easy to use connection d A minimum of a NEMA 1 housing shall be provided for the transmitter Transmitters shall be located in accessible local control panels wherever possible C Smoke Detectors lonization type air duct detectors shall be furnished as specified elsewhere in Division 16 for installation under Division 15 All wiring for air duct detectors shall be provided under Division 16 Fire Alarm System D Status and Safety Switches 1 General Requirements Switches shall be provided to monitor equipment status safety conditions and generate alarms at the FMS when a failure or abnormal condition occurs Safety switches shall be provided with two sets of contacts and shall be interlock wired to shut down respective equipment 2 Current Sensing Switches a The current sensing switch shall be self powered with solid state circuitry and a dry contact output It shall consist of a current transformer a solid state current sensing circuit adjustable trip point solid state switch SPDT relay and an LED indicating the on or off status A conductor of the load shall be passed through the window of the device It shall ac
27. 9 5 of AIA Document A201 2007 B 5 1 7 The progress payment amount determined in accordance with Section 5 1 6 shall be further modified under the following circumstances 1 Add upon Substantial Completion of the Work a sum sufficient to increase the total payments to the full amount of the Contract Sum less such amounts as the Architect shall determine for incomplete Work retainage applicable to such work and unsettled claims and Section 9 8 5 of AIA Document A201 2007 requires release of applicable retainagetpon Substantial Completion of Work with consent of surety if any 2 Add if final completion of the Work is thereafter materially delayed through no fault of the Contractor any additional amounts payable in accordance with Section 9 10 3 ef AIA Document A201 2007 5 1 8 Reduction or limitation of retainage if any shall be as follows If it is intended prior to Substantial Completion of the entire Work to reduce or limit the retainage resulting from the percentages inserted in Sections 5 1 6 1 and 5 1 6 2 above and this is not explained elsewhere in the Contract Documents insert here provisions for such reduction or limitation Retainage may be reduced to 2 5 at 50 completion if in the architect s opinion the work is progressing in a timely manor and AIA Document G707A is submitted 5 1 9 Except with the Owner s prior approval the Contractor shall not make advance payments to suppliers for materi
28. Control and signal wiring shall not use the above named colors except Green for grounding Any other colors or striping may be used but the coding shall provide same color or striping between any two terminals being jointed Travelers in switching circuits shall be of the same color as phase conductors serving the circuit TESTING AND REPORTS Prior to energizing feeders sub feeders and service conductor cables shall be tested for electrical continuity and short circuits A copy of these tests shall be sent to the Owner END OF SECTION 16120 CONDUCTORS AND CABLES 16120 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16130 CONDUIT AND BOXES PART 1 GENERAL 1 1 WORK INCLUDED Rigid metal conduit and fittings Electrical metallic tubing and fittings Liquidtight flexible metal conduit and fittings Schedule 40 rigid PVC conduit and fittings Wall and ceiling outlet boxes nmo oO Ww p Pull and junction boxes 1 2 RELATED WORK A Cutting and Patching Section 01045 B Trenching Excavation and backfill for conduit and utilities on site Section 02225 C Cast In Place Concrete Protective envelope for underground conduit installations Section 03300 D Sheet Metal Flashing and Trim Section 07620 E Wiring Devices Section 16140 1 3 REFERENCES ANSI C80 1 Rigid Steel Conduit Zinc Coated ANSI C80 3 Electrical Metallic Tubing Zinc Coated ANSI NEMA FB
29. For securing field applied flexible glass fiber insulation to ductwork pipes amp equipment other than internal duct liner insulation materials adhesive shall have a dry flame spread rating of 5 per ASTM E 162 20 to 180 F service temperature fast drying synthetic elastomer adhesive designed to adhere fibrous glass insulation to sheet metal Childers Chil Stix Clear CP 85 Foster Stic Safe 85 15 or Mon Eco 22 05 Foamed Plastic Insulation For securing field applied foamed plastic insulation to ductwork pipes and equipment adhesive shall have a dried film flame spread rating not to exceed 25 per ASTM E 84 and smoke developed rating of 50 service temperature to 200 F for pipe and sheet applications contact adhesive for joining seams butt joints and surface adhesion Armstrong 520 Adhesive Rubatex R 373 Adhesive or equal 2 11 SEALANTS AND ACCESSORIES A INSULATION Sealants Vapor Retarder Finish For all interior field constructed vapor retarder finishes for equipment fittings valves flanges surface patches joints staple punctures lap edges flashings and the like Dry flame spread rating less than 5 per ASTM E 162 20 to 180 F service temperature water vapor permeance to 0 05 perms white finish color flexible high build product suitable for use as a vapor retarder finish on pipe and block insulation and rigid thermal insulation Vapor retarder finish coating shall be Childers Chil Perm CP 30 Foster Tite Fit 30 35
30. Limit of liability or bond amount 0 00 As indicated in Article 11 of 00800 Supplementary Conditions This Agreement entered into as of the day and year first written above OWNER Signature CONTRACTOR Signature Mr Henry Isaacson Chairman of the Board gt gt Printed name and title Printed name and title AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 1162824017 PTIA Ticket Counter Ceilings 12 001 000 SECTION 00700 GENERAL CONDITIONS 1 1 GENERAL CONDITIONS A The General Conditions of the Contract are the GENERAL CONDITIONS OF THE CONTRACT FOR CONSTRUCTION AIA Document A201 2007 Edition are by reference hereby made a part of the Contract Documents the same as if it were included in full herein B Modifications specified in the SUPPLEMENTARY CONDITIONS supplement change delete from an
31. PRODUCTS 2 1 2 2 A A B C D MANUFACTURERS Products Subject to compliance with requirements available products that may be incorporated into the Work include but are not limited to products listed in other Part 2 articles for the paint category indicated PAINT GENERAL MPI Standards Provide products that comply with MPI standards indicated and that are listed in its MPI Approved Products List Material Compatibility 1 Provide materials for use within each paint system that are compatible with one another and substrates indicated under conditions of service and application as demonstrated by manufacturer based on testing and field experience 2 For each coat in a paint system provide products recommended in writing by manufacturers of topcoat for use in paint system and on substrate indicated VOC Content Products shall comply with VOC limits of authorities having jurisdiction and for interior paints and coatings applied at Project site the following VOC limits exclusive of colorants added to a tint base when calculated according to 40 CFR 59 Subpart D EPA Method 24 Flat Paints and Coatings 50 g L Nonflat Paints and Coatings 150 g L Primers Sealers and Undercoaters 200 g L Anticorrosive and Antirust Paints Applied to Ferrous Metals 250 g L PonN gt Low Emitting Materials Interior paints and coatings shall comply with the testing and product requirements of the California D
32. Quartermaster 44N Threaded Lug Type EPDM Seat Aluminum Bronze Disc Note Bolt flanges to lug valves from both sides so either side can be removed Use proper length bolts Check Crane No 147 Flanged Steel 150 Swing Check Bolted Top Wafer Check Mueller 101M AP Wafer Type or 105M AP Globe Type use in discharge of pumps Cast Iron 125 Body Bronze Disc and Seat Stainless Steel Spring Gate Crane 431 Bronze Rising Stem Globe Crane 14 1 2P Straight or 16 1 2P Angle Type Bronze Rising Stem Check Crane 137 Swing Check Threaded End Bronze Screwed Cap Bronze Disc Ball Apollo 70 100 Series Bronze or use 70 300 Series to eliminate unions May be used in place of Gate or Globe Valve PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM 15060SB 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 PIPING SCHEDULE MATERIAL SYSTEM CS 1 Continued Pressure Design 150 psig ITEM Valves Butterfly Operator Strainers Joints Studs amp Nuts Cleaning Valves Flow Control amp Balancing SIZES 1 2 2 gas service only 2 1 2 amp up gas service only 8 amp Larger 6 amp Smaller 2 1 2 amp Larger 2 amp Smaller 2 1 2 amp Larger 2 amp Smaller ALL ALL 3 amp Smaller END OF SECTION 16060SB PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM Temperature Design 250 F MATERIALS Plug Durco G432 Carbon Steel Body
33. Sales Tax that was payable in connection with such purchase The Contractor shall certify that the list is correct and shall submit the list each month for materials used during the preceding month 3 12 Shop Drawings Product Data and Samples Add the following 3 12 6 1 The Contractor shall acknowledge each submittal with the Contractor s approval stamp The approval stamp shall be signed or initialed and dated by the Contractor SUPPLEMENTARY CONDITIONS 00800 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 3 12 11 3 12 12 3 12 13 3 12 14 3 18 Indemnification Certain sections of the Specifications state the requirements for submission of shop drawings product data and samples Stated requirements of the Speci fications for shop drawings and product data are waived for an item if such item is catalog stock and the Contractor in lieu of submittal states in writing that the exact item shown on the Drawings or mentioned in the Specifications will be used The Contractor shall not reproduce the Architect s project drawings for shop drawing use without written approval of the Architect By agreement with the Architect the Contractor may submit more than the required number of copies Receipt of less than the specified number of copies will be cause for the Architect withholding review of the shop drawings or data until receipt of the necessary additional copies In checking shop drawings product data and sample
34. Section 15010B Mechanical General Provisions for paragraph entitled Foundations Supports Piers Attachments Material and finish for all components shall be same as the hanger type required for each location E Provide bracing and supports for all vertical pipe risers with riser clamps at each floor level F Arrangement and fabrication of all supports is subject to Owner s representative s approval G Solid or perforated strap hangers and wire hangers will not be permitted except for temporary supporting during construction H Hanging from unreinforced metal roof deck or from cellular roof deck will not be permitted 3 4 WELDED ATTACHMENTS A All welded type support components shall be in accordance with MSS SP 58 B All attachments welded to the pipe shall be in accordance with MSS SP 58 Attachments welded directly to the pipe shall be compatible with the chemical composition of the pipe material and the process of attachment shall conform to the requirements for fabrication of the pipe with regards to preheating welding and stress relieving C Welded and bolted attachments to the building structural steel shall be in accordance with the requirements of AISC Specification for the Design Fabrication and Erection of Structural Steel Buildings D All welds shall be performed by certified welders in compliance with the welder s qualifications as specified in Section 15060B Pipe Pipe Fittings and Valves E Repaint all exist
35. VOC Latex System Prime Coat Primer latex for interior wood MPI 39 Intermediate Coat Latex interior institutional low odor VOC matching topcoat Topcoat Latex interior institutional low odor VOC flat Gloss Level 1 MPI 143 Topcoat Latex interior institutional low odor VOC Gloss Level 2 MPI 144 Topcoat Latex interior institutional low odor VOC Gloss Level 3 MPI 145 Topcoat Latex interior institutional low odor VOC semi gloss Gloss Level 5 MPI 147 Papp 3 Alkyd System Prime Coat Primer sealer alkyd interior MPI 45 Intermediate Coat Alkyd interior matching topcoat Topcoat Alkyd interior flat Gloss Level 1 MPI 49 Topcoat Alkyd interior Gloss Level 3 MPI 51 Topcoat Alkyd interior semi gloss Gloss Level 5 MPI 47 Topcoat Alkyd interior gloss Gloss Level 6 MPI 48 Hoag B Gypsum Board Substrates 1 Institutional Low Odor VOC Latex System a Prime Coat Primer sealer interior institutional low odor VOC MPI 149 b Intermediate Coat Latex interior institutional low odor VOC matching topcoat C Topcoat Latex interior institutional low odor VOC flat Gloss Level 1 MPI 143 d Topcoat Latex interior institutional low odor VOC Gloss Level 2 MPI 144 e Topcoat Latex interior institutional low odor VOC Gloss Level 3 MPI 145 f Topcoat Latex interior institutional low odor VOC semi gloss Gloss Level 5 MPI 147
36. a period of twenty four 24 hours without pressure drop other than that due to temperature changes Perform hammer test on each welded joint while under test pressure Repair all leaks and repeat test until specifications are met Water piping systems shall be placed in service with all normally open valves at full open position Close coil bypass balancing cocks clean all strainers blow down all drains flush systems and clean out piping and verify that water system chemical treatment is in service Water pipe system cleaning with specified cleaning chemicals shall be completed Verify proper pump rotation and that expansion tanks are not air bound Check all system air vents and determine that all high points are properly bled operating freely and not leaking Verify that all specified flow sensors thermometers or thermo wells are in place pressure gauges or gauge cocks are in place and all required test plugs are installed DUCTWORK AND AIR HANDLING EQUIPMENT TESTS Start up and Placing in Service A Leak test all duct systems as work progresses in accordance with the SMACNA Manual High Pressure Duct Construction Standards Smoke test the entire system if the leaks are greater than one percent 1 for high pressure or five percent 5 for low pressure systems Seal all duct joints with specified sealants Leak test all air handling units A C units VAV boxes plenums coil casings filter boxes and accessories and the connect
37. accordance with the requirements of Section 15010B Submittal A Drawings indicating components assembly dimensions weights required clearances location and size of all field connections pressure and temperature ratings and performance criteria Product data indicating rating capacities accessories and performance criteria Pressure drop ratings versus flow for all triple duty valves and circuit setter balance valves Manufacturer s installation instructions moo Operation and Maintenance manuals to include manufacturer s descriptive literature startup and operating instructions maintenance procedures and parts lists SHIPPING TAG Each unit shall be tagged at the factory with its specific location on the job including building floor system served and unit designation shown on the Drawings NAMEPLATES Provide nameplate or equipment tag on each unit as required by Section 15035B Mechanical Identification QUALITY ASSURANCE All products furnished under this Specification Section shall be asbestos free WARRANTY Unless noted otherwise provide a one year warranty from date of final acceptance under provisions of Section 15010B DELIVERY STORAGE AND HANDLING A Equipment shall be delivered to the site in accordance with the provisions of Section 10B Equipment shall be stored and protected under the provisions of Section 15010B C Store in clean dry place and protect from weather and construction traffic
38. and Jacketing PVC Types 1 C T 2 KF 3 MP 4 Foster Products 1 7 1 12 K Substitutions Under provisions of Section 15010B Mechanical General Provisions QUALITY ASSURANCE The installing Contractor for the insulation systems specified in this section shall have been in continuous uninterrupted stable business for a minimum of five 5 years in the installation of industrial and heavy commercial insulating systems The installing Contractor shall upon request provide a list of at least five 5 successful installations performed by his her company that are similar in size and scope of this project QUALITY CONTROL A All insulation shall be installed in a workmanlike manner by skilled workmen regularly engaged in this type of work B Insulation shall be applied on clean dry surfaces and only after tests and approvals required by the Specifications have been completed Insulation jackets shall be drawn tight fitted smoothly and wrinkle free Do not use short pieces of insulation where a full length section will fit Do not use damaged or crushed insulation products E Do not insulate manholes handholes cleanouts inspection stamps and nameplates Bevel flash and seal around insulation of adjacent surfaces On equipment operating at temperatures below dew point of the space provide removable insulation covers for such items and clearly mark the surface of the insulation cover to identify the hidden appurtenance
39. and Plug class 150 screwed ends asbestos free packing loose handle type wrench Plug Durco G411 Carbon Steel Body ad Plug class 150 flanged ends asbestos free packing loose handle type wrench Manual Gear Operator Crane G41 10 Position Thumbscrew Lock Crane TL7 amp TL10 Mueller No 751 Cast Iron 125 Ib Flanged Y Type Bolted Cover with Drain Stainless Steel Screen Mueller No 351 Threaded Y Type Bronze Screwed Drain Stainless Steel Screen Garlock Ring Gasket for Raised Face Flanges and Full Face Gasket for Flat Face Flanges No asbestos allowed Commercial Grade Pipe Dope or Teflon tape ASTM A 307 Grade B Hex Head Machine Flush with water until water runs clear from each system ITT Bell amp Gossett Circuit Setter Plus bronze threaded flow balancing valves rated 200 psig at 250 F with calibrated nameplates memory stop and differential pressure ports with check valves and caps Size for specified flow to be near midpoint of valve range Equal valves by Armstrong or TACO will be acceptable 15060SB 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15080B HYDRONIC SPECIALTIES PART 1 GENERAL 1 1 1 2 1 3 CONTRACT DOCUMENTS The Contract Documents apply to this section DRAWINGS Drawings show the approximate location of piping and components Flow and control diagrams indicate diagrammatic function SUBMITTALS Submit the following in
40. and blades with linkage out of the air stream Dampers shall be single blade type and unless noted otherwise shall be furnished without blade edge seals Control shaft shall be nominal 3 8 square axle shaft that extends beyond the frame to a factory mounted or field supplied heavy duty locking hand quadrant with minimum 1 1 2 clearance for duct insulation systems Manual dampers shall be Ruskin Model MDRS25 Safe Air Model 613R or approved equal by National Controlled Air Arrow and Louvers amp Dampers Inc C Shop Fabricated Dampers Rectangular or Round In lieu of manufactured manual volume control dampers the Contractor may construct shop fabricated damper assemblies in accordance with SMACNA HVAC Duct Construction Standards Prior to fabrication the Contractor shall submit shop drawings to the Engineer for approval Shop Drawings shall indicate frame construction blade construction shaft type and size shaft extension beyond duct wall maximum and minimum sizes for each type of construction material gauges finishes bearing assemblies reinforcement and the like Furnish with integral locking hand quadrant with minimum 1 1 2 clearance for duct insulation systems INSTRUMENT PORTS shall be Duro Dyne Air Tight Instrument Test Port with neoprene expansion plug for instruments up to 1 1 32 and flat neoprene mounting gasket or equal Ports shall be air tight with heavy duty die cast construction zinc plated heavy gauge cap and inst
41. any time 9 Test fire dampers and smoke dampers to prove that they open and close properly D Operating Controls and Safeties Adjust and record set points of all control valves dampers controls and safeties for each equipment item such as boilers chillers heat exchangers coils pumps fans and the like and for each system Coordinate with the Controls Contractor as required Provide list showing System designation Location of device Designation of valve damper control or safety Type Function Setting DARON 3 4 TEST SCHEDULES Provide the following data as required in Part 1 General of this section For each test record the outside air temperature and humidity during the actual test List the specified design data first test reading taken and final balance reading for each measurement A Title Cover Page 1 Company name 2 Company address TESTS 15042B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 Company telephone number Project name Project location Project Architect Project Engineer Project Contractor CON Ooo B Instrument List 1 Instrument 2 Manufacturer 3 Model 4 Serial number 5 Range 6 Calibration date C Pump Data 1 Pump designation 2 Manufacturer model and serial number 3 Size and impeller diameter 4 Type drive 5 Motor hp volts cycles phase service factor and F L amps nameplate 6 Design conditions GPM Head RPM
42. are improperly loaded above or below their correct operating height or which in any way do not produce the required isolation Cooperate with all other Contractors engaged in this project so that the installation of vibration isolation devices will proceed in a manner that is in the best interest of the Owner Notify the Engineer of any project conditions which affect vibration isolation system installation or performance and which are found to be different from conditions indicated by the Drawings or described by the Specifications Should vibration isolation system installation proceed without such notifications any remedial work required to achieve proper isolator performance shall be accomplished by the Contractor at no additional cost to the Owner Inspect the installed equipment for possible short circuiting of vibration isolation systems by piping supports misalignment electrical connections temperature control connections drain lines building construction etc and notify the involved contractor as to these problems or potential problems Where such situations cannot be easily resolved notify the Engineer so that preventative or remedial action can take place on a timely basis Any VIBRATION ISOLATION 15201B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 remedial measures required shall be undertaken by the contractor responsible at no additional cost to the Owner END OF SECTION 15201B VI
43. as shown on the Drawings C The installed and operating heights shall be the same d A minimum clearance of 1 2 shall be maintained around restraining bolts and between the housing and the spring so as not to interfere with the spring action Minimum static deflection shall be 2 e Limit stops shall be out of contact during normal operations f Mountings used out of doors shall have hot dipped galvanized housings and cadmium plated springs g Products 1 Mason Industries Type SLR 2 VMC Type AWR 3 Amber Booth Type CTC 2 4 Kinetics Type FLS 2 Type D Isolation Spring Hanger a Vibration hangers shall contain a steel spring and 0 3 deflection neoprene element in series b The neoprene element shall be molded with a rod isolation bushing that passes through the hanger box VIBRATION ISOLATION 15201B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 VIBRATION ISOLATION C Spring diameters and hanger box lower holes sizes shall be large enough to permit the hanger rod to swing through a 30 arc before contacting the hole and short circuiting the spring d Springs shall have a minimum additional travel to solid equal to 50 of the rated deflection e Submittals shall include a scale drawing of the hanger showing the 30 capability f Products 1 Mason Industries Type 30N 2 VMC Type RSH 30A Type E Isolation Precompressed Spring Hanger a Vibration hangers shall be
44. attached schedules for required material applications Ductwork amp Hanger Material Legend See Section 15840B Ductwork System Description AL Aluminum BS Black Steel GN Galvaneal Steel PAINTGRIP GS Galvanized Steel SC Black Steel with Steelcote S S Filled Urethane Finish SS Stainless Steel 316 DI Ductile Iron Pipe Material Schedule Ductwork Insulation See Section 15250B Insulation System Description Molded glass fiber Rigid glass fiber Flexible glass fiber Glass fiber duct liner 1 5 lb cu ft Glass fiber duct liner 3 0 Ib cu ft Foamed plastic without finish Foamed plastic with 2 coat finish Qnmoouw gt gt Jacket Material Legend See Section 15250B Insulation System Description Foil Scrim Kraft Canvas field applied Fiberglass field applied PVC sheet field applied solvent weld Aluminum sheet field applied Stainless Steel field applied mMMOUQOWY Insulation Thickness Legend 050 5 1 2 Thick 075 3 4 Thick 100 1 Thick 150 1 1 2 Thick 200 2 Thick 250 2 1 2 Thick 300 3 Thick Insulation Option Legend Insulation x y in schedule means x Contractor s Option 1 from Insulation Material Schedule y Contractor s Option 2 from Insulation Material Schedule DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM 15840SB 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 7 Jacket Option Legend Jacket x y in sc
45. by governing authorities and submit a final statement of accounting giving total adjusted Contract Sum previous payments and sum remaining due Project Record Documents 1 Provide one complete set of Contract Drawings and Specifications marked in red with all changes to the work to indicate actual installation 2 Provide one complete set of As Built Record Submittal Drawing prints 3 These records are a specific contract requirement and final payment will not be made until these Drawings and Specifications have been submitted in an acceptable form 4 Store Project Record Documents separate from those used for construction and in accordance with Section 01720 5 Keep documents current do not permanently conceal any work until required information has been recorded 6 At contract closeout submit documents with transmittal letter containing date project title Contractor s name and address list of documents and signature of Contractor 7 Contract Drawings and Shop Drawings Legibly mark each item to record actual construction including a Measured locations of internal utilities and appurtenances concealed in construction referenced by dimension and otherwise to visible and accessible features of construction b Field changes of dimension and detail C Changes made by modifications d Details not on original Contract Drawings e References to related shop drawings and modifications 8 Specifications Legibly
46. clean dry and tightly sealed at all joints and seams 2 Wrap insulation around the duct with facing to the outside butted to adjacent 3 7 3 8 3 9 3 10 3 11 3 12 insulation Seams shall be stapled approximately 6 on center with outward clinching staples and sealed with pressure sensitive tape matching the facing and designed for use with duct insulation The underside of ductwork 24 or greater in width shall be secured with adhesive and mechanical fasteners and speed clips spaced approximately 18 o c The protruding ends of the fasteners shall be cut off flush after the speed clips are installed and then sealed with approved pressure sensitive tape 3 Adjacent sections of duct wrap insulation shall be butted tightly with a 2 tape flap of the insulation facing overlapping and secured with staples and pressure sensitive tape or two coats of vapor retarder mastic reinforced with one layer of 4 wide open weave glass fiber mesh CEMENTS INSULATING AND FINISHING Unless specified to the contrary elsewhere provide a finished thickness of 1 2 Apply in two layers reinforcing with No 16 AWG 1 mesh galvanized wire netting Trowel to a smooth hard finish Install metal corner beads at all corners FIRE RETARDANT VAPOR RETARDER JACKETS FOR PIPE A Apply adhesive and jacket over insulation Seal lap with field applied adhesive or factory applied pressure sensitive lap adhesive B Apply sealant to fittings valves flanges
47. cleaner to be used in cleaning both HW and CHW piping systems C Welder s Qualifications PART 2 PRODUCTS 2 1 2 2 2 3 2 4 PIPE PIPE FITTINGS VALVES AND ACCESSORIES Shall be as listed in the Piping Schedules at the end of this specification section All pipe pipe fittings valves and installation accessories shall be manufactured in the USA PIPE FITTINGS Welded flanged screwed brazed or soldered fittings for ferrous or copper piping shall be as manufactured by Crane Nibco Walworth Stockham Grinnell Mueller Weldbend Tube Turns or Chase and shall meet the requirements of the standards specified in the Piping Schedules Threadolets and weldolets shall be Boney Forge or equal VALVES Acceptable valve manufacturers subject to compliance with the Specifications shall include the following A Gate Valves Crane Grinnell Jenkins Kennedy Lunkenheimer Milwaukee Nibco Stockham U S Pipe and Watts Ball Valves Conbraco Apollo Crane Grinnell Milwaukee Nibco Stockham and Watts C Butterfly Valves Crane Demco DeZurik Grinnell Milwaukee Nibco and Stockham Note Thin profile high flow capacity disc required See Specifications D Globe Valves Crane Grinnell Jenkins Lunkenheimer Milwaukee and Stockham E Check Valves Crane Grinnell Lunkenheimer Milwaukee and Stockham STRAINERS Acceptable strainer manufacturers Y type subject to compliance with the Specifications shall i
48. contract Operating instructions shall explain maintenance procedures methods of checking the systems for safe and normal operation and the recommended procedure for safely stopping and starting the equipment and or system Provide in each operating and maintenance manual the following data as required by the State Energy Code paragraph 403 2 10 1 HVAC Control Information 2 Certified Air and Water Balancing Report 3 Control System Certification Letter regarding installation and testing Instruct Owner s personnel in proper operation and maintenance of all equipment and controls These requirements shall be fulfilled before any guarantee periods become effective so as to limit the possibility of claims arising from the absence of pertinent information 3 21 GUARANTEE A The Contractor shall guarantee the complete systems against defect due to faulty materials faulty workmanship or failure due to negligence of the Contractor This guarantee will exclude normal wear maintenance lubrication replacement of expendable components or abuse During the guarantee period the Contractor shall make good such defective workmanship and materials and any damage resulting therefrom within a reasonable time of notice given by the Owner The period of Guarantee for all materials labor and equipment shall be 12 months from the date of final acceptance of the work unless noted otherwise The period of guarantee on the affected equipment an
49. detailed description PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport 1000A Ted Johnson Parkway Greensboro NC 27409 Renovate the ceilings over the airline ticket counter ceilings at the Piedmont Triad International Airport The Architect Name legal status address and other information Lindsey Architecture p c 125 S Elm St Suite 300 Greensboro NC 27401 Telephone Number 336 617 4402 Fax Number 336 617 4434 The Owner and Contractor agree as follows ADDITIONS AND DELETIONS The author of this document has added information nea ded for its completion The author may also have revised the text of the original AIA standard form An Additions and Deletions Report that notes added information as well as revisions to the standard form_text is available from the author and should be reviewed This document has important legal consequencesw Consultation_with an attorneywis encouraged with respect tots completion or modification ATA_Docum nt A201 2007 GeneralConditions of the Contract for Gonstructten is adopted in this document by reference Do not use with other general conditions unless this document is modifi d ELECTRONIC COPYING of any portion of this AIA Document to another electronic file is prohibited and constitutes a violation of copyright laws as set forth in the footer of this document AIA Document A101 200
50. equal quality finish performance and durability to that specified Submittals shall include project specification and the specific technical paragraph reference which specifies each item and other information necessary to establish contract compliance of each item to be furnished Deviations from the specifications and performance data shall be clearly itemized on the Shop Drawing cover sheet with technical paragraph reference of all non complying items or features Partial or otherwise incomplete submittals will not be acceptable and will be returned without review Refer to Section 15010B for additional requirements ALTERNATE INSULATION MATERIALS Substitutions for alternate insulation products materials or assemblies shall be submitted by the Contractor as outlined in Section 15010B Mechanical INSULATION 15250B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 13 1 14 1 15 General Provisions Substitutions of alternative materials to improve quality construction schedule or costs will be reviewed by the Owner s representative provided the required documentation as called for in Section 15010B is furnished Submit cost change data associated with the alternate insulation materials proposal for consideration by the Owner WHEN UNABLE TO PROVIDE LABELING as required submit certificates from the manufacturer stating that materials meet specified requirements DELIVERY STORAGE AND HANDLING A
51. exact dimensions shape and locations of openings required in sufficient time for the General Contractor to make the necessary provisions This Contractor shall be responsible for the correct size and location of each opening for his equipment even though these openings are provided by the General Contractor Contractor shall arrange for necessary openings in building to admit his equipment If it becomes necessary to cut any portion of building to admit his equipment Owner s representative s approval shall be obtained before cutting and portions cut shall be restored to their former condition by this Contractor 3 10 SLEEVES INSERTS AND PLATES A This Contractor shall provide and locate all sleeves and inserts required before new floors and walls are built or shall be responsible for the cost of cutting and patching required where sleeves and inserts were not installed or where incorrectly located In existing construction this Contractor shall furnish and locate all sleeves and inserts before openings in floors and walls are cut or shall be responsible for the cost of cutting and patching required where sleeves and inserts were incorrectly located This Contractor shall install sleeves and inserts Where possible openings in existing shall be core drilled or saw cut neatly and cleanly Sleeves shall be provided for all duct and pipe passing through concrete floor slabs and concrete masonry tile plaster and gypsum wall construct
52. for earlier Substantial Completion of certain portions of the Work AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 1162824017 Portion of Work Substantial Completion Date subject to adjustments of this Contract Time as provided in the Contract Documents Insert provisions if any for liquidated damages relating to failure to achieve Substantial Eompletion on time or for bonus payments for early completion of the Work 1 000 per day as indicated in specification section 00800 Supplementary Conditions ARTICLE 4 CONTRACT SUM 4 1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor s performance of the Contract The Contract Sum shall be subject to additions and deductions as provided in the Contract Documents 4 2 The Contract Sum is based upon the following alternates
53. for hanger rod sizes 3 8 3 4 diameter C clamps shall be fitted with integral retaining clamps Clamp assemblies shall be plain carbon steel or electro plated zinc finish 2 Welded beam attachments shall be used for rod sizes above 3 4 diameter and shall comply with hanger system materials as noted above H Where ductwork cannot be suspended from overhead supports use substantial welded wall brackets or trapeze supports as conditions demand and as approved by the Owner s representative l Construct fabricated supports and brackets of structural grade miscellaneous steel and fasteners Black or plain steel components which are not specified to have a special finish shall be delivered to the job site with a prime coat of paint Touch up primer after fabrication and after installation J Provide all miscellaneous steel bridging brackets anchors frames bracing plates bolts nuts washers and the like necessary to properly support ductwork All steel hangers and attachments shall be mounted to the building structural steel frame concrete or masonry walls structural concrete floors or concrete structural members No attachments of any kind shall be made to the roof deck metal Refer to Section 15010B Mechanical General Provisions for paragraph entitled Foundations Supports Piers Attachments Material and finish for all components shall be same as the hanger type required for each location K Arrangement and fabricatio
54. g static pressure when tested in accordance with AMCA Std 500 5 Air foil blade dampers of double skin construction with linkage out of the air stream shall be used whenever the damper face velocity exceeds 1500 FPM or system pressure exceeds 2 5 w g but no more than 4000 FPM or 6 w g FMS CONTROLS AND INSTRUMENTATION 15900B 11 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 Acceptable manufacturers are Johnson Controls D 1300 Ruskin CD50 and Vent Products 5650 6 One piece rolled blade dampers with exposed or concealed linkage may be used with face velocities of 1500 FPM or below 7 Acceptable manufacturers are Johnson Controls D 1100 Ruskin CD36 and Vent Products 5800 8 Multiple section dampers may be jack shafted to allow mounting of piston pneumatic actuators and direct connect electronic actuators Each end of the jack shaft shall receive at least one actuator to reduce jack shaft twist C Control Relays 1 Control Pilot Relays a Control pilot relays shall be of a modular plug in design with retaining springs or clips b Mounting bases shall be snap mount C DPDT 3PDT or 4PDT relays shall be provided as appropriate for application d Contacts shall be rated for 10 amps at 120VAC e Relays shall have an integral indicator light and check button D Control Valves 1 All automatic control valves shall be fully proportioning and provide near linear heat transfer cont
55. in sealing construction joints metal jacketing joints and seams pipe hanger saddles and the like Sealant shall be General Electric Construction 1200 Series Silicon Sealant or approved equal Color shall be translucent clear or white as required to match adjacent material finishes Acoustical Sealants Acoustical sealants for sealing around duct or piping penetrations of building construction materials shall be resilient non shrinking non hardening non drying non sag type sealant designed for interior use in sealing concealed construction joints Apply acoustical sealant over a flexible durable non absorptive compressible rod stock backer rod of polyethylene foam neoprene foam or approved equal Acoustical sealants shall be as manufactured by Tremco U S Gypsum Co Woodmont Products or approved equal Ductwork Insulation For sealing FSK vapor retarder jackets on ductwork insulation use fiberglass scrim reinforced foil faced tape nominal 3 width permanently flame retardant and U L rated permeance rating of 0 02 perms mold and mildew resistant Piping Insulation For sealing ASJ vapor retarder jackets on piping insulation use matching tape with a foil inner layer with acrylic adhesive fiberglass scrim reinforcement imbedded between an outer layer of bleached white fire retardant kraft paper and the inner foil layer Tape shall be nominal 3 width for pipe insulation applications up to 7 1 2 OD and nominal 4 width for pipe
56. in separate section of this Specification Division 3 17 OPERATIONAL TESTS AND SERVICING A In addition to testing balancing and commissioning specified elsewhere in this division of the Specifications the Contractor shall make all tests trial operation balancing and balance tests and the like as specified and as directed by the Owner s representative to prove that all work under these Drawings and Specifications is in complete serviceable condition and will function as intended All costs of tests shall be borne by Contractor Pulley sizes and belts shall be adjusted or changed as necessary to obtain the specified performance All controls valves and equipment shall be adjusted to settings indicated At the completion of performance runs the Contractor shall recheck all equipment and verify that each item is functioning correctly Upon completion of all work each system shall be tested to determine if any excess noise or vibration is apparent during operation of the system If any such objections are detected in the system or equipment the Contractor shall be responsible for correcting the problem MECHANICAL GENERAL PROVISIONS 15010B 15 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 F Bearings shall be re lubricated as recommended by the equipment manufacturer 3 18 VIBRATION ISOLATION A C All work shall operate under all conditions of load without any sound or vibration which
57. insulation over 7 1 2 OD permanently flame retardant and U L rated permeance rating of 0 02 perms mold and mildew resistant Insulating Tape For insulating short lengths of piping and fittings in congested or hard to reach areas use an elastomeric insulation tape equal to Armaflex Insulation Tape Rubatex R 180 FS Insulation Tape or Halstead Insulation Tape Tape shall be nominal 2 wide self stick adhesive backing 1 8 thick and suitable for use on pipe surfaces to 160 F Use only 15250B 8 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 in applications specifically approved by the Engineer PART 3 EXECUTION 3 1 3 2 3 3 3 4 3 5 INSPECT ALL SURFACES AND VERIFY that work of other trades requiring insulation has been completed and is ready to receive insulation Specifically check for obvious defects such as leaking pipe or duct joints broken fittings hanger supports and the like that would result in damage to the completed insulation job or that would adversely affect the execution and quality of the insulation systems as specified Do not proceed with application of insulation until defects are corrected REMOVE ALL DIRT SCALE OIL GREASE or other extraneous loose material from surfaces to be insulated VERIFY that piping ductwork equipment vessels and the like have been tested in accordance with the Specifications prior to applying insulation materials INSTALL SPECIFIE
58. is objectionable in the opinion of the Owner s representative For moving machinery sound or vibration noticeable outside of the room in which it is installed or annoyingly noticeable inside its own room will be considered objectionable Sound or vibration conditions considered objectionable by the Owner s representative shall be corrected in an approved manner by the Contractor at the Contractor s expense 3 19 ACCEPTANCE OF EQUIPMENT In the event that the Owner considers it impractical because of unsuitable test conditions or some other factor to execute simultaneous final acceptance of all equipment portions of the installation may be certified by the Owner s representative for final acceptance when that portion of the system is complete and ready for operation 3 20 OPERATION amp MAINTENANCE INSTRUCTIONS A G Submit four 4 sets of complete descriptive information operating and maintenance instructions and spare parts lists for all equipment installed under this contract All information shall be assembled in three ring binders with index tabs to identify each item of major equipment and each system Provide title sheet with job name and the names addresses and phone numbers of the Contractor subcontractor control subcontractor related contractors and material and equipment suppliers Each manual shall be self contained and include information for efficient servicing of equipment supplied and installed under the
59. isolated from the building structure by means of Type F hangers or Type C floor supports b Spring deflections shall be a minimum of 0 75 PART 3 EXECUTION 3 1 The Contractor and the vibration isolation manufacturer or his regularly designated and factory authorized representative shall perform the following tasks in addition to the supply and installation of isolation equipment A Obtain the approved manufacturer s name model number and other necessary identifying data for each item of equipment to be resiliently mounted Coordinate all resilient mounting systems with the exact equipment to be furnished in regard to physical size isolator locations weight rotating speed etc Direct contact and cooperation between the vibration isolation device fabricator and the equipment manufacturer shall be required Obtain all necessary data in regard to piping systems which are specified to be resiliently supported so that proper isolators can be selected Select piping system isolators for proper coordination with the physical arrangement of pipe lines and with the physical characteristics of the building Provide on the job supervision as required during installation of resiliently mounted equipment and piping to assure that all vibration isolators are installed in strict accordance with normally accepted practices for critical environments Replace at no extra cost to the Owner any isolators which do not produce the required deflection
60. items including light fixtures air outlets and inlets speakers sprinklers and special moldings at walls column penetrations and other junctures of acoustical ceilings with adjoining construction 5 Minimum Drawing Scale 1 8 inch 1 foot Samples for initial selection in the form of manufacturer s color charts consisting of actual acoustical tiles or sections of tiles showing the full range of colors textures and patterns available for each type of tile indicated Samples for verification of each type of exposed finish required prepared on samples of size indicated below Where finishes involve normal color and texture variations include sample sets showing the full range of variations expected 1 Set of 12 inch 300 mm long samples of concealed suspension system members 2 Set of 12 inch 300 mm long samples of exposed moldings for each color and system type required 1 4 QUALITY ASSURANCE A Installer Qualifications Engage an experienced Installer who has completed acoustical tile ceilings similar in material design and extent to that indicated for this Project and with a record ACOUSTICAL TILE CEILINGS 09512 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 of successful in service performance Fire Test Response Characteristics Provide acoustical tile ceilings that comply with the following requirements 1 Fire response tests are performed by a qualified testing and inspecting agency Qualified te
61. nameplate inspection stamp and the like F Insulation on all cold surfaces below 65 F shall be applied with a continuous unbroken vapor seal Hangers supports anchors and the like that are secured directly to cold surfaces shall be adequately insulated and vapor sealed to prevent condensation Continue insulation with vapor retarder through penetrations of walls floors and the like FIRE HAZARD RATINGS FOR INSULATION fasteners mastics adhesives and jacketing materials shall not exceed flame spread of 25 fuel contribution of 50 and when used indoors smoke development of 50 as determined by ASTM E 84 E 87 NFPA 255 and UL 723 tunnel test ratings Flameproofing and fireproofing treatments are not acceptable ASBESTOS of any type shall not be allowed in any materials used under this Section INSULATION INSERTS for use at pipe hangers and supports shall be as specified in Section 15090B Supports Anchors and Seals Provide inserts of approved heavy density insulating material at all support points on piping two inches 2 diameter or larger to prevent insulation from sagging Select inserts suitable for the operating temperature range of the installed piping system SUBMITTALS are required on all insulation as hereinafter specified to include manufacturer s material data thickness for each service standards compliance and installation procedures Each item shall be a standard catalog product of an established manufacturer and of
62. or Mon Eco 55 10 Sealants Weather Barrier Finish For all exterior field constructed weather barrier finishes for equipment tanks fittings valves flanges surface patches joints lap edges flashings and the like Dry flame spread rating less than 5 per ASTM E 162 20 to 200 F service 15250B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 12 TAPE INSULATION temperature water vapor permeance to 1 0 perm aged value white finish color tough durable thixotropic trowelable product for use as mechanical protection and weatherproofing of outdoor thermal insulations Weather barrier finish coating shall be Childers Vi Cryl CP 10 11 Foster Sealfas GPM 35 00 Mon Eco 55 50 or Vimasco WC 1 Sealants Foamed Plastic Insulations For all exterior applications and indoor applications where specifically called for to provide a protective or vapor retarder coating on equipment tanks piping fittings valves flanges ductwork joints lap edges flashings and the like Dry flame spread rating less than 5 per ASTM E 162 white finish color resistant to ultra violet effects compatible with insulation and adhesives tough durable weather resistant finish Sealants for foamed plastic insulation shall be Armstrong WB Armaflex finish Rubatex 374 Coating Childers Vi Cryl CP 10 11 or Foster Sealfas GPM 35 00 Sealants Cellular Glass Insulations For all applications where a vapor barrier joint se
63. or equipment is to be used section and article number of specifications governing Contractor s name and name of job H Catalogs pamphlets or other documents submitted to describe items for approval shall be specific tems submitted shall be clearly marked Data of a general nature will not be accepted Data shall include copies of computation sheets indicating how unit capacity was determined where ratings are at other than standard conditions Submit the same number of copies as required for shop drawings l The submittal of shop drawings shall have the Contractor s approval stamp affixed in a prominent place on each copy This stamp shall indicate that the Contractor by approving and submitting shop drawings represents that he has determined and verified all field measurements and quantities field construction criteria materials performance and similar data that he has reviewed and coordinated information in the shop drawings with the requirements of the work and the Contract Documents and that any deviations from the Contract Documents have been clearly shown on the submittal J Approval by the Owner s representative of shop drawings shall not be considered as a guarantee of quantities measurements or building conditions Where drawings are provided Owner s representative s approval does not mean that drawings have been checked in detail Owner s representative s approval does not in any way relieve the Contractor from his respons
64. or sham that said BIDDER has not colluded conspired connived or agreed directly or indirectly with any BIDDER or person to put in a sham BID or that such other person shall refrain from bidding and has not in any manner directly or indirectly sought by agreement or collusion or communication or conference with any person to fix the Bid Price of affiant or any other BIDDER or to fix any overhead profit or cost element of said Bid Price or of that of any other BIDDER or to secure any advantage against OWNER any person interested in the proposed Contract and that all statements in said Proposal or Bid are true and further that such BIDDER has not directly or indirectly submitted this BID or the contents thereof or divulged information or date relative thereto to any association or to any member or agent thereof Bidder Sworn to and subscribed before me this day of 20 Notary Public in and for County My Commission expires 20 SEAL BID FORM 00310 6 PTIA Ticket Counter Ceiling Renovation 12 001 000 This Affidavit is Part of Bid EQUAL OPPORTUNITY REPORT STATEMENT AS REQUIRED BY 41 CFR 60 1 7 b The Bidder Proposer shall complete the following statement by checking the appropriate blanks Failure to complete these blanks may be grounds for rejection of bid 1 The Bidder Proposer has has not developed and has on file at each establishment affirmative action programs pursuant to 41 CFR 60 1 4
65. protection saddle product sheets coating finish product data sheets and fabrication drawings necessary to confirm compliance with specified hanger types and details on the Drawings E Submittals are required for all fabricated materials and assemblies to be furnished and delivered to the site F Welded connections shall be indicated with standard AWS symbols showing size length and type of each weld QUALITY ASSURANCE A Materials and fabrication procedures shall be subject to inspection and tests in mill shop and at the site Test shall be conducted by a qualified inspection agency employed by the Owner B Such inspections and tests shall not relieve the Contractor of responsibility for providing materials and fabrication procedures in compliance with specified requirements C Contractor shall promptly remove and replace materials or fabricated components which do not comply with requirements of Contract Documents D Welded construction shall comply with AWS Code for procedures appearance and quality of welds and for methods used in correcting welding work QUALIFICATION FOR WELDING WORK A C Qualify welding processes and welding operators in accordance with AWS Standard Qualification Procedure At Contractor s expense provide certification to the Engineer that welders to be employed in the work have satisfactorily passed AWS qualification tests within the previous twelve 12 months prior to start of work
66. repaint completely equipment on which factory paint has been damaged Paint all miscellaneous support steel exposed to weather or visible within an occupied space or mechanical room Painting materials and methods shall be as specified under the Specification Division and Section titled Painting 3 14 IDENTIFICATION OF EQUIPMENT PIPING amp DUCTWORK All mechanical equipment piping ductwork and controls furnished and or installed under this division shall be identified by nameplates or tags as specified in separate section Mechanical Identification 3 15 PLACING IN SERVICE MECHANICAL GENERAL PROVISIONS 15010B 14 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 G H Before being placed into operation each item of equipment shall be serviced in accordance with the requirements of these Specifications and the manufacturer s recommendations This servicing shall include alignment lubrication instrument liquids instrument and control calibrations and adjustments testing and adjusting of operating controls Prior to final inspection demonstrate operation of each system to Engineer and Owner Instruct Owner s personnel in operation adjustment and maintenance of equipment and systems using the operation and maintenance data as the basis of instruction Prior to Final Acceptance of the work for items so designated in individual Specification Sections an authorized representative of each manufactur
67. shall be UL Class RK1 or RK5 in accordance with the Disconnect Schedule on the Drawings DISCONNECT SWITCHES AND FUSING 16410 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B All fuses shall have a 60 cycle interrupting rating of 200 000 RMS Amperes at their rated voltage and shall be current limiting PART 3 EXECUTION 3 1 INSTALLATION A Install disconnect switches where indicated on Drawings B Install fuses in fusible disconnect switches 3 2 DISCONNECT SWITCH SCHEDULE As shown on the Drawings 3 3 SPARE FUSES Provide Owner with minimum of three 3 fuses of each type and rating END OF SECTION 16410 DISCONNECT SWITCHES AND FUSING 16410 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16440 PANELBOARDS PART 1 GENERAL 1 1 1 3 1 4 WORK INCLUDED A Distribution panelboards B Lighting and appliance branch circuit panelboards REFERENCES A FS W C 375 Circuit Breakers Molded Case Branch Circuit and Service B FS W P 115 Power Distribution Panel C NEMA AB 1 Molded Case Circuit Breakers D NEMA PB 1 Panelboards E NEMA PB 1 1 Instructions for Safe Installation Operation and Maintenance of Panelboards Rated 600 Volts or Less SUBMITTALS A Submit shop drawings for equipment and component devices under provisions of Sections 01300 and 16010 B Include outline and support point dimensions voltage main bus amp
68. singular however the Contractor shall provide and install the number of items of equipment as indicated on the Drawings or as required for complete systems F Provide all items required to complete the construction in accordance with reasonable interpretation of the intent of the Drawings and Specifications Any minor items required by code law or regulations shall be provided whether or not specified or specifically shown where it is a part of a major item of equipment or of the control system specified or shown on the plans G Conflicts between the requirements of this Specification standards purchase orders or design drawings shall be referred to the Owner s representative for clarification before proceeding with work on the affected parts EXAMINATION OF WORK SITE Contractor and subcontractors shall before submitting proposals inform themselves of the conditions under which the work is to be performed concerning the site of the work the location of utilities the structure of the building the obstacles which may be encountered and all other relevant matters concerning the work to be performed No extra compensation will be allowed for failure to secure such information which was available prior to bidding The successful Contractor shall employ insofar as possible such methods and means in the carrying out of this work as will not cause any interruption or interference with any separate Contractor or with Owner PRESENCE ON WO
69. site one complete set of red marked Contract Drawings and Specifications continuously updated as the work progresses to show all changes to the work and indicate actual installation of equipment and systems The Contractor shall prepare complete Record Submittal Drawings from these red marked documents for submittal to the Owner s representative as a part of the Contract Closeout submittals INSTRUCTIONS AND MAINTENANCE Instruct Owners operators in proper operation and maintenance of all equipment and controls Supervise the operation of the system until the Owners operators are familiar with the equipment and controls See other Specification Sections for additional requirements PART 2 PRODUCTS 2 1 SUBSTITUTIONS AND PRODUCT OPTIONS A Contractor s Options 1 For products specified only by reference standard select any product meeting that standard 2 For products specified by naming several products or manufacturers select any one of the products or manufacturers named which complies with the Specifications 3 For products specified by naming one or more products or manufacturers and or equal Contractor shall submit a request for substitutions for any product or manufacturer not specifically named B Substitutions Contractor shall obtain written approval from Owner s representative for the use of substitute products materials or manufacturers claimed as equal to those specified Requests for substitution approv
70. such substitute including the cost of redesign and claims of other contractors affected by the resulting change all of which shall be considered by the Architect in evaluating the proposed substitute The Architect will be the sole judge of acceptability and no substitute will be ordered or installed without the Architect s prior written acceptance The Owner may require the Contractor to furnish at the Contractor s expense a special performance guarantee or other surety with respect to any substitution SUPPLEMENTARY CONDITIONS 00800 8 PTIA Ticket Counter Ceiling Renovation 12 001 000 13 8 3 The Architect will record the time required in evaluating substitutions proposed by the Contractor including time required by consultants and resultant changes in the Drawings and Specifications Whether or not the Architect accepts a proposed substitute the Contractor shall reimburse the Owner for the charges of the Architect and the Architect s consultants for evaluating any proposed substitute 13 9 Preconstruction Conference 13 9 1 Before starting any construction work on this Project a conference will be held in the Owner s office for the purpose of verifying general procedures expediting shop drawings and schedules and to establish a working understanding between the parties concerned with this Project The Contractor s representative and representatives of major subcontractors may also be present The data and time of the conference sha
71. test and verify that moisture level is below tile manufacturer s recommended limits Measure each ceiling area and establish the layout of acoustical tile to balance border widths at opposite edges of each ceiling Avoid using less than half width units at borders and conform to the layout shown on reflected ceiling plans 3 3 INSTALLATION A General Install acoustical tile ceilings to comply with publications referenced below per manufacturer s instructions and CISCA Ceiling Systems Handbook 1 Standard for Ceiling Suspension System Installations Comply with ASTM C 636 2 CISCA Recommendations for Acoustical Ceilings Comply with CISCA Recommendations for Direct Hung Acoustical Tile and Lay In Panel Ceilings 3 Installed as required for support of light fixtures etc per all applicable building codes Suspend ceiling hangers from building s structural members and as follows 1 Install hangers plumb and free from contact with insulation or other objects within ceiling plenum that are not part of the supporting structure or of the ceiling suspension system 2 Splay hangers only where required to miss obstructions offset resulting horizontal forces by bracing countersplaying or other equally effective means 3 Where width of ducts and other construction within ceiling plenum produces hanger spacings that interfere with the location of hangers at spacings required to support standard suspension system members install su
72. the opportunity to participate in the performance of contracts financed in whole or in part by the Owner in order to maximize opportunities for women and minority owned businesses in Airport Authority projects By submitting a bid under this solicitation except for those listed by the Bidder in a clearly identified attachment to the bid the bidder certifies that steel and each manufactured product is produced in the United States as defined in the clause Buy American Steel and Manufactured Products for Construction Contracts and that components of unknown origin are considered to have been produced or manufactured outside the United States By submitting a bid under this solicitation the bidder certifies to have reviewed all documents in reference to the Contract General Conditions Modifications to General Conditions Supplementary Conditions Specification Sections Drawings addenda and modifications to the Contract Documents issued subsequent to the initial printing of this project manual and including but not necessarily limited to printed material referenced by any of these documents so to complete the work as indicated in the documents The bidders must be properly licensed under Chapter 87 General Statues of North Carolina G S 87 15 The bidders shall certify by submission of a proposal that neither it nor its principals is presently debarred suspended proposed for debarment declared ineligible or voluntarily excluded from
73. this Bid and it shall be made a condition of each subcontract entered into pursuant to the prime contract that the Contractor and any Subcontractor shall not require any laborer or mechanic employed in performance of the contract to work in surroundings or under working conditions which are unsatisfactory hazardous or dangerous to his health or safety as determined under Construction Safety and Health Standards Title 29 CFR Part 1518 36FR7340 promulgated by the U S Secretary of Labor in accordance with Section 107 of the Contract Work Hours and Safety Standards Act 82 Statt 96 that it is a further condition of this Bid that he shall be solely responsible for the enforcement of such Construction and Health Standards and that he definitely understands that the Owner and his authorized representatives will not assume any liability resulting from his failure to police and enforce all such standards f The description under each bid item being briefly stated implies although it does not mention all incidentals and that the prices stated are intended to cover all such work materials and incidentals as constitute Bidder s obligations as described in the Bid Documents and any details not specifically mentioned but evidently included in the Contract shall be compensated for in the item which most logically includes it 4 Contract Time Bidder agrees that a The work will be installed prior to sixty 120 calendar days from the no
74. throw pattern on each individual device Materials of construction Finishes Accessories and options Installation details and mounting methods Reference to the Contract Documents for performance information is unacceptable ommoo wp SAMPLES Submit one sample of each air distribution device for review and approval PART 2 PRODUCTS 2 1 2 2 DIFFUSERS GRILLES REGISTERS AND ACCESSORIES shall be the products of Metal Industries Metal Aire Carnes Titus Corporation Price Krueger Manufacturing Co or Tuttle amp Bailey ONE MANUFACTURER S products shall be used for like components throughout the work Do not mix manufacturers without the prior written approval of the Owner s representative or unless required to comply with product specifications and performance criteria AIR OUTLETS amp INLETS DISTRIBUTION 15870B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 3 PRODUCT MODEL NUMBERS types sizes styles accessories and other details shall be as scheduled on the Drawings PART 3 EXECUTION 3 1 3 2 3 3 3 4 3 5 COORDINATE with General Contractor for all openings and penetrations required in building construction for air outlets and inlets prior to the construction of work to be penetrated SURFACE MOUNTED OUTLETS AND INLETS Fit surface mounted outlets and inlets tight against the surface on which they are mounted with no perceivable gaps between the outlet
75. turn around times paopgp PROJECT RECORD DOCUMENTS 01720 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 Inspection and system test procedures Copies of applicable Shop Drawings and Product Data Listing of required maintenance materials and services Names and addresses of sources of maintenance materials Maintenance drawings and diagrams Precautions against improper maintenance and exposure ATO sem 5 Each prime contractor is responsible for maintenance manuals for its own Work Wherea manual includes information on installations by more than one contract the Contractor who is the principal source of information as designated by the Architect shall receive information from other contractors coordinate and collate information for a unified manual and provide binders and submittal as specified PART 2 PRODUCTS Not Applicable PART 3 EXECUTION 3 1 RECORDING A Post changes and modifications to the Documents as they occur Do not wait until the end of the Project END OF SECTION 01720 PROJECT RECORD DOCUMENTS 01720 4 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 06202 INTERIOR FINISH CARPENTRY PART 1 GENERAL 1 1 A 1 2 A B SUMMARY Section Includes 1 Interior trim 2 Interior plywood hardboard board panels ACTION SUBMITTALS Product Data For each type of process and factory fabricated product Samples For each type of paneling PART 2 PRODUCTS
76. which are frequently encountered f Markers shall be suitable for 40 F to 180 F operating range On lines exposed to a temperature above 180 F markers shall be placed over insulation not on bare pipe g Markers shall be Setmark Pipemarkers as manufactured by Seton or equal by listed acceptable manufacturers 2 3 IDENTIFICATION NAMEPLATES A Plastic Nameplates 1 Nameplates shall be 1 16 thick satin surfaced plastic material with beveled edges and engraved letters 2 Each plate shall be drilled with two mounting holes sized for 3 8 No 3 round headed or 3 8 No 4 sheet metal screws Plates shall be furnished with mounting screws When scheduled or designated plates shall be furnished undrilled 3 Plates shall have black letters on white background Letters shall be 3 16 high minimum 4 Plates shall be Setonply style 2060 as manufactured by Seton or equal by listed acceptable manufacturer B Aluminum Nameplates 1 Nameplates shall be 0 020 flexible aluminum material with engraved letters 2 Each plate shall be drilled with two mounting holes sized for 3 8 No 3 round headed or 3 8 No 4 sheet metal screws Plates shall be furnished with mounting screws 3 Plates shall have aluminum letters on a black enamel background 4 Plates shall be style 2065 as manufactured by Seton or equal by listed acceptable manufacturer 2 4 UNDERGROUND WARNING TAPES A Polyethylene Tape 1 Polyethylene tape shall be
77. wrinkles Immediately apply a 1 8 film of flashing compound to the entire membrane surface leaving a large bead or fillet over the joint All compound shall dry then extend adjacent finish over the flashing a minimum of 3 inches CANVAS JACKET Cover entire insulation surface with canvas embedded between two 1 8 thick layers of lagging adhesive Overlap canvas at least 2 on itself and adjoining surfaces Provide premolded PVC fitting covers for all insulated fittings valves and the like installed on systems scheduled to receive canvas jackets PVC fitting covers shall be as specified elsewhere in this section FIBERGLASS JACKET Cover entire insulation surface with fiberglass jacket between two 1 8 thick layers of lagging adhesive liberally applied Overlap fiberglass jacket at least 2 on itself and adjoining surfaces When applied on chilled water pipe insulation systems provide a continuous vapor seal and smooth exterior finish PVC fitting covers shall be as specified elsewhere in this section METAL JACKET Cover entire insulation surface of piping with aluminum jacket and fitting covers Locate longitudinal joints along the side of horizontal piping with the overlapped joint positioned to INSULATION 15250B 12 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 shed water Overlap circumferential joints 2 minimum Seal all longitudinal joints and circumferential joints with vapor barrier sealant Secure j
78. 0 and 41 CFR 60 2 The Bidder Proposer has has not participated in any previous contract or subcontract subject to the equal opportunity clause prescribed by Executive Order 11246 as amended The Bidder Proposer has has not filed with the Joint Reporting Committee the annual compliance report on Standard Form 100 EEO 1 Report The Bidder Proposer does does not employ fifty 50 or more employees NAME OF BIDDER BY TITLE DATE BID FORM 00310 7 PTIA Visitor Information Booths 12 040 000 This Affidavit is Part of Bid SUBCONTRACTS EXCEEDING 10 000 WHICH ARE NOT EXEMPT FROM THE EQUAL OPPORTUNITY CLAUSE CERTIFICATION OF NONSEGREGATED FACILITIES The federally assisted construction contractor certifies that he does not maintain or provide for his employees any segregated facilities at any of his establishments and that he does not permit his employees to perform their services at any location under his control where segregated facilities are maintained The federally assisted construction contractor certifies that he will not maintain or provide for his employees segregated facilities at any of his establishments and that he will not permit his employees to perform their services at any location under his control where segregated facilities are maintained The federally assisted construction contractor agrees that a breach of this certification is a violation of the equal opportunity clause in this
79. 001 000 F Joints that leak shall be disassembled cleaned and made again Applying additional solder to a leaking joints is prohibited 3 8 THREADED JOINTS A Piping specified to be joined by threading shall be cut square to accurate lengths and after threading shall be reamed to remove burrs and to provide full flow diameter of pipe through the joint Threads shall be cut full clean and concentric with the outside of the pipe Threads shall be in accordance with ANSI B2 1 for taper threads Remove excess thread cutting lubricant from the inside and outside of pipe Threaded joints shall be made leak tight by use of a suitable joint compound or teflon tape for pipe threads No 51 Permatex pipe joint compound or equal except as otherwise required by attached Piping Schedules When assembled not more than three threads shall be visible at any joint Make joints in piping systems tight and leakproof against design pressures Care shall be taken to avoid over tightening of threaded joints and to avoid damaging the pipe exterior with the pipe wrench Backing off of made up threaded joints to facilitate fit up or alignment will not be permitted Repair leaks in screwed or flanged joints which cannot be eliminated by normal wrench tightening methods by remaking the joint Caulking will not be allowed 3 9 FLANGED JOINTS A moo OW G H Flanges shall be permitted in sizes and for the maximum service ratings on
80. 001 000 receive sensors The Mechanical Contractor shall install the primary sensing elements and controls provided by the Electrical Contractor Installation of each item shall be as recommended by the Electrical Contractor If his recommendation conflicts with or is substantially different from the Specifications and Drawings the conflict or difference shall be resolved with the Owner s representative before proceeding The Mechanical Contractor shall provide an access door immediately adjacent to each duct mounted ionization or smoke detector for servicing The Mechanical Contractor shall be responsible for the final installation with regard to proper locations as required by the Electrical Contractor workmanship and final insulation of equipment and systems in which the elements and controls are installed The Electrical Contractor shall be responsible for the installation and operation of the Fire Safety Systems complete except as described above The Contractor is referred to the Instrumentation and Control Drawings and Specifications and to Division 16 Electrical for information TEMPORARY FACILITIES AND CONTROLS A Construction aids such as scaffolds staging ladders ramps railings hoists cranes chutes and other such facilities and equipment and all tools shall be provided by Contractor as necessary to accomplish the work Barriers shall be furnished installed and maintained as required to prevent public entry
81. 01 000 5 VIBRATION ISOLATION capability Hangers shall be type W30 as manufactured by Mason Industries Inc or equal Type K Isolation Neoprene Pump Connectors a b C d Flexible neoprene connectors shall be used on all equipment as indicated on the Drawings or on the Equipment Schedule They shall be manufactured of multiple plys of nylon tire cord fabric and neoprene both molded and cured in hydraulic rubber presses No steel wire or rings shall be used as pressure reinforcement Straight connectors shall have two spheres Connectors up to and including 1 1 2 diameter may have threaded ends Connectors 2 and larger shall be manufactured with floating galvanized flanges recessed to lock the connector s raised face neoprene flanges Hoses shall be installed on the equipment side of the shut off valves Connectors shall be rated a minimum of 150 psi at 220 F Flanged equipment shall be directly connected to neoprene elbows in the size range 2 1 2 through 12 if the piping makes a 90 turn at the equipment All straight through connections shall be made with twin spheres properly pre extended as recommended by the manufacturer to prevent additional elongation under pressure Submittals shall include two test reports by independent consultants showing minimum reductions of 20 DB in vibration accelerations and 10 DB in sound pressure levels at typical blade passage frequencies Elbows shall be Mason Flex type M
82. 1 Fittings and Supports for Conduit and Cable Assemblies FS WW C 563 Electrical Metallic Tubing FS WW C 566 Specification for Flexible Metal Conduit FS WW C 581 Specification for Galvanized Rigid Conduit NEMA TC 3 PVC Fittings for Use with Rigid PVC Conduit and Tubing room mMm OO UW ANSI NEMA OS 1 Sheet Steel Outlet Boxes Device Boxes Covers and Box Supports NEMA 250 Enclosures for Electrical Equipment 1000 Volts Maximum PART 2 PRODUCTS 2 1 RIGID METAL CONDUIT AND FITTINGS A Rigid Steel Conduit ANSI C80 1 FS WW C 581 B Fittings and Conduit Bodies ANSI NEMA FB 1 threaded type material to match conduit 2 2 ELECTRICAL METALLIC TUBING EMT AND FITTINGS A EMT ANSI C80 3 FS WW C 563 galvanized tubing CONDUIT AND BOXES 16130 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B Fittings and Conduit Bodies ANSI NEMA FB 1 steel compression type 2 3 LIQUIDTIGHT FLEXIBLE CONDUIT AND FITTINGS 2 4 2 5 2 6 2 7 2 8 A Conduit Flexible metal conduit with PVC jacket B Fittings and Conduit Bodies ANSI NEMA FB 1 PLASTIC CONDUIT AND FITTINGS A Conduit NEMA TC 2 Schedule 40 PVC B Fittings and Conduit Bodies NEMA TC 3 CONDUIT SUPPORTS A Conduit Clamps Straps and Supports Steel or malleable iron B Galvanized for moist locations Hot dip galvanized for exposure to weather Non metal in corrosive areas ACCEPTABLE CONDUIT MANUFACTUR
83. 1600 2 5 RECEPTACLES A Convenience and Straight blade Receptacles NEMA WD 1 FS W C 596 20A 120V B Locking Blade Receptacles NEMA WD 5 C Convenience Receptacle Configuration NEMA WD 1 Type 5 20 R ivory 20A 120V D Specific use Receptacle Configuration NEMA WD 1 or WD 5 type as indicated on Drawings ivory E GFCI Receptacles Duplex convenience receptacle with integral ground fault current interrupter 20A 120V E Receptacles shall be of the grounding type with hex head grounding screw to be connected to the green grounding conductor 2 6 ACCEPTABLE MANUFACTURERS WALL PLATES Leviton Crouse Hinds Hubbell Pass amp Seymour Arrow Hart nmo Ow p Substitutions Under provisions of Section 01600 2 7 WALL PLATES A Decorative Cover Plate Smooth stainless steel B Weatherproof Cover Plate Gasketed cast metal with hinged gasketed device in use covers PART 3 EXECUTION Not Used END OF SECTION 16140 WIRING DEVICES 16140 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16410 DISCONNECT SWITCHES AND FUSING PART 1 GENERAL 1 1 WORK INCLUDED A Furnish and install disconnect switches as shown or indicated on the Drawings B Furnish and install fuses in all fusible disconnect switches in accordance with the Drawings and these Specifications REFERENCES A ANSI UL 198C High Intensity Capacity Fuses Current Limiting Types B ANSI UL 198E
84. 2 0001 000 a Air Handling Units b Fans C Pumps d Boilers e Unit Heaters f Terminal Units C Ductwork Identification 1 Identify all externally insulated ductwork systems with adhesive mounted plastic nameplates 2 Identify as to fan air handling unit number and area served 3 Locate identification as follows a At each item of equipment b At each side of penetration of structure or enclosure C At each control device d At each obstruction 4 Provide identification at or on each duct access door identifying item or items behind door such as smoke detector fire damper smoke damper control damper O A for example etc D Underground Utilities 1 Underground warning and metallic detection tapes shall be installed a maximum of 6 below grade directly above buried pipe 2 Metallic pipes shall have polyethylene warning tape 3 Non metallic pipes shall have metallic detection tape E Electrical Controls Identification 1 Identify all control panels and devices components outside panels with screw mounted plastic nameplates For small devices nameplates may be fastened to the mounting location directly above or below the device 2 All controls conduit shall be identified with snap around electrical markers Markers shall say CONTROLS and indicate the line voltage contained in the conduit Pneumatic lines contained in conduit shall say CONTROLS AIR for identification 3 Locate conduit identification as follows
85. 200 deg F service temperature with insulation extending one inch beyond metal jacket Thickness of insulation in the insert shall be equal to the insulation thickness scheduled for the service pipe where applied Saddles shall be Model A2000 as manufactured by Pipe Shields Inc or approved equivalent FIRESTOP SEALS All holes voids or openings created to extend mechanical systems through fire rated floors partitions and walls shall be sealed by the Contractor with an intumescent material capable of expanding up to 10 times when exposed to temperatures beginning at 250 F All firstrop systems shall be UL Classified and have ICBO BOCAI and SBCCI NER 243 approved ratings per ASTM E 814 UL 1479 Manufacturer shall be 3M Dow Corning Hilti or approved equal Refer to specific details on the Drawings MECHANICAL WALL SLEEVE SEAL LINK SEAL Modular mechanical type wall sleeve seals shall consist of interlocking synthetic rubber links shaped to continuously fill the annular space between the pipe and wall sleeve Links shall be loosely assembled with bolts to form a continuous rubber belt around the pipe with a pressure plate under each bolt head and nut Tightening of the bolts shall cause the rubber links to expand and provide a positive water tight seal between the service pipe and wall sleeve Wall sleeves shall be of Schedule 40 carbon steel with welded water stop anchor collar Mechanical wall sleeve seals shall be Link Seal model as m
86. 2824017 ARTICLE 6 DISPUTE RESOLUTION 6 1 INITIAL DECISION MAKER The Architect will serve as Initial Decision Maker pursuant to Section 15 2 of AIA Document A201 2007 unless the parties appoint below another individual not a party to this Agreement to serve as Initial Decision Maker If the parties mutually agree insert the name address and other contact information of the Initial Decision Maker if other than the Architect 6 2 BINDING DISPUTE RESOLUTION For any Claim subject to but not resolved by mediation pursuant to Section 15 3 of AIA Document A201 2007 the method of binding dispute resolution shall be as follows Check the appropriate box If the Owner and Contractor do not select a method of binding dispute resolution below or do not subsequently agree in writing to a binding dispute resolution method other than litigation Claims will be resolved by litigation in a court of competent jurisdiction Arbitration pursuant to Section 15 4 of AIA Document A201 2007 Litigation in a court of competent jurisdiction X Other Specify As specified in Specification 00800 Supplementary Conditions ARTICLE 7 TERMINATION OR SUSPENSION 7 1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201 2007 7 2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201 2007 ARTICLE 8 MISCELLANEOUS PROVISIONS 8
87. 5 inches 100 by 125 mm on the label or beside the title block on Shop Drawings to record the Contractor s review and approval markings and the action taken 2 Include the following information on the label for processing and recording action taken Project name Date Name and address of the Architect Name and address of the Contractor Name and address of the subcontractor Name and address of the supplier Name of the manufacturer Number and title of appropriate Specification Section Drawing number and detail references as appropriate saroao0op C Submittal Transmittal Package each submittal appropriately for transmittal and handling Transmit each submittal from the Contractor to the Architect using a transmittal form The Architect will not accept submittals received from sources other than the Contractor 1 On the transmittal record relevant information and requests for data On the form or separate sheet record deviations from Contract Document requirements including variations and limitations Include Contractor s certification that information complies with Contract Document requirements SUBMITTALS 01300 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 1 5 1 6 A CONTRACTOR S CONSTRUCTION SCHEDULE Bar Chart Schedule Prepare a fully developed horizontal bar chart type for each individual contractor s construction schedule Submit within 10 days after the date the contract is awarded Sc
88. 5B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 G Motors furnished as proprietary selections to equipment manufacturers 2 2 MANUFACTURERS PREMIUM EFFICIENCY MOTORS 3 0 HP AND LARGER A Baldor Super E Series B General Electric Energy Saver Series C Lincoln Electric Energy Efficient Series D Reliance XE Series E Magnetek Century E Plus III F Substitutions Under provisions of Section 15010B Substitutions 2 3 GENERAL CONSTRUCTION AND REQUIREMENTS A Electrical Service Refer to equipment specification sections and schedules on Drawings for required electrical characteristics B Motors Designed for continuous operation in 40 degrees C environment and for temperature rise in accordance with ANSI NEMA MG 1 limits for insulation class Service Factor and motor enclosure type C Visible Nameplate Indicating motor horsepower voltage phase cycles RPM full load amps locked rotor amps frame size manufacturer s name and model number Service Factor Power Factor efficiency D Electrical Connection Conduit connection boxes threaded for conduit For fractional horsepower motors where connection is made directly provide screwed conduit connection in end frame 2 4 SINGLE PHASE POWER SPLIT PHASE MOTORS A Starting Torque Less than 150 percent of full load torque B Starting Current Up to seven times full load current C Breakdown Torque Approximately 200 percent of full loa
89. 6 Store equipment and specialties in safe clean dry areas with open ends and pipe connection points covered until removed for installation C Handling 1 Unload unpack and handle items with extreme care use slings cradles or other appropriate appurtenances 2 Transport all items as required from unloading point to storage or installation location protect components from damage during transportation 3 Handle items in accordance with special instructions of manufacturer or supplier 4 Replace parts damaged during transportation and handling at no additional cost to Owner so that schedule of this portion of work is not impaired 5 Protect painted and machined surfaces where exposed PART 2 PRODUCTS SUPPORTS ANCHORS AND SEALS 15090B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 1 2 2 MANUFACTURERS Support and hanger products are specified below by reference to Grinnell or Michigan figure numbers Equivalent products by Bergen Paterson Grinnell B Line Corner amp Lada Michigan Hanger Co Gulf States F amp S Central Crawford Modern or Pipe Shields Inc will be accepted SUPPORTS AND HANGERS A General 1 Contractor shall provide adequate pipe suspension systems in accordance with recognized engineering practices All piping systems shall have adequate hangers supports guides and anchors designed in compliance with the latest requirements of the ANSI Code for Pressure P
90. 7 Copyright 1915 1918 1925 1937 1951 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 1162824017 TABLE OF ARTICLES 1 THE CONTRACT DOCUMENTS 2 THE WORK OF THIS CONTRACT 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 4 CONTRACT SUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 TERMINATION OR SUSPENSION 8 MISCELLANEOUS PROVISIONS 9 ENUMERATION OF CONTRACT DOCUMENTS 10 INSURANCE AND BONDS ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement Conditions of the Contract General Supplementary and other Conditions Drawings Specifications Addenda issued prior to execution of this Agreement other documents listed in this Agreement and Modifications issued after execution of this Agreement all of which form the Contract and are as fully a part of the Contract as if attached to this Agreement or repeated herein The Contract represents the entire and integrated agreement between the parties hereto and supersedes p
91. ATION PART 1 GENERAL 1 1 RELATED DOCUMENTS A Drawings and general provisions of the Contract including General and Supplementary Conditions and other Division 1 Specification Sections apply to this Section 1 2 SUMMARY A This Section includes administrative and supervisory requirements necessary for coordinating construction operations including but not necessarily limited to the following 1 General project coordination procedures 2 Conservation 3 Coordination Drawings 4 Administrative and supervisory personnel 5 Cleaning and protection B Related Sections The following Sections contain requirements that relate to this Section 1 Division 1 Section Project Meetings for progress meetings coordination meetings and preinstallation conferences 2 Division 1 Section Submittals for preparing and submitting the Contractor s Construction Schedule 3 Division 1 Section Contract Closeout for coordinating contract closeout 1 3 COORDINATION A Coordinate construction operations included in various Sections of these Specifications to assure efficient and orderly installation of each part of the Work Coordinate construction operations included under different Sections that depend on each other for proper installation connection and operation 1 Schedule construction operations in the sequence required to obtain the best results where installation of one part of the Work depends on installation of other compo
92. All vibration isolation equipment shall be furnished by one of the following manufacturers Kinetics Peabody Noise Control Mason Industries Vibration Mountings amp Controls Vibration Eliminator or Amber Booth A single manufacturer for all vibration isolation equipment will be required except as specifically approved in writing by the Engineer or by his specific approval of shop drawings VIBRATION ISOLATION 15201B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 2 VIBRATION ISOLATION SYSTEMS A General 1 The vibration isolation systems described herein and identified by type letter designations shall be applied to specific classifications of mechanical equipment as indicated on the Drawings 2 The minimum static deflection of the isolators for each classification of mechanical equipment shall be as indicated in the Specifications or on the Drawings B System Types 1 Type C Isolation Restrained Spring Mount a Equipment with operating weight different from the installed weight such as chillers boilers and the like and equipment exposed to the wind such as cooling towers shall be mounted on spring mountings as described in Type B Isolation but a housing shall be used that includes vertical limit stops to prevent spring extension when weight is removed b The housing shall serve as blocking during erection and cooling tower mounts shall be located between the supporting steel and roof or
93. BHP apop 7 Field tests Discharge pressure full flow and no flow Suction pressure full flow and no flow Operating head No load amps Full flow amps No flow amps Calculated bhp a 9aoop D Heat Transfer Equipment Data 1 Chilled water coils Manufacturer model and serial number Element designation Size and type Specified conditions Flow rate GPM Face velocity FPM Entering and leaving water temperatures Deg F Entering and leaving air dry and wet bulb temperatures Deg F Pressure drop feet of water Pressure drop air in wg Calculate BTU Hour for both fluid and air AT ose 9 A0Tp 2 Unit heaters hot water Designation Manufacturer model and serial number Size Specified conditions Fan speed RPM Air flow rate CFM Water flow rate GPM a paoop TESTS 15042B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 h Water temperature in amp out Deg F 3 Circulating water distribution each system all control valves open TESTS a Flow rate GPM b Supply water temperature each zone Deg F Return water temperature each zone Deg F Hot water coils AHU coils Manufacturer model and serial number Element designation Size and type Specified conditions Face velocity FPM Entering and leaving air temperatures Deg F Entering and leaving water temperatures Deg F Pressure drop air in wg Hot water flow rate gpm Pressure dro
94. BRATION ISOLATION 15201B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15250B INSULATION PART 1 GENERAL 1 1 1 2 1 4 1 5 CONTRACT DOCUMENTS The Contract Documents apply to this section INTENT The intent of this Specification is to provide a quality installation which may not be attainable through the use of a standard composite consisting of insulation vapor retarder and jacket assembled by an insulation manufacturer However in some installations composites will be acceptable provided they meet the requirements of the Specifications relating to referenced standards for individual components STANDARDS Insulation products and installation shall as a minimum comply with the National Commercial amp Industrial Insulation Standards published by the Midwest Insulation Contractors Association MICA Omaha Nebraska latest edition DEFINITIONS A All Service Jacket ASJ A white kraft paper bonded to aluminum foil and reinforced with glass fibers The composite jacket has an integral longitudinal lap with a pressure sensitive tape lap sealing system B Concealed Spaces All areas other than finished spaces which are generally not visible after completion of the project C Finishing Cement A mixture of various insulating fibers fillers and binders with water with or without hydraulic cement to form a smooth trowelable paste insulation for application over insulating ce
95. C ambient 13 Ballast shall meet FCC Rules and Regulations Part 18 ACCEPTABLE MANUFACTURERS BALLASTS A G E B Advance C Universal ACCEPTABLE MANUFACTURERS LAMPS A Sylvania G E Philips B Substitutions Under provisions of Section 01600 ACCEPTABLE MANUFACTURERS LUMINAIRES A As noted on Schedule B Substitutions Under provisions of Sections 01600 and 16010 LAMPS Fluorescent Lamps Type T8 lamps 3500 K unless otherwise scheduled on Drawings PART 3 EXECUTION 3 1 3 2 3 3 3 4 INSTALLATION A Install lamps in luminaires and lampholders B Where a recessed fluorescent or downlight fixture replaces a section or part of a ceiling tile fixture is to be supported at all two 2 corners to the steel frame of the building Supports shall be provided with the same type of wire as used to support the lay in ceiling track Attach one end of the wire to one corner of the fixture and the other end to the building s structural system C Install recessed luminaires to permit removal from below Use plaster frames Install grid Clips RELAMPING All lamps are to be new at time of Owner s acceptance ADJUSTING AND CLEANING A Align luminaires and clean lenses and diffusers at completion of Work Clean paint splatters dirt and debris from installed luminaires B Touch up luminaire finish at completion of work LUMINAIRE SCHEDULE As shown and as indicated on the Drawings and as described in thes
96. CUMENTS 01720 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 C Note related record Product Data where applicable For each principal product specified indicate whether record Product Data has been submitted in maintenance manual instead of submitted as record Product Data Upon completion of markup submit record Specifications to the Architect for the Owner s records Each contractor is responsible for marking up Sections that contain its own Work a The Contractor for General Construction is responsible for collecting marked up record Sections from each of the other contractors The Contractor for General Construction is also responsible for collating these Sections in proper numeric order with its own Sections to form a complete set of record Specifications b The Contractor for General Construction is responsible for submitting the complete set of record Specifications as specified 1 5 RECORD PRODUCT DATA A During the construction period maintain one copy of each Product Data submittal for Project Record Document purposes 1 Mark Product Data to indicate the actual product installation where the installation varies substantially from that indicated in Product Data submitted Include significant changes in the product delivered to the site and changes in manufacturer s instructions and recommendations for installation Give particular attention to information on concealed products and installations that cannot be re
97. Certificate of Prompt Payment Required Bid Security in the form of a Bid Bond payable to the order of the Piedmont Triad Airport Authority 7 Qro The terms used in this Bid which are defined in the General Provisions of the Contract for Furniture Furnishings and Equipment AIA A251 included as a part of the Contract Documents have the meanings assigned to them in the General Provisions Bidder hereby acknowledges receipt of the following addenda Addendum No Date Addendum No Date Addendum No Date 00310 3 PTIA Visitor Information Booths 12 040 000 1 LUMP SUM BASE BID Proposed lump sum price for the work complete and acceptable Dollars BID FORM 00310 4 PTIA Ticket Counter Ceiling Renovation Respectfully submitted on day of 2013 Bidder Address Signed Witness Individual trading in own name Individual trading under firm name Co partners trading under firm name Corporation State of President Name Address Secretary Treasurer END OF SECTION 00310 BID FORM Corporate Seal 12 001 000 00310 5 PTIA Visitor Information Booths 12 040 000 This Affidavit is Part of Bid FORM OF NONCOLLUSION AFFIDAVIT STATE OF JSS COUNTY OF being first duly sworn deposes and says that he is Sole owner a partner president secretary etc of the party making the foregoing Proposal or BID that such BID is genuine and not collusive
98. Class R Fuses C FS W F 870 Fuseholders For Plug and Enclosed Cartridge Fuses D FS W S 865 Switch Box Enclosed Surface Mounted E NEMA KS 1 Enclosed Switches SUBMITTALS A Submit product data under provisions of Sections 01300 and 16010 B Include outline drawings with dimensions and equipment ratings for voltage capacity horsepower and short circuit PART 2 PRODUCTS 2 1 2 2 2 3 2 4 ACCEPTABLE MANUFACTURERS DISCONNECT SWITCHES A Square D Company General Electric Westinghouse B Substitutions Under provisions of Section 01600 and 16010 DISCONNECT SWITCHES A Fusible Switch Assemblies Heavy duty type NEMA KS 1 FS W S 865 quick make quick break load interrupter enclosed knife switch with externally operable handle interlocked to prevent opening front cover with switch in ON position Handle lockable in OFF position Fuse Clips FS W F 870 Designed to accommodate Class R fuses B Nonfusible Switch Assemblies NEMA KS 1 Type HD GD FS W S 865 quick make quick break load interrupter enclosed knife switch with externally operable handle interlocked to prevent opening front cover with switch in ON position Handle lockable in OFF position C Enclosures NEMA KS 1 Type as indicated on Drawings ACCEPTABLE MANUFACTURERS FUSES A Buss Fuse Company Gould Shawmut B Substitutions Under provisions of Sections 01600 and 16010 FUSES A Fuses rated 600 Amperes or less
99. Comply with manufacturer s instructions for transporting and handling insulation products B Protect products from physical damage Leave factory shipping cartons in place until installation GUARANTEE The installing Contractor shall guarantee the installation of insulating systems installed under this specification for a period of one year from acceptance of the system by the Owner against deterioration of insulating value compaction or water leakage under normal operating conditions PART 2 PRODUCTS 2 1 2 2 2 3 MOLDED GLASS FIBER INSULATION Pipes and Circular Ducts ASTM C 547 preformed glass fiber insulation Insulation shall be Class 1 or 2 rigid non combustible one piece pipe insulation with 850 F maximum service temperature nominal K value of 0 23 at 75 F mean temperature jacket permeance of 0 02 perms for ASJ facing When specified for applications requiring a vapor seal furnish insulation with ASJ and self sealing lap SSL joint on longitudinal seams Acceptable Products A C T CertaBlue Bond SSL or ASJ as specified B KF Pipe Insulation ASJ SSL or ASJ as specified C MP Micro Lok AP T Plus or AP as specified D O C Fiberglas Heavy Density Pipe Insulation ASJ SSL II or ASJ as specified FOAMED PLASTIC INSULATION Pipe Ductwork and Equipment ASTM C 534 closed cell elastomeric thermal insulation Insulation shall be Type tubular or Type II sheet water vapor permeability of maximum 0 20 perm in p
100. Contract and assembled by the Contractor and upon approval by the Owner will issue a final Certificate for Payment upon compliance with the Contract Documents SUPPLEMENTARY CONDITIONS 00800 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 4 2 10 Delete entirely and substitute the following 4 2 10 If the Owner and Architect agree the Architect will provide one or more Project Representatives to assist the Architect in carrying out his responsibilities at the site 4 2 11 Delete entirely and substitute the following 4 2 11 Claims disputes and other matters in question between the Contractor and Owner relating to the execution or progress of the Work or the interpretation of the Contract Documents shall be referred initially to the Architect for interpretation which the Architect will render in writing within a reasonable time 4 2 12 Delete entirely and substitute the following 4 2 12 Allinterpretations of the Architect shall be consistent with the intent of and reasonably inferred from the Contract Documents and will be in writing or in the form of drawings In the Architect s capacity as interpreter the Architect will endeavor to secure faithful performance by both the Owner and the Contractor will not show partiality to either and will not be liable for the result of any interpretation rendered in good faith in such capacity ARTICLE 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS 6 1 General 6 1 3 Delete en
101. Contractor Where the Specification refers to the FMS Controls Contractor it shall be understood that the FMS Controls Contractor is a subcontractor to the Mechanical Contractor Furnish and install a complete electronic Building Automation System for the HVAC system including all control accessories hardware software and devices necessary to execute the sequence of operation These Specifications together with the information shown on the Drawings define the automatic control of all equipment described under Sequence of Operation The automatic temperature control system includes but is not limited to temperature transmitters controllers automatic dampers and valves damper operators switches control panels and other accessory equipment and devices along with a complete system of control and electrical wiring to fulfill the intent of these Specifications and to provide for a complete and operable system The system shall be installed started up and serviced by factory trained mechanics and system specialists regularly employed by the manufacturer of the control equipment The system vendor shall have an operating branch office within 100 miles of the job site and shall show proof of this branch office providing engineering installation start up on going support and services for the proposed type system for the past 10 years Contractors shall note that the requirements of this section are specific and describe in detail the
102. Counter Ceilings Piedmont Triad International Airport 12 0001 000 Contractors on work awarded separately by the Owner to the end that all work is properly anchored installed and finished without hindrance or delay Care shall be taken to avoid marring surfaces of the work of other Contractors and each Contractor shall be held responsible for any damage to the work of others Repair of new work shall be made by the original Contractor at the expense of the Contractor responsible for the damage Contractor shall obtain all necessary measurements of existing conditions and work by others in order that his work shall fit properly No extra compensation will be allowed because of differences between actual dimensions and the measurements indicated on the Drawings The project will be observed by Owner s representative periodically as construction progresses The Contractor will be responsible for notifying the Owner s representative at least 48 hours in advance when any work to be covered is ready for inspection No work shall be covered or concealed until after observation has been completed on such items as piping ductwork insulation and the like 1 9 COORDINATION OF INSTALLATION OF FMS INSTRUMENTATION AND CONTROLS A The Mechanical Contractor shall coordinate with the FMS Controls Contractor and the instrumentation and controls supplier regarding proper location and installation of sensing and control devices in piping ductwork and equi
103. D FINISHING PANELS Comply with ASTM C 840 Examine panels before installation Reject panels that are wet moisture damaged and mold damaged Isolate perimeter of gypsum board applied to non load bearing partitions at structural abutments except floors Provide 1 4 to 1 2 inch wide spaces at these locations and trim edges with edge trim where edges of panels are exposed Seal joints between edges and abutting structural surfaces with acoustical sealant Install trim with back flanges intended for fasteners attach to framing with same fasteners used for panels Otherwise attach trim according to manufacturer s written instructions ae Aluminum Trim Install in locations indicated on Drawings 2 Control Joints Install control joints according to ASTM C 840 and in specific locations approved by Architect for visual effect Prefill open joints and damaged surface areas Apply joint tape over gypsum board joints except for trim products specifically indicated as not intended to receive tape Gypsum Board Finish Levels Finish panels to levels indicated below and according to ASTM C 840 T Level 1 Ceiling plenum areas concealed areas and where indicated 2 Level 4 At panel surfaces that will be exposed to view unless otherwise indicated a Primer and its application to surfaces are specified in Section 09912 Interior Painting 3 Level 5 Where indicated on Drawings a Primer and its application to surfaces are specified in
104. D MATERIALS either as sequentially applied components or as a composite system if applicable Follow manufacturer s installation guides and instructions PIPE AND EQUIPMENT INSULATION A Molded Glass Fiber Insulation Apply thickness shown in insulation schedule 1 Sectional and segmental jacketed pipe insulation shall be applied so that ends of adjacent sections are butted tightly against each other Sections of pipe furnished with all service jacket shall be securely taped in place on all longitudinal seams and circumferential joints Sections of pipe furnished with all service jacket with self sealing lap shall have the integral lap seam secured and all circumferential joints securely taped Tape shall match the pipe insulation jacket 2 Sectional and segmental unfaced pipe insulation shall be applied so that ends of adjacent sections are butted tightly against each other Sections shall be securely wired or banded in place using not less than three ties of wire or two bands every eight inches 8 on center for each 3 ft section on pipe sizes up to and including 6 size For larger pipes use two bands every eight inches 8 on center per 3 ft section Wires shall be drawn taut to embed them flush with the insulation firmly twisted excess clipped and ends bent over and fully embedded into the insulation prior to application of finish jacketing 3 Flanges Strainers Automatic and Manual Valves and Bonnets Cover with plain duct wrap of
105. EM 15060SB 4 Ticket Counter Ceilings Piedmont Triad International Airport PIPING SCHEDULE MATERIAL SYSTEM CS 1 Pressure Design 150 psig ITEM Pipe amp Pipe Nipples Fittings Flanges Unions Valves Valves Unless noted otherwise in Piping Schedule SIZES 2 1 2 amp Larger 2 1 1 2 amp Smaller 2 1 2 amp Larger 2 amp Smaller 2 1 2 amp Larger 2 amp Smaller 2 1 2 amp Larger 2 amp Smaller 12 0001 000 Temperature Design 250 F MATERIALS ANSI ASTM A 53 Grade B Seamless or ERW ANSI ASME B31 1 and ANSI B36 1 Standard Weight Carbon Steel Bevel Ends for Weld ANSI ASTM A 53 Grade B Seamless or ERW ANSI ASME B31 1 and ANSI B36 1 Standard Weight Carbon Steel Threaded amp Coupled furnished with coupling for joint Same as for 2 or ANSI ASTM A 106 Grade B Seamless ANSI ASME B31 1 and ANSI B36 1 Standard Weight Carbon Steel Threaded amp Coupled furnished with coupling for joint ANSI B16 9 and ANSI ASTM A 234 WPB Standard Weight Carbon Steel Butt Weld ANSI B16 3 and ANSI ASTM A 197 150 Ib Black Malleable Iron Screwed ANSI B16 5 and ANSI ASTM A 181 150 lb Carbon Steel Weld Neck or Slip on Raised Face Standard Flat Face where necessary to match valves or equipment Slip on not allowed at valves or equipment ANSI B16 39 and ANSI ASTM A 197 300 Ibs Black Malleable Iron Ground Joint Brass Seat Butterfly Crane
106. ERS A Allied B Triangle C Wheatland OUTLET BOXES A Sheet Metal Outlet Boxes ANSI NEMA OS 1 galvanized steel B Cast Boxes Cast malleable iron gasketed cover threaded hubs C Acceptable Manufacturers Appleton Crouse Hinds Steel City PULL AND JUNCTION BOXES A Sheet Metal Boxes ANSI NEMA OS 1 galvanized steel B Sheet Metal Boxes Larger Than 12 Inches in Any Dimension Hinged enclosure C Cast Metal Boxes for Outdoor and Wet Location Installations NEMA 250 Type 4 and Type 6 flat flanged surface mounted junction box UL listed as raintight Cast aluminum box and cover with ground flange neoprene gasket and stainless steel coverscrews D Acceptable Manufacturers Appleton Crouse Hinds Steel City PART 3 EXECUTION 3 1 CONDUIT SIZING ARRANGEMENT AND SUPPORT A Size conduit for conductor type installed 3 4 minimum size Minimum size liquidtight conduit is 3 4 Arrange conduit to maintain headroom and present a neat appearance C Route exposed conduit and conduit above accessible ceilings parallel and perpendicular to walls and adjacent piping D Maintain minimum 6 inch clearance between conduit and piping Maintain 12 inch clearance between conduit and heat sources such as flues steam pipes and heating appliances CONDUIT AND BOXES 16130 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 G H Arrange conduit supports to prevent distortion of alignme
107. F operating range 5 Markers shall be style ESPEC as manufactured by Seton or equal by listed acceptable manufacturer B Electrical Conduit Electrical conduit identification that may be installed under the mechanical contract shall comply with paragraph 2 5A above PART 3 EXECUTION 3 1 PREPARATION A Degrease and clean surfaces to receive adhesive for identification materials B Prepare surfaces in accordance with manufacturer s instructions for stencil painting C Refer to Division 9 Painting for preparation requirements of all surfaces 3 2 INSTALLATION A Pipe Installation 1 Identify all piping systems concealed and exposed with plastic pipe markers or stencil and coating Refer to piping systems specifications 15060SB for specific application requirements 2 Locate pipe markers stencils or identification tags as follows a Adjacent to each valve and fitting b At each branch and riser take off Cc At each pipe passage through walls floors or ceilings d On all straight pipe runs every 25 feet e At each passage to underground f At each item of equipment 3 Identify service flow direction and pressure of all piping systems 4 Install all identification in clear view and align for maximum visibility B Equipment Identification 1 Identify all the following equipment with screw mounted plastic nameplates MECHANICAL IDENTIFICATION 15035B 4 Ticket Counter Ceilings Piedmont Triad International Airport 1
108. FNEC straight connectors Mason Flex type MFTFU or MFTNC and control cable assemblies type ACC all as manufactured by Mason Industries Inc or equal Horizontal Pipe Isolation a The first three pipe hangers in the main lines near the mechanical equipment shall be as described in Type E When indicated or called for on the Drawings the horizontal runs in all other locations throughout the building shall be isolated by hangers as described in Type D When indicated or called for on the Drawings floor supported piping shall rest on isolators as described in Type C Heat exchangers shall be considered part of the piping run All Type E hangers or the first three Type C mounts as noted above shall have the same static deflection as specified for the mountings under the connected equipment Note If piping is connected to equipment located in basements and hangs from ceiling under occupied spaces the first three hangers shall have 0 75 deflection for pipe sizes up to and including 3 1 5 deflection for pipe sizes up to and including 6 and 2 5 deflection thereafter 15201B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 f All other hangers and mounts shall have a minimum steel spring deflection of 0 75 g Hangers shall be located as close to the overhead supports as practical 7 Duct Isolation a Discharge runs for a distance of 50 fifty feet from the air handling unit shall be
109. Factory Mutual and UL listed Hanger shall be Grinnell Figure 260 3 Type B hangers shall be standard weight carbon steel adjustable clevis type hanger with ASTM B633 SC1 or SC3 electro plated zinc finish Hanger shall be Grinnell Figure 260 Hanger Rods 1 Hanger rods shall be subjected to tension only Lateral and axial movements shall be accommodated by proper linkage in the rod assembly 2 Hanger rod diameters shall be based on MSS SP 69 Table 4 3 Type A hanger system shall shall have ASTM A 36 carbon steel rods with plain or black finish 4 Type B hanger systems shall have ASTM A 36 carbon steel rods with ASTM B633 electro plated zinc finish Beam Clamps 1 C clamps with locknuts shall be used where applicable for hanger rod sizes 3 8 SUPPORTS ANCHORS AND SEALS 15090B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 3 2 4 2 5 2 6 2 7 3 4 diameter C clamps shall be fitted with integral retaining clamps Clamp assemblies shall be carbon steel or electro plated zinc finish to comply with hanger system designation 2 Welded beam attachments shall be used for rod sizes above 3 4 diameter and shall comply with hanger system materials as noted above PROTECTION SADDLES FOR INSULATION Saddles for insulated pipes shall be prefabricated assemblies constructed of cellular glass insulation two piece 360 degree inserts with integral galvanized metal jacket 450 to 1
110. Handle carefully to avoid damage to components and painted finish Components damaged by weather construction activities or mishandling shall be replaced at the Contractor s expense PART 2 PRODUCTS 2 1 AUTOMATIC FLOW CONTROL VALVES Gray lron body factory set to maintain constant flow with 5 percent over system pressure fluctuations and equipped with a readout kit including flow meter probes hoses flow charts and carrying case Each valve shall have an identification tag attached by chain and factory marked with the AHU identification and flow rate A Brass or ferrous metal body designed for 200 psig at 250 degrees with corrosion resistant tamperproof self cleaning piston spring assembly easily removable for inspection or replacement Manufacturer Griswold Controls or Flow Design Inc AutoFlow or approved equivalent C Unit Heaters amp Fan Coils Griswold Controls Threaded Mini 2 32 psi range 7 4 ft HYDRONIC SPECIALTIES 15080B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 maximum head loss 3 4 inch body D AHU 18 amp 19 Chilled Water Valves Griswold Controls Threaded Flange 2 32 psi range 7 4 ft maximum head loss body size may exceed line size to meet the minimum head loss requirement E AHU 18 amp 19 Hot Water Valves Griswold Controls Threaded Flange 2 32 psi range 7 4 ft maximum head loss 1 1 2 inch body PART 3 EXECUTION 3 1 3 2 3 3 3 4 3 5
111. IALS AND EQUIPMENT A Contractor shall submit within twenty 20 calendar days after award of contract seven 7 copies of a complete list of all manufacturers to be used on the job No substitutions will be allowed after this date except in extenuating circumstances with approval of the Owner s representative Use of a manufacturer s name or equipment number in these Specifications or on the Drawings shall not be considered as equipment approval by the Owner s representative without confirming shop drawing submittal and approval 3 6 SHOP DRAWINGS A Contractor shall submit for approval detailed shop drawings of all equipment and materials listed in this section and in other Specification Sections No materials or equipment required to be approved shall be delivered to the job site or installed until the Contractor has in his possession the approved shop drawings for the particular material or equipment The MECHANICAL GENERAL PROVISIONS 15010B 10 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 submittals of shop drawings shall be complete as described herein Submit the number of copies required by the General and Special Conditions of the contract but in no case less than seven 7 copies B Shop drawings shall be submitted sufficiently in advance of requirements to allow the Owner s representative ample time for review and approval Submit for approval detailed dimensioned drawings or catalog cut
112. ITTALS 01300 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 A Prepare a daily construction report recording the following information concerning events at the site and have available for review by the Architect or Owner 1 List of subcontractors at the site 2 Approximate count of personnel at the site 3 High and low temperatures general weather conditions 4 Accidents and unusual events 5 Meetings and significant decisions 6 Stoppages delays shortages and losses 7 Meter readings and similar recordings 8 Emergency procedures 9 Orders and requests of governing authorities 10 Change Orders received implemented 11 Services connected disconnected 12 Equipment or system tests and startups 13 Partial Completions occupancies 14 Substantial Completions authorized 1 7 SHOP DRAWINGS A Submit newly prepared information drawn accurately to scale Highlight encircle or otherwise indicate deviations from the Contract Documents Do not reproduce Contract Documents or copy standard information as the basis of Shop Drawings Standard information prepared without specific reference to the Project is not a Shop Drawing B Shop Drawings include fabrication and installation Drawings setting diagrams schedules patterns templates and similar Drawings Include the following information Dimensions Identification of products and materials included by sheet and detail number Compliance with specifi
113. If recertification of welders is required retesting shall also be Contractor s responsibility SUPPORTS ANCHORS AND SEALS 15090B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 7 DELIVERY STORAGE AND HANDLING A Shipment and Delivery 1 Identify equipment or shipping containers with following a Item name b Item number if any C Purchase Order number d Manufacturer and model number e Destination f Owner s name g Contractor s name 2 Ship items in appropriate labeled containers and crates 3 Protect items from physical damage during shipment 4 Receive unload uncrate and inspect all items specified and required for proper execution of this portion of work 5 Upon receipt of items at project site examine surfaces for defects and damage 6 Return defective or damaged parts of supplier for repair or replacement so that schedule of this portion of work is not impaired 7 Identify all documents certifying quality and compliance with Specifications and deliver to Owner s representative B Storage 1 Store items in dry clean areas safe from damage 2 Maintain condition of all storage areas while items are stored 3 Store pipe and associated accessories off floor or off ground 4 Store small items and loose materials in clearly labeled neatly arranged bins 5 Protect ends of pipe valves and fittings from weather and abuse keep open ends sealed or covered until removed for installation
114. JECT CONDITIONS A Environmental Conditions Do not install interior metal ceilings until space is enclosed and weatherproof and until wet work in space is completed and nominally dry 1 8 EXTRA MATERIALS A Deliver extra materials to Owner Furnish extra materials matching products installed as described below packaged with protective covering for storage and identified with labels clearly describing contents A Metal Units Furnish quantity of full size units a Provide four 4 panels of each length used in project 2 Patterned Aluminum Ceiling Units Furnish quantity of full size units a Provide four 4 of each length used in project 1 9 WARRANTY A Provide written warranty against defective workmanship and materials for a period of one 1 year from date of substantial completion CUSTOM METAL CEILINGS 09514 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 PART 2 PRODUCTS 2 1 MANUFACTURERS A Manufacturer Subject to compliance with requirements provide metal ceilings of the following 1 Steel Ceilings a Gordon Inc Shreveport LA 71134 2 Patterned Aluminum Ceilings Millennium Panels a Baker Metal Products Inc Dallas TX 75229 3 Extruded Aluminum Ceilings Grid a Gordon Inc Shreveport LA 71134 The listed manufacturers shall not be construed as closing specifications to other prospective manufacturers but rather as establishing a level of quality in a metal system Other
115. NDATIONS SUPPORTS PIERS ATTACHMENTS A F Provide all hangers miscellaneous steel brackets and attachments necessary to adequately support equipment ductwork and piping installed under this Division All hangers miscellaneous steel brackets and attachments shall be connected only to the base building structure Proper expansion anchors may be used into the structural floor above Steel supports and fastening devices shall be of structural quality Steel supports shall be prime painted before installation Any primer removed or damaged during installation shall be repainted or touched up with primer after installation The Mechanical Contractor shall coordinate closely with the Plumbing Contractor Electrical Contractor and Controls Contractor to confirm quantities and sizes of all utilities scheduled or required to be supported from the pipe duct or equipment supports The Mechanical Contractor shall furnish locations spacing quantities and the like to the General Contractor for coordinating the installation with the structure Refer to pipe support details for details of the permitted attachment types to the building structure Concrete structural bases and housekeeping pads shall be installed by the Mechanical Contractor for equipment designated on the Drawings and as required for leveling and elevation Bases shall be provided where shown and as typically detailed Each base shall have a rubbed finish and have top edges and
116. NSI standards A continuous vapor retarder and a continuous insulation thickness including all joints fittings valves equipment and accessories is required and is extremely important to prevent condensation Contractor s option on insulation system Provide canvas jacket over insulation assembly in mechanical rooms all basement areas and all attic areas Refer to Specifications Provide all service jacket ASJ over insulation assembly in all areas including areas to receive canvas jacket ASJ shall be completely sealed to serve as primary vapor retarder PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM 15060SB 1 Ticket Counter Ceilings Piedmont Triad International Airport PIPE INSULATION SCHEDULE See Section 152508B Insulation System Description Pipe Size Insulation A Molded glass fiber with 1 amp Smaller 1 0 Thick 100 160 F all service jacket ASJ 1 1 4 2 1 0 Thick Continuous vapor retarder 2 1 2 4 1 5 Thick not required Provide 5 6 1 5 Thick finish jacket as scheduled 8 amp Larger 1 5 Thick B 170 220 F C 170 220 F D 35 70 F E 35 70 F F 35 70 F G 100 240 F Underground PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM Runouts less than 12 feet long to individual terminal equipment may have 0 75 thick insulation If runout is greater than 12 feet long entire length shall have 1 0 thick insulation Same as System A except thicker insulation
117. Number TO PIEDMONT TRIAD AIRPORT AUTHORITY Attn Mr J Alex Rosser P E Director of Planning and Engineering 1000 A Ted Johnson Parkway Greensboro NC 27409 The Undersigned has received and reviewed a complete set of the Bid Documents and Bidding Requirements for the Project titled PTIA Ticket Counter Ceiling Renovation PIEDMONT TRIAD INTERNATIONAL AIRPORT GREENSBORO N C 27409 Including the Addenda specified below and in submitting this Bid agree to the following 1 The undersigned hereinafter called Bidder in response to the Invitation to Bid accepting all of the terms and conditions of the Instructions to Bidders proposes and agrees if awarded the Contract to enter into an Agreement with the Owner upon notice of such award in the form of Agreement included in the Bid Documents to furnish all materials equipment machinery tools apparatus means of transportation and labor necessary to complete the work to be performed under this Contract in full and complete accordance with the shown noted described and reasonably intended requirements of the Contract Documents to the full and entire satisfaction of the Owner for the amounts contained in the Bid Schedules 2 This Bid will remain open for 90 days after the day of Bid opening If awarded a contract Bidder will sign the Agreement BID FORM 00310 1 PTIA Visitor Information Booths 12 040 000 3 In submitting this Bid Bidder represents that a Bidde
118. Provide a factory mounted toggle type electrical disconnect switch with each unit 2 Provide a factory mounted temperature controller and a thermostat with each unit Thermostat shall be unit mounted or wall mounted as scheduled 3 The thermostat shall have and LCD display a temperature adjustment for room temperature control and an occupancy override switch to initiate the unit during unoccupied times Thermostat shall be capable of a 5 degree dead band between heating and cooling as required by NC Energy Code 4 The fan speed shall be controlled by the DDC controller at the lowest speed required to provide the required to meet the heating or cooling setpoint 5 The fan shall operate continuously when set to low medium or high speed and the control valves shall be activated to provide cooling or heating 6 A high level switch shall be hard wired to disable the unit indicate an alarm disable the unit supply fan and close the chilled water control valve in the event of condensate pan high level 7 The unit controls shall be monitored and configured remotely thru the Owners facility management system This shall include at least the following Run enable for occupied and unoccupied modes Monitor room temperature Monitor unit high level condensate alarm Monitor unit cooling or heating status Configure cooling low and high setpoint limits Configure heating low and high setpoint limits Configure low room temp setpoint limit Configu
119. RK SITE Contractor shall comply with the Owner s general safety rules including insurance requirements Contractor shall instruct all of his employees and subcontractors and shall take all practicable measures to enforce compliance with all of the applicable safety and security rules and regulations in and adjacent to these areas to insure the least possible interruption of or interference with Owner s operations and work by others PROJECT SCHEDULE Contractor and subcontractors shall before submitting proposals inform themselves of the Project Schedule phase requirements and complexities associated with the construction of the work under this contract The Contractor shall assess all pertinent aspects of manpower requirements coordination supervision scheduling mobilization equipment procurement demands of construction project management and the like to assure proper planning to meet the Project Schedule COORDINATION GENERAL A Contractor shall perform only the specific work assignments set forth in the contract In all other respects the Contractor and his employees and his subcontractors shall observe the rights of the Owner to control and assign work not specifically described in this contract without interference or interruption from the Contractor or his employees or his subcontractors B Contractor shall effect cooperation between his employees and those of Owner and MECHANICAL GENERAL PROVISIONS 15010B 2 Ticket
120. Required Unsolicited Submittals The Architect will return unsolicited submittals to the sender without action PART 2 PRODUCTS Not Applicable PART 3 EXECUTION Not Applicable END OF SECTION 01300 SUBMITTALS 01300 7 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 01720 PROJECT RECORD DOCUMENTS PART 1 GENERAL 1 1 RELATED DOCUMENTS A Drawings and general provisions of the Contract including General and Supplementary Conditions and other Division 1 Specification Sections apply to this Section 1 2 SUMMARY A This Section includes administrative and procedural requirements for Project Record Documents B Project Record Documents required include the following 1 Marked up copies of Contract Drawings 2 Field records for variable and concealed conditions 3 Record information on Work that is recorded only schematically C Related Sections The following Sections contain requirements that relate to this Section 1 Division 1 Section Submittals specifies general requirements for preparing and submitting Project Record Documents 2 Divisions 2 through 16 Sections for specifying Project Record Document requirements for specific pieces of equipment or building operating systems D Single Prime Contracts The general contractor is responsible for obtaining maintaining and recording Project Record Document information for all of the subcontractors work The Contractor for General Construction is re
121. S MECHANICAL GENERAL PROVISIONS 15010B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 A Motors shall be furnished as a part of the equipment to be driven and shall meet applicable requirements of Division 16 Electrical B Enclosures shall be as scheduled on the Drawings or as required by the Equipment Specification Section If not specified otherwise enclosures shall meet code requirements and shall be appropriate for the service and location C Motors shall be sized so as not to overload or to exceed nameplate current under any conditions of operation of the driven equipment Motors shall be at least the horsepower indicated or specified D Motors for use with variable speed drives shall be selected for proper continuous duty operation within the manufacturer s rated temperature limitations at all operating speeds E Motors shall be built in accordance with the latest standards of NEMA and as specified Motors shall be tested in accordance with standards of ANSI NEMA MG1 and conform thereto for insulation resistance and dielectric strength F Each motor shall be provided with conduit terminal box and adequate starting and protective equipment as specified or required G Each motor shall be selected for quiet operation including those to be operated with variable speed drives H Each motor and or the overall piece of equipment it drives shall be UL ETL or CSA listed and so labeled 2 5 FOU
122. S AND VALVES 15060B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 11 3 12 3 13 Elbows shall be factory made long radius type Unions Install unions on each side of all threaded special valves threaded regulators and similar items on one side of each threaded check valve and at all pieces of unflanged equipment so that such equipment might be readily disconnected and removed Unions shall not be placed in a location which will be inaccessible after completion of the work E Gaskets Assemble flanges with gaskets specified in Piping Schedules at the end of this section LEAK TESTING OF PIPING SYSTEMS Perform leak tests according to the applicable paragraphs in Section 15042B Tests CLEANING OF PIPING SYSTEMS The interior surfaces of piping shall be smooth and entirely free from obstructions to flow Clean the systems before connecting to equipment or other systems Thoroughly clean all hot and chilled water piping systems using an alkaline cleaner mixed in accordance with the manufacturer s recommendations Where possible heat the cleaning solution to approximately 160 F and circulate for at least 24 hours in the system When heat cannot be applied circulate the cleaning solution for at least 48 hours Afterwards drain and flush entire system before refilling for final system start up and operation CLEANING OF DOMESTIC WATER PIPING System cleaning and sterilization of domestic water pi
123. S amp FLASHINGS A Pipe sleeves shall be provided where pipes pass through walls floors or partitions Sleeves through floors shall be Schedule 40 steel pipe set flush with bottom of slab and shall extend approximately 1 2 above the finished floor Sleeves through partitions shall be Schedule 40 steel pipe flush with both sides of walls or partitions and coated with rust inhibitive paint Sleeves passing through concrete or masonry walls shall be Schedule 40 steel pipe set flush with the wall on both sides Sleeves for insulated pipes shall be large enough to accommodate insulation and to permit expansion movement Sleeves shall be 1 larger in dimension that the outside diameter of insulation Insulation shall be continuous through sleeves Support pipe from building structure where pipe penetrates walls to prevent resting on building wall or skin Where pipes penetrate firewalls fire partitions or fire rated floors provide U L approved firestop seal between pipe and pipe sleeve in accordance with Section 15090B Supports Anchors amp Seals Pack all other spaces between sleeves and insulation or pipe with PIPE PIPE FITTINGS AND VALVES 15060B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 fiberglass to make airtight When available to meet the same objectives described above prefabricated preinsulated Pipe Shields will be acceptable for pipes passing through floors exterior walls fire w
124. Section 09912 Interior Painting Protect adjacent surfaces from drywall compound and texture finishes and promptly remove from floors and other non drywall surfaces Repair surfaces stained marred or otherwise damaged during drywall application Remove and replace panels that are wet moisture damaged and mold damaged END OF SECTION 09290 GYPSUM BOARD 09290 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 09512 ACOUSTICAL TILE CEILINGS PART 1 GENERAL 1 1 RELATED DOCUMENTS A Drawings and general provisions of the Contract including General and Supplementary Conditions and Division 1 Specification Sections apply to this Section 1 2 SUMMARY A This Section includes the following i Ceilings composed of acoustical tiles and concealed suspension systems B Related Sections The following Sections contain requirements that relate to this Section Ta Division 9 Section Linear Metal Ceilings 1 3 SUBMITTALS A General Submit each item in this Article according to the Conditions of the Contract and Division 1 Specification Sections Product data for each type of product specified Coordination drawings for reflected ceiling plans drawn accurately to scale and coordinating penetrations and ceiling mounted items Show the following 1 Ceiling suspension system members 2 Method of attaching suspension system hangers to building structure 3 Initial direct access openings 4 Ceiling mounted
125. TM A527 2 All low pressure insulated flexible ductwork shall meet the requirements of UL 181 Class 1 Air Duct NFPA 90A and 90B and the requirements of this Specification Section 1 6 PRESSURE VELOCITY CLASSIFICATION OF DUCTWORK A Classifications shall be according to Table 1 1 in the SMACNA HVAC Duct Construction Standards Metal and Flexible latest edition the accompanying information the notes and schedules on the Drawings and the following paragraphs HVAC Ductwork Where pressure classification is NOT shown or scheduled on the drawings the following shall apply 1 One inch 1 water gage pressure class a All ductwork associated with exhaust fans and downstream of VAVs 2 Two inch 2 water gage pressure class a All return duct 3 Four inch 4 water gage pressure class a All outside air intake ductwork b All return duct between shafts and AHU 4 Six inch 6 water gage pressure class a All supply duct between AHU outlet to the fire dampers located at the outlets of the three story fire rated shafts 1 7 DUCTWORK SEALING REQUIREMENTS A Sealing requirements shall be according to Table 1 2 in the SMACNA HVAC Duct Construction Standards the accompanying information and the following paragraphs Oil based caulking and glazing compounds shall not be used HVAC Ductwork 1 All ductwork of one inch 1 water gage class shall meet Seal Class C 2 All ductwork of two inch 2 water gage class
126. a copy along with the bid Material and or Manufacturer NAME OF BIDDER BY TITLE DATE BID FORM 00310 11 PTIA Visitor Information Booths 12 040 000 This Affidavit is Part of Bid CERTIFICATION REGARDING DEBARMENT SUSPENSION INELIGIBILITY AND VOLUNTARY EXCLUSION The bidder offeror certifies by submission of this proposal or acceptance of this contract that neither it nor its principals is presently debarred suspended proposed for debarment declared ineligible or voluntarily excluded from participation in this transaction by any Federal department or agency It further agrees by submitting this proposal that it will include this clause without modification in all lower tier transactions solicitations proposals contracts and subcontracts Where the bidder offer contractor or any lower tier participant is unable to certify to this statement it shall attach an explanation to this solicitation proposal NAME OF BIDDER BY TITLE DATE BID FORM 00310 12 PTIA Ticket Counter Ceiling Renovation 12 001 000 This Affidavit is Part of Bid PROMPT PAYMENT The prime contractor agrees to pay each subcontractor under this prime contract for satisfactory performance of its contract less agreed retainer no later than seven 7 calendar days from the receipt of each payment the prime contractor receives from the Owner The prime contractor agrees further to re
127. acity integrated short circuit ampere rating circuit breaker and fusible switch arrangement and sizes SPARE PARTS Keys Furnish four each to Owner PART 2 PRODUCTS 2 1 2 2 2 3 ACCEPTABLE MANUFACTURES PANELBOARDS A Square D Company General Electric Cutler Hammer Siemens B Substitutions Under provisions of Sections 01600 and 16010 DISTRIBUTION PANELBOARDS A Panelboards NEMA PB 1 circuit breaker type B Enclosure NEMA PB 1 Type 1 Cabinet size As per equipment manufacturer C Provide cabinet front with concealed trim clamps screw cover and hinged door with flush lock Finish in manufacturer s standard gray enamel D Provide panelboards with copper bus ratings as scheduled on Drawings Provide copper ground bus in all panelboards E Minimum Integrated Short Circuit Rating As shown on Drawings Full Rating Only Cascading system not acceptable F Molded Case Circuit Breakers NEMA AB 1 FS W C 375 provide circuit breakers with integral thermal and instantaneous magnetic trip in each pole Provide circuit breakers UL listed as Type HACR for air conditioning equipment branch circuits BRANCH CIRCUIT PANELBOARDS A Lighting and Appliance Branch Circuit Panelboards NEMA PB1 circuit breaker type FS PANELBOARDS 16440 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 W P 115 Type l Class 1 Enclosure NEMA PB 1 Type 1 Provide flush or surface cabinet f
128. acket in place with three 3 stainless steel bands per section of metal jacketing Use all aluminum pop rivets on fitting covers where recommended by manufacturer 3 13 INSULATION SCHEDULE See Also Drawings A General Specific details and notes in this schedule shall take precedence over other paragraphs of this specification Section 15250B For example if the product specification in Part 2 above calls for 1 5 pounds per cubic foot minimum density and this schedule calls for 3 0 pounds per cubic foot PCF then the scheduled 3 0 PCF applies to this job B Piping Piping insulation shall be as scheduled in Section 15060SB Pipe Piping Schedule Materials and Insulation END OF SECTION 15250B INSULATION 15250B 13 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15767B FAN COIL UNITS PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 REFERENCES A B C D ARI 440 Standard for Room Fan Coil Units NFPA 90A Installation of Air Conditioning and Ventilation Systems SMACNA HVAC Duct Construction Standards ARI 350 Standard for Acoustical Testing 1 3 QUALITY ASSURANCE A C D The unit manufacturer shall be regularly engaged in production of components and shall have published complete catalog data on total product offering Units shall have certified capacity static pressure fan speed brake horsepower and sele
129. ad and rated voltage when tested in accordance with ANSI IEEE 112 Nominal Power Factor Meet values in Schedules at full load and rated voltage within 5 5 percent when tested in accordance with ANSI IEEE 112 PART 3 EXECUTION 3 1 APPLICATION A D E MOTORS Motors drawing less than 250 Watts and intended for intermittent service may be proprietary to equipment manufacturer and need not conform to these Specifications Motors shall be open drip proof type except where specifically noted otherwise Motors shall meet the requirements of paragraph 401 2 of the North Carolina State Building Code Volume X Energy Single phase motors for shaft mounted fans or blowers shall be permanent split capacitor type Motors located in exterior locations shall be totally enclosed type 15045B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 Unless specifically scheduled otherwise motors 3 0 horsepower and larger shall be premium energy efficient type and shall have minimum efficiencies in accordance with the following tables 2 Pole 87 5 88 5 90 2 90 2 91 7 92 4 93 0 93 6 94 1 94 5 94 5 94 5 95 0 95 4 95 4 ODP Enclosure 4 Pole 87 5 88 5 89 5 90 2 91 7 92 4 93 0 93 0 94 1 94 1 95 0 95 0 95 4 95 4 95 8 95 8 6 Pole 89 5 89 5 90 2 91 0 91 0 91 7 92 4 93 0 93 6 93 6 94 5 95 0 95 0 95 0 95 4 95 4 3 2 NEMA OPEN MOTOR SERVICE FACTORS
130. adequate curing time for all sealants and mastics prior to covering with insulation finish systems ra Inspect all insulation and accessory materials to be certain that the installation is in conformance with the manufacturer s recommendations and the requirements of referenced ASTM standards and this Specification Section All joints shall be tight with complete sealing for vapor barrier Exterior finish shall be uniform free of defects and installed in a neat workmanlike manner E Polystyrene Insulation Chilled Water Systems Apply thickness and density shown in insulation schedule 1 Apply single layer half sections of insulation to pipe and fittings with ends of adjacent sections butted tightly against each other Sections of pipe insulation furnished with all service jacket shall be securely taped in place on all longitudinal seams and circumferential joints Sections of pipe furnished with all service jacket with self sealing lap shall have the integral lap seam secured and all circumferential joints securely taped Tape shall match the pipe insulation jacket 2 Saddles for insulated chilled water pipes shall be in accordance with the requirements of Section 15090B Supports Anchors and Seals 3 Cover fittings standard or Victaulic type with one piece PVC pre molded fitting covers stapled or tacked in place Apply over proper shape factory precut insulation blanket Before applying fitting cover on piping requiring a vapor barri
131. adily identified and recorded later Note related Change Orders and markup of record Drawings where applicable Upon completion of markup submit a complete set of record Product Data to the Architect for the Owner s records Where record Product Data is required as part of maintenance manuals submit marked up Product Data as an insert in the manual instead of submittal as record Product Data Each prime contractor is responsible for marking up and submitting record Product Data for its own Work 1 6 MAINTENANCE MANUAL SUBMITTAL A When each construction activity that requires submittal of maintenance manuals is nominally complete but before Substantial Completion submit maintenance manuals specified 1 2 Organize operation and maintenance manuals into suitable sets of manageable size Bind data into individual binders for each manual properly identified on front and spine For large manuals provide an index sheet and thumb tabs for separate information categories Provide heavy duty 3 ring vinyl covered binders 1 to 2 inch 25 to 50 mm thick as required to contain information sized for 8 1 2 by 11 inch 215 by 280 mm paper with inside pockets or pocket folders for folded sheets In each maintenance manual include information specified in individual Specification Sections and the following Emergency instructions Spare parts list Copies of specific warranties Wiring diagrams Recommended maintenance procedures and
132. alant is specified on equipment tanks piping fittings valves flanges ductwork joints lap edges and the like Moisture and vapor barrier joint sealant and bedding compound for rigid insulation service temperature of 20 to 200 F maximum 0 01 perm inch water vapor transmission Foster 30 46 PC Pittcote 300 or insulation manufacturer s recommended sealant Reinforcing Mesh for Sealants For all sealants specified or recommended by the manufacturer to be applied with a reinforcing mesh High strength open weave pre sized and resin treated fiberglass cloth minimum 6x6 mesh 6 strands by 6 strands per square inch conforming to ASTM D 1688 Type Ill non combustible flexible not subject to rot mildew or decay Childers Chil Glas 5 or 10 or equal Vimasco Elastafab 894 constructed of modacrylic fibers or equal is also acceptable Cements for Pipe and Equipment ASTM C 449 blended mineral fibers and inorganic refractory materials hydraulic setting binder thermal insulating and finishing cement for applications to 1200 F Product shall be trowelable over surfaces valves flanges and irregular surfaces and be non cracking and exhibit low shrinkage High temperature insulating cement shall be Pabco Pabcote One Coat Insulating Cement Fibrex Superkote Cement or equal by Power House Sealants Miscellaneous Joints ASTM C 920 Type S NS Class 25 construction sealant shall be non toxic weatherproof silicone sealant suitable for use
133. all authorities having jurisdiction and deliver these to the Owner s representative before request for acceptance and final payment of the work C The Contractor shall include in his work without extra cost to the Owner any labor materials service apparatus drawings and the like required in order to comply with all applicable laws ordinances rules and regulations whether or not shown on Drawings and or specified D All materials furnished and all work installed shall comply with the National Fire Codes of the National Fire Protection Association and with the requirements of all governmental departments having jurisdiction E All materials and equipment for the electrical portion of systems shall bear the U L label and shall be listed by the Underwriters Laboratories Inc F All materials and equipment furnished under this Division shall be asbestos free 1 3 REFERENCES MECHANICAL GENERAL PROVISIONS A Air Conditioning and Refrigeration Institute ARI B American National Standards Institute ANSI C Air Moving and Conditioning Association AMCA D American Gas Association AGA E American Society for Testing and Materials ASTM F American Society of Heating Refrigeration amp Air Conditioning Engineers ASHRAE G American Society of Mechanical Engineers ASME H American Welding Society AWS l Anti Friction Bearing Manufacturers Association AFBMA J Commercial Standards CS K Factory Mutual Corporation FM L Institute
134. all be UL listed and NFPA 90A approved Flexible Connections Smaller than 8 feet total duct perimeter 1 Connections shall be made with Duro Dyne Type Metal Fab fabric or equal 2 Fabric shall be 3 wide Neoprene type by Duro Dyne Fabric shall be of durable construction consisting of a heavy glass fabric double coated with Neoprene Weight of fabric shall be approximately 30 oz per sq yd Outdoor installations shall be Durolon type by Duro Dyne as specified above 3 Integral metal connector pieces shall be nominal 3 wide 24 gauge metal Grip Loc seam or equal 4 Fabric and fabric assembly shall be UL listed and NFPA 90A approved 2 18 SPLITTER BUTTERFLY AND MULTI BLADE DAMPERS shall be in accordance with SMACNA duct construction standards for the specified pressure velocity classifications 2 19 DUCT SLEEVES through floors shall be at least 14 gage galvanized steel 2 20 FIRE DAMPERS shall be as follows A DUCTWORK Duct mounted dampers shall be dynamic factory built curtain type with blades out of airstream Type B Dampers shall have a minimum 1 1 2 hour fire protection rating and shall include a U L label in accordance with UL555 standard Dampers shall have a dynamic label that shall illustrate maximum allowed CFM at 8 static pressure for in duct mounting and maximum allowed CFM at 4 static pressure for non ducted in wall mounting Dampers shall have vertical and horizontal closure spring operation fo
135. all be by factory trained engineers and technicians directly employed by the FMS Controls Contractor INSTRUCTIONS AND MANUALS A Upon completion of the project the Controls Contractor shall have completely adjusted and calibrated the entire control system to operate as described in this section of the Specifications before beginning Demonstration and Training B Demonstration and Training Provide the services of a factory authorized service representative for a minimum of 12 hours to demonstrate and train Owner s maintenance personnel as specified below The Owner reserves the right to replace any instructor who in their opinion does not demonstrate sufficient qualifications 1 Train Owner s maintenance personnel on procedures and schedules related to startup and shutdown troubleshooting servicing and preventive maintenance 2 Schedule training with Owner with at least 7 days notice 3 Provide operator training on data display alarm and status descriptors requesting data execution of commands and request of logs and turn over to the owner all LonWorks and Lon Mark address and binding codes C The Contractor shall obtain from the Owner a signed receipt that Owner s personnel have received complete instruction on the operation of the system D Manuals The Contractor shall submit to the Owner s representative four 4 sets of as built drawings and operating and maintenance manuals to be approved and delivered to the Owne
136. all include the cost of furnishing the more expensive item or installation and the greater quantity INSTRUCTIONS TO BIDDERS 00100 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 21 22 23 24 25 The bid documents are not to be scaled or used to determine any quantities Contractor is responsible for providing protection of all existing finishes equipment and anything that is within the project scope area All work can be done between the hours of 8 00 p m and 4 00 a m Contractor is responsible to repair any and all damage that is done by the contractor or their subs during construction Inquiries All inquiries in regard to the Contract Documents during the bid period shall be directed to Lindsey Architecture p c 125 S Elm Street Suite 300 Greensboro North Carolina 27401 336 617 4402 336 617 4434 fax Attention Rod Lindsey AIA Re PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport END OF SECTION 00100 INSTRUCTIONS TO BIDDERS 00100 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 00310 BID FORM FOR GENERAL CONSTRUCTION TO BE SUBMITTED IN DUPLICATE FOR GENERAL CONSTRUCTION WORK PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport Greensboro North Carolina 27409 PIEDMONT TRIAD AIRPORT AUTHORITY AEP File No 12 001 000 Date of Bid Name of Bidder Address City State and Zip Code Phone
137. alls and fire resistive walls and partitions 3 6 WELDED JOINTS A K L Welded joints between sections of pipe and between pipe and fittings shall be in strict compliance with ANSI B31 1 Chapter 5 Section 127 Each welded joint shall be stamped with the individual welder s identification number See Quality Assurance in Part 1 of this section Make joints in piping for all services tight and leakproof against the design pressure Peening of welded joints to correct leaks will not be permitted Carbon steel pipe welding shall be done by the manual metal arc process using coated electrodes or gas arc GMAW process All socket welds shall be made by manual metal arc processes Heat Treatment of Welds No preheating of carbon steel piping is required except no welding shall be performed on metal colder than 32 F Welding shall penetrate the full wall thickness of the pipe Slag shall be cleaned from each weld layer and any serious defects removed before the next layer is applied The completed weld shall be cleaned of slag Preparatory to final welding the proper gap shall be maintained while tack welding the pipe and connections in position so that a proper gap is made for a full penetration weld Tack welds shall be of the same quality and made by the same process as the rest of the weld or they shall be removed prior to completion of the weld Small sound tack welds which penetrate to the bottom of the welding grove m
138. als or equipment which have not been delivered and stored at the site 5 2 FINAL PAYMENT 5 2 1 Final payment constituting the entire unpaid balance of the Contract Sum shall be made by the Owner to the Contractor when 1 the Contractor has fully performed the Contract except for the Contractor s responsibility to correct Work as provided in Section 12 2 2 of AIA Document A201 2007 and to satisfy other requirements if any which extend beyond final payment and 2 afinal Certificate for Payment has been issued by the Architect 5 2 2 The Owner s final payment to the Contractor shall be made no later than 30 days after the issuance of the Architect s final Certificate for Payment or as follows thirty 30 days after the final payment is reviewed by the Airport Authority Board AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 116
139. als shall be made by bidding Contractors and Subcontractors and not by material and equipment suppliers Requests for substitutions will be considered by the Owner s representative until ten 10 calendar days prior to bid date per the following guidelines 1 Substitutions offered shall be supported by submittal of complete data 2 Substitution submittal shall include manufacturer s data test reports performance data and certifications dimensions drawings samples and other information as required to permit determination by the Owner s representative whether the offered substitute is equal to the specified standard 3 Owner s representative shall be the judge of the acceptability of the proposed substitution 4 The Owner s representative will review requests for substitutions and notify Contractor in writing of the decision to accept or reject the requested substitutions C Contractor s Representation A request for a substitution constitutes a representation that Contractor 1 Has investigated the proposed product and determined that it is equal to or superior in all respect to that specified 2 Has compared dimensions of the proposed product to the specified product and has determined that the proposed product will fit properly in the available space with adequate clearances for safety and maintenance MECHANICAL GENERAL PROVISIONS 15010B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 W
140. alvanized steel strikes Doors shall be internally lined with 1 thick fiberglass inside a double panel construction Gaskets shall be PVC foam type or neoprene and comply with the requirements of NFPA 90A for flame spread and smoke developed ratings If space does not permit door opening removable door models may be used Access doors for round ductwork shall be of the rolled hinge plate design shaped to match the contour of the duct or bolted access door design with integral hand operated knobs to create a compression fit with the duct wall Bolted type round duct access doors shall be Sandwich type by Ductmate Industries or equal and shall comply with the requirements of the general paragraphs above relating to access door construction Rectangular access doors for rectangular ductwork shall be Cesco Model HAD or CAD or approved equal by National Controlled Air Louvers amp Dampers Inc Safe Air and Ruskin Round access doors for rectangular ductwork shall be Flexmaster Inspector Series access doors or approved equal by National Controlled Air Louvers amp Dampers Inc Safe Air and Ruskin 2 23 INSULATED FLEXIBLE DUCTWORK A DUCTWORK Low pressure flexible duct shall be a factory fabricated assembly of a trilaminate of aluminum foil fiberglass and polyester with a perm rating of 0 02 high tear strength and properties to resist temperature change mildew and age hardening The liner shall be mechanically locked
141. and to protect the work work by others and areas accepted for substantial completion from construction operations DRAWINGS AND SPECIFICATIONS A Contractor is cautioned to read the entire Contract Specifications and the entire set of Contract Drawings to assure that no reference to work by the Contractor is overlooked and to assure an understanding of the division of work between the various trades and or contracts Failure of the Contractor to do this shall not relieve him of any responsibility or remove any work from the contract The general arrangement of ductwork piping and equipment shall be as shown on the Drawings Detailed drawings of proposed departures due to actual field conditions or other causes shall be submitted to the Owner s representative for approval and any such changes shall be made without additional cost to the Owner The Contractor shall examine carefully all Contract Documents and shall be responsible for the proper fitting of materials and equipment in each location as indicated without substantial alteration The Drawings are generally diagrammatic It is not possible to indicate all off sets fittings and accessories which may be required The Contractor shall investigate all potential obstructions carefully plan ahead and provide at no additional cost to the Owner such fittings valves transitions and accessories as may be required to meet such conditions Shop drawing plans and sections shall be submit
142. and outputs a Analog inputs shall monitor the following analog signals 1 0 10 VDC Sensors 2 10000hm RTDs b Binary inputs shall monitor dry contact closures Input shall provide filtering to eliminate false signals resulting from input bouncing Counter inputs shall monitor dry contact pulses with an input resolution of one HZ minimum d Analog outputs shall provide the following control outputs 1 0 10 VDC e Binary outputs shall provide SPDT output contacts rated for 2 amps at 24 VAC Surge and noise suppression shall be provided on all pilot relays Inductive loads i e solenoids shall be controlled by pilot relays f TriState outputs shall be paired binary outputs for use as Power Close Power Open control output contacts rated for 2 amps at 24 VAC Surge and noise suppression shall be provided on all pilot relays 4 VAV Controllers shall have a library of control routines and program logic to perform the sequence of operations specified in the Execution portion of this Specification 5 VAV Controllers shall directly support the temporary use of a portable service terminal that can be connected to the VAV via zone temperature or directly at the controller 6 Powerfail Protection All system setpoints proportional bands control algorithms and any other programmable parameters shall be stored such that a power failure of any duration does not necessitate reprogramming the VAV 2 3 INPUT DEVICES
143. and similar items Vapor seal these items by embedding reinforcing mesh fiber glass fabric between two 1 16 thick coats of adhesive Lap seal fabric 1 to 2 Inches on itself and 2 inches on adjoining insulation FIRE RETARDANT VAPOR RETARDER JACKETS FOR DUCTWORK AND EQUIPMENT A Apply Foil Scrim Kraft with adhesive over glass fiber insulation unless Foil Scrim Kraft is furnished integrally with the flexible or rigid insulation Apply fire resistive adhesive sealant to full surface of laps and secure them with staples applied 6 o c Vapor seal all lap edges jacket breaks penetrations and staples with matching foil reinforced Kraft tape 3 wide with integral or field applied full coverage coating of fire resistive adhesive Lap tape not less than 1 inch on itself and adjacent insulation Finish shall be wrinkle free Cover breaks and penetrations with 3 inch width strip of glass fabric embedded between two 1 16 coats of vapor retarder sealant lapping fabric not less than one inch on adjacent insulation B Apply flashing on pipe ductwork and equipment for a complete moisture and vapor seal at all metal to insulation joints exposed edges of insulation and other protrusions through jackets Apply a continuous bead or fillet of flashing compound to completely seal the joint Extend a 1 16 film of flashing compound over adjacent insulation and metal surfaces at least 3 Embed glass fabric into the wet coating over entire surface smoothing out all
144. anometer 0 1 inclined Shortridge or Alnor balancing cones Aspirating smoke generator Pressure fan for leak testing Superior Smoke bombs 3 RPM Stroboscope Digital 1 RPM accuracy Digital tachometer 1 RPM accuracy 4 Water 30 Hg to 60 psi pressure gauge 1 2 accuracy 0 to 200 psi pressure gauge 1 2 accuracy 0 to 36 Hg manometer 0 200 digital differential pressure meter 5 Temperature Digital thermometer 1 10 resolution 1 accuracy Surface and immersion probes for thermometer Wet bulb wicks and fans 6 Thermometer 30 to 120 0 2 16 mercury 7 Air Quality CO analyzer All meters shall be checked and calibrated with primary instruments prior to beginning any tests on this project Voltmeters and other instruments that cannot be checked shall be laboratory calibrated at reasonable intervals of not more than one year Magnehelic or dial type differential pressure gauges may be used only for preliminary or non certified work within their ranges after calibration using fluid filled manometers PART 2 PRODUCTS Not Applicable PART 3 EXECUTION 3 1 TESTS PIPING TESTS Start up and Placing in Service A Test all new water piping systems with a hydrostatic pressure test at 150 psig or 1 1 2 times 15042B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 2 3 3 TESTS operating pressure whichever is greater measured at the lowest point in the system for
145. ant on back of vertical leg before fastening to vertical surface Locate so that sealant will be concealed after installation 2 Secure moldings to building construction by fastening through holes drilled in vertical leg Space holes not more than 3 inches from each end and not more than 16 inches o c Draw up fasteners for tight set against vertical surfaces 3 Miter corners of moldings accurately to provide hairline joints CUSTOM METAL CEILINGS 09514 6 PTIA Ticket Counter Ceiling Renovation 12 001 000 4 Level moldings with ceiling suspension system to level tolerance of 1 8 inch in 12 0 5 Use only items that have been finished in accordance with the finishes article or this specification section Scribe and cut metal acoustical units for accurate fit at borders and at interruptions and penetrations by other work through ceilings Stiffen edges of cut units as required to eliminate evidence of buckling or variations in flatness exceeding referenced standards for stretcher leveled metal sheet F Install metal units in coordination with suspension system and exposed moldings 1 Align joints in adjacent courses to form uniform straight joints parallel to room axis in both directions unless otherwise shown 2 Fit adjoining units to form flush tight joints Scribe and cut units for accurate fit at borders and around construction penetrating ceiling 3 Install directionally patterned or textured panels in directions indicated
146. ant release wing nut ACCESS DOOR LATCH shall be Ventfabrics Inc No 260 Ventlock or equal latch for doors large enough to enter only QUADRANTS CONTROLS INDICATING INSTRUMENTS and similar equipment shall be provided with extensions and or brackets for mounting on the surface of the insulation of externally DUCTWORK 15840B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 insulated ducts 2 16 SUPPORT AND BRACING MATERIAL for galvanized ductwork shall be galvanized steel Dielectrically isolate galvanized steel supports from aluminum duct with two coats of zinc chromate paint or bitumastic paint 2 17 FLEXIBLE CONNECTIONS A Large Flexible Connections Greater than or equal to 8 feet total duct perimeter 1 Connections shall be made with Duro Dyne Type Super Metal Fab wide span fabric or equal 2 Indoor installation fabric shall be 6 wide Excelon type by Duro Dyne Fabric shall be of tear resistant construction with a no tear nylon base cloth Weight of fabric shall be approximately 22 oz per sq yd 3 Outdoor installation fabric shall be 6 wide Durolon type by Duro Dyne Fabric shall be flame proof ozone resistant heavy glass fabric having excellent weathering and abrasion qualities Weight of fabric shall be approximately 24 oz per sq yd 4 Integral metal connector pieces shall be nominal 3 wide 24 gauge metal Grip Loc seam or equal 5 Fabric and fabric assembly sh
147. antee it is understood that this requirement is included in the purchase price of the equipment and components furnished under this Specification 1 5 QUALITY CONTROL A Products furnished under this Specification shall be provided by the same manufacturer for each specific application Vibration isolators furnished shall be specifically approved by the manufacturer for use in the intended application VIBRATION ISOLATION 15201B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 6 SHOP DRAWINGS A Shop Drawings shall include but not be limited to the following 1 Overall arrangement dimensions and weight loading of equipment and isolator loading for each isolator 2 Rated static deflection spring diameters free height compressed spring height solid spring height limit stops clearances and the like 3 Dimensional and weight data for concrete inertia bases steel and rail bases and details of isolator attachment 4 Indication of use and to which equipment item the product will be installed 5 Vibration isolators shall be submitted along with the corresponding equipment shop drawings to verify compliance with Specifications for proper application of the isolators Lump submittals of vibration isolators may need to be held for review in conjunction with the equipment to which the isolator is intended to be applied B Submittal shall be clearly tabulated by unit or fan or pump num
148. anufactured by Thunderline Corporation or equal by MetraSeal MISCELLANEOUS SUPPORT MATERIALS A Rolled Steel Plates Shapes and Bars ASTM A36 B Cold Formed Steel Tubing ASTM A500 Grade B Fy 46 ksi C Steel Pipe ASTM A53 Type E Non Tested Grade B Fy 35 ksi D Anchor Bolts ASTM A36 E High Strength Threaded Fasteners Heavy hexagon bolts nuts and hardened washers complying with ASTM A325 F Electrodes for Welding Comply with AWS Code ASTM A233 E70 Series electrodes SHOP COATING SYSTEMS A Shop Primer Standard shop primer equal to Steel Structures Painting Council SSPC Specification No 13 Total dry film thickness shall be not less than 2 5 mils Verify compatibility of primer with specified finish paint All miscellaneous steel supports provided for equipment piping and accessories furnished under Division 15B Specifications shall be fully coated with approved shop primer paint Uncoated bare steel supports will not be accepted B Electro Plated Galvanized ASTM B633 SC1 or SC3 coating of zinc on steel by electrolysis from a bath of zinc salts This coating is pure zinc and adheres to the steel with a molecular bond PART 3 EXECUTION 3 1 SUPPORT SPACING Space supports or hangers for horizontal standard weight carbon steel piping as follows This spacing does not apply where there are concentrated loads between supports such as valves or specialties Refer to appropriate tables in MSS SP 69 for reco
149. art hereof In case of dispute the Architect will identify the various sheets comprising the Drawings 1 1 9 Provide The term provide shall mean to furnish or install the work or item complete unless otherwise defined 1 1 10 Sponsor The word sponsor shall mean the Owner Piedmont Triad Airport Authority 1 2 Correlation and Intent of the Contract Documents Add the following 1 2 4 Reference to the standard specifications manuals or codes of any technical society organization or association or to the code of any government authority whether such reference be specific or by implication shall mean the latest standard specification manual or code in effect at the time of opening of Bids or on the effective date of the Agreement if there were no Bids except as may be otherwise specifically stated However no provision of any referenced standard specification manual or code whether or not specifically incorporated by reference in the Contract Documents shall change the duties and responsibilities of the Owner the Contractor or the Architect or any of their SUPPLEMENTARY CONDITIONS 00800 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 agents or employees from those set forth in the Contract Documents Clarifications and interpretations of the Contract Documents shall be issued by the Architect as provided in Section ARTICLE 2 OWNER 2 1 General 2 1 2 Delete entirely 2 2 Information and Services Re
150. as described in Type D Isolation but they shall be precompressed to the rated deflection so as to keep the piping or equipment at a fixed elevation during installation b The hangers shall be designed with a release mechanism to free the spring after the installation is complete and the hanger is subjected to its full load amp Deflection shall be clearly indicated by means of a scale d Submittals shall include a scale drawing of the hanger showing the 30 capability e Hangers shall be type PC30N as manufactured by Mason Industries Inc or equal Type F Isolation Duct Isolation Hanger a Vibration hangers shall contain a steel spring located in a neoprene cup manufactured with a grommet to prevent short circuiting of the hanger rod b The cup shall contain a steel washer designed to properly distribute the load on the neoprene and prevent its extrusion C Spring diameters and hanger box lower hole sizes shall be large enough to permit the hanger rod to swing through a 30 arc before contacting the hole and short circuiting the spring d Springs shall have a minimum additional travel to solid equal to 50 of the rated deflection e Hangers shall be provided with an eye bolt on the spring end and provision to attach the housing to the flat iron duct straps f Submittals shall include a scale drawing of the hanger showing the 30 15201B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 00
151. ata for firms and persons specified in Quality Assurance Article to demonstrate their capabilities and experience The installer must submit a written certification by the system manufacturer Include list of completed projects with project names addresses names of Architects and Owners plus other information specified 1 5 QUALITY ASSURANCE A Installer Qualifications Engage an experienced Installer who is certified in writing by the system manufacturer Complete custom metal ceiling system to be installed by one installer Single Source Responsibility The installer is to be the single source for complete system Obtain each type of metal ceiling system with resources to provide coordination of and provide products of consistent quality in appearance and physical properties without delaying progress of the Work Coordination of Work Coordinate layout and installation of acoustical ceiling units and suspension system components with other work supported by or penetrating through ceilings including light fixtures and HVAC equipment Preinstallation Conference Conduct conference at Project site to comply with specification requirements 1 6 DELIVERY STORAGE AND HANDLING A Deliver metal units to Project site in manufacturer s original unopened packages fully identified with type finish performance data and compliance labels Handle and store in compliance with manufacturer s instructions and recommendations 1 7 PRO
152. ay become a part of the finished weld Tack welds lacking penetration are not acceptable and must be removed Large tack welds which almost fill the welding groove are not acceptable and must be removed Branch connection joints shall be prepared so as to permit full penetration welds of a quality comparable to the circumferential welds in the same piping system Permanently welded in back up strips shall not be used 3 7 SOLDERED JOINTS A The procedure outlined in ASTM B 828 Standard Practice for Making Capillary Joints by Soldering of Copper and Copper Alloy Tube and Fittings shall be followed in making all soldered or brazed joints The flux used during the soldering or brazing procedure shall meet the requirements of ASTM B 813 Standard Specification for Liquid Paste Fluxes for Soldering Applications of Copper and Copper Alloy Tube No solder or brazing materials shall be present on the job site other than those which are specified in Section 15060SB Using an oxy acetylene torch apply heat to the joint being brazed Minimum 15 silver brazing alloy shall be used when making copper to copper joints After brazing allow the completed joint to cool naturally in accordance with the ASTM B 828 procedure Shock cooling the joint with water is prohibited When cool clean off any remaining flux residue with a wet rag PIPE PIPE FITTINGS AND VALVES 15060B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0
153. b superintendent on this project The superintendent shall not be responsible for duties or projects other than those required to complete the scope of work required on the construction documents Safety The Contractor shall be responsible for initiating maintaining and supervising all safety measures and precautions and programs in connection with the work as required to meet all the safety standards of the governing agencies ELECTRICAL GENERAL REQUIREMENTS 16010 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 4 CONTRACT DOCUMENTS A The Contract Drawings and Specifications are intended to depict the scope of work required However the drawings are schematic and diagrammatic and do not depict every item of material and equipment required to accomplish the work B Contractor shall maintain on the job site one complete set of contract documents of all trades and shall coordinate with other trades so as to avoid conflicts C Indicated locations of equipment boxes etc are approximate and shall be verified by the Contractor and shall be coordinated with the Owner s representative 1 5 RECORD DRAWINGS Contractor shall prepare drawings showing proposed rearrangement of work to meet job conditions including changes to work specified under other sections Obtain permission of Owner before proceeding 1 6 REFERENCES A ANSI IEEE C2 National Electrical Safety Code B ANSI NFPA 70 National Electri
154. be factory furnished or field applied ACCEPTABLE MANUFACTURERS shall be the following referred to hereafter by abbreviation INSULATION 15250B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 A INSULATION Insulation Glass Fiber Blanket Molded Pipe and Board Type 1 Certain Teed Corporation Insulation Group C T 2 Knauf Fiberglass KF 3 Manville Product MP 4 Owens Corning O C Insulation Foamed Plastic Types 1 Armstrong World Industries AWI Armstrong 2 Rubatex Insulation Calcium Silicate Types 1 MP 2 O C 3 Pabco Insulation Division 4 Calsilite Insulation Products Insulation Cellular Glass Types 1 Pittsburg Corning PC Insulation Polystyrene Type 1 Dow Corning DC 2 Accessible Products Company APC Vapor Barrier Jackets Factory Applied IRN z U Metal Jackets Aluminum and Stainless Steel 1 Childers Products Co 2 Pabco Insulation Division 3 RPR Products Inc Mastics Adhesives Sealants Coatings AWI Foster Products KF C T MP O C PC Rubatex Childers Products 0 VIMASCO 1 Mon Eco TSO PNOORON 1 3M Corporation 2 Hardcast Inc 3 Ideal Tape Co 4 Morgan Adhesives Co 5 Nashua Tape Products 6 Shurtape Shurford Mills Tape Division 7 Compac Corporation 15250B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 J Insulated Fitting Covers
155. below Automatic control and smoke dampers shall be furnished and installed by the Mechanical Contractor or his Sheet Metal Subcontractor under this Contractor s supervision It shall be the responsibility of the Mechanical Contractor or his Sheet Metal Contractor to see that the dampers are correctly installed so that they operate freely and close tightly It shall be the responsibility of the Mechanical Contractor or his Sheet Metal Contractor to provide and install transitions when the control application requires dampers smaller than duct size It shall be the responsibility of the Mechanical Contractor or his Sheet Metal Contractor to provide and install oval to rectangular transitions when the control application requires dampers in oval or round duct Smoke detectors shall be furnished by the Electrical Contractor installed by the Mechanical Contractor and wired by the Electrical Contractor VAV Terminal Units The FMS Controls Contractor shall furnish and install the space sensor The FMS Controls Contractor shall connect all control devices to the individual VAV controllers All finish painting required for building management and control equipment shall be done by the Controls Contractor All cutting and patching necessary for the installation of the Building Management and Control System shall be done by the Controls Contractor See Section 15010B for detailed requirements for cutting and patching Refer to Section 15010B for c
156. ber indicating isolator type model number number required and isolator loading SHIPPING TAGS Each vibration isolator shall be tagged at the factory with its specific location on the job including equipment designation which corresponds to the application Where required isolators shall be identified to correspond to the specific corner load point of the scheduled equipment SUBSTITUTIONS Refer to Section 15010B for specific requirements concerning substitutions and product options Substitutions shall require written approval from the Owner s representative and shall be submitted by the Contractor as soon after contract awards as possible and before any materials are ordered Substitute products that are submitted as a shop drawing without prior written request for offering as a substitute product may at the Engineer s discretion be returned or rejected by the Engineer PART 2 PRODUCTS 2 1 GENERAL A This Specification pertains to the furnishing and installation of vibration isolation devices for rotating or reciprocating mechanical equipment and piping systems attached thereto B This work shall include all material and labor required for installation of the resilient mounting and suspension systems adjusting each mounting system and measurement of isolator system performance Specific mounting arrangement for each item of equipment shall be as described herein and as indicated by schedules and details on the Drawings C
157. black line prints of each drawing whether or not changes and additional information were recorded Organize the copies into manageable sets Bind each set with durable paper cover sheets Include appropriate identification including titles dates and other information on the cover sheets 1 Organize and bind original marked up set of prints that were maintained during the construction period in the same manner and submit to Architect RECORD SPECIFICATIONS During the construction period maintain 3 copies of the Project Specifications including addenda and modifications issued for Project Record Document purposes 1 Mark the Specifications to indicate the actual installation where the installation varies from that indicated in Specifications and modifications issued Note related project record drawing information where applicable Give particular attention to substitutions selection of product options and information on concealed installations that would be difficult to identify or measure and record later a In each Specification Section where products materials or units of equipment are specified or scheduled mark the copy with the proprietary name and model number of the product furnished b Record the name of the manufacturer supplier installer and other information necessary to provide a record of selections made and to document coordination with record Product Data submittals and maintenance manuals PROJECT RECORD DO
158. by change order or Construction Change Directive Changes made following the Architect s written orders Details not on original Contract Drawings Faro ao 2 Mark record prints of Contract Drawings or Shop Drawings whichever is most capable of showing actual physical conditions completely and accurately Where Shop Drawings are marked show cross reference on Contract Drawings location 3 Mark record sets with red erasable colored pencil Use other colors to distinguish between changes for different categories of the Work at the same location 4 Mark important additional information that was either shown schematically or omitted from original Drawings 5 Note Construction Change Directive numbers alternate numbers change order numbers and similar identification Responsibility for Markup The individual or entity who obtained record data whether the individual or entity is the Installer subcontractor or similar entity shall prepare the markup on record drawings 1 Accurately record information in an understandable drawing technique 2 Record data as soon as possible after obtaining it Record and check the markup prior to enclosing concealed installations 3 At time of Substantial Completion submit record drawings to the Architect for the Owner s records Organize into sets and bind and label sets for the Owner s continued use Copies and Distribution After completing the preparation of record drawings print 1
159. cal Code C NECA Standard of Installation 16 in addition to Division 1 provisions 1 7 REGULATORY REQUIREMENTS A Conform to ANSI NFPA 70 B Conform to ANSI IEEE C2 C Conform to local Building Codes D Obtain electrical permits plan review and inspections from authority having jurisdiction 1 8 SUBMITTALS A Contractor shall submit inspection and permit certificates under provisions of Division 1 B Bid Submittals 1 The Contractor shall study all Contract Documents to determine any conflicts or discrepancies of items which in the opinion of the Contractor are not clear All errors or omissions shall be reported to the Owner s representative for clarification prior to bid submittal No additional cost to the Owner shall result by Contractor s failure to request clarification on any item 2 Submittal of bid shall indicate the Contractor has examined the site Drawings and Specifications and has included all required allowances in his bid No allowance shall be made for any error resulting from Contractor s failure to visit job site and to review Drawings and Specifications Bid shall include costs for all required changes including record drawing changes and all shop drawings 3 Before bid submittals are made the Contractor shall determine that specified materials availability shall not delay progress of the work If undue delays or other major circumstances are foreseen the Contractor must alert the Owner s representative imme
160. calibrated signal Analog Output values to Pneumatic transducers shall be displayed so that a O percent display value corresponds to the pressure required to set the pneumatic actuator to minimum position and a 100 percent display value corresponds to the pressure required to set the pneumatic actuator to the maximum position 5 All analog output points shall be tested using a command from the workstation to modulate the output device from minimum calibrated signal to maximum calibrated output 6 All analog input points are to be tested by comparing the reading obtained through the workstations or portable terminal to the value of an independent testing meter E VAV box performance verification and documentation 1 As part of the commissioning of the terminal unit control and air distribution system the Contractor shall initiate an automated test where the dampers in one half of a group of boxes are stepped towards full open while the other half are stepped towards full closed At each step after a settling time box airflows and damper positions will be sampled Following the cycle a pass fail report indicating results shall be produced Possible results are Pass No change in flow between full open and full close Reverse operation or Maximum flow not achieved The report shall be submitted as documentation of the installation 2 The Controls Contractor shall issue a report based on a sampling of the VMA calculated loop performance m
161. cate equipment and accessories in such a manner as to provide easy access for proper service and maintenance Special care is required to provide accessibility to openings in equipment requiring maintenance Bring to the attention of the Engineer any condition which prevents adequate accessibility for maintenance prior to installation of that work Before submitting proposals examine the Specifications and Drawings relating to the work and become fully informed as to the extent and character of the work and the relation of the work to that of other sections Examine the Drawings of other sections to become familiar with all the possible problems and details of the building construction which affect the work SHOP DRAWINGS A Submittals shall comply completely with Section 15010B Mechanical General Requirements Submit for review by the Engineer prior to purchase or installation of equipment shop drawings of all major equipment and all specially constructed equipment proposed for use in the project Submittals shall consist of manufacturer s scale drawings cuts or catalogs including descriptive literature which shall indicate the construction material physical dimensions and complete operating data All automatic controls shop drawings shall contain a verbal description of the sequence of operations enumerating and describing the FMS CONTROLS AND INSTRUMENTATION 15900B 3 Ticket Counter Ceilings Piedmont Triad International Airpor
162. cated 3 3 APPLICATION A Apply paints according to manufacturer s written instructions and to recommendations in MPI Manual B Apply paints to produce surface films without cloudiness spotting holidays laps brush marks roller tracking runs sags ropiness or other surface imperfections Cut in sharp lines and color breaks 3 4 CLEANING AND PROTECTION A Protect work of other trades against damage from paint application Correct damage to work of other trades by cleaning repairing replacing and refinishing as approved by Architect and leave in an undamaged condition B At completion of construction activities of other trades touch up and restore damaged or defaced painted surfaces 3 5 INTERIOR PAINTING SCHEDULE A Wood Substrates Including wood trim wood based panel products 1 Latex over Alkyd Primer System Prime Coat Primer sealer alkyd interior MPI 45 Intermediate Coat Latex interior matching topcoat Topcoat Latex interior flat Gloss Level 1 MPI 53 Topcoat Latex interior Gloss Level 2 MPI 44 Topcoat Latex interior Gloss Level 3 MPI 52 29009 INTERIOR PAINTING 09912 4 PTIA Ticket Counter ceiling Renovation 12 001 000 F Topcoat Latex interior Gloss Level 4 MPI 43 g Topcoat Latex interior semi gloss Gloss Level 5 MPI 54 h Topcoat Latex interior gloss Gloss Level 6 except minimum gloss of 65 units at 60 degrees MPI 114 2 Institutional Low Odor
163. cept over current up to twice its trip point range b Current sensing switches shall be used for run status for fans pumps and other miscellaneous motor loads C Current sensing switches shall be calibrated to show a positive run status only when the motor is operating under load A motor running with a broken belt or coupling shall indicate a negative run status d Acceptable manufacturers Veris Industries 3 Air Filter Status Switches a Differential pressure switches used to monitor air filter status shall be of the automatic reset type with SPDT contacts rated for 2 amps at 120VAC b A complete installation kit shall be provided including static pressure tops tubing fittings and air filters C Provide appropriate scale range and differential adjustment for intended service 4 Air Flow Switches Differential pressure flow switches shall be bellows actuated mercury switches or snap acting micro switches with appropriate scale range FMS CONTROLS AND INSTRUMENTATION 15900B 9 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 4 and differential adjustment for intended service 5 Air Pressure Safety Switches a Air pressure safety switches shall be of the manual reset type with SPDT contacts rated for 2 amps at 120VAC b Pressure range shall be adjustable with appropriate scale range and differential adjustment for intended service 6 Low Temperature Limit Switches a The low te
164. ceptable or not acceptable as determined by the authority having jurisdiction Where these Specifications or the Construction Drawings identify materials or equipment by a catalog number it shall be understood that all parts of that material or equipment which are necessary for the complete working installation shall be included For example motor starters shall be furnished with overload heaters PART 3 EXECUTION 3 1 WORKMANSHIP A B Contractor shall install work using procedures defined in NECA Standard of Installation The Contractor shall furnish the services of an experienced superintendent who shall be constantly in charge of the construction All work shall be done by experienced workmen properly supervised 3 2 OBSERVATION The project will be observed periodically as construction progresses The Contractor will be responsible for notifying the Owner at least 24 hours in advance when any work to be covered up is ready for inspection No work will be covered up until after observation has been completed 3 3 PAINTING FINISHING A D E Suitable finishes shall be provided on all items of electrical equipment conduit etc which are exposed This shall consist of either an acceptable finish as manufactured and supplied to the job or application of suitable finishes after installation Where installed in finished areas exposed equipment raceways panel covers etc shall be supplied with prime coat and sha
165. ceptance checklist shall be completed that documents FMS CONTROLS AND INSTRUMENTATION 15900B 16 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 compliance with each item of this Specification B Testing Procedure Upon completion of the installation the FMS Contractor shall start up the system and perform all necessary testing and run diagnostic tests to ensure proper operation The FMS Contractor shall be responsible for generating all software and entering all database information necessary to perform the sequences of control herein specified C Testing Documentation Prior to acceptance testing FMS Contractor shall create on an individual system basis trend logs of input and output points or have an automatic Point History feature for documentation purposes D Field Points Testing 1 This step shall verify that all of the installed points receive or transmit the correct information prior to loading activating the system software 2 ON OFF commands from the workstation shall be performed in order to verify each binary output point 3 All binary input points are to be tested using the HAND OFF AUTOMATIC selector switch on the associated motor control center or by manually jumpering across the field device contacts 4 All analog output points providing pneumatic output control shall be tested using a command from the workstation to modulate the output from minimum calibrated signal to maximum
166. conduit unless otherwise specified a Class 2 wiring not installed in conduit shall be supported every 5 from the building structure utilizing metal hangers designed for this application Wiring shall be installed parallel to the building structural lines All wiring shall be installed in accordance with local code requirements Exposed wiring shall only be allowed in concealed accessible locations 5 All wiring in mechanical rooms shall be in conduit Minimum control wiring conduit size 3 4 3 2 INSPECTION AND PREPARATION A Prior to executing the work carefully inspect the installed work of other trades and verify FMS CONTROLS AND INSTRUMENTATION 15900B 13 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 that all such work is complete and to the point where the control systems may be installed without damage Coordinate with other trades Verify that conditioned power supply is available to control units and operator workstation Verify that field end devices wiring and pneumatic tubing are installed before proceeding with installation 3 3 INSTALLATION All work shall be installed in strict accordance with the Drawings and Specifications by personnel directly in the employ of the Controls Contractor or his subcontractors A B G H Install equipment as indicated to comply with manufacturer s written instructions Install software in control units and operator workstation Implem
167. connections and assembly details FAN COIL UNITS 15767B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 Product data indicating rated capacities weights accessories vibration isolation components electrical requirements and material finishes 3 Complete sound performance data at design conditions determined in accordance with ARI and AMCA Standards Submit sound power ratings in decibel levels referred to 10 watts obtained in accordance with ARI 350 for each individual unit at the specified performance 4 Motor data indicating voltage phase frame size and RPM 5 Unit performance data indicating selections in accordance with ARI Standard 440 Provide computer generated selection data to demonstrate compliance with the specified operating conditions 6 All equipment and component warranties 7 Manufacturer s installation instructions 8 Operation and Maintenance manuals to include manufacturer s descriptive literature start up and operating instructions maintenance procedures and parts lists B The manufacturer shall guarantee all units components and performance data to meet or exceed the specified performance requirements IDENTIFICATION A Each unit shall be tagged at the factory with its specific location on the job and the unit designation shown on the Drawing B Provide permanently attached nameplate on each unit indicating manufacturer model capacity voltage an
168. contract As used in this certification the term segregated facilities means any waiting rooms work areas restrooms and washrooms restaurants and other eating areas timeclocks locker rooms and other storage or dressing areas parking lots drinking fountains recreation or entertainment areas transportation and housing facilities provided for employees which are segregated by explicit directives or are in fact segregated on the basis of race color religion or national origin because of habit local custom or any other reason The federally assisted construction contractor agrees that except where he has obtained identical certifications from proposed subcontractors for specific time periods he will obtain identical certifications from proposed subcontractors prior to the award of subcontracts exceeding 10 000 which are not exempt from the provisions of the equal opportunity clause and that he will retain such certifications in his files Certification The information above is true and complete to the best of my knowledge and belief Please Type Name and Title of Signer Signature Date Company Address Note The penalty for making false statements in an offer are prescribed in 18 U S C 1001 BID FORM 00310 8 PTIA Ticket Counter Ceiling Renovation 12 001 000 This Affidavit is Part of Bid PERFORMANCE OF WORK BY SUBCONTRACTORS The Bidder hereby states that he proposes if awarded the Contract
169. coordinating with other trades and so as to cause interference with work of other trades the necessary changes shall be made at no extra charge 3 2 INSTALLATION A pan ee ee Excessive cutting and similar operations likely to weaken a structure or support to facilitate piping installation will not be permitted Prevent trash and dirt from entering pipes before during and after installation taking care and implementing suitable control measures throughout the construction period Temporarily plug pipe ends as construction progresses and until final connections are made Run piping parallel to walls of building adjacent piping fencing and the like unless otherwise indicated Where pipe is to be insulated provide a clearance equal to the insulation thickness plus a minimum of 2 inches Piping shall be worked in place without springing or forcing and so as to properly clear all openings and equipment Piping shall be installed to permit free expansion and contraction without damage to joints or supports Thermal expansion of pipe shall be provided for in accordance with good trade practices Use swing joints turns expansion loops or long offsets anchors and guides as necessary to allow for and control pipe movement in accordance with ANSI B31 1 Piping connections to equipment shall be installed in such manner that no excessive stresses will be transferred from the piping system to the equipment either during constr
170. cting with an Unlimited classification and Mechanical Contracting with an H 1 and H 2 class 1 classification All equipment supplied by the building level supplier shall be new The equipment and materials shall be cataloged products of manufactures regularly engaged in the production and installation of HVAC control systems Products shall be the manufacturer s latest standard design and have been tested and proven in actual use The factory branch office supplier shall have a minimum of five years experience in the design and installation of computerized DDC building systems similar in performance to the system specified 1 14 WARRANTY A The control system herein specified shall be free from defects in material and workmanship under normal use and service for a period of twelve 12 months after final inspection and acceptance by the Owner under the provisions of Section 15010B If within the twelve 12 month period any equipment software or labor is found to be defective in workmanship or materials it shall be replaced or corrected free of charge by the FMS Controls Contractor Factory authorized warranty service shall be required within 100 miles of jobsite 24 hours per day 7 days per week PART 2 PRODUCTS 2 1 SYSTEM ARCHITECTURE A Second Tier Network 1 Second tier networks shall provide either Peer to Peer Master Slave or Supervised Token Passing communications and shall operate at a minimum commun
171. ction a Unless noncompliance with Contract Document provisions is observed the submittal may serve as the final submittal b Sample sets may be used to obtain final acceptance of the construction associated with each set Distribution of Samples Prepare and distribute additional sets to subcontractors manufacturers fabricators suppliers installers and others as required for performance of the Work Show distribution on transmittal forms 1 Field samples are full size examples erected on site to illustrate finishes coatings or finish materials and to establish the Project standard a Comply with submittal requirements to the fullest extent possible Process transmittal forms to provide a record of activity 1 10 QUALITY ASSURANCE SUBMITTALS A Submit quality control submittals including design data certifications manufacturer s instructions manufacturer s field reports and other quality control submittals as required under other Sections of the Specifications Certifications Where other Sections of the Specifications require certification that a product material or installation complies with specified requirements submit a notarized certification from the manufacturer certifying compliance with specified requirements 1 Signature Certification shall be signed by an officer of the manufacturer or other individual authorized to sign documents on behalf of the company Inspection and Test Reports Requirements f
172. ction procedures in accordance with ARI Standard 440 Unit Insulation shall comply with UL 181 and NFPA 90A Units shall be UL or ETL listed 1 4 EQUIPMENT SELECTION A Unit selections are based on units scheduled Where the Contractor provides units different from those scheduled he shall be responsible for all changes to systems and other equipment incurred as a result of furnishing the different equipment Equipment layouts shown on the Drawings are based on units scheduled The space available for this equipment is limited on this project Where the Contractor elects to provide equipment other than that upon which the Drawings are based he shall be responsible for fitting the equipment into the available space providing adequate clearances for safety and good maintenance Any changes required such as routing of ductwork and piping motor horsepowers starters electrical services or architectural or structural changes shall be the responsibility of the Contractor at no additional cost to the Owner No changes will be allowed without the prior approval of the Owner s representative 1 5 SUBMITTALS A Submit equipment shop drawings showing plans and sections of proposed arrangement and size of each unit including maintenance access filter removal spaces and the like Submit the following for approval 1 Drawings indicating components dimensions weights and loadings required clearances location and size of all field
173. ctor shall disconnect the neutral feeder conductor from the neutral bar and take a megger reading between the neutral bar and the grounded enclosure If this reading is less than 250 000 ohms the Contractor shall disconnect the branch circuit neutral wires from this neutral bar He shall than test each one separately to the panel and until the low readings are found The Contractor shall correct troubles reconnect and retest until at least 250 000 ohms from the neutral bar to the grounded panel can be achieved with only the neutral feeder disconnected The Contractor shall send a letter to the Engineer certifying that the above has been done and tabulating the megger readings for each panel This shall be done at least four 4 days prior to final inspection At final inspection the Contractor shall furnish a megger and show the Engineers that the panels comply with the above requirements He shall also furnish a hook on type ammeter and a voltmeter and take current and voltage readings as directed by the representative END OF SECTION 16080 ELECTRICAL TESTING 16080 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16120 CONDUCTORS AND CABLES PART 1 GENERAL 1 1 WORK INCLUDED A Building wire and single conductor cable B Multi conductor cable and cords C Wiring connections and terminations 1 2 REFERENCES A NEMA WC 3 Rubber Insulated Wire and Cable for the Transmission and Distr
174. d Wedge Disc Crane No 351 Flanged 125 Cast Iron OS amp Y Bronze Trim and Stem Crane No 1 Threaded End No 2 Angle Threaded End or No 1310 Solder End Bronze Screwed Bonnet Composition Disc Crane No 373 Flanged 125 Cast Iron Swing Check Bolted Top Bronze Trim Crane No 37 Threaded End or No 1342 Solder End Bronze Swing Check Screwed Cap Bronze Disc Apollo 70 400 Series Bronze Solder Ends with Integral Union Use at equipment connections Apollo 70 200 Series Bronze Solder Ends Use for general service and isolation valve Mueller No 751 Flanged 125 Cast Iron Y Type Bolted Cover with Drain Stainless Steel Screen Mueller No 351 Threaded End or No 353 1 2 Solder End Y Type Bronze Screwed Drain Stainless Steel Screen PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM 15060SB 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 PIPING SCHEDULE MATERIAL SYSTEM CP 1 Continued Pressure Design 100 psig Temperature Design 210 F ITEM SIZES MATERIALS Joints Flanged Garlock Full Face Gasket Threaded Commercial Grade Pipe Dope or Teflon Thread Tape Solder 94 6 Tin Silver 430 F solidus 535 F liquidus Stay Brite 8 as manufactured by J W Harris or equivalent Studs amp Nuts ALL Tee A 307 Grade B Zinc Plated Hex Head Machine Cleaning ALL Flush water systems with water until water runs clear from each system PIPING SCHEDULE SERVICE amp MATERIAL SYST
175. d add to the above referenced AIA Document A201 Where articles paragraphs subparagraphs and clauses are modified in the SUPPLEMENTARY CONDITIONS the unaltered provisions of the articles shall remain in effect Paragraphs not listed in the SUPPLEMENTARY CONDITIONS are not modified END OF SECTION 00700 GENERAL CONDITIONS 00700 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 00800 SUPPLEMENTARY CONDITIONS General A These Supplementary Conditions modify extend and add to provisions of the General Conditions for specific project requirements B The General Conditions of the Contract for Construction AIA Document A201 2007 Edition are the General Conditions for this Contract except as herein amended deleted or supplemented A copy of the referenced General Conditions is bound herein Referenced Articles A All Article numbers and titles of the referenced AIA General Conditions are referenced for continuity and convenience New provisions added by these Supplemental Conditions shall be deemed to have been inserted in the General Conditions in the places called for by the numbering of such new provisions ARTICLE 1 GENERAL PROVISIONS 1 1 Basic Definitions Add the following 1 1 1 1 The Drawings applicable to this Project are titled PTIA Ticket Counter Ceiling Renovation at the Piedmont Triad International Airport Greensboro North Carolina The Drawings accompany these specifications and become a p
176. d and labeled for the specific use All wiring shall be in conduit All Junction Box covers shall have the word CONTROLS painted on them 3 8 high or larger All electrical wiring shall comply with the National Electrical Code Project Specifications and shall be installed by licensed journeyman electricians Low voltage and line voltage wiring shall be installed in separate conduits All interlock and control wiring for the HVAC systems not shown on the Electrical Drawings shall be by the FMS Controls Contractor This may include but not be limited to 1 Sensor and transmitter wiring to DDC panels 2 Safety interlocks to the starters i e low and high pressure safety switches smoke detector shut down contacts start stop functions and limit controls 3 Wiring of thermostats or factory prewired panels furnished by others to control fans and the like FMS CONTROLS AND INSTRUMENTATION 15900B 14 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 4 Trunk communication wiring G Signal and Communication Cable 1 Bundle and harness multiconductor instrument cable in place of single cables where a number of cables follow a common path 2 Fasten flexible conductors bridging cabinets and doors neatly along hinge side protect against abrasion Tie and support conductors neatly 3 Number code or color code conductors except local individual room controls for future identification and servic
177. d baked finish for all components of custom metal ceiling system a Fluropon b Fluropon Classic Il C Acrodize d Acroflur Paint 2 Color and Gloss As indicated by reference to manufacturer s standard color and gloss designations 3 Color As selected by Architect from manufacturer s standard choices for color and gloss 2 9 STEEL SHEET FINISHES A Baked Enamel Finish AA C12C42R1x Chemical Finish cleaned with inhibited chemicals Chemical Finish chemical conversion coating acid chromate fluoride phosphate pretreatment Organic Coating as specified below Apply baked enamel in compliance with paint manufacturer s specifications for cleaning conversion coating and painting 1 Factory applied and baked finish for all components of custom metal ceiling system a Fluropon b Fluropon Classic Il c Acrodize d Acroflur Paint 2 Color and Gloss As indicated by reference to manufacturer s standard color and gloss designations 3 Color As selected by Architect from manufacturer s standard choices for color and gloss PART 3 EXECUTION 3 1 EXAMINATION A Examine substrates and structural framing to which ceiling system attaches or abuts with Installer present for compliance with requirements specified in this and other sections that affect installation and anchorage of ceiling system Do not proceed with installation until unsatisfactory conditions have been corrected CUSTOM METAL CEILINGS 09514 5
178. d by a surety company licensed under the laws of North Carolina to execute the contract in accordance with the bid bond Said deposit shall be retained by the Owner as liquidated damages in event of failure of the successful bidder to execute the contract within ten days after the award or to give satisfactory surety as required by law A Performance Bond and a Payment Bond will be required for one hundred percent 100 of the contract price Payment will be made on the basis of ninety five percent 95 of monthly estimates and final payment made upon completion and acceptance of work A Pre bid Conference will be held Thursday January 24 2013 at 2 00 p m at the Piedmont Triad Airport Authority office in the Stanley Frank Board Room All bidders are strongly required to attend A tour of the project site will be conducted after this conference No proposal may be withdrawn after the scheduled closing time for the receipt of bids for a period of 90 days INVITATION TO BID 00020 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 Contractor will be given notice to proceed after Owners review of bids and should complete construction ready for Owner occupancy not later than 120 calendar days after the date of the Notice to Proceed This project does not have any direct goals for HUB s DBEs attached to this project it is the policy of the Piedmont Triad Airport Authority the Owner that Disadvantaged Business Enterprises shall have
179. d extent of the work any local conditions that may affect the work and the equipment materials and labor required The bidder is also required to examine carefully the drawings specifications the Form of Agreement the Bid Guaranty insurance requirements and to become accurately informed of conditions and requirements contained herein that may affect the work to be performed Neither the Architect Engineer nor Owner will assume any responsibility for bidding errors and omissions caused by failure of the Contractor or any subcontractor to fully comply with these requirements Complete sets of drawings specification and other contract documents related to this contract are available for inspection The submission of a BID will constitute an incontrovertible representation by BIDDER that BIDDER has complied with every requirement of this article and the Contract Documents are sufficient in scope and detail to indicate and convey understanding of all terms and conditions for performance and furnishing of the documents Two 2 sets of the following original signed documents shall be included within the envelope submitted by the bidder i The Bid Form including all affidavits and sub sections of the Bid Form Right to Reject Bid Right is reserved to reject any or all Bids and to waive any informality or irregularity in any Bid received Award of Contract The award of the contract if it is awarded will be to the lowest responsible respon
180. d systems shall be extended as necessary to provide one full season of operation of the cooling systems and of the heating systems MECHANICAL GENERAL PROVISIONS 15010B 16 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 22 C Where items of equipment or material carry a manufacturer s warranty for a period in excess of twelve 12 months the manufacturer s warranty shall apply for that particular piece of equipment or material CONTRACT CLOSEOUT SUBMITTALS A All close out submittals shall be completed satisfactorily before final application for payment will be approved Evidence of compliance with requirements of governing authorities shall be submitted As the construction of the project nears completion collect all guarantees warranties affidavits that all payrolls and bills have been paid Consent of Surety to final payment certificates of inspection operating manuals keys and keying schedule Project Record Drawings and other items required in the number of copies specified to be delivered to the Owner upon completion of the project When Contractor considers work has reached final completion submit written certification that Contract Documents have been reviewed work has been inspected and that work is complete in accordance with Contract Documents and ready for Engineer s inspection In addition to submittals required by the conditions of the Contract provide submittals required
181. d tag number WARRANTY Contractor shall provide one year warranty from date of final acceptance DELIVERY STORAGE HANDLING AND PROTECTION A B Products shall be delivered to the site at the convenience of the Owner Products shall be stored and protected Store in clean dry place and protect from weather and construction traffic Handle carefully to avoid damage to components enclosures and finish Units damaged by weather construction activities or mishandling shall be replaced at the Contractor s expense Any insulation that becomes wet due to exposure to weather shall be completely replaced If units are double wall construction the entire unit shall be replaced PART 2 PRODUCTS 2 1 ACCEPTABLE MANUFACTURERS A Units by Trane McQuay or Carrier are acceptable provided the units meet the construction FAN COIL UNITS 15767B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B and performance requirements specified herein and on the equipment schedule All units on the project shall be by the same manufacturer 2 2 CONSTRUCTION A B Unit casing shall be 18 gauge minimum G60 galvanized steel All exterior panels shall be insulated with 1 2 minimum thickness closed cell or foil faced glass fiber insulation Drain pan shall be stainless steel or plastic construction Drain pan shall be sloped in two planes and insulated with closed cell insulation Drain co
182. d torque D Drip proof Enclosure Class A 50 degrees C temperature rise insulation NEMA Service Factor prelubricated sleeve or ball bearings E Enclosed Motors Class A 50 degrees C temperature rise insulation 1 0 Service Factor prelubricated ball bearings 2 5 SINGLE PHASE POWER PERMANENT SPLIT CAPACITOR MOTORS A Starting Torque Exceeding one fourth of full load torque B Starting Current Up to six times full load current C Multiple Speed Through tapped windings D Open Drip proof or Enclosed Air Over Enclosure Class A 50 degrees C temperature rise insulation minimum 1 0 Service Factor prelubricated sleeve or ball bearings automatic reset overload protector 2 6 SINGLE PHASE POWER CAPACITOR START MOTORS A Starting Torque Three times full load torque B Starting Current Less than five times full load current C Pull up Torque Up to 350 percent of full load torque D Breakdown Torque Approximately 250 percent of full load torque MOTORS 15045B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 E Motors Capacitor in series with starting winding capacitor start capacitor run motors shall have two capacitors in parallel with run capacitor remaining in circuit at operating speeds F Drip proof Enclosure Class A 50 degrees C temperature rise insulation NEMA Service Factor prelubricated ball bearings G Enclosed Motors Class A 50 degrees C temperature rise insulatio
183. dge moldings fabricated to diameter required to fit penetration exactly 2 Baked Enamel Finish AA C12C42R1x Chemical Finish cleaned with inhibited chemicals Chemical Finish acid chromate fluoride phosphate conversion coating Organic Coating as specified below Apply baked enamel according to paint ACOUSTICAL TILE CEILINGS 09512 4 PTIA Ticket Counter Ceiling Renovation 12 001 000 manufacturer s specifications for cleaning conversion coating and applying organic coating 3 Manufacturer Subject to compliance with requirements provide aluminum accessories by one of the following a Fry Reglet Corporation b Gordon Inc c MM Systems Inc PART 3 EXECUTION 3 1 EXAMINATION A Examine substrates and structural framing to which acoustical tile ceilings attach or abut with Installer present for compliance with requirements specified in this and other Sections that affect ceiling installation and anchorage Do not proceed with installation until unsatisfactory conditions have been corrected 3 2 PREPARATION A Coordination Furnish layouts for preset inserts clips and other ceiling anchors whose installation is specified in other Sections 1 Furnish concrete inserts and similar devices to other trades for installation well in advance of time needed for coordinating other work Testing Substrates Before installing adhesively applied tile on wet placed substrates such as cast in place concrete or plaster
184. diately and before submittal of his bid 4 Contractor s base bid shall include only those Manufacturers and equipment types called for in the Specifications or on the Drawings If a specific Manufacturer is not listed the Contractor may submit other manufacturers and equipment types as outlined in Section 10631 C Equipment Submittals Shop Drawings Record Drawings Shall be submitted in accordance with Division 1 ELECTRICAL GENERAL REQUIREMENTS 16010 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 PART 2 PRODUCTS 2 1 MATERIALS AND EQUIPMENT A All materials and equipment shall be new undamaged and top quality They shall be so selected and arranged as to fit properly and fulfill their intended purpose Materials and equipment shall bear the manufacturers label marking or name tag whichever is applicable giving pertinent information Materials and equipment shall be inspected upon arrival at the site to insure they are correct Adequate facilities shall be provided on site for orderly and protective storage of all materials and equipment Materials and equipment shall be as given in these Specifications or on the Drawings except that if Contractor proposes to furnish an alternate he shall furnish complete detailed information to the Owner and obtain written approval for the substitution within 10 days after award of contract Where materials and equipment are not specified they shall be ac
185. dual welded joint shall have the number of the responsible welder legibly stamped into the surface of a polished place on the pipe adjacent to the weld 1 6 SUBMITTALS Submit shop drawings in accordance with Section 15010B Mechanical General Provisions A Various piping material systems are specified for this project e g CP 1 CS 1 CS 2 and the like Refer to Specification Section 15060SB For each piping material system listed provide the following 1 Description of piping material s to be provided for each system PIPE PIPE FITTINGS AND VALVES 15060B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 Description of fittings to be provided for each system 3 Description of flanges to be provided for each system 4 Manufacturer s data sheets on valves indicate on individual valve data sheets which material system s the valve will be used in Provide construction and materials compliance data dimensional data and Country of origin for each valve or valve specialty type 5 Manufacturer s data sheet on strainers indicate on individual strainer data sheets which material system s the strainer will be used in 6 Manufacturer s data sheets on Soldering Brazing materials to include composition solidus and liquid temperatures indicate on individual data sheets which material system s the soldering materials will be used in B Manufacturer s Product Data Sheets for the alkaline
186. ducts in undamaged condition in manufacturer s original containers or packaging with identifying labels intact and legible b Immediately on delivery inspect shipments to assure compliance with requirements of Contract Documents and approved submittals and to verify that products are properly protected and undamaged C Promptly provide all labor and equipment necessary to receive inspect unload and store all deliveries 2 Provide equipment and personnel to handle products by methods to prevent soiling or damage to products or packaging D Storage and Protection 1 Contractor shall provide satisfactory means of weather and security protection for materials products tools and equipment such as trailers or other enclosures 2 Store products in accord with manufacturer s instructions with seals and labels intact and legible a Store products subject to damage by the elements in weathertight enclosures b Maintain temperature and humidity within the ranges required by manufacturer s instructions 3 Arrange storage in a manner to provide easy access for inspection Make periodic inspections of stored products to assure that products are maintained under specified conditions and free from damage or deterioration 4 Protection After Installation Provide substantial coverings as necessary to protect installed products from damage from traffic and subsequent construction operations Remove when no longer needed 2 4 ELECTRIC MOTOR
187. dustry accepted installation procedures required for the work as outlined in these documents All systems equipment components accessories and installation hardware shall be new and free from defects and shall be UL listed where applicable All components shall be in current production and shall be a standard product of the system or device manufacturer Refurbished or reconditioned components are unacceptable Each component shall bear the make model number device tag number if any and the UL label as applicable All systems components of a given type shall be the product of the same manufacturer INTENT OF SPECIFICATIONS AND DRAWINGS A It shall be understood that the Drawings and Specifications describe the approximate locations of the work Do not scale the Drawings to determine exact positions and clearances Obtain from the Engineer any dimensions not shown Bring to the attention of the Engineer immediately any changes in the size or location of the material or equipment which may be necessary in order to meet field conditions or in order to avoid conflict with the equipment of other sections Obtain the Engineer s approval before such deviations are made Details of construction and of workmanship where not specifically described herein or indicated on the Drawings shall be subject to the Engineer s approval Obtain from the Engineer at the site the location of any apparatus not definitely located on the Drawings Lo
188. e Do not attach hangers to steel deck tabs Do not attach hangers to steel roof deck Attach hangers to structural members Space hangers not more than 48 inches 1200 mm o c along each member supported directly from hangers unless otherwise shown and provide hangers not more than 8 inches 200 mm from ends of each member Install hangars on all corners of lay in light fixtures C Install edge moldings and trim of type indicated at perimeter of acoustical tile ceiling area and where necessary to conceal edges of acoustical units 1 2 Screw attach moldings to substrate at intervals not over 16 inches 400 mm o c and not more than 3 inches 75 mm from ends leveling with ceiling suspension system to a tolerance of 1 8 inch in 12 feet 3 18 mm in 3 66 m Miter corners accurately and connect securely Do not use exposed fasteners including pop rivets on moldings and trim D Install suspension system runners so they are square and securely interlocked with one another Remove and replace dented bent or kinked members E Arrange directionally patterned acoustical tiles as follows 1 2 3 4 CLEANING In the manner indicated on reflected ceiling plans Install tiles in a basket weave pattern A Clean exposed surfaces of acoustical tile ceilings including trim edge moldings and suspension system members Comply with manufacturer s instructions for cleaning and touchup of minor finish damage Remove and replace ti
189. e Specifications END OF SECTION 16500 LIGHTING 16500 2
190. e manufacture as the duct system with all dimensions and components compatible ROUND ELBOWS shall be smooth stamped type or five piece type having centerline radius of 1 1 2 times the duct diameter RECTANGULAR ELBOWS amp AIR TURNING VANES based on SMACNA 1990 Systems Duct Design Table 14 10 G A Elbows in supply return outside and relief air ductwork with a dimension larger than 12 inches shall be SMACNA smooth radius type with two splitter vanes and with a 0 30 minimum inside R W B Elbows in supply return outside and relief air ductwork with both dimensions being 12 inches or less may be constructed with no turning vanes however the minimum inside R W shall not be less than 1 0 C Elbows in exhaust air ductwork shall be SMACNA smooth radius type with a 0 30 minimum inside R W and with no turning vanes except where mitered elbows are absolutely necessary they shall have turning vanes as described below D Mitered elbows without turning vanes shall NOT be used Where mitered elbows are absolutely necessary because of space limitation single thickness SMACNA Type 1 turning vanes with minimum 3 4 long trailing edges shall be provided Turning vanes shall be same material as ductwork and shall have same sealing requirement as ductwork E Vanes over 30 long in mitered elbows shall be single thickness as above with intermediate supports or tie rods or shall be double thickness airfoil SMACNA Type 1 or 4 Trailing edg
191. e of the date established for Substantial Completion Indicate Substantial Completion on the schedule to allow time for the Architect s procedures necessary for certification of Substantial Completion Phasing On the schedule show how requirements for phased completion to permit Work by separate Contractors and partial occupancy by the Owner affect the sequence of Work Work Stages Indicate important stages of construction for each major portion of the Work including submittal review testing and installation Area Separations Provide a separate time bar to identify each major construction area for each major portion of the Work Indicate where each element in an area must be sequenced or integrated with other activities Distribution Following response to the initial submittal print and distribute copies to the Architect Owner subcontractors and other parties required to comply with scheduled dates Post copies in the Project meeting room and temporary field office 1 When revisions are made distribute to the same parties and post in the same locations Delete parties from distribution when they have completed their assigned portion of the Work and are no longer involved in construction activities Schedule Updating Revise the schedule after each meeting event or activity where revisions have been recognized or made Issue the updated schedule concurrently with the report of each meeting DAILY CONSTRUCTION REPORTS SUBM
192. e provided by the FMS Contractor unless specifically shown on the Electrical Drawings under Division 16 Electrical All wiring shall comply with the requirements of applicable portions of Division 16 and all local and national electric codes unless specified otherwise in this section M All system input wiring shall be twisted shielded pair minimum 18 gauge wire All system analog output wiring shall be twisted shielded pair 3 wire as required minimum 18 gauge wire Preconfigured cables between Terminal Unit Controllers and Thermostats are acceptable minimum 24 gauge N All internal panel device wiring for binary outputs and pilot relay shall be minimum 16 gauge wire O All Class 2 24VAC or less wiring shall be installed in conduit unless otherwise specified FMS CONTROLS AND INSTRUMENTATION 15900B 15 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 5 3 6 3 7 a Class 2 wiring not installed in conduit shall be supported every 5 from the building structure utilizing metal hangers designed for this application Wiring shall be installed parallel to the building structural lines All wiring shall be installed in accordance with local code requirements Exposed wiring shall only be allowed in concealed accessible locations P All wiring in mechanical rooms shall be in conduit Minimum control wiring conduit size 3 4 WIRING SUPERVISION AND CHECKOUT Supervision and checkout of the system sh
193. e segregated All terminal strips and wiring shall be UL listed 300 volt service and provide adequate clearance for field wiring 5 All wiring for every control panel shall follow a common color coded format All terminal strip color coding and numbering shall follow a common format All wiring shall be neatly installed in plastic trays or tie wrapped 6 A convenience 120 VAC duplex receptacle shall be provided in each enclosure fused on off power switch and required transformers PART 3 EXECUTION 3 1 INSTALLATION PRACTICES A HVAC Control System Wiring 1 All conduit wiring accessories and wiring connections required for the installation of the Facility Management System as herein specified shall be provided by the FMS Contractor unless specifically shown on the Electrical Drawings under Division 16 Electrical All wiring shall comply with the requirements of applicable portions of Division 16 and all local and national electric codes unless specified otherwise in this section 2 All system input wiring shall be twisted shielded pair minimum 18 gauge wire All system analog output wiring shall be twisted shielded pair 3 wire as required minimum 18 gauge wire Preconfigured cables between Terminal Unit Controllers and Thermostats are acceptable minimum 24 gauge 3 All internal panel device wiring for binary outputs and pilot relay shall be minimum 16 gauge wire 4 All Class 2 24VAC or less wiring shall be installed in
194. e shall be tested and rated in accordance with the Air Movement and Controls Association AMCA Standard 500 to have leakage ratings as listed below or better Maximum Maximum Leakage Damper System System of CFM Width Pressure Velocity Max Flow Sq Ft 48 6 2 in wg 4000 fpm 0 067 2 7 36 8 5 in wg 4000 fpm 0 075 3 0 24 10 75 in wg 5000 fpm 0 060 3 0 12 13 0 in wg 6000 fpm 0 050 3 0 10 Dampers shall be Model CD50 low leakage airfoil control dampers as manufactured by Ruskin Arrow or approved equal by National Controlled Air Louvers amp Dampers Inc Johnson Controls and Safe Air 15840B 10 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 PART 3 EXECUTION 3 1 3 2 3 3 3 4 3 5 3 6 3 7 DUCTWORK A All ductwork shall be fabricated and installed in accordance with applicable SMACNA Standards according to the pressure class described in PART 1 GENERAL B Size round ducts installed in place of rectangular ducts in accordance with ASHRAE table of equivalent rectangular and round ducts C Ductwork shall be supported as recommended by SMACNA Standards from structural members Ductwork shall not be allowed to rest on ceiling light fixtures or structural members Ductwork supported from joists shall be supported from the top chord of all joists D Ducts unless otherwise approved shall be true to dimensions indicated straight and smooth on inside with neatly f
195. ections shall be not less than 4 inches in length 3 9 FLEXIBLE DUCTS A H To connect flexible ducts to sheet metal ducts or equipment apply duct sealer to inside of the flexible duct and secure the inner duct surface to the ductwork using a vinyl drawband Do not pressurize duct system for a minimum of 48 hours or as recommended by the manufacturer to allow sealant to dry After the connection has been made on insulated duct reshape the insulation and vapor barrier over the duct end Wrap twice around with duct tape compatible with sealer taking two or three tucks in the vapor barrier while taping Where flexible duct is used for elbows construct so that length shall be sufficient to provide a radius not less than 1 5 times the diameter Support flexible ducts to prevent sagging more than 1 2 per foot of length between supports Support flexible duct within two 2 feet of connection to ductwork and terminal units Maximum spacing between supports shall be six 6 feet Flexible duct lengths shall be at least 12 inches long and no more than 10 ten feet long and shall be of the same nominal size as sheet metal duct or diffuser grille or register neck to which it connects Flexible ducts shall be used only at locations as shown on Drawings 3 10 DUCT SEALING Sealing shall be done as required in Part 1 General in this section using duct sealer duct sealer and tape or gaskets in accordance with SMACNA duct construc
196. ed moisture content Handle acoustical tiles carefully to avoid chipping edges or damaging units in any way 1 6 PROJECT CONDITIONS A Space Enclosure and Environmental Limitations Do not install acoustical tile ceilings until spaces are enclosed and weatherproof wet work in spaces is completed and dry work above ceilings is complete and ambient temperature and humidity conditions are being maintained at the levels indicated for Project when occupied for its intended use 1 7 COORDINATION A Coordinate layout and installation of acoustical tiles and suspension system components with other construction that penetrates ceilings or is supported by them including light fixtures HVAC equipment fire suppression system components if any and partition assemblies if any 1 8 EXTRA MATERIALS A Furnish extra materials described below that match products installed are packaged with protective covering for storage and are identified with labels clearly describing contents 1 Acoustical Ceiling Tile Furnish quantity of full size units equal to 10 percent of amount ACOUSTICAL TILE CEILINGS 09512 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 installed 2 Suspension System Components Furnish quantity of each component equal to 2 0 percent of amount installed PART 2 PRODUCTS 2 1 MANUFACTURERS A Products Subject type indicated 1 ACT 1 to compliance with requirements provide one of the follo
197. ed Finish Made to patterns included in WMMPA WM 12 1 Softwood Moldings WMMPA WM 4 P grade a Species Eastern white Idaho white lodgepole ponderosa radiata or sugar pine b Maximum Moisture Content 15 percent 2 Hardwood Moldings WMMPA HWM 2 P grade a Species Aspen basswood cottonwood gum magnolia soft maple tupelo or yellow poplar b Maximum Moisture Content 9 percent 3 Optional Material Primed MDF Molding Patterns 1 As indicated on the drawings PANEL Hardwood Veneer Plywood Panels Manufacturer s stock hardwood plywood panels complying with HPVA HP 1 made without urea formaldehyde adhesive 1 Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following a Chesapeake Hardwood Products Inc b Georgia Pacific Corp c Holland Southwest International Face Veneer Species and Cut Rotary cut wood type and finish to match existing Veneer Matching Selected for similar color and grain Thickness 1 8 inch Face Pattern Manufacturer s standard channel grooved pattern G1 a INTERIOR FINISH CARPENTRY 06202 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 2 4 A B C 6 Finish Manufacturer s standard transparent UV resistant protective finish color to match existing MISCELLANEOUS MATERIALS Low Emitting Materials Adhesives shall c
198. ed standards Notation of coordination requirements Notation of dimensions established by field measurement Sheet Size Except for templates patterns and similar full size Drawings submit Shop Drawings on sheets at least 8 1 2 by 11 inches 215 by 280 mm but no larger than 36 by 48 inches 890 by 1220 mm 7 Final Submittal Submit 5 black line prints 8 Do not use Shop Drawings without an appropriate final stamp indicating action taken OahRWNM 1 8 PRODUCT DATA A SUBMITTALS Collect Product Data into a single submittal for each element of construction or system Product Data includes printed information such as manufacturer s installation instructions catalog cuts standard color charts roughing in diagrams and templates standard wiring diagrams and performance curves 1 Mark each copy to show applicable choices and options Where printed Product Data includes information on several products that are not required mark copies to indicate the applicable information Include the following information Manufacturer s printed recommendations Compliance with trade association standards Compliance with recognized testing agency standards Application of testing agency labels and seals Notation of dimensions verified by field measurement f Notation of coordination requirements 2 Submittals Submit 5 copies of each required submittal The Architect will retain Popop 01300 4 PTIA Ticket Counter C
199. eiling Renovation 12 001 000 1 9 SAMPLES A SUBMITTALS one and will return the others marked with action taken and corrections or modifications required a Unless noncompliance with Contract Document provisions is observed the submittal may serve as the final submittal Distribution Furnish copies of final submittal to installers subcontractors suppliers manufacturers fabricators and others required for performance of construction activities Show distribution on transmittal forms a Do not proceed with installation until a copy of Product Data is in the Installer s possession b Do not permit use of unmarked copies of Product Data in connection with construction Submit full size fully fabricated Samples cured and finished as specified and physically identical with the material or product proposed Samples include partial sections of manufactured or fabricated components cuts or containers of materials color range sets and swatches showing color texture and pattern 1 Mount or display Samples in the manner to facilitate review of qualities indicated Prepare Samples to match the Architect s sample Include the following Specification Section number and reference Generic description of the Sample Sample source Product name or name of the manufacturer Compliance with recognized standards Availability and delivery time D2QA9Tp Submit Samples for review of size kind color pattern and tex
200. elboards F Make conductor lengths for parallel circuits equal 3 2 WIRING INSTALLATION IN RACEWAYS A Pull all conductors into a raceway at the same time Use UL listed wire pulling lubricant for pulling 4 AWG and larger wires B Completely and thoroughly swab raceway system before installing conductors 3 3 CABLE INSTALLATION A Provide protection for exposed cables where subject to damage B Use spring metal clips or plastic metal cable ties to support cables from structure Include bridle rings or drive rings C Use suitable cable fittings and connectors 3 4 WIRING CONNECTIONS AND TERMINATIONS A Splice only in accessible junction boxes B Joints in solid conductors namely those sized 10 AWG and smaller shall be spliced using Ideal wing nuts 3M Co s Scotchlok or T amp B Piggy connectors in junction boxes and light fixtures Sta Kon or other permanent type crimp connectors shall not be used for branch circuit connections C Stranded conductors namely 8 AWG and larger shall be spliced by approved mechanical connectors plus gum tape plus vinyl tape Solderless mechanical connectors for splices and taps provided with UL approved insulating covers may be used instead of mechanical connectors plus tape D Thoroughly clean wires before installing lugs and connectors Make splices taps and terminations to carry full ampacity of conductors without perceptible temperature rise F Terminate spare conductors wit
201. en and return promptly 1 Compliance with specified characteristics is the Contractor s responsibility Action Stamp The Architect will stamp each submittal with a uniform action stamp The Architect will mark the stamp appropriately to indicate the action taken as follows 1 Final Unrestricted Release When the Architect marks a submittal No Exceptions Taken the Work covered by the submittal may proceed provided it complies with requirements of the Contract Documents Final payment depends on that compliance Final But Restricted Release When the Architect marks a submittal Make Corrections Noted the Work covered by the submittal may proceed provided it complies with notations or corrections on the submittal and requirements of the Contract Documents Final payment depends on that compliance Returned for Resubmittal When the Architect marks a submittal Amend and Resubmit do not proceed with Work covered by the submittal including purchasing fabrication delivery or other activity Revise or prepare a new submittal according to the notations resubmit without delay Repeat if necessary to obtain different action mark a Donotuse or allow others to use submittals marked Amend and Resubmit at the Project Site or elsewhere where Work is in progress Other Action Where a submittal is for information or record purposes or special processing or other activity the Architect will return the submittal marked Action Not
202. ent all features of programs to specified requirements and appropriate to sequence of operation Connect and configure equipment and software to achieve the sequence of operation specified Verify location of thermostats humidistats and other exposed control sensors with plans and room details before installation Locate 60 inches 1524 mm above floor Install averaging elements in ducts and plenums in crossing or zigzag pattern Install damper motors on outside of duct in warm areas not where exposed to outdoor temperatures Install labels and nameplates to identify control components according to Division 15 Sections specifying mechanical identification Install hydronic instrument wells valves and other accessories according to Sections 15010B and 15060B Install duct volume control dampers according to Section 15840B Ductwork 3 4 ELECTRICAL The control system shall be installed according to the following provisions All electrical work shall be installed in accordance with Division 16 Electrical A Power wiring for the control system and smoke detectors shall be provided by the Electrical Contractor Designated circuit breakers shall be furnished by the Electrical Contractor in the distribution panelboards for the control systems Feeders shall be run to junction boxes by the Electrical Contractor as shown on the plans and control diagrams All limited energy cable installed under this specification shall be UL liste
203. ents prepared by Lindsey Architecture Summary by References Work of the contract can be summarized by references to the Contract General Conditions Modifications to General Conditions Supplementary Conditions Specification Sections Drawings addenda and modifications to the Contract Documents issued subsequent to the initial printing of this project manual and including but not necessarily limited to printed material referenced by any of these Itis recognized that work of the Contract is also unavoidably affected or influenced by governing regulations natural phenomenon including weather conditions and other forces outside the contract documents Abbreviated Written Summary Briefly and without force and effect upon the contract documents the work of the Contract can be summarized as follows 1 The work includes the construction of new airline ticket counter ceilings in the terminal building at the existing Piedmont Triad International Airport Greensboro North Carolina 2 In general the scope of the work shall include all equipment materials labor etc as required to complete the work as indicated by Contract Documents 3 Work shall include but shall not be limited to selective demolition and new construction all as shown on the drawings and or specified 4 The Contractor shall be responsible for providing a complete job in accordance with these drawings and specifications The Contractor shall visit the site of the propo
204. epartment of Health Services Standard Practice for the Testing of Volatile Organic Emissions from Various Sources Using Small Scale Environmental Chambers INTERIOR PAINTING 09912 2 PTIA Ticket Counter ceiling Renovation 12 001 000 2 3 2 4 E T Colors As selected by Architect from manufacturer s full range PRIMERS SEALERS Primer Sealer Latex Interior MPI 50 Primer Alkali Resistant Water Based MPI 3 Primer Sealer Interior Institutional Low Odor VOC MPI 149 Primer Latex for Interior Wood MPI 39 Primer Sealer Alkyd Interior MPI 45 Primer Bonding Water Based MPI 17 Primer Bonding Solvent Based MPI 69 WATER BASED PAINTS Latex Interior Institutional Low Odor VOC Flat Gloss Level 1 MPI 143 Latex Interior Institutional Low Odor VOC Gloss Level 2 MPI 144 Latex Interior Institutional Low Odor VOC Gloss Level 3 MPI 145 Latex Interior Institutional Low Odor VOC Semi Gloss Gloss Level 5 MPI 147 Latex Interior High Performance Architectural Gloss Level 2 MPI 138 Latex Interior High Performance Architectural Gloss Level 3 MPI 139 Latex Interior High Performance Architectural Gloss Level 4 MPI 140 Latex Interior High Performance Architectural Semi Gloss Gloss Level 5 MPI 141 PART 3 EXECUTION 3 1 A B C EXAMINATION Examine substrates and conditions with Applicator present for compliance with requirements
205. er apply two vapor barrier mastic beads 1 8 in diameter around pipe covering close to end of covering before applying PVC cover Wrap circumferential edges of cover with vapor barrier pressure sensitive color matching tape Overlap tape 2 inches on adjacent insulation and on cover 3 6 DUCTWORK INSULATION A Rigid Glass Fiber Board Apply thickness shown in insulation schedule 1 Cut insulation to fit between standing seams and stiffeners Secure to metal with welded pins and self locking caps installed flush with adjacent insulation surface Pins shall be spotted 18 o c with not less than two rows of pins per side and with one pin spaced 3 inches in from each corner Apply a heavy bead of vapor barrier sealant around each weld pin before installing cap Caps shall match color of glass cloth jacket if used 2 Cover fittings with material of same type and thickness Score as necessary for curved surfaces 3 Vapor retarders for FSK faced insulation shall overlap a minimum of 2 at all seams and be sealed with appropriate pressure sensitive tape or mastic All penetrations facing damage and mechanical fasteners shall be covered with a minimum 2 overlap of tape or mastic 4 Where scheduled cover with finish jacketing of PVC or canvas INSULATION 15250B 11 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B Flexible Glass Fiber Apply thickness shown in insulation schedule 1 Sheet metal duct shall be
206. er ASTM E 96 K value of 0 28 at 75 F mean temperature service temperature range of 40 to 220 F Insulation to 3 4 thickness shall have a flame spread rating of 25 smoke developed 50 per ASTM E 84 Acceptable Products A Armstrong AP Armaflex Pipe Insulation Armaflex Il Sheet Insulation B Rubatex R 180 FS Pipe Insulation R 1800 FS Sheet Insulation FLEXIBLE GLASS FIBER INSULATION Ductwork Equipment and Pipe Accessories ASTM C 553 glass fiber blanket insulation industrial type Insulation shall be Type l Class B 4 resilient flexible blanket insulation with minimum density of 1 50 Ib cu ft 250 F insulation service temperature K value 0 25 at 75 F mean temperature at labeled thickness and permeance of 0 02 perms for the FSK aluminum foil fiberglass scrim laminated kraft facing Acceptable Products A C T Duct Wrap B KF Duct Wrap C MP Microlite Duct Wrap INSULATION 15250B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 D O C All Service Duct Wrap 2 4 RIGID GLASS FIBER BOARD INSULATION Ductwork and Equipment ASTM C 612 glass fiber 2 5 2 6 2 7 2 8 board insulation industrial type Insulation shall be Class 1 rigid heavy density board insulation with minimum density of 6 0 Ib cu ft 450 F insulation service temperature K value 0 22 at 75 F mean temperature and permeance of 0 02 perms for the FSK facing Acceptable Products A C T Industrial Insulatio
207. er of materials and or equipment installed in the work shall personally inspect the installation and operation of his materials systems and or equipment to determine that they are correctly installed and operating properly 1 Inspection and testing shall be accomplished a For work which will be concealed during the course of the work after completion of installation and prior to concealment b For work which will not be concealed at completion of the work 2 Each representative shall submit a signed statement to the Engineer certifying to his personal inspection and to the correct installation and proper operation of materials systems and or equipment Their certification shall list the items included 3 The Contractor shall transmit all such certifications to the Engineer at or prior to the Final Acceptance Inspection The transmittal shall include a list of all certifications included Ducts plenums and casings shall be cleaned of all debris and blown free of all particles of rubbish and dust before startup Piping shall be continuously flushed with clean water until flushing water leaving the piping runs clean Flushing shall be done at sufficient velocity to ensure proper cleaning Motors shall be bumped to assure proper rotation Alignment of all shafts couplings pulleys belts and the like shall be verified 3 16 TESTING AND BALANCING Provide complete testing and balancing of all systems and equipment as specified
208. es of single thickness vanes shall be properly aligned parallel with the duct G The number size spacing and construction details of vanes shall comply with the SMACNA HVAC Duct Construction Standards H Provide splitter vanes of similar construction in duct transitions and other locations where shown on Drawings DUCT TAPE shall be by the 3 M Company Permacel Company The Kendall Company or approved equal Tape shall be minimum 12 0 mils thick and shall be plastic coated type for non metallic ductwork and metal foil for metallic ductwork Do not use a sealer with these type tapes Tapes shall be as recommended by SMACNA DUCT SEALANTS shall be tested and labeled in accordance with UL 723 and conform to NFPA 90A Standards Sealants shall not be water soluble and shall exhibit good adhesive strength qualities and lifetime aging characteristics Flame spread and smoke developed ratings shall not exceed 25 when cured Duct sealant shall be United Duct Sealer as manufactured by United McGill Corporation or approved equal If a tape or scrim is used in conjunction with the sealant it shall be compatible with the sealant and shall be recommended by the sealant manufacturer For ductwork exposed to weather sealant shall be suitable for outdoor use TRANSVERSE DUCT JOINTS Transverse joints shall be selected and applied consistent with the static pressure class applicable sealing requirements ductwork materials of construction duct support in
209. ess such delay obstruction or hindrance is caused solely by the Owner or its agent The phrase owner or its agent does not include prime contractors or their subcontractors SUPPLEMENTARY CONDITIONS 00800 10 PTIA Ticket Counter Ceiling Renovation 12 001 000 15 3 Mediation Add the following 15 3 4 The Contractor shall ensure through its subcontracts with its subcontractors that the mediation procedure provided for in this Section 15 3 shall be available to all first tier and lower tier subcontractors with respect to any issues arising out of the Work or their respective contracts and that the costs of such mediation shall be divided equally among the parties to the dispute 15 4 Arbitration Delete Section 15 4 in its entirety and substitute the following 15 4 No Arbitration It is the intent of the parties that arbitration not be a required procedure in the dispute resolution process for this Contract Therefore all provisions of the Contract Documents regarding arbitration are deleted END OF SECTION 00800 SUPPLEMENTARY CONDITIONS 00800 11 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 01010 SUMMARY OF WORK PART 1 GENERAL 1 1 CONTRACT DESCRIPTION A The Work will be performed under a separate prime contract 1 2 PROJECT IDENTIFICATION AND SUMMARY A Project name is PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport AEP No 12 001 000 as shown on Contract Docum
210. etrics The report shall indicate performance criteria include the count of conforming and non conforming boxes list the non conforming boxes along with their performance data and shall also include graphical representations of performance The sampling shall take place after completion of Test and Balance when design cooling and heating media have been available and occupied conditions approximated for five consecutive days F Noncompliant Items The Contractor shall remove and replace at its expense all items that are not in compliance with the Specification requirements 3 8 SEQUENCES OF OPERATION FMS CONTROLS AND INSTRUMENTATION 15900B 17 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 A General 1 Refer to Flow amp Control Diagram Drawings for additional requirements 2 Smoke detectors shall be wired to the Fire Alarm Control Panel FACP by the Electrical Contractor SPDT shut down relays from the FACP provided by the Electrical Contractor in the area of air handling equipment starters shall be wired to the starters by the Controls Contractor See Electrical Drawings and Section 15010B 3 The Controls Contractor shall be responsible for furnishing all dampers that are not expressly specified to be furnished by another contractor or supplier 4 The term Sensor Failure is defined as a short circuit an open circuit or an unreal value B Fan Coil Unit FCU Sequence of Operation 1
211. exact components and system capabilities necessary for the optimum operation of the facility s HVAC equipment All requirements will be strictly interpreted and enforced by the Engineer and his representative Failure to comply with any provision may result in rejection of submittals and or default The Mechanical Contractor shall include in his bid all work required by the Mechanical Contractor in this section such as the installation of control valves and dampers sensors and the like The above overview is general and is not all inclusive Refer to the Specifications and Drawings for the complete work required 1 4 GENERAL A C Include all labor materials and appliances required for furnishing installing testing adjusting and placing in operation all control and instrumentation work shown on the Drawings and specified herein complete and satisfactory to the Owner s representative The FMS Controls Contractor shall furnish and install all equipment accessories electrical work and instrument piping required for complete and functioning control system except as described under Work by Others in Part 3 of this Section All materials and equipment used shall be standard components regularly manufactured FMS CONTROLS AND INSTRUMENTATION 15900B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 5 G for this and or other systems and not custom designed especially for this project All sys
212. fication Coatings Sherwin Williams Duron Benjamin Moore and Company Glidden Pittsburgh Paints Substitutions In Accordance with Section 15010B 2 2 PIPING IDENTIFICATION DARON A Legend MECHANICAL IDENTIFICATION 15035B 1 Ticket Counter Ceilings Piedmont Triad International Airport MECHANICAL IDENTIFICATION 12 0001 000 1 Positive identification of the contents of a piping system shall be by lettered legend giving the name of the contents in full or abbreviated form 2 Arrows shall be used to indicate direction of flow 3 Legends shall be applied close to valves or flanges and adjacent to changes in direction branches and where pipes pass through walls or floors and at intervals on straight pipe runs sufficient for identification 4 Identification shall be accomplished by stenciling or the use of markers Color Chart and Piping Identification Sherwin Williams Color Number Stencil Piping System Reference Color Identification Water Chilled Supply 866 Rustoleum Marlin Blue CWS Water Chilled Return 866 Rustoleum Marlin Blue CWR Water Cold Domestic BM 78 8 BXK 769 Dark Green DOM CW Water Hot Supply BM 80 21 BW 1121 Yellow HWS Water Hot Return BM 80 21 BW 1121 Yellow HWR Gas BM 80 8 BX 957 Red GAS Supports Hangers Black Visibility 1 Attention shall be given to visibility with reference to pipe markings 2 Where pipe lines are located above or below the normal line of vision the let
213. fications and changes to the substituted item and to the structure as may be necessary to install the item maintain intended space requirements design requirements function and appearance shall be made by the Contractor at no additional cost to the Owner Requests for review of substitute items of material and equipment will not be accepted by the Architect from any other source than the Contractor If the Contractor wishes to furnish or use a substitute item of material or equipment the Contractor shall make written application to the Architect for acceptance The Contractor shall certify that the proposed substitute will perform adequately the functions indicated by the general design be similar and of equal substance to that specified and be suited to the same use and capable of performing the same function as that specified The application shall state whether or not acceptance of the substitute for use in the Work will require a change in the Drawings or Specifications to adapt the design to the substitute and whether or not incorpora tion or use of the substitute in connection with the Work is subject to payment of any license fee or royalty All variations of the proposed substitute from that specified shall be identified in the application and available maintenance repair and replacement service will be indicated The application shall also contain an itemized estimate of all costs that will result directly or indirectly from acceptance of
214. g location 3 Disconnect Switches 1 4 inch identify load and source END OF SECTION 16075 ELECTRICAL IDENTIFICATION 16075 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16080 ELECTRICAL TESTING PART 1 GENERAL 1 1 1 2 PART 2 PRODUCTS SCOPE A Provide testing of electrical wiring and systems as specified here B Provide the following tests 1 Insulation resistance testing DOCUMENTATION A All tests specified shall be completely documented indicating time of day date temperature and all pertinent test information B All required documentation of readings indicated above shall be submitted to the Engineer prior to and as one of the prerequisites for final acceptance of the project C Meet requirements of Section 01700 and 16010 Not Used PART 3 EXECUTION 3 1 FEEDER INSULATION RESISTANCE TESTING A All current carrying phase conductors and neutrals shall be tested as installed and before connections are made for insulation resistance and accidental grounds This shall be done with a 500 volt megger The procedures are listed below 1 Minimum readings shall be one million 1 000 000 or more ohms for 6 wire and smaller 250 000 ohms or more for 4 wire or larger between conductors and between conductor and the grounding conductor After all fixtures devices and equipment are installed and all connections completed to each panel the Contra
215. greater Coverages shall be maintained without interruption from the date of commencement of the Work until the date of final payment and termination of any coverage required to be maintained after final payment and with respect to the Contractor s completed operations coverage until the expiration of the period for correction of Work or until two years after the date of final payment whichever is later Add the following 11 1 5 Limits of Contractor s Liability Insurance shall not be less than the following Type of Insurance and Limits of Liability i Worker s Compensation a State Statutory b Employer s Liability 100 000 each accident 2 Comprehensive General Liability including Premises Operations Independent Contractors Products amp Completed Operations Broad Form Property Damage Contractual Liability Explosion amp Collapse Hazard Underground Hazard Personal Injury Employment Exclusion Deleted a Bodily injury including products and completed operations 500 000 00 each occurrence 500 000 00 _ aggregate Property damage 500 000 00 _ each occurrence 500 000 00 aggregate Property damage and bodily injury combined 500 000 00 _ each occurrence 500 000 00 aggregate SUPPLEMENTARY CONDITIONS 00800 6 PTIA Ticket Counter Ceiling Renovation 12 001 000 b Applies to products and completed operations 500 000 00 aggregate personal injury 3 Comprehensive automobile liability incl
216. gunnable sealant complying with requirement specified in Division 7 Section Joint Sealers Hidden trim or Accessories Provide factory supplied or installed accessories splice joints angles clips hold down as indicated on Drawings from grid and metal ceiling manufacturers FINISHES GENERAL A Comply with NAAMM Metal Finishes Manual for recommendations relative to application and designations of finishes for metal units and exposed trim CUSTOM METAL CEILINGS 09514 4 PTIA Ticket Counter Ceiling Renovation 12 001 000 Appearance of Finished Work Variations in appearance of abutting or adjacent ceiling units are not acceptable Noticeable variations in the same piece are not acceptable Variations in appearance of other components are not acceptable All components of the custom metal ceiling are to be finished by patterned aluminum manfacturer Baker Metal Products to ensure all components are the same color 2 8 ALUMINUM FINISHES A Finish designations prefixed by AA conform to the system established by the Aluminum Association for designating aluminum finishes Baked Enamel Finish AA C12C42R1x Chemical Finish cleaned with inhibited chemicals Chemical Finish chemical conversion coating acid chromate fluoride phosphate pretreatment Organic Coating as specified below Apply baked enamel in compliance with paint manufacturer s specifications for cleaning conversion coating and painting 1 Factory applied an
217. h electrical tape 3 5 FIELD QUALITY CONTROL A Inspect wire and cable for physical damage and proper connection B Torque test conductor connections and terminations to manufacturer s recommended values C Perform continuity test on all power and equipment branch circuit conductors Verify proper phasing connections 3 6 WIRE AND CABLE INSTALLATION SCHEDULE A Concealed Interior Locations Building wire in raceways B Exposed Interior Locations Building wire in raceways C Above Accessible Ceilings Building wire in raceways 3 7 COLOR CODING A All wiring shall be color coded B On 120 208V 3 phase 4 wire power systems conductors shall be color coded Black CONDUCTORS AND CABLES 16120 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 8 G Phase A Red Phase B Blue Phase C and White Neutral One 277 480V 3 phase 4 wire power systems conductors shall be color coded Brown Phase A Orange Phase B Yellow Phase C and Grey Neutral Ground conductors on all systems shall be Green Conductors AWG6 and larger may be identified with two or more bands of proper color plastic tape applied near each termination Painting of wire will not be acceptable Unless noted otherwise or another arrangement is approved by the Owner busses in panels and switch gear shall be considered A B and C from left to right top to bottom or front to back when facing equipment
218. h the manufacturer s recommendations All components used to form the transverse duct joint system shall be of standard identifiable catalog manufacture as supplied by Ductmate Industries or approved equal All hardware items shall be labeled by the manufacturer so that they may be easily identified as to source of manufacture The construction of the ductwork with regards to sheet metal gauge reinforcing seal class and the like shall be in strict compliance with the transverse duct system manufacturer s printed installation and applications literature SMACNA duct construction standards and the laboratory tested configurations of the duct joint system The transverse duct joint system shall conform to SMACNA guidelines and requirements for all transverse type joints Finished joints shall maintain a deflection of less than 0 25 when the system is at standard operating pressure and shall maintain its structural integrity within the operating range of the system The resulting mid panel deflection of the joined ductwork sections shall not exceed 0 75 for ducts greater than 24 wide Transverse spiral and round duct joints may be accomplished with Spiralmate Round Duct Connector and accessory components as manufactured by Ductmate Indusiries or prior approved equal Installation of Spiralmate Round Mate Connectors shall be in accordance with the manufacturer s printed instruction and installation manuals The round connector shall consist of t
219. he Contractor shall within five days thereafter substitute another Bond and Surety both of which shall be acceptable to the Owner SUPPLEMENTARY CONDITIONS 00800 7 PTIA Ticket Counter Ceiling Renovation 12 001 000 Add the following 11 4 3 If notice of any change affecting the general scope of the Work or change in the Contract Sum is required by the provisions of any Bond to be given to the Surety it will be the Contractor s responsibility to so notify the Surety and the amount of each applicable Bond shall be adjusted accordingly The Contractor shall furnish proof of such adjustment to the Owner ARTICLE 13 MISCELLANEOUS PROVISIONS Add the following 13 8 Equivalent Materials and Equipment 13 8 1 13 8 2 Whenever materials or equipment are specified as described in the Drawings or Specifications by using the name of a proprietary item or the name of a particular manufacturer fabricator supplier or distributor the naming of the item is intended to establish the type function and quality required Unless the name is followed by words indicating that no substitution is permitted materials or equipment of other manufacturers fabricators suppliers or distributors may be accepted by the Architect if sufficient information is submitted by the Contractor to allow the Architect to determine that the material or equipment proposed is equivalent to that specified When an approved substitution is used all adjustments modi
220. he following components two mating round duct connector flanges with integral sealant gasket between the two mating flanges and a roll formed closure ring that is drawn tight with a bolt and nut assembly The manufacturer of the components used to form the transverse duct joint shall guarantee all components against defective materials The manufacturer shall also have factory trained representatives available to provide field assembly instructions to installing contractors Installation of all transverse duct joint systems shall be in strict compliance with the 15840B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 11 2 12 2 13 2 14 2 15 manufacturer s printed instructions K All non complying components and joint systems installed without approved Shop Drawing submittals shall be removed by the Contractor without additional expense to the Owner and shall be promptly replaced with approved components and joining methods for a complete system TDC AND TDF JOINT SYSTEMS Duct joint connection methods classified as TDC or TDF all are non proprietary joints shall not be permitted without prior approval and confirming Shop Drawing submittals The manufacturer or fabricator shall submit certified test reports from an independent testing laboratory to document the specific performance criteria and approved installation methods for all non proprietary type joints proposed for installation under th
221. heavy gauge 0 004 polyethylene film at a minimum width of 6 2 Tapes shall be selected by color code to match the type of utility buried below 3 Tapes shall be style 210 as manufactured by Seton or equal by listed acceptable manufacturer B Metallic Detection Tape 1 Metallic detection tape shall be heavy gauge 0 004 thick with a minimum width of MECHANICAL IDENTIFICATION 15035B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 Tapes shall be selected by color code to match the type of utility buried below 3 Tapes shall be style MLT as manufactured by Seton or equal by listed acceptable manufacturer 2 5 ELECTRICAL IDENTIFICATION A Controls Conduit 1 Semi rigid plastic not pressure sensitive identification markers shall have 1 approved color coded background 2 proper color of legend in relation to background color 3 approved legend letter size and 4 approved marker length 2 Snap around markers shall be used on a cable or conduit diameter of 3 4 to 5 7 8 These markers shall be custom formed to snap on and completely encircle the pipe with a substantial overlap 3 Markers shall be covered and all printing shall be sealed beneath tough clear outdoor grade acrylic plastic Markers shall resist weather repel dirt abrasion and grease as well as withstand acid chemical and other corrosive conditions which are frequently encountered 4 Markers shall be suitable 40 F to 180
222. hedule means x Contractor s Option 1 from Jacket Material Schedule use with Insulation Option 1 y Contractor s Option 2 from Jacket Material Schedule use with Insulation Option 2 B SERVICE amp MATERIAL SYSTEMS See the following DUCTWORK SCHEDULE C SCHEDULE NOTES 1 See Drawings for more detailed requirements for ductwork pressure and seal classifications when not specifically scheduled 2 Flexible ductwork shall not be used upstream of VAV terminal units Note Area Definitions for Ductwork Location heading of attached Material Schedules shall be as follows MER Mechanical Equipments Rooms BUILDING DISTRIBUTION Ductwork from opening of Three Story Fire Rated Shafts to Inlet Side of VAV Box ROOM VAV DISTRIBUTION Ductwork from VAV Box Outlet to Room Air Distribution Device DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM 15840SB 2 Ticket Counter Ceilings Piedmont Triad International Airport SECTION 15840SB DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEMS DUCTWORK SYSTEM AHU 18 19 AHU 18 19 DUCTWORK LOCATION Within Fire Rated Room VAV Shafts Distribution Supply Air Temperature Range 50 F 100 F 50 F 100 F Ductwork Material GS GS Hanger Materials GS GS Insulation 200C 150C Jacket A Pressure Class in 4 0 f Seal Class A Notes 1 Return Air Temperature Range Ductwork Material Hanger Materials Insulation Jacket Pressure Class in Seal Class Notes Outside Air Temperature Range Duct
223. hedules are to be sent to the Project Coordinator which shall be the general contractor Prepare a complete project schedule compiled by the General Contractor which includes coordinating and combining all other prime contractors within 20 days from the date the contract is awarded 1 Provide a separate time bar for each significant construction activity Provide a continuous vertical line to identify the first working day of each week Use the same breakdown of units of the Work as indicated in the Schedule of Values 2 Within each time bar indicate estimated completion percentage in 10 percent increments As Work progresses place a contrasting mark in each bar to indicate Actual Completion 3 Prepare the schedule on a sheet or series of sheets of stable transparency or other reproducible media of sufficient width to show data for the entire construction period 4 Secure time commitments for performing critical elements of the Work from parties involved Coordinate each element on the schedule with other construction activities include minor elements involved in the sequence of the Work Show each activity in proper sequence Indicate graphically the sequences necessary for completion of related portions of the Work 5 Coordinate the Contractor s Construction Schedule with the Schedule of Values list of subcontracts Submittal Schedule progress reports payment requests and other schedules 6 Indicate completion in advanc
224. ibilities or the necessity of furnishing material and performing work as required by the Contract Drawings and Specifications K The Contractor shall keep at the work site at all times at least one copy of all approved shop drawings Shop drawings shall be properly indexed and filed in a filing cabinet for easy retrieval when questions arise L Shop Drawing Submittals Required 1 Coordination shop drawing plans and sections for each mechanical room of the building at a minimum scale of 1 4 inch one foot showing all equipment ductwork piping grilles and registers structural clearances maintenance clearances and other trades including major fire protection piping and major electrical conduit 2 Fans including fan curves motors details and dimensions 3 Valves including ball gate butterfly check circuit setter balancing and other MECHANICAL GENERAL PROVISIONS 15010B 11 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 7 3 8 types 4 Ductwork construction standards 5 Pressure gages 6 Temperature gages 7 Flow measuring devices fluid and air types 8 Insulation pipe duct amp equipment 9 Turning vanes 10 Grilles registers diffusers 11 Duct access doors panels amp test holes 12 Fire dampers 13 Flexible pipe connections 14 Strainers 15 Vibration isolation components 16 Pipe supports hangers and accessories 17 Mechanical identification for pipe valves duct
225. ibility to penetration seals for inspection by applicable code authorities SUPPORTS ANCHORS AND SEALS 15090B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 G H Provide all installation accessories required to install the fire stopping seals in strict accordance with UL and manufacturer s recommendations Accessories shall include but not be limited to sheet metal sleeves and brackets backer rods mineral fiber packing sleeves fasteners and fire rated caulking Fire stopping seals shall be suitable for the penetration being protected as defined by UL and the manufacturer s published literature or data sheets for UL System numbers 3 7 PAINTING A Immediately after surface preparations apply shop paint in accordance with manufacturer s printed instructions and at a rate to provide a uniform dry film thickness as specified Use painting methods that will result in full coverage of joints corners edges finished welds and all surfaces Painting materials and methods shall comply with Specification Section Painting in the Contract Documents END OF SECTION 15090B SUPPORTS ANCHORS AND SEALS 15090B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15201B VIBRATION ISOLATION PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 SUBMITTALS A C Submit drawings indicating components dimens
226. ibution of Electrical Energy B NEMA WC 5 Thermoplastic Insulated Wire and Cable for the Transmission and Distribution of Electrical Energy G NEMA WC 7 Thermoset Insulated Wire and Cable for the Transmission and Distribution of Electrical Energy PART 2 PRODUCTS 2 1 BUILDING WIRE CABLES AND CORDS A Feeders and branch circuits larger than 10 AWG Stranded copper conductor 600 volt insulation THHN THWN UL listed B Feeders and branch circuits 10 AWG and smaller Solid copper conductor 600 volt insulation THHN THWN UL listed C Cords Power Cords for power service shall be portable type meeting UL requirements and NEMA standards and with 600 volt 90 C rated thermoset insulation synthetic rubber jacket and rope stranded copper conductors 2 2 ACCEPTABLE MANUFACTURERS A Cablec B Okonite C Southwire D Triangle E Substitutions Under provisions of Section 16010 PART 3 EXECUTION 3 1 GENERAL WIRING METHODS A Use no wire smaller than 12 AWG for power and no smaller than 14 AWG for control wiring B Use 10 AWG conductor for 20 ampere 120 volt branch circuit home runs longer than 50 feet Place an equal number of conductors for each phase of a circuit in same raceway or cable Splice only in junction or outlet boxes CONDUCTORS AND CABLES 16120 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 E Neatly train and fasten wiring inside boxes equipment and pan
227. ication speed of 9600 baud 2 DDC System Controllers shall reside on the second tier Operator Interface The FMS Contractor shall extend the existing personal computer workstation for command entry information management network alarm management and database management functions All real time control functions including scheduling history collection and alarming shall be resident in the FMS controllers to facilitate greater fault tolerance and reliability 2 2 APPLICATION SPECIFIC CONTROLLERS A Fan Coil Units FCU 1 Each Fan Coil Unit FCU controller shall operate as a standalone controller capable of performing its specified control responsibilities independently of other controllers in the network Each FCU controller shall be a microprocessor based multi tasking real time digital control processor FMS CONTROLS AND INSTRUMENTATION 15900B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 FCU controllers shall support but not be limited to the following configurations of systems to address current requirements as described in the Execution portion of this Specification and to address future expansion a Fan Coil Units 1 Mixed Air Single Path 2 Mixed Air Dual Path 3 100 Single Path 4 100 Dual Path 3 Each FCU controller shall have sufficient memory to support its own operating system and databases including a Control Processes b Energy Management App
228. iently in advance of performance of related construction activities to avoid delay 1 Coordinate each submittal with fabrication purchasing testing delivery other submittals and related activities that require sequential activity 2 Coordinate transmittal of different types of submittals for related elements of the Work so processing will not be delayed by the need to review submittals concurrently for coordination a The Architect reserves the right to withhold action on a submittal requiring coordination with other submittals until all related submittals are received 3 Processing To avoid the need to delay installation as a result of the time required to process submittals allow sufficient time for submittal review including time for resubmittals a Allow 2 weeks for initial review Allow additional time if the Architect must delay processing to permit coordination with subsequent submittals b If an intermediate submittal is necessary process the same as the initial submittal C Allow 2 weeks for reprocessing each submittal d No extension of Contract Time will be authorized because of failure to transmit submittals to the Architect sufficiently in advance of the Work to permit processing B Submittal Preparation Place a permanent label or title block on each submittal for identification Indicate the name of the entity that prepared each submittal on the label or title block 1 Provide a space approximately 4 by
229. ill provide the same warranties or bonds for the substitution as for the product specified 4 Will coordinate the installation of an accepted substitution into the work and make D such other changes as may be required to make the work complete and operational in all respects 5 Waives all claims for additional costs caused by the substitution which may subsequently become apparent Any substitute item installed on the project which has not been approved in writing by the Owner s representative shall be removed and replaced by the Contractor with the required specified item at no cost to the Owner 2 2 EQUIPMENT DEVIATIONS A Where the Contractor proposes to use an item of equipment other than that specified or detailed on the Drawings which requires any redesign of the structure partitions foundations piping wiring or any other part of the mechanical electrical plumbing structural architectural or civil work all such redesign and all new drawings and detailing required therefore shall be prepared by or for the Contractor at his own expense and submitted for approval by the Owner s representative Where such approved deviation requires a different quantity and arrangement of ductwork piping wiring conduit equipment structures and the like from that specified or indicated on the Drawings the Contractor shall furnish and install all such piping structural supports insulation controllers motors starters elect
230. ing of control system H Connect electrical components to wiring systems and to ground as indicated and instructed by manufacturer Tighten connectors and terminals including screws and bolts according to equipment manufacturer s published torque tightening values for equipment connectors Where manufacturer s torquing requirements are not indicated unten connectors and terminals according to tightening requirements specified in L 486A I Connect manual reset limit controls independent of manual control switch positions J Connect HAND OFF AUTO selector switches to override automatic interlock controls when switch is in HAND position K Conduit 1 Conduit Supports a Single runs shall use galvanized conduit straps or ring bolt type hangers with specialty spring clips Plumber s perforated straps are not allowed b Multiple runs shall use conduit racks with 25 spare capacity C Vertical runs shall use channel support with conduit fittings 2 Anchor Methods a Hollow masonry shall have toggle bolts or spider type expansion anchors b Solid masonry shall have lead expansion anchors or preset inserts C Metal surfaces shall have machine screws bolts or welded studs d Wood surfaces shall have wood screws e Concrete surfaces shall have self drilling anchors or power drive studs L All conduit wiring accessories and wiring connections required for the installation of the Facility Management System as herein specified shall b
231. ing or new building steel where the paint is scraped or burned away during welding operations to match existing paint finishes 3 5 EXPANSION AND CONTRACTION Use anchors and expansion bends in the installation where shown on Drawings and as required to accommodate expansion and contraction movements and prevent undue stressing of pipe Expansion loops shall unless shown otherwise on Drawings have appropriate pipe guides on each side of the loop to maintain alignment 3 6 SEALS A Sleeve diameters shall be sufficient to accommodate insulated pipe and or firestop seals See Section 15060B Pipe Pipe Fittings and Valves for detailed requirements for sleeves B Firestop seals shall be installed in strict accordance with the UL Fire Resistance Directory and the manufacturer s recommendations and data sheets for each type of opening or void Surfaces shall be smooth and without gouges or other irregularities C Clean all surfaces that will be in contact with the penetration seal materials of dirt grease oil loose materials rust or other substances that may affect the proper fitting and adhesion of the installed sealant materials D Seal all holes or voids made by penetrations to ensure an effective fire and smoke barrier E Protect materials installed to seal fire rated penetrations from damage where installed on surfaces subject to traffic F Verify thorough penetration seals by inspection of installed materials Provide for access
232. ing with the following requirements 1 Provide selections made by Architect from manufacturer s full range of standard patterns for products of type indicated 2 3 CEILING SYSTEMS A Patterned Aluminum Panels Millennium Panels Extruded from aluminum sheet complying with ASTM B 209 and the following requirements 1 Millennium panels shall be three dimensional material 1 4 thick in sizes as shown on the drawings The pattern shall be rounded top and bottom or flat top and bottom Material shall be opaque in frontal view with 40 open area as required for acoustical CUSTOM METAL CEILINGS 09514 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 2 4 2 5 2 6 2 7 performance Pattern shall run the length of the sheet a Aluminum sheet shall be 3003 14 alloy ASTM B 209 ASTM B 209M b Aluminum Extrusion shall be 6063 T6 Alloy ASTM B221 ASTM B221M C Alloy and Temper for Baked Enamel Finish 3003 H14 or 3105 H14 as standard with manufacturer d Minimum Nominal Thickness 0 050 inch 16 gage e Pattern Flat f Noise Reduction Coefficient NRC 0 70 g Acoustical backing where indicated Factory adhered to panel with a non woven 008 thick black fabric Class A According to ASTM E 84 Sound Tex Size As indicated i Edge Detail Square SUSPENSION SYSTEMS GENERAL A Standard for Extruded Aluminum Suspension System Provide ceiling manufacturers standard suspension systems of type
233. inish 9995 as manufactured by J P Stevens Company or equal Metal Aluminum Pipes and Accessories Field Applied 1 Metal jacketing shall be 0 016 thick aluminum or aluminum alloys conforming to ASTM B 209 Metal jacketing installed outdoors shall be furnished with a stucco embossed pattern and 3 16 deep corrugated exterior surface All jacketing shall have an integrally bonded moisture barrier coating over the entire surface in contact with the insulation The moisture barrier coating shall be composed of one layer of one mil thick polyethylene film with a protective layer of 40 pound kraft paper or the 15250B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 D equivalent to prevent moisture and corrosives within the insulation from contacting the metal jacket and causing a galvanic or chemical corrosion 2 Jacketing for straight pipe shall have a weathertight or watertight side crimp closure Jacketing shall be equal to Aluminum Roll Jacketing by Childers Products Company 3 Fastening devices shall be Type T 304 stainless steel bands 0 020 thick 3 4 wide equal to Fabstraps by Childers Products Company 4 Metal fitting covers shall be 0 024 thick aluminum with a smooth or stucco embossed exterior finish moisture barrier coating on interior surface and interlocking weathertight joints Secure metal fitting covers with all aluminum fasteners such as pop rivets as necessary to secu
234. inished joints securely anchored to building in an approved manner and installed to be completely free from vibration or chatter under all conditions of operation Exact routing of ductwork will be dependent on location of structural members and coordination with locations of other utilities Route duct to avoid cutting structural members E Brace ducts not more than 60 inches on center Make slip joints in direction of flow unless shown otherwise on the Drawings Off set ducts around obstructions where possible The total included angle of duct tapers or transitions shall not exceed 45 for diverging air flow or 60 for converging air flow However in no case shall the angle between the air flow path entering the transition and any side of the transition exceed 30 for diverging or converging air flow In general diverging transitions shall be limited to 15 from the air flow path and the above angles shall be considered maximum requirements F Provide easements where low pressure ductwork conflicts with piping and structure Where easements exceed 10 percent of duct area split into two ducts maintaining original duct area G Use double nut and lock washers on threaded rod supports During construction provide temporary closures of metal or taped polyethylene on open ductwork to prevent construction dust from entering ductwork system l All ductwork accessories shall be installed in strict accordance with manufacturer s recommenda
235. ion Sleeves shall not be provided for piping running imbedded in concrete or in insulating concrete slabs on grade Sleeves shall not be required for smooth core drilled holes in existing concrete construction unless specifically required by details or notes on the Drawings This Contractor shall do all drilling required for the installation of hangers inserts and other components 3 11 PROTECTION MECHANICAL GENERAL PROVISIONS 15010B 13 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 A C Contractor shall protect all work and material from damage and shall be liable for all damage during construction Contractor shall be responsible for work and equipment until all construction is finally inspected tested and accepted He shall protect work against theft injury or damage and shall carefully store material and equipment received on site which are not immediately installed He shall close open ends of work including ductwork pipe and equipment with temporary covers or plugs during storage and construction to prevent entry of obstructing materials See the Contract Documents including the General Conditions Supplementary General Conditions and General Requirements 3 12 HOUSEKEEPING AND CLEANING A B Refer to General Conditions and Supplementary General Conditions Maintain the work site and surrounding areas reasonably clean and free of dirt debris waste and surplus materials
236. ion shall be entered at the time of joint inspection on the system report C Problems which occur within approved hardware or software shall be corrected in an appropriate fashion under warranty Any such occurrence shall not void previous approval however the System Contractor shall be responsible to attend to and remedy such items within the warranty period Appropriate logs schedules and reports shall be maintained to reflect these items and their redress 1 10 OWNER S INSTRUCTION See Part 3 Execution 1 11 SHIPPING TAG Each component shall be tagged at the factory with its specific location on the job including FCU designation building floor room area served and the unit designation shown on the Drawing FMS CONTROLS AND INSTRUMENTATION 15900B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 12 NAMEPLATES Provide nameplate on each component as required by Section 15035B Mechanical Identification 1 13 QUALITY ASSURANCE A The building level supplier shall be responsible for complete installation including the proper operation of the system which also includes debugging of all software and calibration of all devices The building level supplier shall be in the business of design installation and service of the building DDC system similar in size and complexity of this project The building level supplier shall be properly licensed in the following disciplines Electrical Contra
237. ions to the ductwork systems Verify that all access doors and panels are gasketed and have operable latches Outlets or taps shall be covered with plastic during testing Verify that terminal units such as VAV boxes are operating properly Coordinate testing adjusting and balancing effort with the Controls Contractor to verify that damper maximum and minimum settings provide the CFM quantities as scheduled Confirm that dampers open and close in response to the controlling thermostat Coordinate testing of the air handling systems with the Controls Contractor to obtain performance in accordance with the airflows scheduled on the Drawings Verify that each air handling system fan equipped with a variable speed drive when the drive is bypassed maximum rpm that the fan does not exceed maximum CFM quantities as scheduled on the Drawings Verify that the motor current draw does not exceed 95 of the nameplate rating Adjust belts and align drives for all rotating equipment Lubricate bearings dampers etc and check systems for excessive vibration and noise levels Make adjustments necessary to prepare systems for final testing and balancing ADJUSTING AND BALANCING A In cooperation with the Mechanical Contractor the Controls Contractor and Owner s representative set adjustment of controls to operate as specified Piping Systems 1 Adjust balancing valves to provide the specified liquid flows for each system and each system co
238. ions weights and loadings static deflections hanger sizes spring sizes materials of construction required clearances and location and size of field connections Clearly indicate where the isolators are to be installed on the project Submit the required number of Submittals product data sheets Clearly indicate product features options loading rated capacities and other data pertinent to fully describe the product Refer to Section 15010B for additional requirements regarding submittals Submit manufacturer s installation instructions 1 3 DELIVERY STORAGE AND HANDLING Comply with manufacturer s installation instructions for handling storage and protection of products furnished under this Specification Refer to Section 15010B Mechanical General Provisions 1 4 WARRANTY A Provide a full parts warranty for one year from start up or 18 months from shipment whichever occurs first The guarantee shall be in effect from the day of final acceptance The manufacturer shall guarantee his equipment to perform in accordance with specified performance The guarantee shall include all parts and labor to repair or replace factory defects Assembly erection or installation by other than manufacturer s forces shall not affect his guarantee if performed in accordance with his instructions If inspection or supervision of assembly erection or installation by a representative of the manufacturer is required to validate his guar
239. iping B31 1 2 Contractor shall perform accurate weight balance calculations to determine the required supporting force at each hanger location and anchor point and the pipe weight load at each equipment connection 3 Hangers and supports shall be selected to support the weight of the pipe fittings and valves weight of the medium transported or the medium used for testing whichever is heavier and the weight of the insulation covering used 4 All pipe and tubing shall be supported as required to prevent significant stresses in the pipe or tubing material valves and fittings and to support and secure the pipe in the intended position and alignment All supports shall be designed to adequately secure the pipe against excessive dislocation due to thermal expansion and contraction internal flow forces and all probable external forces such as equipment pipe and personnel contact 5 All materials used in manufacturing hangers and supports shall be capable of meeting the respective ASTM Standard Specifications with regard to tests and physical and chemical properties and be in accordance with MSS SP 58 Manufacturer s Standardization Society 6 Hangers and supports shall be spaced in accordance with MSS SP 69 Table 3 Hangers 1 All hangers shall have some form of adjustment available after installation 2 Type A hangers shall be standard weight carbon steel adjustable clevis type hanger with black or plain finish approved by
240. is Specification In addition submit product data sheets and installation details for duct joint components MANUAL VOLUME CONTROL DAMPERS A Rectangular Dampers 1 Manual rectangular dampers shall be constructed of minimum 16 gauge mill finish galvanized steel frames and blades with linkage out of the air stream Dampers shall be opposed blade type and unless noted otherwise shall be furnished without blade edge seals Blades shall be 6 wide secured to nominal 1 2 diameter shafts Bearings shall be molded synthetic type bearings or the equivalent Furnish all manual dampers with a matching heavy duty hand quadrant with minimum 1 1 2 clearance for duct insulation systems Manual dampers shall be Safe Air Model 610 Ruskin Model CD35 or approved equal by National Controlled Air Arrow and Louvers amp Dampers Inc for duct velocities up to 1800 fom Where duct velocity exceeds 1800 fpm provide manual dampers equal to Ruskin Model CD50 or CD60 2 Manual dampers for duct sizes up to 180 square inches or smaller may be single blade type construction of 22 gauge galvanized steel frame and blade Damper shall be Ruskin Model MD25 or approved equal by National Controlled Air Arrow Louvers amp Dampers Inc and Safe Air Furnish with integral locking hand quadrant with minimum 1 1 2 clearance for duct insulation systems B Round Dampers Manual round dampers shall be constructed of minimum 20 gauge mill finish galvanized steel frames
241. its and permanent damage to fasteners and anchors 1 4 SUBMITTALS A General Submit the following in accordance with Conditions of Contract and Division 1 Specification Sections 1 2 Product data for each type of product specified Coordination drawings for reflected ceiling plans drawn accurately to scale and coordinating penetrations and ceiling mounted items Show the following a Joint pattern b Ceiling suspension members G Method of attaching hangers to building structure d Ceiling mounted items including light fixtures air outlets and inlets speakers access panels and special moldings at walls column penetrations and other junctures with adjoining construction e Scale 1 4 inch equals 1 0 Samples for initial selection purposes in form of manufacturer s color charts consisting of actual metal units or sections of units showing full range of colors textures and patterns available for each type of unit indicated a 12 inch square samples metal pan units b 12 inch long samples of each exposed molding and exposed trim Cc 12 inch square samples of patterned aluminum panels CUSTOM METAL CEILINGS 09514 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 4 Product test reports from and based on tests performed by qualified independent testing laboratory showing compliance of metal ceiling system and components with requirements based on comprehensive testing of current products 5 Qualification d
242. l be provided as required by the sequence of operations Actuators shall provide the minimum torque required for proper valve close off against the system pressure for the required application The valve actuator shall be sized based on valve manufacturers recommendations for flow and pressure differential All actuators shall fail in the last position unless specified with mechanical spring return in the sequence of operations The spring return feature shall permit normally open or normally closed positions of the valves as required All direct shaft mount rotational actuators shall have external adjustable stops to limit the travel in either direction d Modulating Actuators shall accept 24 VAC or VDC and 120 VAC power supply and be UL listed The control signal shall be 2 10 VDC or 4 20 mA and the actuator shall provide a clamp position feedback signal of 2 10 VDC The feedback signal shall be independent of the input signal and may be used to parallel other actuators and provide true position indication The feedback signal of each valve actuator except terminal valves shall be wired back to a terminal strip in the control panel for trouble shooting purposes e Two position or open closed actuators shall accept 24 or 120 VAC power supply and be UL listed Butterfly isolation and other valves as specified in the sequence of operations shall be furnished with adjustable end switches to indicate open closed position or be hard wired to star
243. l rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 1162824017 1 ATA Document E201 2007 Digital Data Protecol Exhibit completed bythe parties or the 2 Other documents if any listed below List here any additional documents that are intended to form part of the Contract Documents AIA Document A201 2007 provides that bidding requirements such as advertisement or invitation to bid Instructions to Bidders sample forms and the Contractor s bid are not part of the Contract Documents unless enumerated in this Agreement They should be listed here only if intended to be part of the Contract Documents 00020 Invitation to Bid 00100 Instruction to Bidders 00310 Bid Form for General Construction ARTICLE 10 INSURANCE AND BONDS The Contractor shall purchase and maintain insurance and provide bonds as set forth in Article 11 of AIA Document A201 2007 State bonding requirements if any and limits of liability for insurance required in Article 11 of AIA Document A201 2007 Type of insurance or bond
244. lems All information shall be assembled in a three ring binder with index tabs to identify each item of major equipment and each system SCOPE OF WORK A SYSTEM PREPARATION START UP INITIAL TESTING AND PLACING IN SERVICE shall be performed by the Mechanical Contractor The Mechanical Contractor shall be responsible for performing initial equipment and system checks and system start up in order to prepare the system s for testing adjusting and balancing The Mechanical Contractor shall furnish specific project information to the TAB Contractor including but not limited to the following Two 2 sets of all submittal data complete shop drawings duct and pipe 15042B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 TESTS fabrication or layout drawings contract drawings project specifications controls system s shop drawings and initial system testing reports for use by the TAB Contractor SYSTEM TESTING ADJUSTING AND BALANCING TAB shall be performed by an independent TAB Contractor certified in performing TAB services have trained in house staff and have certified test equipment for performing Testing Adjusting and Balancing in accordance with appropriate sections of the AABC or NEBB standards Furthermore the independent TAB Contractor shall demonstrate that they have been providing TAB services on projects for the previous five 5 consecutive years that are similar in size and scope
245. les and other ceiling components that cannot be successfully cleaned and repaired to permanently eliminate evidence of damage END OF SECTION 09512 ACOUSTICAL TILE CEILINGS 09512 6 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 09514 CUSTOM METAL CEILINGS PART 1 GENERAL 1 1 RELATED DOCUMENTS A Drawings and general provisions of Contract including General and Supplementary Conditions and Division 1 Specification Sections apply to this Section 1 2 SUMMARY A This Section includes the following 1 Unperforated steel ceilings 2 Patterned aluminum ceilings 3 Extruded aluminum ceiling grid B Related Sections The following sections contain requirements that relate to this section Te Division 9 Section Acoustical Tile Ceilings for mineral base acoustical tile ceilings Division 15 Section Air Outlets and Inlets for grilles registers and diffusers in acoustical metal pan ceilings 3 Division 16 Section Interior Lighting Fixtures for lighting fixtures in acoustical metal pan ceilings 1 3 SYSTEM PERFORMANCE REQUIREMENTS A Structural Performance Design engineer fabricate and install interior metal ceiling systems to withstand the effects of loads and stresses from wind and normal thermal movement without showing permanent deformation of ceiling system components including pans and suspension system noise or metal fatigue caused by vibration deflection and displacement of ceiling un
246. lications c Operator I O Portable Service Terminal 4 Point Types Each FCU controller shall support the following types of point inputs and outputs a Analog inputs shall monitor the following analog signals 1 4 20 mA Sensors 2 0 10 VDC Sensors 3 10000hm RTDs b Binary inputs shall monitor dry contact closures Input shall provide filtering to eliminate false signals resulting from input bouncing C Counter inputs shall monitor dry contact pulses with an input resolution of one HZ minimum d Analog outputs shall provide the following control outputs 1 4 20 mA Sink or Source 2 0 10 VDC e Binary outputs shall provide SPDT output contacts rated for 2 amps at 24 VAC Surge and noise suppression shall be provided on all pilot relays Inductive loads i e solenoids shall be controlled by pilot relays f TriState outputs shall be paired binary outputs for use as Power Close Power Open control output contacts rated for 2 amps at 24 VAC Surge and noise suppression shall be provided on all pilot relays 5 Manual Overrides a Manual override switches shall be provided for all binary outputs that do not have a MCC Hand Off Auto switch b Switches shall be mounted within the system controller key accessed enclosure or the adjacent local control panel C Switches for analog outputs shall be rotary gradual position providing the full analog signal range of the associated analog output and shall be ope
247. ll be agreed upon by the Contractor and the Architect 13 10 Compliance with Laws 13 10 1 Contractor if applicable assures that it will undertake an affirmative action program as required by 14 CFR Part 152 Subpart E to ensure that no person shall on the grounds of race creed color national origin or sex be excluded from participating in any employment activities covered in 14 CFR Part 152 Subpart E Contractor assures that no person shall be excluded on these grounds from participating in or receiving the services or benefits of any program or activity covered by said subpart Contractor assures that it will require assurances from its suborganizations as required by 14 CFR Part 152 Subpart E to the same effect 13 10 2 Contractor shall comply at its own expense with all applicable laws rules regulations and orders concerning civil rights and minorities now in force or hereafter prescribed or promulgated by Federal State or local governments or Owner whether foreseen or unforeseen or ordinary or extraordinary 13 10 3 Contractor agrees to observe and comply with all requirements of the constituted public authorities and all Federal State and local statutes laws ordinances rules regulations and standards now and hereafter in force which may be applicable to the operations of Contractor pursuant to this contract including but not limited to such Rules and Regula tions as may be adopted by the Owner and without in any man
248. ll be professionally painted or enameled as directed to match or blend with adjacent surfaces In unfinished areas such as equipment rooms etc exposed equipment shall be furnished with suitable factory applied finish Equipment furnished in finishes such as stainless steel brushed aluminum etc shall not be painted All finishing shall be as directed by and satisfactory to the Owner 3 4 EQUIPMENT LABELS ETC A Suitable nameplates shall be provided for the identification of major items of electrical ELECTRICAL GENERAL REQUIREMENTS 16010 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B C D equipment including panelboards safety switches enclosed circuit breakers etc Nameplates shall be of engraved plastic laminate not less than 1 16 thick Engraving shall be of professional quality with block style letters minimum 1 4 high Nameplates shall be attached with pop rivets or with epoxy glue 3 5 FOUNDATIONS SUPPORTS PIERS ATTACHMENTS A This Contractor shall furnish and install all necessary foundations supports pads and piers required for all equipment furnished under this contract All equipment unless otherwise shown shall be securely attached to the building structure in an approved manner 3 6 ACCEPTANCE TESTS AND GUARANTEE A Upon completion of work Contractor shall demonstrate and make such tests as may be required to satisfy Owner that construc
249. ll be submitted for approval where changes are significant or impact the work of other trades PART 2 PRODUCTS 2 1 DUCTWORK MATERIALS A C D General Non combustible or conforming to requirements for Class 1 air duct materials or UL 181 System GS galvanized steel shall meet requirements of ASTM A90 ASTM A525 and ASTM A527 Steel Sheet Zinc Coated by the Hot Dip Process Lock Forming Quality based on G 90 coating Insulated low pressure flexible ductwork shall conform to the requirements of UL 181 and the requirements of this Specification Section Fasteners such as rivets bolts or sheet metal screws shall be of same material as duct system Fasteners for galvanized steel shall be cadmium plated or galvanized steel 2 2 SUPPORTS AND HANGERS A C D DUCTWORK Materials and Finish for supports hangers fasteners and accessories shall be as scheduled for hangers in Section 158408 and shall comply with the following 1 System BS black steel shall be ASTM A 36 carbon steel with black or plain mill finish Components shall be cleaned and painted with primer after fabrication Primer shall be touched up after installation Primer color shall be selected by Owner s representative 2 System GS galvanized steel sheet materials shall meet requirements of ASTM A90 ASTM A525 and ASTM A527 Steel Sheet Zinc Coated by the Hot Dip Process Lock Forming Quality based on G 90 coating Hanger
250. llowing J American Gypsum 2 CertainTeed Corp GYPSUM BOARD 09290 1 PTIA Ticket Counter Ceiling Renovation 12 0001 000 2 3 2 4 2 5 3 Georgia Pacific Gypsum LLC 4 Lafarge North America Inc 5 National Gypsum Company 6 PABCO Gypsum ls Temple Inland 8 USG Corporation Gypsum Wallboard ASTM C 1396 C 1396M 1 Thickness 5 8 inch Flexible Gypsum Board ASTM C 1396 C 1396M Manufactured to bend to fit radii and to be more flexible than standard regular type gypsum board of same thickness 1 Thickness 1 4 inch 2 Long Edges Tapered Gypsum Ceiling Board ASTM C 1396 C 1396M 1 Thickness 1 2 inch 2 Long Edges Tapered TRIM ACCESSORIES Interior Trim ASTM C 1047 1 Material Galvanized or aluminum coated steel sheet or rolled zinc Aluminum Trim ASTM B 221 Alloy 6063 T5 JOINT TREATMENT MATERIALS General Comply with ASTM C 475 C 475M Joint Tape 1 Interior Gypsum Board Paper Joint Compound for Interior Gypsum Board For each coat use formulation that is compatible with other compounds applied on previous or for successive coats AUXILIARY MATERIALS Laminating Adhesive Adhesive or joint compound recommended for directly adhering gypsum panels to continuous substrate GYPSUM BOARD 09290 2 PTIA Ticket Counter Ceiling Renovation 12 0001 000 B Steel Drill Screws ASTM C 1002 unless otherwise indicated PART 3 EXECUTION 3 1 APPLYING AN
251. low manual positioning Modulating actuators shall accept 24 VAC or VDC power supply consume no more than 15 VA and be UL listed The control signal shall be 2 10 VDC or 4 20 mA and the actuator shall provide a clamp position feedback signal of 2 10 VDC The feedback signal shall be independent of the input signal and may be used to parallel other actuators and provide true position indication The feedback signal of one damper actuator for each separately controlled damper shall be wired back to a terminal strip in the control panel for trouble shooting purposes Two position or open closed actuators shall accept 24 or 120 VAC power supply and be UL listed Isolation smoke exhaust fan and other dampers as specified in the sequence of operations shall be furnished with adjustable end switches to indicate open closed position or be hard wired to start stop associated fan Two position actuators as specified in sequences of operations as quick acting shall move full stroke within 20 seconds All smoke damper actuators shall be quick acting FMS CONTROLS AND INSTRUMENTATION 15900B 10 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 Electronic Valve Actuators a Electronic valve actuators shall be manufactured by the valve manufacturer b Each actuator shall have current limiting circuitry incorporated in its design to prevent damage to the actuator C Modulating and two position actuators shal
252. ly as covered by the American National Standard B16 5 Where flanges larger than those covered by the ANSI Standard are required they shall be submitted for approval at time of bid Carbon steel flanges shall not be back faced or spot faced below standard thicknesses Pipe in screwed flanges shall seal within 1 16 to 1 8 of face Flange bolt holes shall straddle vertical pipe center lines Bolts in flanged joints shall be drawn up to provide even and adequate pressure to seat the gaskets and to provide relatively uniform stresses in the bolts All flanged joints shall be made with new undamaged gaskets and bolting materials as specified in Piping Schedules in Section 15060SB Care shall be taken to assure that all gaskets are properly positioned prior to tightening of the bolts Care shall be taken to avoid over torquing any bolts Bolts and nuts which are over torqued shall be replaced 3 10 FITTINGS A Reducers Make changes in pipe size by using factory made reducers Use eccentric reducers in horizontal gravity flow systems with the flat side on bottom Bushings victaulic reducing couplings and field made reducers will not be permitted Tees weldolets sockolets and threadolets or factory made tee fittings shall be used for branch connections when the diameter of the branch connection does not exceed 50 of the diameter of the main otherwise factory made tee fittings shall be used for tee connections PIPE PIPE FITTING
253. mark each item to record actual construction including a Manufacturer trade name and catalog number of each product actually installed particularly optional items and substitute items MECHANICAL GENERAL PROVISIONS 15010B 17 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 b Changes made by Addenda and Modifications 9 Other Documents Maintain manufacturer s certifications inspection certifications field tests and startup records and other information required by individual Specification sections Operating amp Maintenance Manuals Submit as described elsewhere in this section H Testing Adjusting and Balancing Reports Submit as described elsewhere in this Specification Division I Spare parts and maintenance materials if required by these Contract Documents shall be delivered to Owner as directed by Owner s representative J Statement of payment of taxes K Affidavit of Payment of Debts and Claims L Affidavit of Release of Liens END OF SECTION 15010B MECHANICAL GENERAL PROVISIONS 15010B 18 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15035B MECHANICAL IDENTIFICATION PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 REFERENCES ANSI 253 1 Safety Color Code for Marking Physical Hazards 1 3 SUBMITTALS Submit shop drawings in accordance with Section 15010B Submittals shall include bu
254. ment or unfinished block insulation D Finished Spaces All areas except pipe and duct tunnels shafts and chases and spaces above furred or dropped ceilings E Foamed Plastic Plastic expanded by thermal or chemical means containing closed cells throughout Glass Fiber A composite material consisting of glass fibers with a resin binder Mineral Wool A generic term which applies to all types of inorganic fibrous insulations H Perm The measure of vapor transmission in grains of water through one square foot of a membrane in an hour at one inch mercury pressure difference l PVC Polyvinyl Chloride A polymerized vinyl compound using chloride J Rock Wool A generic term which applies to all types of inorganic fibrous insulations Also includes mineral wool products K Sealer A liquid coating used to prevent excessive absorption of finish coats into porous surfaces L Solvent Weld A bonding method which uses a liquid solvent to dissolve one substance or material to form an adhesive base to permanently seal a joint usually associated with PVC plastic materials M Vapor Retarder formerly Vapor Barrier A membrane installed on the high vapor pressure side of an insulation material to prevent moisture penetration A vapor retarder shall have a rating of 0 02 Perms or less N Vapor Retarder Jacket Any material or composite meeting the requirements of a vapor retarder and used for the finish of insulation material It may
255. mmended SUPPORTS ANCHORS AND SEALS 15090B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 2 3 3 support spacing for Copper Tube Water Service or Air Steam or Gas Service A NOMINAL PIPE MAXIMUM SPAN IN FEET Sizes Inches Water Service Air Steam or Gas 1 1 2 and below 7 9 2 and 2 1 2 10 13 3 12 15 4 and 5 14 17 6 17 21 8 and 10 19 24 12 and 14 23 30 16 and 18 27 35 20 and 24 30 39 Provide pipe hanger or support within 18 of every change in direction for piping 1 1 2 and below and within 3 of every change in direction for piping 2 and above Provide additional support as required to maintain alignment avoid excess stress and prevent sagging where there are concentrated loads such as valves or specialties Provide anchors braces rigid supports or guides as required to restrict excessive motion in piping Support horizontal plastic piping and control air tubing every 4 and at every change in direction Follow pipe manufacturer s recommendations for support spacing based on material type application and service temperature HANGER RODS Use hanger rods sized as follows A Ferrous piping and copper tubing 2 pipe and smaller 3 8 diameter 2 1 2 and through 3 1 2 1 2 diameter 4 and 5 pipe 5 8 diameter 6 pipe 3 4 diameter 8 through 12 pipe 7 8 diameter 14 and 16 1 diameter 18 through 24 pipe 1 1 4 diameter SUPPORT AND ATTACHMENTS
256. movement without cracking so as to provide an airtight and watertight flexible joint seal Product shall have maximum flame spread rating of 10 smoke developed rating of 25 Gasket materials shall be Ductmate 440 Tape or approved equal and shall be as recommended by the joint system manufacturer Gasket materials shall be non skinning non oxidizing product capable of withstanding joint movement without cracking or excessive deformation so as to provide a functional airtight and watertight flexible joint seal Product shall have a maximum flame spread rating of 10 smoke developed rating of 25 Duct joint systems shall have been tested in accordance with SMACNA test procedures with test results certified in writing by an independent testing laboratory Tests of joint performance shall clearly indicate whether or not an external sealant was applied in conjunction with the manufactured duct joint system 1 SMACNA Class J transverse joints shall be accomplished using the Ductmate 35 Systems as manufactured by Ductmate Industries The Ductmate 35 Systems shall not be used with duct gauges heavier than 16 gauge or lighter than 26 gauge in accordance with the manufacturer s recommendations 2 SMACNA Class F transverse joints shall be accomplished using the Ductmate 25 Systems as manufactured by Ductmate Industries The Ductmate 25 Systems shall not be used with duct gauges heavier than 20 gauge or lighter than 26 gauge in accordance wit
257. mperature limit switch shall be of the manual reset type with Double Pole Single Throw snap acting contacts rated for 16 amps at 120VAC b The sensing element shall be a minimum of 15 feet in length and shall react to the coldest 18 inch section Element shall be mounted horizontally across duct in accordance with manufacturers recommended installation procedures Cc For large duct areas where the sensing element does not provide full OUTPUT DEVICES A Actuators coverage of the air stream additional switches shall be provided as required to provide full protection of the air stream 1 General Requirements Damper and valve actuators shall be electronic as specified in the System Description section 2 Electronic Damper Actuators a b Electronic damper actuators shall be direct shaft mount Modulating and two position actuators shall be provided as required by the sequence of operations Damper sections shall be sized based on actuator manufacturers recommendations for face velocity differential pressure and damper type The actuator mounting arrangement and spring return feature shall permit normally open or normally closed positions of the dampers as required All actuators except terminal units shall be furnished with mechanical spring return unless otherwise specified in the sequences of operations All actuators shall have external adjustable stops to limit the travel in either direction and a gear release to al
258. mponent Measure flow at each balancing valve using flow versus pressure chart and liquid electronic or dial type manometer recommended by valve manufacturer 2 Balance each individual chilled water and hot water coil 3 After making adjustments to coils and valves where installed retest settings at pumps and equipment Re adjust if required 4 Upon completion of flow readings and coil adjustments and after water balance is complete permanently scribe or punch mark all balancing valves cocks and fittings so that they can be restored to their correct position if disturbed 15042B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 5 Provide any pressure taps thermometer wells balancing valves balancing cocks fittings and the like required for water balance 6 If flow measuring devices are not specified for each coil install temporary pressure gages on inlet and outlet of each coil at time of balancing C Ductwork Systems 1 Adjust fan speeds duct systems and components to provide air quantities within 10 percent of specified requirements under minimum and maximum flow conditions at each air inlet outlet and variable air volume terminal unit 2 Measure air quantities in main and branch ducts by traversing cross sectional area of duct with pitot tube Ducts having minimum velocities of 1000 feet per minute or more shall be measured with inclined manometers draft gage or magnehelic gages
259. mstrong 520 Rubatex R 373 or equal Fabricate fitting covers from miter cut tubular insulation using over sized insulation segments lapped over adjacent sections Do not stretch insulation to fit use proper lengths of materials d Unless scheduled otherwise indoor applications will not require protective finish coats Provide high density insulation inserts calcium silicate or compressed glass at the hanger support and the pipe to prevent compressing the foamed plastic insulation at pipe hangers Thoroughly seal all joints at the insulation inserts When protective or weather barrier finishes are specified apply a single layer of reinforcing fiberglass cloth fully adhered to the surface Apply two finish coats of sealant specified for foamed plastic insulations Adhesives and sealants shall be compatible and approved for use on foamed plastics C Calcium Silicate Insulation Apply thickness shown in insulation schedule 1 Tightly butt edges half sections and break joints Secure with wire for small areas and aluminum bands 12 o c for large areas Where required provide welded studs clips or angles as anchors for wires and bands 2 Cover valves bonnets flanges and fittings with molded calcium silicate fitting insulation where commercially available 3 Cover valves bonnets flanges and fittings with fabricated mitered segments of molded calcium silicate of same thickness as insulation on adjacent pipe wired in place Fini
260. n 1 0 Service Factor prelubricated ball bearings 2 7 THREE PHASE POWER SQUIRREL CAGE MOTORS A B C Starting Torque Between one and one and one half times full load torque Starting Current Six times full load current Power Output Locked Rotor Torque Breakdown or Pullout Torque NEMA Design B characteristics Design Construction Testing and Performance Conform to ANSI NEMA MG 1 for Design B motors Insulation System NEMA Class B or better Testing Procedure In accordance with ANSI IEEE 112 Test Method B Load test motors to determine freedom from electrical or mechanical defects and compliance with performance data Motor Frames NEMA standard T frames of steel aluminum or cast iron with end brackets of cast iron or aluminum with steel inserts Bearings Grease lubricated anti friction ball bearings with housings equipped with plugged provision for relubrication rated for minimum AFBMA 9 L 10 life of 200 000 hours Calculate bearing load with NEMA minimum V belt pulley with belt center line at end of NEMA standard shaft extension Stamp bearing sizes on nameplate Sound Power Levels To ANSI NEMA MG 1 Part Winding Start Where Indicated Use part of winding to reduce locked rotor starting current to approximately 60 percent of full winding locked rotor current while providing approximately 50 percent of full winding locked rotor torque Nominal Efficiency Meet or exceed values in Schedules at full lo
261. n A statement setting forth changes in other materials equipment or other portions of the work including changes in the work of other contracts that incorporation of the proposed substitution would require shall be included The burden of proof of the merit of the proposed substitution is upon the proposer The Architect s decision of approval or disapproval of a proposed substitution shall be final If the Architect approved a proposed substitution prior to receipt of Bids such approval will be set forth in an Addendum Bidders shall not rely upon approvals made in any other manner No substitutions will be approved after award of the contract unless specifically provided for in the contract documents Bid Form Bids shall be submitted on the form furnished herein A loose copy of Bid Form can be provided if requested for submitting Bid All blank spaces shall be filled in correctly for each and every item for which a price or information is requested The Bidder shall state the price typewritten or written in ink both in words and numerals for each item Signature on Bid The Bidder must sign the bid correctly If made by an individual his or her name and post office address shall be shown If made by a firm or partnership the name and post office address of each member of the firm or partnership shall be shown If made by a corporation the person signing the Bid shall show the name of the state under the laws of which the corporation was char
262. n the North Carolina State Building Code and manufacturer s recommendations where applicable 1 4 SHOP DRAWINGS Submit shop drawings of the following A r O nmu oO K L Ductwork layout and dimensions at minimum scale of 1 4 1 0 for each floor level to include project coordination details Ductwork layout dimensions and sections at minimum scale of 1 2 1 0 for each mechanical room and mechanical chase to include project coordination details Rectangular duct reinforcements for 1 2 3 4 and 6 w g class construction Intermediate duct reinforcement details Transverse joint reinforcement details Tie rod installation details Corner closure details Duct sealing details Fittings and other construction details to include elbows transitions turning vanes branch connections offsets obstructions volume dampers and air distribution connections Ductwork accessories to include flexible connections spin in fittings access doors bird screen gaskets duct tape duct sealant sealer and instrument test ports Flexible duct installation details Hangers and supports 1 5 DUCTWORK MATERIALS A DUCTWORK HVAC Ductwork General 15840B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 1 All HVAC ductwork unless otherwise specifically indicated on the Drawings shall be galvanized steel conforming to the requirements of ASTM A90 ASTM A525 and AS
263. n Board IB 600 B KF Insulation Board 6 0 C MP 800 Series Spin Glas 817 D O C 700 Series Insulation 705 CALCIUM SILICATE INSULATION Pipe and Equipment ASTM C 533 calcium silicate pipe and block insulation Insulation shall be Type 1 rigid heavy density half section or block form with a minimum average density of 13 5 lb cu ft minimum 150 psi compressive strength for five percent compression based on 1 50 block thickness 1200 F insulation service temperature and K value of maximum 0 40 at 200 F mean temperature The insulation shall not contribute to stress corrosion cracking of austenitic stainless steel and shall meet the requirements of ASTM C 795 Insulation flame spread and smoke developed ratings shall be zero 0 Acceptable Products A MP Thermo 12 Blue Pipe and Block insulation B O C Kaylo insulation C Pabco Super Caltemp insulation D Calsilite Calcium Silicate insulation CELLULAR GLASS INSULATION Pipe and Equipment ASTM C 552 for cellular glass block and pre formed pipe insulation Product shall be rigid 100 psi compressive strength minimum 8 0 lb cu ft average density service temperature range of 450 F to 900 F K value of 0 33 at 75 F mean temperature Insulation shall be non combustible and have a water vapor permeability of 0 00 perm in Material shall be pure glass totally inorganic containing no binders and have a UL flame spread rating of 5 and a smoke developed rating of 0 Insula
264. n fire partitions Access doors shall be as specified in the Architectural sections of the Specifications and on the Drawings E Access doors in ductwork and related surfaces shall be provided by the Mechanical Contractor as specified in Section 15840B Ductwork PART 3 EXECUTION 3 1 GENERAL A Contractor shall provide all materials and equipment called for in these Specifications and accompanying Drawings complete in every respect Anything called for in the Specifications and not shown on the Drawings or shown on the Drawings and not called for in the Specifications shall be furnished by the Contractor B Contractor shall follow the Drawings in laying out work and check drawings of other trades to verify spaces in which work will be installed Maintain maximum headroom and space conditions at all points Where headroom or space conditions appear inadequate the Owner s representative shall be consulted before proceeding with the installation C The Drawings are diagrammatic and are not intended to show each and every duct pipe fitting valve damper pipe hanger and the like or a complete detail of all the work to be done but are for the purpose of illustrating the type of system showing pipe sizes duct sizes equipment locations and the like and special conditions considered necessary for the experienced mechanic to take off his materials and lay out his work This Contractor shall be responsible for taking such measuremen
265. n from damage or deterioration at Substantial Completion Clean and provide maintenance on completed construction as frequently as necessary through the remainder of the construction period Adjust and lubricate operable components to assure operability without damaging effects Limiting Exposures Supervise construction operations to assure that no part of the construction completed or in progress is subject to harmful dangerous damaging or COORDINATION 01040 2 PTIA Terminal Building Security Expansion 02 094 000 otherwise deleterious exposure during the construction period Where applicable such exposures include but are not limited to the following Excessively high or low humidity Air contamination or pollution Solvents Chemicals Light Combustion Electrical current Improper lubrication Unusual wear or other misuse 10 Contact between incompatible materials 11 Misalignment 12 Excessive weathering 13 Unprotected storage 14 Improper shipping or handling 15 Theft 16 Vandalism O00 SOF OT RO Ns END OF SECTION 01040 COORDINATION 01040 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 01300 SUBMITTALS PART 1 GENERAL 1 1 RELATED DOCUMENTS A Drawings and general provisions of the Contract including General and Supplementary Conditions and other Division 1 Specification Sections apply to this Section 1 2 SUMMARY A This Section includes administrati
266. n less than 0 05 perms 3 PVC jackets and accessories shall be minimum 20 mil 0 020 inch thick suitable for use with solvent type welding adhesive All jacketing materials shall have a smooth high gloss sanitary finish UV resistant Color White 4 Adhesives tapes sealant and solvent weld compounds shall be compatible with the jacketing materials and recommended for use by the manufacturer Vapor retarder jackets applied to the insulation shall also be compatible with the PVC jacketing 5 Furnish precut or field fabricated insulation inserts for all pipe fittings and accessories Insulation inserts shall be constructed of insulation matching the service pipe insulation 6 For piping and round ductwork applications provide pre curled jacket sections sized to yield a minimum one inch 1 overlap of the installed insulation assembly Pre curled jacketing shall be MP Zeston 2000 PVC Cut amp Curled jacketing or approved equal 7 Acceptable products subject to compliance with this specification MP Zeston 2000 PVC Foster Speedline 25 50 Smoke Safe Accessible Products Company Type 800HD or approved equal Kraft and Foil Pipes and Equipment Meet or exceed ASTM C 1136 NFPA 90A requirements permanently flame retardant and ULL listed Outer ply minimum 35 Ib white bleached embossed kraft Inner ply aluminum foil reinforced with fiberglass yarn 1 16 o c both directions Ply bonding adhesive flame extinguishing Wate
267. n of all supports shall be subject to Owner s representative s approval L Solid or perforated strap hangers and wire hangers will not be permitted except for temporary supporting during construction M Hanging from unreinforced metal roof deck or from cellular roof deck will not be permitted N Welded and bolted attachments to the building structural steel shall be in accordance with the requirements of AISC Specification for the Design Fabrication and Erection of Structural Steel Buildings O All welds shall be performed by certified welders P Repaint all existing or new building steel where the paint is scraped or burned away during welding operations to match existing paint finishes Q Painting 1 Immediately after surface preparations apply shop paint in accordance with manufacturer s printed instructions and at a rate to provide a uniform dry film thickness as specified 2 Use painting methods that will result in full coverage of joints corners edges finished welds and all surfaces 3 Painting materials and methods shall comply with Specification Section Painting in the Contract Documents 2 3 FITTINGS DAMPERS AND ACCESSORIES FOR ALL DUCT SYSTEMS shall be of the same DUCTWORK 15840B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 4 2 5 2 6 2 7 2 8 2 9 2 10 material as the adjacent duct FITTINGS FOR FACTORY MANUFACTURED DUCT SYSTEMS shall be of sam
268. n of the contract or subcontract for default at no cost to the Government Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this provision The knowledge and information of a contractor is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings This certification concerns a matter within the jurisdiction of an agency of the United States of America and the making of a false fictitious or fraudulent certification may render the maker subject to prosecution under Title 18 United States Section 1001 NAME OF BIDDER BY TITLE DATE BID FORM 00310 10 PTIA Ticket Counter Ceiling Renovation 12 001 000 This Affidavit is Part of Bid BUY AMERICAN CERTIFICATE By submitting a bid proposal the offeror certifies that steel and each manufactured product is produced in the United States as defined in the clause Buy American Steel and Manufactured Products or Buy American Steel and Manufactured Products For Construction Contracts and that components of unknown origin are considered to have been produced or manufactured outside the United States Any material that is not produced or manufactured in the United States must have been granted a waiver by the Federal Aviation Administration FAA PRIOR TO BID List all waivers below and include
269. nate masonry cutting to achieve neat openings for boxes Provide knockout closures for unused openings Support boxes independently of conduit except for cast boxes that is connected to two rigid metal conduits both supported within 12 inches of box Use multiple gang boxes where more than one device are mounted together do not use sectional boxes Provide barriers to separate wiring of different voltage systems Install boxes in walls without damaging wall insulation Coordinate mounting heights and locations of outlets mounted above counters benches and backsplashes Position outlets to locate luminaires as shown on reflected ceiling plans In inaccessible ceiling areas position outlets and junction boxes within 6 inches of recessed luminaire to be accessible through luminaire ceiling opening Provide recessed outlet boxes in finished areas secure boxes to interior wall and partition studs accurately positioning to allow for surface finish thickness Use stamped steel stud bridges for flush outlets in hollow stud wall and adjustable steel channel fasteners for flush ceiling outlet boxes Align wall mounted outlet boxes for switches thermostats and similar devices CONDUIT AND BOXES 16130 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 L Provide cast outlet boxes in exterior locations and wet locations 3 7 PULL AND JUNCTION BOX INSTALLATION A Provide and install all boxes in accorda
270. nce with 49 CFR 30 17 no contract shall be awarded to a contractor or subcontractor who is unable to certify to the above If the contractor knowingly procures or subcontracts for the supply of any product or service of a foreign country on the said list for use on the project the Federal Aviation Administration may direct through the sponsor cancellation of the contract at no cost to the Government Further the contractor agrees that if awarded a contract resulting from this solicitation it will incorporate this provision for certification without modification in each contract and in all lower tier subcontracts The contractor may rely upon the certification of a prospective subcontractor unless it has knowledge that the certification is erroneous The contractor shall provide immediate written notice to the sponsor if the contractor learns that its certification or that of a subcontractor was erroneous when submitted or has become erroneous by reason of changed circumstances The subcontractor agrees to provide immediate written notice to the contractor if at any time it learns that its certification was erroneous by reason of changed circumstances This certification is a material representation of fact upon which reliance was placed when making the award If it is later determined that the contractor or subcontractor knowingly rendered an erroneous certification the Federal Aviation Administration may direct through the sponsor cancellatio
271. nce with the requirements of Articles 370 373 and 501 of the National Electric Code B Install pull and junction boxes where indicated on Drawings In addition install pull boxes per the following for above grade conduit runs 1 Install pull boxes in each conduit run such that the total of all bends including offsets does not exceed 360 2 Install pull boxes in conduit runs containing wire sizes 1 AWG or smaller at intervals not exceeding 100 ft 3 Install pull boxes in conduit runs containing wire sizes 1 0 AWG and larger at intervals not exceeding 200 ft C Provide pull and junction box sizes as indicated on Drawings Where sizes are not indicated on Drawings size boxes for 600V or less wiring in accordance with Article 314 28 of the NEC and the following table TABLE FOR STANDARD PULL BOX SIZE FOR STRAIGHT PULL 600V Conduit Size Box Size Length Width Depth 1 1 1 8 4 4 2 24 6 6 2 1 30 6 6 3 36 6 6 3 1 2 42 8 8 4 48 1 0 1 0 TABLE FOR STANDARD PULL BOX SIZE FOR ANGLE PULL 600V Conduit Size Box Size Length Width Depth 1 1 2 18 18 4 2 24 24 6 2 1 2 30 30 6 3 32 32 6 4 36 36 10 D Rigidly support all boxes directly from ceiling or walls or via hangers END OF SECTION 16130 CONDUIT AND BOXES 16130 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16140 WIRING DEVICES PART 1 GENERAL 1 1 WORK INCLUDED A Wall swi
272. nclude the following Muesco Mueller Steam Specialty Armstrong Metraflex Spriax Sarco and Watts PART 3 EXECUTION 3 1 INSPECTION AND PREPARATION A Prior to all piping work carefully inspect the work by other trades and verify that all such work is complete to the point where the piping may be installed in accordance with these documents B Prior to all piping work carefully inspect all existing conditions to verify that the piping may be installed in accordance with these documents PIPE PIPE FITTINGS AND VALVES 15060B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 C Follow the Drawings in layout work and check drawings of other trades to verify sufficient space to install piping D Undimensioned Drawings are intended to indicate the general arrangement of piping systems and are not intended to convey precise locational information E Coordinate with other trades to permit the work of all trades to be installed F Coordinate the work to insure that supports sleeves and inserts are positioned accurately along with other built in items before concrete pouring takes place so as to reduce to an absolute minimum the necessity for cutting or patching at a later stage G Offsets fittings and extra pipe necessary to avoid interference or provide maximum headroom and space shall be furnished and installed without additional expense to the Owner H If the piping is installed without
273. nents before or after its own installation 2 Coordinate installation of different components to assure maximum accessibility for required maintenance service and repair 3 Make provisions to accommodate items scheduled for later installation Where necessary prepare memoranda for distribution to each party involved outlining special procedures required for coordination Include such items as required notices reports and attendance at meetings 1 Prepare similar memoranda for the Owner and separate contractors where coordination of their work is required Administrative Procedures Coordinate scheduling and timing of required administrative procedures with other construction activities to avoid conflicts and assure orderly progress of the Work Such administrative activities include but are not limited to the following COORDINATION 01040 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 Preparation of schedules Installation and removal of temporary facilities Delivery and processing of submittals Progress meetings Project closeout activities OP Go TO Conservation Coordinate construction operations to assure that operations are carried out with consideration given to conservation of energy water and materials 1 Salvage materials and equipment involved in performance of but not actually incorporated in the Work 1 4 SUBMITTALS A Coordination Drawings Prepare coordination drawings where ca
274. ner limiting the generality of the foregoing rules and regulations of the Owner or other governmental unit pertaining to the use or employment of socially and economically disadvantaged individuals laws rules and regulations pertaining to the minorities and laws rules and regulations pertaining to disabled persons insofar as they may be applicable to Contractor 13 11 Forum for Civil Actions 13 11 1 Any action or legal proceeding arising out of or related to this Contract shall be brought in the General Court of Justice of Guilford County North Carolina or in the Federal District for the Middle District of North Carolina and the parties hereby consent to and waive any objection to the jurisdiction or venue of said courts SUPPLEMENTARY CONDITIONS 00800 9 PTIA Ticket Counter Ceiling Renovation 12 001 000 ARTICLE 14 TERMINATION OR SUSPENSION OF CONTRACT 14 3 Suspension by the Owner for Convenience 14 3 2 Delete in its entirety and substitute the following 14 3 2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension delay or interruption as described in Section 14 3 1 The adjustment of the Contract Sum shall not include any profit No adjustment shall be made to the extent 1 that performance is was or would have been so suspended delayed or interrupted by another cause for which the Contractor is responsible or 2 that an equitable adjustment is made or denied under anothe
275. ning Do not use sealant to fill voids or cracks Check for tight seal at all joints and edges and reapply sealant as necessary Do not use broken or cracked insulation products 2 Secure insulation to piping with 0 5 x 0 020 aluminum bands with matching seals or where approved by the insulation manufacturer use one inch wide high tensile strength fiber reinforced strapping tape equal to Scotch Brand Filament Tape Provide metal bands or tape where approved on maximum twelve inch 12 centers Metal jacketing not required on indoor installations unless noted otherwise INSULATION 15250B 10 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 After securing in place apply approved all service vapor barrier jacketing ASJ in accordance with manufacturer s recommendations Provide a minimum two inch overlap of jacket at all joints both circumferential and longitudinal Jacket shall be thoroughly sealed to form a vapor barrier seal over the entire insulation assembly Fittings shall be covered with approved PVC jacketing over the specified insulation 4 Saddles shall be in accordance with the requirements of Section 15090B Supports Anchors and Seals 5 On long straight pipe runs provide expansion joints at 20 foot intervals using wide joints of sealant equal to Childers Chil Byl CP 76 6 Verify that all sealants mastics and the like are compatible for use on the specified insulation systems Allow
276. nnection shall be minimum 7 8 size Fan shall be direct drive centrifugal double width double inlet forward curve type with galvanized steel construction Fan shall be statically and dynamically balanced Motors shall be three speed permanent split capacitor type permanently lubricated with integral thermal overload protection and separate speed connection taps Coils shall be ARI 410 certified and labeled pressure tested at 450 psig 300 psi maximum working pressure and leak tested at 100 psig Fins shall be aluminum mechanically bonded to 1 2 minimum OD tubes 3 8 tubes will be considered at the Owner s option Coils shall be capable of continuous operation at 200 F entering water temperature Filters shall be easily removable 1 thick throw away type with pleated media such as Farr 30 30 or equal Provide louvered bottom panels as scheduled All exposed panels shall be constructed of 16 gauge minimum galvanized steel with 1 mil minimum thickness electrostatic powder spray finish All components requiring access shall be accessible from the bottom of the unit 2 3 ELECTRICAL Unit shall be provided with factory mounted electrical components as indicated on the Drawings and Schedules PART 3 EXECUTION 3 1 FIELD SERVICES Manufacturer shall provide on site system startup services as required for unit installation 3 2 EXTRA STOCK Provide filter sets for construction startup and testing END OF SECTION 15767B
277. nt by wire pulling operations Fasten conduit using galvanized straps lay in adjustable hangers clevis hangers or bolted split stamped galvanized hangers Group conduit in parallel runs where practical and use conduit rack constructed of steel channel with conduit straps or clamps Provide space for 25 percent additional conduit Do not fasten conduit with wire or perforated pipe straps Remove all wire used for temporary conduit support during construction before conductors are pulled Support conduit at a maximum of 7 feet on center unless otherwise noted or indicated on the Drawings 3 2 CONDUIT INSTALLATION A B C N O Cut conduit square using a saw or pipecutter de burr cut ends Bring conduit to the shoulder of fittings and couplings and fasten securely Use conduit hubs or sealing locknuts for fastening conduit to cast boxes and for fastening conduit to sheet metal boxes in damp or wet locations Install no more than the equivalent of three 90 degree bends between boxes Use conduit bodies to make sharp changes in direction as around beams Use hydraulic one shot conduit bender or factory elbows for bends in conduit larger than 2 inch size Avoid moisture traps where possible where unavoidable provide junction box with drain fitting at conduit low point Use suitable conduit caps to protect installed conduit against entrance of dirt and moisture Provide No 10 AWG insulated conductor or suitable pull
278. nt in an electrical box through a hole in the duct and be positioned so as to be easily accessible for repair or replacement b Duct sensors shall be insertion type and constructed as a complete assembly including lock nut and mounting plate C For outdoor air duct applications a weatherproof mounting box with weatherproof cover and gasket shall be used 5 Averaging Sensors a For ductwork greater in any dimension that 48 inches and or where air temperature stratification exists an averaging sensor with multiple sensing points shall be used b For plenum applications such as mixed air temperature measurements a string of sensors mounted across the plenum shall be used to account for stratification and or air turbulence The averaging string shall have a minimum of 4 sensing points per 12 foot long segment C Capillary supports at the sides of the duct shall be provided to support the sensing string FMS CONTROLS AND INSTRUMENTATION 15900B 8 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 6 Carbon Dioxide Sensor Vaisala GMD20 single beam dual wave length sensor with display or Engineer approved equivalent 7 General Air and Water Pressure Transmitter Requirements a Pressure transmitters shall be constructed to withstand 100 pressure over range without damage and to hold calibrated accuracy when subject to a momentary 40 over range input b Pressure transmitters shall transmit a 0 to
279. nt items test each system to determine that 15042B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 all items perform as integral parts of the system Make corrections and adjustments to produce the specified conditions The Contractor shall make any changes in pulleys belts motors dampers and valves and add any dampers and valves as required for achieving correct air and water balancing Contractor shall maintain records of all inspections and tests performed on all systems Records shall indicate which systems were tested date of test test witness es test conditions be specific test pressure and duration test results weather conditions visual inspections percent of system installation completed at time of test specific test observations and pertinent statements for the purpose of qualifying results or observations and number of tests required to achieve a successful test 1 6 INSTRUMENTS A The following instruments shall be furnished by the TAB Contractor for the purpose of performing systems testing and adjusting as specified in this section Instruments required shall include but not be limited to the following 1 Electrical Digital volt ohm clamp on amp 1 2 accuracy Digital Wattmeter 2 Air Alnor velometer optional if Shortridge Velprobe is used Micromanometer Shortridge electronic with velocity probe and grid 8 18 36 and 60 ASME pitot tubes 1 4 oil filled m
280. ntal suspension members and hangers to support ceiling loads within performance limits established by referenced standards 3 Secure wire hangers by looping and wire tying either directly to structures or to inserts eyescrews or other devices that are secure and appropriate for substrate and in a manner that will not cause them to deteriorate corrode and fail with age or elevated temperatures 4 Secure flat angle channel and rod hangers to structure including intermediate framing members by attaching to inserts eyescrews or other devices that are secure and appropriate for structure to which hangers are attached as well as for type of hanger involved and in a manner that will not cause them to deteriorate or fail because of age corrosion and elevated temperatures 5 Do not support ceilings directly from permanent metal forms furnish cast in place hanger inserts that extend through forms Do not attach hangers to steel deck tabs Do not attach hangers to steel roof deck Attach hangers to structural members Space hangers not more than 4 0 o c along each member supported directly from hangers unless otherwise shown and provide hangers not more than 8 inches from ends of each member oN Install edge moldings of type indicated at edges of each metal acoustical ceiling area and at locations where edge of units would otherwise be exposed after completion of work 1 Sealant Bed Apply continuous ribbon of acoustical seal
281. ntractor is liable due to the work on this project shall be included in the Contractor s lump sum bid The contractor shall be responsible for any and all fines that are assessed for lack of compliance to codes laws or any requirements of government agencies The term Successful Bidder means the lowest qualified responsible responsive BIDDER to whom OWNER on the basis of OWNER s evaluation as hereinafter provided makes an award OWNER and ARCHITECT in making copies of the Bidding Documents available on the above terms do so only for the purpose of obtaining bids on the Work and do not confer a license or grant for any other use Substitute or Or Equal Material and Equipment The materials product and equipment described in the Bidding Documents establish a standard of required function dimension appearance and quality to be met by proposed substitution No substitution will be considered prior to receipt of Bids unless the Architect has received substitutions that must have written documentation proving that it meets or exceeds all aspects of the basis of design and shall include a strike off of actual fiber style color weight and backing before January 24 2013 Such requests shall include the name of the material or equipment for which it is to be substituted and a complete description of the proposed substitution including drawings performance and test data and other information necessary for an evaluatio
282. oad currents at each panelboard feeder Should the difference at any panelboard between phases exceed 20 percent rearrange circuits in the panelboard to balance the phase loads within 20 percent Take care to maintain proper phasing for multi wire branch circuits Visual and Mechanical Inspection Inspect for physical damage proper alignment anchorage and grounding Check proper installation and tightness of connections for circuit breakers fusible switches and fuses PANELBOARD SCHEDULE Panelboard types and ratings as indicated or scheduled on the Drawings END OF SECTION 16440 PANELBOARDS 16440 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16500 LIGHTING PART 1 GENERAL 1 1 WORK INCLUDED A Provide complete working lighting systems as shown or indicated on the Drawings and as described in these Specifications Provide new lamps for all lighting fixtures at time of Owner s acceptance Provide supports pole bases cords fittings and all accessories necessary for complete working systems and as shown or indicated on the Drawings and as described in these Specifications 1 2 REFERENCES A ANSI C82 1 Specification for Fluorescent Lamp Ballasts B ANSI C82 4 Specification for High Intensity Discharge Lamp Ballasts Multiple Supply Type C FS W F 414 Fixture Lighting Fluorescent Alternating Current 1 3 SUBMITTALS A Submit product data under provisions of Sec
283. of Boiler and Radiator Manufacturers IBR M Industrial Risk Insurers IRI N Manufacturers Standardization Society of the Valve amp Fittings Industry Standard Practice MSS SP O National Electrical Code NFPA 70 NEC P National Electrical Manufacturer s Association NEMA Q National Fire Protection Association NFPA R Sheet Metal amp Air Conditioning Contractors National Association SMACNA 15010B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 S Steel Structures Painting Council SSPC T Underwriters Laboratories UL U United States Standard USS 1 4 WORK A Provide all labor materials equipment and supervision necessary for a complete installation 1 7 1 8 and start up of equipment and systems required by these Contract Documents B These Specifications and Drawings are intended to require finished work tested and ready for operation Whenever the word provide is used it shall mean furnish and install complete and ready for use C Minor details not usually shown or specified but necessary for the proper installation and operation shall be included in the work the same as if herein specified or shown D Work such as excavation backfill concrete flashing wiring and the like which is required by the work of this Division shall be performed in accordance with the requirements of the applicable section of the Specifications E Some items of equipment may be specified in the
284. omplete details of Mechanical Electrical and Controls work coordination REFERENCED STANDARDS CODES AND ORDINANCES A It is the responsibility of the Controls Contractor to be familiar with all codes rules ordinances and regulations of the authority having jurisdiction and their interpretations which are in effect at the site of the work The latest issue of applicable standards and recommended practices of the following agencies in effect shall form a part of the specification to the extent each agency s relative standards or recommended practices apply to the systems and their components as FMS CONTROLS AND INSTRUMENTATION 15900B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 specified herein 1 Federal Communications Commission FCC 2 American National Standards Institute ANSI 3 American Society of Mechanical Engineers ASME 4 Electronic Industries Association EIA 5 Institute of Electrical and Electronics Engineers IEEE 6 National Electrical Manufacturers Association NEMA 7 National Fire Protection Association NFPA 8 Underwriters Laboratories UL 9 Occupational Safety and Health Administration OSHA 10 American Society of Heating Refrigeration and Air Conditioning Engineers ASHRAE The Controls Contractor shall be solely responsible for compliance with all health and safety regulations performing the work in a safe and competent manner and shall use in
285. omply with the testing and product requirements of the California Department of Health Services Standard Practice for the Testing of Volatile Organic Emissions from Various Sources Using Small Scale Environmental Chambers Glue Aliphatic resin polyurethane or resorcinol wood glue recommended by manufacturer for general carpentry use 1 Wood glue shall have a VOC content of 30 g L or less when calculated according to 40 CFR 59 Subpart D EPA Method 24 Paneling Adhesive Comply with paneling manufacturer s written recommendations for adhesives 1 Adhesive shall have a VOC content of 50 g L or less when calculated according to 40 CFR 59 Subpart D EPA Method 24 PART 3 EXECUTION 3 1 A 3 2 A PREPARATION Before installing interior finish carpentry condition materials to average prevailing humidity in installation areas for a minimum of 24 hours unless longer conditioning is recommended by manufacturer INSTALLATION GENERAL Install interior finish carpentry level plumb true and aligned with adjacent materials Use concealed shims where necessary for alignment 1 Scribe and cut interior finish carpentry to fit adjoining work Refinish and seal cuts as recommended by manufacturer 2 Countersink fasteners fill surface flush and sand unless otherwise indicated 3 Install to tolerance of 1 8 inch in 96 inches for level and plumb Install adjoining interior finish carpentry with 1 32 inch maximum off
286. onal Airport for furnishing labor and materials for construction of PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport Greensboro North Carolina Bidding Requirements Bids will be received for construction of the project as follows SINGLE PRIME CONTRACT Bids will be received up until 2 00 p m local time Thursday February 7 2013 and at that time publicly opened and read aloud Bidders may inspect the applicable bidding requirements and the drawings specifications and other contract documents at the office of the Airport Authority Piedmont Triad International Airport 1000 A Ted Johnson Parkway Greensboro North Carolina or at the office of Lindsey Architecture 125 South Elm St Greensboro North Carolina Bidding documents may be obtained from the office of Lindsey Architecture as follows Purchase Price Make checks payable to Lindsey Architecture Complete sets of Drawings and Specifications 25 00 per set Requests for documents shall include the name of the firm and shall include a phone number fax number mailing address and contact person Proposals Each proposal shall be accompanied by a cash deposit or a cashier s check or certified check drawn on some bank or trust company insured by the Federal Deposit Insurance Corporation of an amount equal to not less than five percent 5 of the proposal or in lieu thereof a bidder may offer a bid bond of five percent 5 of the bid execute
287. or inlet and the mounting surface and gasket of the grille register or diffuser INSTALL OUTLETS AND INLETS level and plumb with building surfaces Fasten securely to the adjacent structure or surface as recommended by the manufacturer with matching tamper proof fasteners PROVIDE T bar panels as required to match standard lay in ceiling modules INSTALL minimum 1 1 2 thick fiberglass blanket insulation with vapor retarder jacket securely taped to the backside plenum side of all supply diffusers installed in lay in ceiling assemblies to prohibit the formation of condensate on the diffuser face END OF SECTION 15870B AIR OUTLETS amp INLETS DISTRIBUTION 15870B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15900B FMS CONTROLS AND INSTRUMENTATION PART 1 GENERAL 1 1 CONTRACT DOCUMENTS The Contract Documents apply to this section 1 2 SCOPE OF WORK OVERVIEW A Johnson Controls system shall be provided as the Base Bid on all controls for this project Invensys formerly Siebe shall be provided as an Alternate Bid Two 2 new fan coil units and three 3 relocated existing terminal units New controls to be provided for each unit and terminal unit and be connected to either the existing Johnson Controls system or the Invensys system Alternate Bid It is intended that the Facility Management System FMS Control and Instrumentation work shall be a subcontract to the Mechanical
288. or submittal of inspection and test reports from independent testing agencies are specified in Division 1 Section Quality Control 1 11 APPROVED EQUAL SUBMITTALS A Submit approved equal submittals including design data certifications manufacturer s instructions manufacturer s field reports and any information that is required for review and other submittals as required under other Sections of the Specifications The burden of proof of the merit of the proposed substitution is upon the proposer 1 Submittal for an Approved Equal are to be submitted to the Architect not less than ten 10 days prior to bid 2 Provide 12 x12 samples for each product submitted 3 The Architect will review and issue a written action within seven 7 days of the submittal 4 The Architects action on an Approved Equal submittal will be final 5 If the Architect approved a proposed substitution prior to receipt of Bids such approval will be set forth in an Addendum 6 Bidders shall not rely upon approvals made in any other manner 7 No substitutions will be approved after award of the contract unless specifically provided for in the contract documents 1 12 ARCHITECT S ACTION SUBMITTALS 01300 6 PTIA Ticket Counter Ceiling Renovation 12 001 000 A B D Except for submittals for the record or information where action and return is required the Architect will review each submittal mark to indicate action tak
289. p feet of water promoa Tp Air Balance Test Data 1 Fan name plate data Unit designation Manufacturer model and serial number Size Arrangement discharge class Motor HP volts phases cycles full load amps Dang Design conditions a CFM b Static pressure inches of water c CFM outside air at minimum outside air d Inlet outlet and outdoor air dry and wet bulb temperatures Deg F Field test results full load and minimum load for variable flow equipment CFM Suction and discharge static pressure inches of water Inlet and outlet air dry bulb temperatures Deg F Fan RPM Fan motor operating volts and amps each phase Dang Velocity tests for main and branch ducts and fresh air intake duct a Duct location and designation b Duct size C Static pressure d Duct average velocity FPM e Total air quantity CFM VAV terminal units Designation Location Manufacturer model and serial number Size Fan nameplate data Maximum air flow setting CFM Minimum air flow setting CFM Entering air temperature Deg F Leaving air temperature Deg F e 9290p 15042B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 j Type controls k Pressure dependent or independent l Entering and leaving air static pressure and velocity sensor differential pressure at max and min flow inches water 6 Individual diffusers registers and grilles a Diffuser regis
290. participation in this transaction by any Federal department or agency or the State of North Carolina All bids must be made on the appropriate Bid Form Each proposal submitted shall be placed in a sealed envelope marked PTIA Ticket Counter Ceiling Renovation Piedmont Triad International Airport Greensboro North Carolina and delivered to the Airport Authority s office at the Piedmont Triad International Airport 1000 A Ted Johnson Parkway Greensboro North Carolina The owner reserves the right to accept or reject any bid to reject all bids and re advertise or to reject all bids without further action whatever appears to be in the best interest of the Project END OF SECTION 00020 INVITATION TO BID 00020 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 00100 INSTRUCTIONS TO BIDDERS 1 10 Bidder is an individual firm or corporation submitting a Bid to the Owner for the items contemplated Sealed Bids will be received at a time and place designated in the INVITATION TO BID The successful Contractor will be required to obtain any and all necessary licenses or permits to conduct the work within their contract as may be prescribed by the State of North Carolina Costs of building and utility permits fees capacity usage fees impact fees or any other fees for inspections required by all City County and or State authorities all Local State and Federal Taxes and all other fees and taxes for which the Co
291. ping shall be performed by the Plumbing Contractor END OF SECTION 15060B PIPE PIPE FITTINGS AND VALVES 15060B 7 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15060SB PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM I D CD CHS CHR HWS HWR Notes 10 DESCRIPTION OPERATING MATERIAL INSULATION NOTES PSIG F SYSTEM SYSTEM Condensate Drain ATM 45 CP 1 E 3 4 7 Chilled Water Supply 60 45 CS 1 E 3 7 9 10 Above ground Chilled Water Return 60 55 CS 1 D E 3 7 9 10 Above ground Drain ATM 45 180 CP 1 2 3 Gas 5 70 CS 1 PL 1 3 5 6 Heating Water Supply 60 180 CP 1 B C G 1 3 8 9 Above ground Heating Water Return 60 160 CP 1 B C G 1 3 8 9 Above ground Use CP 1 solder joint material system for piping at terminal unit hot water coils See detail on Drawings Insulate as required by notes on Drawings and as necessary to prevent a surface temperature above 120 F prevent burning personnel or below 55 F prevent condensation Refer to Section 15035B for pipe painting and identification Insulation thickness on air conditioning condensate drain lines shall be 3 4 thick regardless of pipe size Gas piping shall comply with the requirements of Section 15061B It is the Contractor s option to provide either plastic piping or steel piping outside underground only Aboveground gas piping shall be Material System CS 1 Paint exposed gas piping yellow in accordance with A
292. pment The FMS Controls Contractor shall be responsible for the sizing and selection of all sensors primary signaling devices and controls such as but not limited to flowmeters temperature sensors pressure sensors thermo wells pressure taps damper operators valves and the like The FMS Controls Contractor shall also be responsible for providing instructions for the proper installation of his equipment such as maintaining proper upstream and downstream straight run dimensions on piping and ductwork to receive sensors The Mechanical Contractor shall install the primary sensing elements and controls provided by the FMS Controls Contractor Installation of each item shall be as recommended by the FMS Controls Contractor and instrumentation and controls supplier If the recommendation conflicts with or is substantially different from the Specifications and Drawings the conflict or difference shall be resolved with the Owner s representative before proceeding The Mechanical Contractor shall be responsible for the final installation with regard to proper locations workmanship and final insulation of equipment and systems in which the elements and controls are installed The Mechanical Contractor shall have sole responsibility for providing and installing self contained instruments and controllers such as thermometers and pressure gages installed on piping ductwork and equipment The FMS Controls Contractor shall provide all electrical work
293. point On a rise in temperature the reverse shall occur END OF SECTION 15900B FMS CONTROLS AND INSTRUMENTATION 15900B 19 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16010 ELECTRICAL GENERAL REQUIREMENTS PART 1 GENERAL 1 1 SCOPE A General Conditions of the Contract Special Conditions and Instructions to Bidders contained herein are a part of these specifications This Contractor shall furnish all labor materials and equipment and perform all operations necessary for installation of complete electrical work within the intent of and as indicated on the Drawings and as specified herein 1 2 DEFINITIONS A The word Contractor as used in this section of the specification refers to the Electrical Contractor unless specifically noted otherwise The word provide means furnish completely installed including labor and incidental materials necessary for operation or use the item referred to or described herein and or shown or referred to on the Contract Drawings 1 3 CONTRACTOR S MISCELLANEOUS RESPONSIBILITIES A The Contractor shall provide in his work without extra cost to the Owner any labor materials service apparatus drawings in order to comply with all applicable laws ordinances rules and regulations whether or not shown on the Drawings and or specified The right to make any responsible change in location of apparatus or equipment or routing of conduit
294. pplemental suspension members and hangers in the form of trapezes or equivalent devices Size supplemental suspension members and hangers to support ceiling loads within performance limits established by referenced standards and publications ACOUSTICAL TILE CEILINGS 09512 5 PTIA Ticket Counter Ceiling Renovation 12 001 000 4 10 11 Secure wire hangers to ceiling suspension members and to supports above with a minimum of 3 tight turns Connect hangers either directly to structures or to inserts eye screws or other devices that are secure that are appropriate for substrate and that will not deteriorate or otherwise fail due to age corrosion or elevated temperatures Secure flat angle channel and rod hangers to structure including intermediate framing members by attaching to inserts eye screws or other devices that are secure and appropriate for both the structure to which hangers are attached and the type of hanger involved Install hangers in a manner that will not cause them to deteriorate or fail due to age corrosion or elevated temperatures Secure bracing wires to ceiling suspension members and to supports with a minimum of 4 tight turns Fasten bracing wires to concrete with cast in place or postinstalled anchors Do not support ceilings directly from permanent metal forms Fasten hangers to cast in place hanger inserts powder actuated fasteners or drilled in anchors that extend through forms into concret
295. prior to the time of roughing in is reserved by the Owner without involving any additional expense to the Owner The Owner reserves the right to relocate any receptacle outlet 10 0 up to the time roughing in at no additional expense Coordination Issues 1 The Contractor shall coordinate his schedule of work with the Owner and other contractors and shall plan his work to minimize disruption to the Owner s use of this facility 2 Contractor shall effect cooperation between his employees and those of Owner and Contractors on work awarded separately by the Owner to the end that all work is properly anchored installed and finished without hindrance or delay Care shall be taken to avoid marring surfaces of the work of other Contractors and each Contractor shall be held responsible for any damage to the work of others Repair of new work shall be made by the original Contractor at the expense of the Contractor responsible for the damage Protection of Equipment and Facility The Contractor shall have the responsibility of protecting the Owner s equipment stored materials fixtures piping conduit and other building components and finishes at all times during the construction and shall replace and or repair any damage that is a result of his construction activities Working Hours Working days and hours shall be as scheduled in Division 1 Contractor Supervisor The Contractor shall assign and maintain a single qualified person as a jo
296. project Certificates of Compliance Submit manufacturers certificates of compliance with standards for all pipe and pipe fittings as specified in Section 15060B Pipe and Pipe Fittings Submit four 4 copies of the certificates to the Owner s representative Certificates of Compliance shall be specific to the project and to the piping materials for which the certificate is submitted Generalized non specific letters of compliance are not acceptable PERMITS LICENSES AND INSPECTION FEES The Contractor shall obtain and pay for all permits and licenses required give all legal notices and pay all fees for inspection or otherwise required for the work ACCESSIBILITY A The Contractor shall be responsible for the sufficiency of the size of shafts and chases and the adequate clearance in double partitions and hung ceilings for the proper installation of his work He shall cooperate with the General Contractor and all other contractors whose work is in the same space and shall advise the General Contractor of his requirements Such spaces and clearances shall however be kept to the minimum size required MECHANICAL GENERAL PROVISIONS 15010B 12 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 B The Contractor shall locate all equipment which must be serviced operated or maintained in fully accessible positions Equipment shall include but not be limited to sensors controls fire dampers valves trap
297. quences interlocks and associated parameters and other pertinent information for the operating system and data base shall be forwarded from the Contractor to the Owner Prior to full operation a complete demonstration of the system operation shall be performed in the presence of the Owner and the Engineer This demonstration having satisfactorily met previously approved submittals shall with the Owner s written acceptance allow commissioning of the system Upon successful completion of system operation the Owner and Engineer shall be requested in writing to inspect and approve the satisfactory operation of the system sub systems and accessories Upon completion of the installation the System contractor shall start up the system and perform all necessary testing and debugging operations An acceptance test in the presence of the Owner s representative and the Engineer shall be performed When the system performance is deemed satisfactory in whole or in part by the observers the system parts will be accepted for beneficial use and placed under warranty B Upon receipt of a detailed punchlist from the Owner an installation inspection report shall prepared by the System Contractor showing by system each outstanding item on the punchlist After all items appearing on the installation inspection report are completed a second written request for system approval shall be made to the Owner As each or all items are approved an appropriate notat
298. quired of Owner 2 2 1 Delete entirely 2 4 Owner s Right to Carry Out Work 2 4 1 Delete entirely and substitute the following 2 4 1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within seven days after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and prompiness the Owner may after seven days following receipt by the Contractor of an additional written notice and without prejudice to any other remedy the Owner may have make good such deficiencies In such case an appropriate Change Order shall be issued deducting from the payments then or thereafter due the Contractor the cost of correcting such deficiencies including without limitation compensation for the Architect s additional services made necessary by such default neglect or failure If the payments then or thereafter due the Contractor are not sufficient to cover such amount the Contractor shall pay the difference to the Owner ARTICLE 3 CONTRACTOR 3 6 Taxes Add the following 3 6 1 For all materials incorporated into the Work under this contract the Contractor shall furnish to the Owner a list of all purchases of such materials showing with respect to each such purchase the invoice number date the person or firm the invoice is from the materials that were purchased the cost of the materials and the amount of North Carolina State
299. r as follows 1 Operators Manuals with explanations of operator functions Although operator functions are to be self instructional and menu interactive from the keyboard terminal this manual shall be for off line study and refresher use 2 Computerized printouts of all data file construction including all point processing assignments physical terminal relationships flowcharts of graphic program etc 3 Manuals including revised as built documents of all materials required under the Part 1 paragraph Shop Drawings in this Specification Section 4 A user manual for the integrated spreadsheet package only one required E The Contractor shall obtain from the Owner s representative a signed receipt that he has received the drawings and manuals COMMISSIONING Commissioning the Facility Management System is a mandatory documented performance requirement of the selected FMS Contractor for all control systems detailed in this Specification and sequence of operations Commissioning shall include verification of proper installation practices by the FMS Contractor and subcontractors under the FMS Contractor point verification and calibration system sequence of operation verification with respect to specified operation and network workstation verification Documentation shall be presented upon completion of each commissioning step and final completion to ensure proper operation of the Facility Management System A Acceptance Check List An ac
300. r assured closure under airflow Provide factory built sleeves of design and length to permit mounting within the opening and as required to meet State Building Code requirements Factory manufactured fire dampers shall be by Ruskin Prefco Products Louvers and 15840B 8 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 H Dampers Inc Safe Air National Controlled Air or approved equal Fusible links shall be temperature rated in accordance with NFPA 90A Each fire damper type and rating shall be as required to maintain the fire resistive construction rating of the floor wall or partition in which it is installed See Drawings for additional information and requirements 2 21 FIRESTOP SEALS All holes voids or openings created to extend mechanical systems through fire rated floors partitions and walls shall be sealed by the Contractor with an intumescent material capable of expanding up to 10 times when exposed to temperatures beginning at 250 F It shall be UL Classified and have ICBO BOCAI and SBCCI NER 243 approved ratings to 4 hours per ASTM E 814 UL 1479 Manufacturers shall be 3M Hilti or equivalent by Dow Corning 2 22 ACCESS DOORS A moo m Access doors shall have galvanized steel frames and galvanized steel door panels suitable for the applicable duct pressure class Doors shall have continuous zinc plated steel hinge Latches shall be galvanized steel sash type with g
301. r direction vanes Vertical vanes shall be on the room side of wall mounted units D Return grilles and registers are ceiling wall or floor mounted air return or transfer inlets with fixed vertical and or horizontal vanes Vertical vanes shall be on the room side of wall mounted units E Registers have built in volume adjusting opposed blade dampers whereas grilles do not F High capacity industrial grilles are wall or ceiling mounted air supply outlets offering directional control of large air volumes CEILING DIFFUSERS GRILLES AND REGISTERS shall be as scheduled on Drawings ADJUSTABLE AIR EXTRACTORS shall be provided behind supply grilles and at branch ducts where shown on the Drawings and scheduled on the air distribution schedules SOUND PRESSURE LEVEL of all diffusers grilles and registers shall not exceed NC 35 Noise Criteria 35 in all areas unless specifically noted otherwise at the scheduled maximum air flow NC ratings are based on sound power level re 10 watts minus an 8 db room attenuation in all octave bands SHIPPING TAG Each unit shall be tagged at the factory with its specific location on the job including building floor room area served and the unit designation shown on the Drawings SUBMITTALS Submit the following for each air distribution device Manufacturers details indicating components dimensions connections clearances Performance criteria indicating type size cfm NC rating neck size and
302. r has become thoroughly familiar with the terms and conditions of the proposed Contract Documents accepting the same as sufficient to indicate understanding of all the conditions and requirements under the Contract which will be executed for the Work b Bidder has examined the site and locality where the Work is to be performed the legal requirements Federal state and local laws ordinances rules and regulations and the conditions affecting cost progress or performance of the Work and has made such independent investigations as Bidder deems necessary C This Bid is genuine and not made in the interest of or on behalf of any undisclosed person firm or corporation and is not submitted in conformity with any agreement or rules of any group association organization or corporation Bidder has not directly or indirectly induced or solicited any other Bidder to submit a false or sham Bid Bidder has not solicited or induced any person firm or corporation to refrain from bidding and Bidder has not sought by collusion to obtain for himself any advantage over any other Bidder or over Owner d That no member of the Authority or other officers or employees of said Owner is interested directly or indirectly in the Bid or in any portion of the Bid nor in the Contract or any part of the Contract which may be awarded the undersigned on the basis of such Bid e It is a condition of this Bid and any subsequent contract entered into pursuant to
303. r provision of the Contract 14 4 Termination by the Owner for Convenience 14 4 3 Delete in its entirety and substitute the following 14 4 3 In case of such termination for the Owner s convenience the Contractor shall be entitled to receive payment for Work already executed and any out of pocket costs that the Contractor incurs by reason of such termination but shall not be entitled to any overhead or profit on work that had not been completed at the time of such termination ARTICLE 15 CLAIMS AND DISPUTES 15 1 Claims Add the following ee ee ee ee erected and the construction is under root jf aday as a pad weatherday the Contractor musi netiy the Architect by the ofthe Contractors intention te make_such_clain aiture by the Contractor to notify the Architect of such claim by the next business day shall as to whether to allow any such claim by the Contractor The Contractor must a 15 1 7 Indemnities Nothing in Section 15 1 6 shall constitute a waiver of or in any manner limit any indemnity that is owed to either the Owner or the Contractor under the other provisions of this Contract 15 1 8 Limit on Owner s Liability for Delay Notwithstanding any other provision of this Contract the Contractor shall not be entitled to claim or recover any additional payment from the Owner by reason of any delay obstruction or hindrance in the execution of the Work or any part thereof unl
304. r vapor permeance 0 02 perms or less 20 to 450 F service temperature Plain joint laps for field applied adhesive or laps with pressure sensitive adhesive will be accepted Acceptable products MP type AP or AP T Plus O C 25 ASJ C T ASJ or KF ASJ or equal Foil Scrim Kraft Ductwork Meet NFPA 90A requirements permanently flame retardant and ULL listed Inner ply minimum 40 Ib flame resistant paper Outer ply aluminum foil ply bonding adhesive flame extinguishing Water vapor permeance 0 02 perms or less 40 to 250 F service temperature Acceptable products MP type FSK O C FRK 25 C T FSK or KF FSK 2 9 PROTECTIVE FINISH JACKETS A INSULATION Canvas Pipes Ducts and Equipment Field Applied U L listed plain weave 100 percent cotton fabric with hard twisted yarns impregnated with a dilute fire retardant lagging adhesive minimum 8 0 oz sq yd unless scheduled otherwise Furnish a certificate of compliance letter from the manufacturer to verify that the products provided meet the specification Fiberglass Pipes Ducts and Equipment Field Applied Industrial quality fiberglass fabric constructed of glass fiber materials with a density of 0 094 Ibs cu in and tensile strength of 500 Ibs at 70 F Jacketing fabric shall have a minimum density of 14 oz sq yd and be treated by the manufacturer to contain a water activated adhesive for lagging applications Fiberglass jackets shall be Glas Tex fabric Style 84215 F
305. rable whether the panel processor is operational or not 6 FCU controllers shall have a library of control routines and program logic to perform the sequence of operations specified in the Execution portion of this Specification 7 FCU controllers shall directly support the temporary use of a portable service FMS CONTROLS AND INSTRUMENTATION 15900B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 terminal that can be connected to the FCU via zone temperature or directly at the controller 8 Powerfail Protection All system setpoints proportional bands control algorithms and any other programmable parameters shall be stored such that a power failure of any duration does not necessitate reprogramming the FCU B VAV Terminal Unit Controllers VAV 1 Each VAV Controller shall operate as a standalone controller capable of performing its specified control responsibilities independently of other controllers in the network Each VAV Controller shall be a microprocessor based multi tasking real time digital control processor 2 VAV Terminal Unit Controllers shall support but not be limited to the control of the following configurations of VAV boxes to address current requirements described in the Execution portion of this Specification and to address future expansion a Dual Duct Variable Volume 3 Point types Each VAV controller shall support the following types of point inputs
306. re of system and a stainless steel vane Valves for modulating service shall be sized and travel limited to 50 degrees of full open Valves for isolation service shall be the same as the pipe Valves in the closed position shall be bubble tight 2 5 MISCELLANEOUS DEVICES A Local Control Panels 1 All control panels shall be factory constructed incorporating the FMS manufacturer s standard designs and layouts All control panels shall be UL FMS CONTROLS AND INSTRUMENTATION 15900B 12 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 inspected and listed as an assembly and carry a UL 508 label listing compliance Control panels shall be fully enclosed with sub panel hinged door and key locking latch 2 In general the control panels shall consist of the DDC controller s display module and I O devices such as relays transducers and so forth that are not required to be located external to the control panel due to function The display module shall be flush mounted in the panel face unless otherwise noted 3 All I O connections on the DDC controller shall be extended to a numbered color coded and labeled terminal strip for ease of maintenance and expansion Wiring to I O devices shall be made from this terminal strip 4 All other wiring in the panel internal and external shall be made to additional line or low voltage color coded and labeled terminal strips Low and line voltage wiring shall b
307. re alarms for each setpoint sa 9990p 8 Interlocks a A shutdown relay wired from the Fire Alarm Control Panel FACP shall de energize the control circuit of the supply fan b A low limit temperature switch adjustable setpoint shall stop the supply fan if the mixed air temperature entering the cooling coil drops below 35 deg F manual reset This safety shall be directly wired into the starter circuit C A low limit duct pressure sensor cutout shall stop the supply fan if the suction side duct pressure drops below setpoint manual reset FMS CONTROLS AND INSTRUMENTATION 15900B 18 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 d A high limit duct pressure sensor cutout shall stop the supply fan if the discharge duct pressure increases above maximum setpoint manual reset This safety interlock shall be directly wired into the starter circuit 9 Miscellaneous A filter gauge station shall be provided to monitor the pressure drop of each filter section C Dual Duct Terminal Units 1 Cooling and Heating When the space temperature is warm the cold damper is maintaining the maximum cooling airflow setpoint while the hot damper is closed As space temperature drops the cold air flow modulates from maximum to minimum flow rate As the space temperature continues to fall the hot damper modulates open As temperature continues to drop hot damper will open to maximum heating flow to maintain set
308. re fitting covers in place Pop rivets with galvanized or carbon steel pins shall not be used Fitting covers for 90 or 45 degree elbows shall be equal to ELL JACS Elbow Insulation Covers by Childers Products Company 5 Miscellaneous insulation covers for Flanges Valves Blind Flanges Reducing Flanges Concentric Eccentric Reducers and the like shall be constructed of 0 020 aluminum Tees shall be constructed of two matching halves of 0 024 aluminum All aluminum components shall have an integral moisture barrier coating and all such fittings shall be either factory fabricated units or skillfully crafted field fabricated insulation covers 6 Seal all laps seams joints and raw edges of aluminum jackets installed on outdoor iping or where required for indoor piping jackets with caulking or sealant Childers Chil Byl CP 76 Foster 95 44 or clear silicone caulking G E 1200 or equal PVC Pipe Covers and Accessories Pipe and Ductwork Refer to paragraph 2 8 Vapor Retarder Jackets 2 10 ADHESIVES FIRE RESISTIVE A Canvas Jackets For securing field applied canvas jackets on insulation with or without vapor retarder lagging adhesive shall have a dry flame spread rating of 5 per ASTM E 162 0 to 180 F service temperature water vapor permeance of 1 3 perms white color tough washable finish when dry Childers Chil Seal CP 50A Coating Foster Sealfas 30 36 Mon Eco 11 02 or Vimasco 713 Flexible Glass Fiber Insulation
309. reful coordination is needed for installation of products and materials fabricated by separate entities Prepare coordination drawings where limited space availability necessitates maximum utilization of space for efficient installation of different components 1 Show the relationship of components shown on separate Shop Drawings 2 Indicate required installation sequences 3 Comply with requirements contained in Section Submittals Staff Names Within 15 days of commencement of construction operations submit a list of the Contractor s principal staff assignments including the superintendent and other personnel in attendance at the Project Site Identify individuals and their duties and responsibilities List their addresses and telephone numbers PART 2 PRODUCTS Not Applicable PART 3 EXECUTION 3 1 GENERAL COORDINATION PROVISIONS A Inspection of Conditions Require the Installer of each major component to inspect both the substrate and conditions under which Work is to be performed Do not proceed until unsatisfactory conditions have been corrected in an acceptable manner Coordinate temporary enclosures with required inspections and tests to minimize the necessity of uncovering completed construction for that purpose 3 2 CLEANING AND PROTECTION A Clean and protect construction in progress and adjoining materials in place during handling and installation Apply protective covering where required to assure protectio
310. required for the controls systems as described in Section 15900B and on the Drawings all per the Electrical Specifications or specific installation requirements The Contractor is referred to the Instrumentation and Control Drawings and Specifications for information Where instrumentation and or controls are called for on one drawing but are not shown on another they shall be installed Where an instrument controller and or indicator is shown or called for but the primary sensing element or transmitter is not shown the installation shall be provided complete 1 10 COORDINATION OF INSTALLATION OF FIRE SAFETY EQUIPMENT A The Mechanical Contractor shall coordinate with the Electrical Contractor Fire Alarm Equipment Supplier Instrumentation and Controls Supplier and others as necessary regarding proper location and installation of sensing and control devices in ductwork and equipment The Electrical Contractor shall be responsible for the sizing and selection of all sensors primary signaling devices and controls such as but not limited to temperature sensors and ionization or smoke detectors The Electrical Contractor and his supplier shall also be responsible for providing instructions for the proper installation of his equipment such as maintaining proper upstream and downstream straight run dimensions on ductwork to MECHANICAL GENERAL PROVISIONS 15010B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0
311. requirements Finishes and Colors Provide manufacturer s standard factory applied finish for type of system indicated Attachment Devices Size for 5 times the design load indicated in ASTM C 635 Table 1 Direct Hung unless otherwise indicated 1 Powder Actuated Fasteners in Concrete Fastener system of type suitable for application indicated fabricated from corrosion resistant materials with clips or other accessory devices for attachment of hangers of type indicated and with capability to sustain without failure a load equal to 10 times that imposed by ceiling construction as determined by testing per ASTM E 1190 conducted by a qualified testing agency Wire Hangers Braces and Ties Provide wires complying with the following requirements de Zinc Coated Carbon Steel Wire ASTMA 641 ASTMA 641M Class 1 zinc coating soft temper 2 Size Select wire diameter so that its stress at 3 times the hanger design load ASTM C 635 Table 1 Direct Hung will be less than the yield stress of wire but provide not less than 0 106 inch 2 69 mm diameter wire Sheet Metal Edge Moldings and Trim Type and profile indicated or if not indicated manufacturer s standard moldings for edges and penetrations that fit acoustical tile edge details and suspension systems indicated formed from sheet metal of same material and finish as that used for exposed flanges of suspension system runners 1 For circular penetrations of ceiling provide e
312. rical wiring and conduit and any additional material and equipment required by the system at no additional cost to the Owner 2 3 MATERIALS AND WORKMANSHIP A Quality and Performance 1 All materials and apparatus required for the work except as particularly specified otherwise shall be new of first class quality and shall be furnished delivered erected connected and finished in every detail and shall be so selected and arranged as to fit properly into the building spaces 2 Where no specific kind or quality of material is given a first class standard article as approved by the Owner s representative shall be furnished 3 Conform to applicable Specifications and standards 4 Comply with size capacity make type dimensions and quality specified unless variations are specifically approved in writing by Owner s representative 5 Manufactured and Fabricated Products a Design fabricate and assemble in accord with the best engineering and shop practices b Manufacture like parts of duplicate units to standard sizes and gages to be interchangeable C Two or more items of the same kind shall be by the same manufacturer d Products shall be suitable for service conditions 6 All hardware such as nuts bolts washers lockwashers threaded rod and the like shall be adequately sized to do the intended job and to take some physical abuse 7 Do not use material or equipment for any purpose other than that for which i
313. rior negotiations representations or agreements either written or oral An enumeration of the Contract Documents other than a Modification appears in Article 9 ARTICLE 2 THE WORK OF THIS CONTRACT The Contractor shall fully execute the Work described in the Contract Documents except as specifically indicated in the Contract Documents to be the responsibility of others ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 3 1 The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner Insert the date of commencement if it differs from the date of this Agreement or if applicable state that the date will be fixed in a notice to proceed The commencement date will be fixed in a notice to proceed If prior to the commencement of the Work the Owner requires time to file mortgages and other security interests the Owner s time requirement shall be as follows Not Applicable 3 2 The Contract Time shall be measured from the date of commencement 3 3 The Contractor shall achieve Substantial Completion of the entire Work not later than One hundred sixty 160 days from the date of commencement or as follows Insert number of calendar days Alternatively a calendar date may be used when coordinated with the date of commencement If appropriate insert requirements
314. rods rolled shapes and other parts shall be ASTM A 36 carbon steel with ASTM B633 SC1 or SC3 electro plated zinc finish Shop Coating Systems 1 Shop Primer Standard shop primer equal to Steel Structures Painting Council SSPC Specification No 13 Total dry film thickness shall be not less than 2 5 mils Verify compatibility of primer with specified finish paint All miscellaneous steel supports provided for equipment piping and accessories furnished under Division 15 Specifications shall be fully coated with approved shop primer paint Uncoated bare steel supports will not be accepted 2 Electro Plated Galvanized ASTM B633 SC1 or SC3 coating of zinc on steel by electrolysis from a bath of zinc salts This coating is pure zinc and adheres to the steel with a molecular bond Fasteners such as rivets bolts or sheet metal screws shall be cadmium plated or galvanized steel Hanger Rods shall be threaded continuously or threaded each end 15840B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 E Hanger rods shall be subjected to tension only Lateral and axial movements shall be accommodated by proper linkage in the rod assembly F Support hangers by using beam clamps with lock nuts or retaining straps or other special fastening devices as required for the support of hangers Refer to specific details on the Drawings G Beam Clamps 1 C clamps with locknuts shall be used where applicable
315. rol The valves shall be quiet in operation and fail safe open closed or in their last position All valves shall operate in sequence with another valve when required by the sequence of operations All control valves shall be sized by the control manufacturer and shall be guaranteed to meet the heating and cooling loads as specified All control valves shall be suitable for the system flow conditions and close against the differential pressures involved Body pressure rating and connection type sweat screwed or flanged shall conform to the pipe schedule elsewhere in this Specification 2 Chilled water control valves shall be modulating ball and or butterfly as required by the specific application Modulating water valves shall be sized per manufacturer s recommendations for the given application In general valves 2 or 3 way serving variable flow air handling unit coils shall be sized for a pressure drop equal to the actual coil pressure drop but no less than 5 PSI 3 Ball valves shall be acceptable for water terminal reheat coils radiant panels unit heaters package air conditioning units and fan coil units 4 Butterfly valves shall be acceptable for modulating large flow applications greater than modulating plug valves and for all two position open close applications In line and or three way butterfly valves shall be heavy duty pattern with a body rating comparable to the pipe rating replaceable lining suitable for temperatu
316. ront with concealed trim clamps as indicated on the Drawings concealed hinge and flush lock all keyed alike Finish in manufacturer s standard gray enamel Provide panelboards with copper bus ratings as scheduled on Drawings Provide copper ground bus in all panelboards Minimum Integrated Short Circuit Rating As shown on Drawings Molded Case Circuit Breakers NEMA AB 1 FS W C 375 bolt on type thermal magnetic trip circuit breakers with common trip handle for all poles Provide circuit breakers UL listed as Type SWD for lighting circuits Provide UL Class A ground fault interrupter circuit breakers where scheduled on Drawings Provide UL Class A arc fault interrupter circuit breaker for all branch circuits serving sleeping quarters PART 3 EXECUTION INSTALLATION 3 1 3 2 3 3 A Install panelboards plumb and where recessed mounted install flush with wall finishes in conformance with NEMA PB 1 1 For surface mounted panelboards support from building members independent of all finished surfaces and conduits Height 6 ft to top of panelboard from finished floor Provide filler plates for unused spaces in panelboards Provide typed circuit directory for each branch circuit panelboard Revise directory to reflect circuiting changes required to balance phase loads Stub 5 empty one inch conduits to accessible location above ceiling out of each recessed panelboard FIELD QUALITY CONTROL A Measure steady state l
317. rounding ductwork collar or fan housing Maximum blade length in any section shall be 48 Additional stiffening or bracing shall be provided with suitable bearings for smooth operation and all blades shall be interconnected to provide unison operation Dampers shall be provided with either parallel or opposed blade linkage and arranged for normally open or normally closed operation as shown on the Drawings Multi section dampers shall be provided with sufficient interconnecting hardware and jackshafts to provide unison operation of all blades in the entire assembly Low Leakage Control Dampers 1 Frames shall be 5 x 1 x 0 125 6063 T5 extruded aluminum channel Dampers 12 high and less shall be equipped with low profile 5 x 1 2 frame dimensions 2 Blades shall be 6 wide 6063 T5 heavy gage extruded aluminum airfoil shape 3 Axles shall be 1 2 plated steel hex for positive connection with blades 4 Bearings shall be non corrosive two piece molded synthetic 5 Blade seals shall be extruded vinyl double edge design with inflatable pocket which enables air pressure from either direction to assist in blade to blade seal off Blade seals shall be locked in extruded blade slots without the use of cement 6 Jamb seals shall be aluminum flexible metal compression type 7 Linkage shall be concealed in frame for low maintenance and reduced air turbulence 8 Dampers shall be rated for temperatures from 50 F to 250 F 9 Leakage rat
318. s amp equipment 18 Soldering materials 19 Motors furnish data along with the driven equipment 20 Flexible ductwork and accessories 21 Unit heaters 22 Variable speed drives 23 Starters 24 Variable air volume terminal units 25 Firestopping 26 Air filters 27 Piping materials Certificates of Compliance 28 Test procedures 29 Air handling units with coils 30 Valves and hydronic specialties 31 Insulation pipe saddles 32 Welder s qualifications 33 FMS controls system drawings product cut sheets sequence of operation complete for all systems 34 Other specific submittals as required by Division 15B Specifications Submittal Drawings Coordination shop drawings drawings prepared of the mechanical equipment rooms drawings prepared for the layout fabrication and installation of piping ductwork and the like drawings prepared to coordinate clearances with other trades and other such drawings and sketches shall be submitted as shop drawings for approval 1 One complete set of approved Record Submittal Drawings shall be kept at the work site at all times and shall be updated and maintained in the same manner as that required for Record Drawings CAD computer aided drafting drawings shall also be updated and maintained for submittal as part of Project Closeout 2 Record Submittal Drawings shall be subject to review and approval and shall be submitted as required for review and approval throughout the
319. s cleanouts vent and drain points Provide access doors in ductwork equipment and the like as required for good maintenance and service access The Contractor shall arrange for access doors required in building surfaces which are to be provided by the General Contractor The Contractor shall provide the General Contractor the exact locations of access doors needed for equipment concealed valves controls or other devices requiring service Locations of these doors shall be submitted in sufficient time to be installed in the normal course of the work Minor deviations from Drawings may be made to allow for better accessibility and changes shall be submitted to the Owner s representative for approval 3 9 CUTTING AND PATCHING A Mechanical Contractor shall provide all cutting and patching necessary to install the work specified in this Division unless noted otherwise Patching shall match adjacent surfaces or new finishes as specified No structural member shall be cut without the specific approval of the Owner s representative except as specifically detailed on the Drawings All such cutting and reinforcing shall be done in a manner directed by the Owner s representative Cutting and patching of footings after general construction will not be permitted The General Contractor shall provide all duct and pipe openings chases and shafts in all existing and new construction however it is this Contractor s responsibility to advise
320. s showing materials finishes construction size arrangement operating clearances performance characteristics capacity and the like Each equipment submittal shall include manufacturer s installation instructions Submittals which lack installation instructions shall be returned C Each item of equipment proposed shall be a standard catalog product of an established manufacturer and of equal quality finish performance and durability to that specified Each item shall comply with the requirement for Substitutions and Product Options described in this section D No payment for any material equipment or labor will be approved until all required shop drawings for that material equipment and labor have been approved by the Owner s representative E Failure of the Contractor to submit shop drawings in ample time for review and approval shall not entitle him to an extension of contract time and no claim for extension by reason of default will be allowed F All shop drawing submittals shall be in the office of the Owner s representative within 90 days after the contract has been awarded The Contractor shall be financially responsible for any price increase of shop drawing items from the time shop drawings are issued until they are returned to the Contractor for purchase of items G Shop drawing samples drawings specifications or catalogs submitted for approval shall be properly labeled indicating specific service for which material
321. s Section to compliance with requirements provide one of the products specified in each Acoustical Tile Ceiling Product Data Sheet at the end of this Section ACOUSTICAL TILE CEILINGS 09512 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 2 2 ACOUSTICAL TILE GENERAL A Acoustical Tile Standard Provide manufacturer s standard tiles of configuration indicated that comply with ASTM E 1264 classifications as designated by types patterns acoustical ratings and light reflectances unless otherwise indicated Acoustical Tile Colors and Patterns Match appearance characteristics indicated for each product type 1 Where appearance characteristics of acoustical tiles are indicated by reference to ASTM E 1264 pattern designations and not to manufacturers proprietary product designations provide products selected by Architect from each manufacturer s full range of products that comply with requirements indicated for type pattern color light reflectance acoustical performance edge detail and size Tile Characteristics Comply with requirements indicated on each Acoustical Tile Ceiling Product Data Sheet at the end of this Section including those referencing ASTM E 1264 classifications 2 3 METAL SUSPENSION SYSTEMS GENERAL A Metal Suspension System Standard Provide manufacturer s standard metal suspension systems of types structural classifications and finishes indicated that comply with applicable ASTM C 635
322. s at 60 degrees according to ASTM D 523 Gloss Level 6 70 to 85 units at 60 degrees according to ASTM D 523 Gloss Level 7 More than 85 units at 60 degrees according to ASTM D 523 ACTION SUBMITTALS Product Data For each type of product Include preparation requirements and application instructions Samples For each type of paint system and in each color and gloss of topcoat MAINTENANCE MATERIAL SUBMITTALS Furnish extra materials from the same product run that match products installed and that are packaged with protective covering for storage and identified with labels describing contents 1 Paint 5 percent but not less than 1 gal of each material and color applied INTERIOR PAINTING 09912 1 PTIA Ticket Counter ceiling Renovation 12 001 000 1 5 A QUALITY ASSURANCE Mockups Apply mockups of each paint system indicated and each color and finish selected to verify preliminary selections made under Sample submittals and to demonstrate aesthetic effects and set quality standards for materials and execution 1 Architect will select one surface to represent surfaces and conditions for application of each paint system specified in Part 3 a Architect will designate items or areas required 2 Final approval of color selections will be based on mockups a If preliminary color selections are not approved apply additional mockups of additional colors selected by Architect at no added cost to Owner PART 2
323. s prior to submittal the Contractor is requested to note corrections or comments on the drawings and product data in orange pencil Add the following 3 18 3 Contractor shall indemnify and hold harmless the Owner from any penalties or fines levied upon the Owner for any violations of security laws or of any other rules or regulations by the Contractor by the Contractor s officers agents or employees by any of the Contractor s subcontractors or by any of the officers agents or employees of any of the Contractor s subcontractors and Contractor shall further indemnify the Owner from all expenses including but not limited to attorneys fees resulting from any such violations ARTICLE 4 ARCHITECT 4 1 Architect Add the following 4 1 1 1 4 1 2 The terms Architect Engineer and Architect Engineer mean the Architect Delete entirely and substitute the following The duties responsibilities and limitations of authority of the Architect as set forth inthe Contract Documents will not be extended without the written consent of the Owner the Contractor and the Architect 4 2 Administration of the Contract 4 2 9 Delete entirely and substitute the following 4 2 9 The Architect will conduct inspections to determine the date or dates of Substantial Completion and the date of final completion will receive and forward to the Owner for the Owner s review and records written warranties and related documents required by the
324. sed work to determine for himself the location and character of the work involved 5 Contractor will be given notice to proceed after Owners review of bids and upon approval from the PTAA Board The contractor should complete construction ready for Owner occupancy not later than 120 calendar days after the date of Notice to Proceed 6 The use of sections throughout these specifications is not intended as an itemization of the various materials or the types of work or to the limit or to define the scope of any subcontract 7 The Contractor will be held responsible for any and all fines that are assessed for lack of compliance to codes or any requirements of a governing agency SUMMARY OF WORK 01010 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 1 3 CONTRACTOR USE OF PREMISES A General The Contractor shall limit his use of the premises to the work indicated B Use of the Site The Owner will be occupying and using the adjacent areas at all times Confine operations at the site to the areas permitted under the Contract Portions of the site beyond areas on which work is indicated are not to be disturbed Conform to site rules and regulations affecting the work while engaged in project construction The Contractor shall schedule the work so that the adjacent tenant s work schedules are not interrupted END OF SECTION 01010 SUMMARY OF WORK 01010 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 01040 COORDIN
325. set for flush installation and 1 16 inch maximum offset for reveal installation 4 Install stairs with no more than 3 16 inch variation between adjacent treads and risers and with no more than 3 8 inch variation between largest and smallest treads and risers within each flight INTERIOR FINISH CARPENTRY 06202 3 PTIA Ticket Counter Ceiling Renovation 12 001 000 3 3 STANDING AND RUNNING TRIM INSTALLATION A Install with minimum number of joints practical using full length pieces from maximum lengths of lumber available Miter at returns miter at outside corners and cope at inside corners to produce tight fitting joints with full surface contact throughout length of joint Use scarf joints for end to end joints 3 4 PANEL INSTALLATION A Wood Panels Select and arrange panels on each wall to minimize noticeable variations in grain character and color between adjacent panels Leave gaps as indicated on the drawings Install with uniform tight joints between panels 1 Attach panels to supports with manufacturer s recommended panel adhesive and fasteners Space fasteners and adhesive as recommended by panel manufacturer 2 Conceal fasteners to greatest practical extent END OF SECTION 06202 INTERIOR FINISH CARPENTRY 06202 4 PTIA Ticket Counter Ceiling Renovation 12 0001 000 SECTION 092900 GYPSUM BOARD PART 1 GENERAL 1 1 SUMMARY A Section Includes 1 Interior gypsum board 1 2 ACTION SUBMITTALS A Product Da
326. sh with 1 4 thickness of hydraulic insulating and finishing cement 4 Fittings on pipe sized 1 1 2 and smaller may be insulated with hydraulic insulating and finishing cement of same thickness as pipe insulation 5 Cover equipment with fabricated mitered segments of molded calcium silicate of same thickness as insulation on adjacent pipe wired in place Finish with 1 2 thickness of hydraulic insulating and finishing cement with metal corner beads 6 Cover equipment removable heads with 20 gage galvanized steel cover over insulation 7 Where no additional finish is specified apply 16 gage nickel copper alloy wire 16 gage copper clad steel wire or 16 gage stainless steel wire on 4 centers up to 6 pipe and 6 centers on pipe over 6 diameter 8 Block insulation greater than 2 thick shall be applied in layers not exceeding 1 1 2 thick All joints shall be staggered Secure with wire Cover with 1 2 thick hydraulic insulating and finishing cement Protect all corners with metal corner beads D Cellular Glass Insulation Chilled Water Systems Apply thickness and density shown in insulation schedule 1 Apply single layer half sections of insulation to pipe and fittings Provide fabricated coverings suitable for use on valves pipe fittings and hydronic specialties fabricated in accordance with ASTM C552 for proper fit Tightly butt edges and seal all joints full depth with Pittseal 444N Sealant as supplied by Pittsburgh Cor
327. shall be installed in strict accordance with the manufacturer s recommendations for each type of opening or void Surfaces shall be smooth and without gouges or other irregularities 3 13 DUCT SMOKE DETECTORS shall be furnished by the Electrical Contractor under Division 16 and installed in the duct system by the Mechanical Contractor All wiring and interlocks shall be furnished and installed by the Electrical Contractor 3 14 CLEANING A All ductwork shall be thoroughly cleaned inside and out prior to system startup and shall be left in a neat and orderly manner Duct sections open ends taps and the like shall be covered with plastic at all times during construction to prevent entry of dust and debris B See Section 15010B Mechanical General Provisions and Section 15042B Tests for additional requirements 3 15 STARTUP TESTING ADJUSTING amp BALANCING See Sections 15010B Mechanical General Provisions and 15042B Tests END OF SECTION 15840B DUCTWORK 15840B 13 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15840SB DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM A GENERAL NOTES amp LEGENDS 1 Refer to Section 15840B Ductwork and Section 15250B Insulation for detailed material and installation requirements Refer to Section 15840B for insulated flexible ductwork Note Not all materials described in Part A of this Specification are used on this project Refer to
328. shall meet Seal Class B 3 Three inch 8 water gage pressure class ductwork and higher shall meet Seal Class A 1 8 OFFSETS BENDS AND RELATED WORK The Drawings covering the work of other trades and all work already existing shall be thoroughly examined and arrangements made to provide all necessary offsets bends or changes including duct enlargements and streamlined pipe and hanger rod casings as required to resolve and eliminate conflict with other trades 1 9 PRESSURE LOSS CALCULATIONS amp EQUIPMENT SIZES A B DUCTWORK The calculation of pressure losses and the sizing of fans and motors for each system has been based on the arrangement and sizes of ductwork and the number and type of fittings and accessories shown on the Drawings Where additional fittings accessories or size changes are required to install a duct system 15840B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 the pressure losses through the system shall be calculated by the Contractor and compared with the scheduled requirements The calculations comparison and proposed revisions shall be submitted to the Owner s representative for approval If a change in fan and or motor size is required Contractor shall bear all costs This includes the costs of duct changes equipment changes and _ re arrangements accessories starters conduit wiring controls and the like Shop drawings showing proposed changes sha
329. side corners chamfered 45 Bases shall generally incorporate a minimum edge distance of ten 10 bolt diameters all around the outermost anchor bolt to allow development of full drill in wedge anchor ratings and shall generally be a minimum of 4 inches thick with structural reinforcing and dowel anchors set into the floor with structural epoxy unless shown otherwise on the Drawings Refer to Section 15201B for coordination of vibration and seismic requirements 2 6 DIELECTRIC CONNECTIONS A B A dielectric connection shall be used at any point within the piping systems where dissimilar metals meet A dielectric isolating material shall be used at any point within the ductwork systems where dissimilar metals meet MECHANICAL GENERAL PROVISIONS 15010B 8 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 C Supports brackets and hangers touching piping or ductwork shall be same material as piping or ductwork or a dielectric isolation material shall be installed between the piping or ductwork and its supporting members 2 7 ACCESS DOORS A Access doors in building surfaces shall be furnished and installed by the General Contractor B Access doors shall be provided for concealed equipment furnished under this division requiring periodic inspection servicing or maintenance where such equipment is located above nonremovable ceilings or behind walls B Label Doors shall be used where installed i
330. sive Bidder Bid Proposal complies with the requirements of the Contract Documents In no case will the award be made until all necessary investigations have been made to determine the qualifications of the low bidder To demonstrate qualifications to perform the work the contractor submitting the lowest responsive bid must submit within seven 7 days of Bid Opening evidence which may be required by the owner such as but not limited to financial data and previous experience Each responsive bid by the contract must contain evidence of the Bidder s qualifications to do business in the state where the project is located Conditional or qualified Bids by the contractor will not be accepted Execution of the Agreement The individual firm or corporation to which the contract has been awarded shall sign the Agreement entering into contract with the Owner and return it to the Owner within ten days from the date of award No contract shall be considered binding upon the Owner until it has been properly executed The agreement shall be executed on the contract form included herein Withdrawal of Bids Bids may be withdrawn by written communication with the Owner without prejudice to the Bidder no later than the day and hour set for opening Bids The Bid will be returned unopened Intent of the Drawings and Specifications If contradictions occur within the specifications or drawings concerning quantity quality or method of installation the Bidder sh
331. sponsible for coordinating information where information from more than one prime contractor is to be integrated with information from other prime contractors to form one combined record Maintenance of Documents and Samples Store record documents and Samples in the field office apart from the Contract Documents used for construction Do not use Project Record Documents for construction purposes Maintain record documents in good order and in a clean dry legible condition Make documents and Samples available at all times for the Architect s inspections 1 3 RECORD DRAWINGS A Markup Procedure During construction maintain a set of blue or black line white prints of Contract Drawings and Shop Drawings for Project Record Document purposes i Mark these Drawings to show the actual installation where the installation varies from the installation shown originally Give particular attention to information on concealed elements that would be difficult to identify or measure and record later Items required to be marked include but are not limited to the following a Dimensional changes to the Drawings b Revisions to details shown on the Drawings PROJECT RECORD DOCUMENTS 01720 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 1 4 Revisions to routing of piping and conduits Revisions to electrical circuitry Actual equipment locations Duct size and routing Locations of concealed internal utilities Changes made
332. sting and inspecting agencies include Underwriters Laboratories UL Warnock Hersey or another agency that is acceptable to authorities having jurisdiction and that performs testing and follow up services 2 Surface burning characteristics of acoustical tiles comply with ASTM E 1264 for Class A materials as determined by testing identical products per ASTM E 84 Single Source Responsibility for Ceiling Tile Obtain each type of acoustical ceiling tile from a single source with resources to provide products of consistent quality in appearance and physical properties without delaying the Work Single Source Responsibility for Suspension System Obtain each type of concealed suspension system from a single source with resources to provide products of consistent quality in appearance and physical properties without delaying the Work 1 Obtain both acoustical ceiling units and suspension system from the same manufacturer Preinstallation Conference Conduct conference at Project site to comply with requirements of Division 1 Section Project Meetings 1 5 DELIVERY STORAGE AND HANDLING A C Deliver acoustical tiles and suspension system components to Project site in original unopened packages and store them in a fully enclosed space where they will be protected against damage from moisture direct sunlight surface contamination and other causes Before installing acoustical tiles permit them to reach room temperature and a stabiliz
333. string in empty conduit except sleeves and nipples Install expansion joints where conduit crosses building expansion joints All conduit bodies to be malleable iron with weather proof coating neoprene gasket and malleable iron cover Route conduit through roof openings for piping and ductwork where possible otherwise route through roof jack with pitch pocket Use asphalt coated rigid steel factory elbows for all bends in plastic conduit Wipe plastic conduit clean and dry before joining Apply full even coat of cement to entire area that will be inserted into fitting Let joint cure for 20 minutes minimum Use compression type steel fittings with EMT 3 3 CONDUIT INSTALLATION SCHEDULE A Concealed Dry Interior Locations 1 Branch circuit conduit shall be electrical metallic tubing Connections to Movable or Vibrating Equipment Provide a minimum of 2 ft of liquidtight flexible conduit in each connection to transformers motors and other equipment which may be moved for maintenance Provide a minimum of 2 ft of flexible steel conduit in all connections to recessed fixtures and equipment in suspended ceilings 3 4 SLEEVES AND PENETRATIONS CONDUIT AND BOXES 16130 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 5 3 6 Contractor shall provide sleeves and openings for raceways penetrating exterior wall interior walls and partitions floors and roofs Provisions for all such penetra
334. structural classification material and finish indicated that complies with applicable ASTM C 635 Provide systems that are complete with snap in runners splice plates connector clips alignment clips hangers trim and other suspension components required to support ceiling units and other ceiling supported construction DIRECT HUNG METAL SUSPENSION SYSTEMS A System composed of snap in main runners supported by hangers attached directly to building structure and complying with the following requirements 1 Hangers Angles or channels as standard with ceiling system manufacturer formed from same metal as main runners 2 Main Runners Formed from the following metal a Aluminum Alloy 6063T 5 b Aluminum Sheet Alloy and temper recommended by manufacturer for use intended and as suitable for application of finish indicated but with not less than the strength and durability properties specified in ASTM B 209 for 5005 H15 3 Structural Classification Intermediate duty system 4 Structural Classification Heavy duty system 5 Maximum Deflection L 360 1 8 maximum MISCELLANEOUS COMPONENTS AND MATERIALS A Exposed Trim Provide exposed members as indicated or required for edges of ceiling fixture trim beams fascias at changes in ceiling height and other conditions of metal and finish matching snap in metal ceiling units Concealed Acoustical Sealant Nondrying nonhardening nonskinning nonstaining nonbleeding
335. systems may be submitted for approval as provided for in the specification at least 10 working days prior to submission of bids Companies desiring to submit a proposal shall submit all descriptive information of the system proposed including photographs and shop drawings of at least three projects similar in detail and scope 2 2 METAL CEILING SYSTEMS GENERAL A Standard for Metal Ceiling Units Provide units of configuration indicated that comply with ASTM E 1264 classifications as designated by reference to types acoustical ratings and light reflectances unless otherwise indicated Sheet Metal Characteristics Form metal pans from sheet metals selected for their surface flatness smoothness and freedom from surface blemishes where exposed to view in the finished unit Do not use materials whose exposed surfaces exhibit pitting seam marks roller marks variations in flatness exceeding those permitted by referenced standards for stretcher leveled metal sheet stains discolorations or other imperfections Fabrication Construct metal pans from metal indicated into units of size indicated and configuration standard with manufacturer with either dimples continuous beads or spring clips on flanges for snap in engagement with concealed suspension system and finished to comply with requirements indicated on Drawings and under Finishes article Patterns Where manufacturer s standard products are indicated provide metal units comply
336. t who shall be constantly in charge of the installation of the work together with all skilled workmen fitters MECHANICAL GENERAL PROVISIONS 15010B 9 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 metal workers welders helpers laborers and the like required to unload transfer erect connect adjust start operate and test each system All work shall be done by first class and experienced mechanics properly supervised It is understood that the Owner s representative has the right to stop any work that is not being properly done and has the right to require that any workman deemed incompetent by the anore representative be removed from the job and a competent workman substituted therefore All equipment and material shall be installed in accordance with the recommendations of the manufacturer unless otherwise specifically indicated on the Drawings or Specifications or unless otherwise approved by the Owner s representative This shall include the performance of such tests as the manufacturer recommends 3 3 COOPERATION A The Contractor shall give full cooperation to the Owner and other trades and shall furnish any information necessary to permit the work of all trades to be installed satisfactorily and with the least possible interference or delay Where the work of the Contractor will be installed in close proximity to or may interfere with work of the Owner or other trades he shall assis
337. t 12 0001 000 function of each component C Provide complete catalog cuts engineering data and other applicable information on all items of equipment Submittals shall include product bulletins engineering manuals application manuals installation manuals and commissioning troubleshooting manuals for all devices D The following submittals are required 1 System architecture showing all digital devices 2 Well and tap schedule 3 Software descriptions 4 Valves actuators and accessories 5 Dampers actuators and accessories 6 Control and wiring diagrams of controlled mechanical systems 7 Control unit panels point layouts and addresses 8 Sensor and transmitter wiring diagrams 9 Starter and interlock wiring diagrams 10 Sequences of operation 11 Material lists with part numbers quantities and descriptions 12 Technical data sheets for each piece of equipment 13 As built drawings with interconnecting wiring diagrams or wire lists of the complete field installed system with complete properly identified ordering numbers of each system component and device 14 Operator s manual s with pictures and step by step operating procedures This manual shall be indexed and shall have a separate tabbed section for each operator function 15 Trunk cable schematic showing remote unit locations and all trunk data conductors 1 9 SYSTEM COMMISSIONING AND ACCEPTANCE PROCEDURE A Submittal data relevant to point index functions se
338. t Triad International Airport 12 0001 000 SECTION 16075 ELECTRICAL IDENTIFICATION PART 1 GENERAL 1 1 WORK INCLUDED A Nameplates B Wire and cable markers C Conduit color coding 1 2 RELATED WORK Painting Section 16010 1 3 SUBMITTALS A Submit shop drawings under provisions of Section 16010 B Include schedule for nameplates PART 2 PRODUCTS 2 1 MATERIALS A Nameplates Engraved three layer laminated plastic black letters on a white background B Wire and Cable Markers Cloth markers split sleeve or tubing type PART 3 EXECUTION 3 1 INSTALLATION A Degrease and clean surfaces to receive nameplates B Install nameplates parallel to equipment lines C Secure nameplates to equipment fronts using screws rivets or adhesive Secure nameplate to inside face of recessed panelboard doors in finished locations 3 2 WIRE IDENTIFICATION Provide wire markers on each conductor in panelboard gutters pull boxes outlet and junction boxes and at load connection Identify with branch circuit or feeder number for power circuits 3 3 NAMEPLATE ENGRAVING SCHEDULE A Provide nameplates to identify all electrical distribution and loads served B Provide nameplates of minimum letter height as scheduled below 1 Panelboards 1 4 inch identify equipment designation 1 8 inch identify voltage rating and source 2 Individual Circuit Breakers in Panelboards 1 8 inch identify circuit and load served includin
339. t in working out space conditions to make a satisfactory adjustment If so directed by the Owner the Contractor shall prepare composite working drawings and sections at a suitable scale not less than 3 8 1 0 clearly showing how his work is to be installed in relation to the work of other trades If the Contractor installs his work before coordination with other trades he shall make the necessary changes in his work to correct the condition without extra charge to the Owner The Contractor shall furnish to other trades as necessary for coordination all templates patterns setting plans shop details and the like for the proper installation of work and for the purpose of coordinating adjacent work Piping ductwork and equipment to be concealed in walls floors and ceilings shall be installed before walls floors and ceilings are constructed Penetrations or openings required in walls floors and ceilings for piping ductwork equipment or for any other reason shall be sized located and coordinated with other trades involved before construction of the walls floors and ceilings 3 4 SAFETY REQUIREMENTS A B The finished installation of all systems and equipment shall be safe creating no hazard when operating or at rest All moving parts shall be covered with appropriate guards All rough edges of equipment and materials shall be made smooth Applicable OSHA requirements shall be met in full 3 5 MANUFACTURERS OF MATER
340. t is designed or is specified MECHANICAL GENERAL PROVISIONS 15010B 6 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 8 Except as specifically indicated or specified materials and equipment removed from an existing structure shall not be used in the completed work B Manufacturer s Instructions 1 When Contract Documents require that installation of work shall comply with manufacturer s printed instructions obtain and distribute copies of such instructions to parties involved in the installation including two copies to Owner s representative Maintain one set of complete instructions at the job site during installation and until completion 2 Handle install connect clean condition and adjust products in strict accord with such instructions and in conformity with specified requirements a Should job conditions or specified requirements conflict with manufacturer s instructions consult with Owner s representative for further instructions b Do not proceed with work without clear instructions 3 Perform work in accord with manufacturer s instructions Do not omit any preparatory step or installation procedure unless specifically modified or exempted by Contract Documents or by Owner s representative in writing C Transportation and Handling 1 Arrange deliveries of products in accord with construction schedules coordinate to avoid conflict with work and conditions at the site a Deliver pro
341. t not be limited to the following A Submit legend list of wording abbreviations symbols letter size and color coding for all mechanical identification B Submit pipe identification coatings including color schemes color field legend coating specification and material safety data sheets MSDS C Submit pipe identification plastic snap or strap around markers including color scheme size color field and legend D Submit underground warning tape showing color scheme color field legend size and construction specifics polyethylene and metallic E Submit plastic nameplates showing material color schemes size lettering and attachment F Submit conduit identification plastic snap around markers including color scheme size color field and legend G Submit manufacturer s installation instructions for all products 1 4 SAMPLES A Submit representative samples of valve tags equipment labels underground tapes conduit markers and pipe markers for approval B Submit a complete as installed sample of stencil painting of pipe labels for approval of color field text size clarity and stencil method quality Stenciling will not be allowed without confirming sample submittal for quality control PART 2 PRODUCTS 2 1 ACCEPTABLE MANUFACTURERS A Identification Markers and Components Almetek Industries Brady USA Inc Craftmark Identification Systems Panduit Corporation Seton Name Plate Company IRN B Identi
342. t stop the associated pump or chiller B Control Dampers 1 The FMS Contractor shall furnish all automatic dampers not provided by unit manufacturer All automatic dampers shall be sized for the application by the FMS Contractor or as specifically indicated on the Drawings 2 All dampers used for throttling airflow shall be of the opposed blade type arranged for normally open or normally closed operation as required The damper is to be sized so that when wide open the pressure drop is a sufficient amount of its close off pressure drop to shift the characteristic curve to near linear 3 All dampers used for two position open close control shall be parallel blade type arranged for normally open or closed operation as required 4 Damper frames and blades shall be constructed of either galvanized steel or aluminum Maximum blade length in any section shall be 48 Damper blades shall be 16 gauge minimum and shall not exceed six 6 inches in width Damper frames shall be 16 gauge minimum hat channel type with corner bracing Additional stiffening or bracing shall be provided for any section exceeding 48 in height All damper bearings shall be made of stainless steel or oil impregnated bronze Dampers shall be tight closing low leakage type with synthetic elastomer seals on the blade edges and flexible stainless steel side seals Dampers of 48x48 size shall not leak in excess of 8 5 cfm per square foot when closed against 4 w
343. ta For each type of product PART 2 PRODUCTS See Editing Instruction No 1 in the Evaluations for cautions about named manufacturers and products For an explanation of options and Contractor s product selection procedures see Section 016000 Product Requirements 2 1 PERFORMANCE REQUIREMENTS Retain Fire Resistance Rated Assemblies Paragraph below where gypsum board is part of fire resistance rated assemblies Indicate design designations of specific assemblies on Drawings A Fire Resistance Rated Assemblies For fire resistance rated assemblies provide materials and construction identical to those tested in assembly indicated according to ASTM E 119 by an independent testing agency Retain STC Rated Assemblies Paragraph below where gypsum board is part of STC rated assemblies Indicate design designations of specific assemblies on Drawings B STC Rated Assemblies For STC rated assemblies provide materials and construction identical to those tested in assembly indicated according to ASTM E 90 and classified according to ASTM E 413 by an independent testing agency 2 2 INTERIOR GYPSUM BOARD Retain Manufacturers Paragraph and list of manufacturers below to require products from manufacturers listed or a comparable product from other manufacturers A Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the fo
344. tches B Receptacles C Device plates and box covers REFERENCES A FS W C 596 Electrical Power Connector Plug Receptacle and Cable Outlet B FS W S 896 Switch Toggle C NEMA WD 1 Specification Grade Wiring Devices D NEMA WD 5 Specific Purpose Wiring Devices SUBMITTALS A Submit product data under provisions of Section 01300 B Provide product data showing configurations finishes dimensions and manufacturer s instructions PART 2 PRODUCTS 2 1 2 2 2 3 2 4 GENERAL DESIGN Wiring devices shall be of the grounding type with hex head grounding screw to be connected to the green ground conductor ACCEPTABLE MANUFACTURERS WALL SWITCHES A Hubbell B Leviton C Pass amp Seymour D Substitutions Under provisions of Section 01600 WALL SWITCHES A Wall Switches for Lighting Circuits and Motor Loads Under 1 2 HP NEMA WD 1 FS W S 896 AC general use snap switch with toggle handle rated 20 amperes and 120 277 volts AC Handle Ivory B Wall switches shall be of the grounding type with hex head grounding screw to be connected to the green grounding conductor C Pilot Light Type Pilot strap in adjacent gang D Locator Type Lighted handle ACCEPTABLE MANUFACTURERS RECEPTACLES A Hubbell B Leviton WIRING DEVICES 16140 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 C Pass amp Seymour D Substitutions Under provisions of Section 0
345. ted and approved for all mechanical equipment rooms before proceeding with installation in these areas See other Specification Sections regarding shop drawings The right to make any responsible change in location of apparatus equipment and or routing of piping or ductwork up to the time of roughing in without involving any additional expense to the Owner is reserved by the Owner s representative SURVEYS AND MEASUREMENTS A The Contractor shall base all measurements both horizontal and vertical from established bench marks All work shall agree with these established lines and levels Verify all measurements at the site and check correctness of these as related to the work Should the Contractor discover any discrepancy between actual measurements and those indicated which prevents following good practice or the intent of the Drawings and MECHANICAL GENERAL PROVISIONS 15010B 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 Specifications he shall notify the Owner s representative and shall not proceed with his work until he has received instructions from the Owner s representative SHOP DRAWINGS AND PRODUCT DATA Submit shop drawings product data and the like as required by Part 3 Execution and by other applicable Specification Sections Identify each item submitted using applicable Specification section number or Drawing reference RECORD DOCUMENTS Contractor shall maintain at the project
346. tems and components shall have been thoroughly tested and proven in actual use No used or existing control equipment will be permitted in the new control system The DDC Direct Digital Control System shall be of a fully modular architecture permitting expansion by adding computer memory application software operator peripherals and field hardware Tie ins are required into Mechanical Contractor furnished equipment The FMS Controls Contractor shall coordinate The FMS Controls Contractor shall provide a permanently assigned engineering and construction coordinator that is experienced in coordination and directing work of the magnitude and complexity of this project The FMS Controls Contractor shall submit for review and acceptance by the Engineer prior to commencing the work the name of the proposed coordinator to be assigned to this project This coordinator shall be assigned to this project until final site visitation unless otherwise released by the Engineer Asbestos shall not be present in any materials or equipment provided on this project WORK BY OTHERS A G Automatic control valves and separable wells for immersion elements shall be furnished by the Controls Contractor and shall be installed by the Mechanical Contractor under this contractor s supervision The Mechanical Contractor shall provide and install pressure taps isolation valves and other couplings required by any pressure and or flow instrumentation specified
347. ter or grille identification as to location area and system b Manufacturer type and size C Required and resultant test quantities CFM d Deflector and or diffuser core setting e Discharge pattern setting degrees and direction Note All diffusers grilles and registers shall have their deflection and trim dampers adjusted to minimize drafts and noise 7 Duct accessories a Test fire dampers smoke dampers and combination fire and smoke dampers to prove that they open and close properly b Test control dampers to prove that they open and close properly and verify all max and min settings G Vibration isolators 1 Verify that isolators are properly installed and are not bottomed out or short circuited by improper contact 2 Document potential isolator problems for resolution by the Contractor END OF SECTION 15042B TESTS 15042B 8 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15045B MOTORS PART 1 GENERAL 1 1 1 2 CONTRACT DOCUMENTS The Contract Documents apply to this section REFERENCES A AFBMA 9 Load Ratings and Fatigue Life for Ball Bearings B AFBMA 11 Load Ratings and Fatigue Life for Roller Bearings C ANSI IEEE 112 Test Procedure for Polyphase Induction Motors and Generators D ANSI NEMA MG 1 Motors and Generators E ANSI NFPA 70 National Electrical Code F North Carolina State Building Code Volume X Energy SUBMITTALS A S
348. tered and the name and business address of its president secretary and treasurer The Bid shall bear the seal of the corporation attested by the secretary Anyone signing the Bid as agent shall file with the Bid legal evidence of the authority to do so INSTRUCTIONS TO BIDDERS 00100 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 11 13 14 15 16 17 18 19 20 Familiarity with Laws The Bidder is assumed to be familiar with all federal state and local laws ordinances rules and regulations that in any manner affect bidding and performance The Bidder will not be relieved of responsibility due to ignorance of the law Addenda All addenda issued by the Owner prior to the opening of Bids for the purpose of changing the specifications or clarifying the meaning of same shall be binding in the same way as if written in the specifications All addenda are available to Bidders at the office of the Owner and it is each Bidder s responsibility to check with the issuing office and immediately secure all addenda before submitting a Bid It is the usual practice for the Owner to mail addenda to known Bidders but it cannot be guaranteed that all Bidders will receive addenda in this manner Each Bidder shall acknowledge receipt of the addenda by notation in the space provided on the Bid Form Examination of Drawings and Specifications The Bidder is required before submitting a bid to become familiar with the nature an
349. tering shall be placed below or above the horizontal centerline of the pipe Size of Legend Letters OUTSIDE DIAMETER OF LENGTH OF SIZE OF INSULATION OR PIPE COLOR FIELD LETTERS 3 z 1 1 8 1 1 1 2 fa 2 8 2 2 1 2 6 12 3 8 m 10 24 4 Over 10 32 4 Pipe Markers 1 Semi Rigid Plastic a Semi rigid plastic not pressure sensitive identification markers shall have 1 approved color coded background 2 proper color of legend in relation to background color 3 approved legend letter size 4 approved marker length and 5 direction of flow arrows b Snap around markers shall be used on outside diameters of 3 4 thru 5 7 8 These markers shall be custom formed to snap on and completely encircle the pipe with a substantial overlap C Strap around markers shall be used on outside diameters of 6 and larger 15035B 2 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 Markers shall be secured with stainless steel spring fasteners Non metallic fasteners shall be used where specifically directed d For pipes with outside diameter under 3 4 too small for color bands and legends brass identification shall be used at specified locations e Markers shall be covered and all printing shall be sealed beneath tough clear outdoor grade acrylic plastic Markers shall resist weather repel dirt abrasion and grease as well as withstand acid chemical and other corrosive conditions
350. tervals and duct reinforcement requirements in accordance with SMACNA HVAC Duct Construction Standards Notching folding bending and fit up tolerances shall be appropriate for the composite duct assembly Joints shall be sealed with approved materials in accordance with SMACNA Duct Sealing Requirements in Table 1 2 in the SMACNA HVAC Duct Construction Standards for the duct static pressure construction class Bar or angle stock that is incorporated into the transverse joint shall be secured in accordance with SMACNA recommendations Fasteners shall be appropriate for the ductwork materials of construction and shall be in accordance with SMACNA recommendations TRANSVERSE DUCT JOINTS PROPRIETARY SYSTEM Contractor Option For transverse DUCTWORK 15840B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 joints 36 wide and larger transverse duct joints shall be accomplished using components manufactured and supplied by Ductmate Industries or prior approved equal and shall comply with the following requirements A DUCTWORK All angle steel components shall comply with ASTM A 527 with G90 galvanized finish All corner steel components shall comply with ASTM A 526 with G90 galvanized finish Joint sealant materials shall be Ductmate 5511M or approved equal and shall be as recommended by the joint system manufacturer Joint sealant shall be non skinning non oxidizing product capable of withstanding joint
351. tice to proceed that will be issued by the Owner BID FORM 00310 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 10 BID FORM b The bidder will commence work with an adequate force and equipment at the time stated in the Notice to Proceed and complete all work in the number of days stipulated from the date stated in said notice including working overtime or on Saturdays Sundays or legal holidays except as specifically allowed by the Contract Documents and approved by the Owner Bids shall include all sales tax and other applicable taxes and fees Name and business address mailing and street of Bidder to which all formal notices shall be sent Execution of Contract Bidder agrees that in case of failure on his part to execute the said Contract and Bonds within two 2 days after the date indicated in the Notice of Award the check or bid bond accompanying this Bid and the money payable thereon shall be paid to the OWNER as liquidated damages for such failure otherwise the Bid Bond or check accompanying this Bid shall be returned to the undersigned Bid Documentation The following documents are attached to and made a part of this Bid Non collusion Affidavit EEO Report Statement Certificate of Nonsegregated Facilities Performance of Work by Subcontractors Certification Regarding Fair Trade Buy American Certification Certification Regarding Debarment Suspension Ineligibility and Voluntary Exclusion
352. tion is in accordance with Drawings Specifications and instructions In the event that the Owner considers it impractical because of unsuitable test conditions or some other factors to execute simultaneous final acceptance of all equipment portions of the installation may be certified by the Owner for final acceptance when that portion of the system is complete and ready for operation Contractor shall guarantee the work done in accordance with Drawings and Specifications and to be free of defective materials and workmanship Anything unsatisfactory shall be corrected immediately and at Contractor s expense For a period of one year after acceptance Contractor shall replace without any expense to the Owner any defective materials or workmanship including any cutting or patching which may be required END OF SECTION 16010 ELECTRICAL GENERAL REQUIREMENTS 16010 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 16060 GROUNDING AND BONDING PART 1 GENERAL 1 1 WORK INCLUDED Grounding and bonding of the electrical systems 1 2 SYSTEM DESCRIPTION A The power distribution system shall be grounded at each voltage level The conduit and neutral conductors of the wiring systems and all electrical equipment shall be grounded B Each conductive non current carrying part of the electrical system shall be bonded to an equipment grounding conductor sized in accordance with NEC unless otherwise sho
353. tion shall be PC Foamglas POLYSTYRENE INSULATION Piping Product shall be rigid 20 psi compressive strength minimum 1 6 lb cu ft average density service temperature range of 297 deg F to 165 deg F k value of 0 24 at 75 deg F mean temperature Insulation shall have a water vapor permeability of 1 5 perm inch Material shall be manufactured by expanding molten polystyrene in a continuous extrusion process to form a rigid closed cell foam with a uniform void free micro cellular structure Insulation shall have a flame spread rating of 5 for insulation thickness of 1 and less the smoke developed rating shall be 115 for insulation thickness greater than 1 the smoke developed rating shall be 165 When specified for applications requiring a vapor seal furnish insulation with ASJ and self sealing lap SSL joint on longitudinal seams ASJ facing shall have a maximum permeance of 0 02 perms Acceptable Products A DC B APC VAPOR RETARDER VAPOR BARRIER JACKETS A PVC Pipe Covers and Accessories Pipe 1 PVC jackets and accessories shall be self extinguishing type flame spread 25 smoke developed 50 as tested per ASTM E 84 Products shall also comply with INSULATION 15250B 5 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 NFPA 90A and 90B 2 PVC jackets and accessories shall have a service temperature range of 0 to 500 F ambient temperature range of 0 to 150 F and moisture transmissio
354. tion standards manufacturer s recommendations and this Specification 3 11 FIRE DAMPERS A DUCTWORK Fire dampers shall be installed at all locations where ductwork penetrates any floor wall or partition with a fire rating of 2 hours or more and where otherwise shown or specified on the Drawings Fire dampers shall be installed at all locations where ductwork with more than 100 square inches cross sectional area penetrates walls or partitions with a 1 hour fire rating Fire dampers are not required to be installed within ducts meeting all requirements listed below 1 Duct cross sectional area shall be 100 square inches or less 2 Duct shall be constructed of minimum 0 0217 inch thick steel 3 Duct shall continue with no openings at least 5 feet on each side of rated wall 4 Duct shall be installed above a ceiling Install fire dampers in accordance with manufacturer s UL approved printed instructions or SMACNA s Fire Smoke and Radiation Damper Installation Guide for HVAC Systems whichever is more stringent Provide and locate access door to allow easy adjusting and link replacement Adjust fire dampers as follows 1 Disconnect fusible link 2 Operate the fire damper several times 15840B 12 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 Adjust and correct each fire damper to assure free positive operation and proper latching 4 Reconnect fusible link 3 12 FIRESTOP SEALS
355. tions SPECIAL ITEMS OF EQUIPMENT Install special items of equipment in the duct systems including automatic dampers thermostats humidistats thermometers and other related controls under the direct supervision of the Controls Contractor Install fire alarm system smoke and temperature sensors under the direct supervision of the Electrical Contractor QUADRANTS CONTROLS INDICATING INSTRUMENTS Mount quadrants controls indicating instruments and similar equipment on the surface of the insulation of insulated ductwork CROSS BREAK OR BEAD DUCTWORK having a width or depth in excess of 12 inches VOLUME CONTROL Provide volume control and balancing dampers of the splitter butterfly or multi louver type for controlling air volume and direction and for balancing the system Stiffen ducts at damper locations to provide adequate rigidity Provide balancing damper for each supply diffuser or grille where branch duct connects to supply duct ACCESS DOORS Provide access doors in duct for all automatic dampers fire dampers controls filters duct mounted smoke detectors and similar equipment INSTRUMENT PORTS Provide instrument ports in ductwork for pitot tube test where required for air flow measurement Coordinate with TAB Contractor DUCTWORK 15840B 11 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 8 FLEXIBLE CONNECTIONS Seal flexible connections and firmly band at each connection point Flexible conn
356. tions 01300 and 16010 B Include outline drawings lamp and ballast data support points weights and accessory information for each luminaire type C Submit manufacturer s installation instructions under provisions of Section 01300 1 4 DELIVERY STORAGE AND HANDLING A Deliver products to site under provisions of Sections 01600 and 16010 B Store and protect products under provision of Section 01600 PART 2 PRODUCTS 2 1 FLUORESCENT LUMINAIRES AND ACCESSORIES A Fluorescent luminaires shall be provided with ballasts meeting the following criteria 1 Ballast to be UL Listed Class P unless otherwise noted on the Drawings Ballast to be Sound Rated A Ballast to be electronic unless otherwise noted on the Drawings Ballasts containing PCB s are not acceptable Ballast enclosure size shall be same as or smaller than magnetic ballast Light regulation shall be 10 input voltage variation Ballast shall have high power factor minimum of 90 Lamp current crest factor shall be equal to or less than 1 7 o oN oN A CO YD Input current third harmonics shall not exceed ANSI recommendations LIGHTING 16500 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 2 2 2 3 2 4 2 5 10 Flicker shall be 15 or less with any lamp suitable for the ballast 11 Ballasts shall withstand line transients per IEEE 587 Category A 12 Ballast case temperature shall not exceed 25 C rise over 40
357. tions shall be as approved by the Owner For any raceway passing through an exterior wall above or below grade provide appropriate sleeve and waterproofing Route conduits penetrating roof through openings for piping and ductwork where feasible Otherwise route through roof jacks with pitch pockets For raceways penetrating non fire rated interior walls or partitions provide steel pipe sleeves with flush fit and mortared in or plastered in as required Penetrations through fire rated walls floors and ceilings shall not diminish the fire rating and shall meet ASTM 814 UL and NEC requirements COORDINATION OF BOX LOCATIONS A C D Provide electrical boxes as shown on Drawings and as required for splices taps wire pulling equipment connections and code compliance Electrical box locations shown on Contract Drawings are approximate unless dimensioned Verify location of floor boxes and outlets in offices and work areas prior to rough in Locate and install boxes to allow access Where installation is inaccessible coordinate locations and sizes of required access doors with Owner Locate and install to maintain headroom and to present a neat appearance OUTLET BOX INSTALLATION A Do not install boxes back to back in walls Provide minimum 6 inch separation except provide minimum 24 inch separation in acoustic rated walls Locate boxes in masonry walls to require cutting of masonry unit corner only Coordi
358. tirely 6 2 Mutual Responsibility 6 2 3 Delete entirely and substitute the following 6 2 3 The Contractor shall reimburse the Owner for any costs the Owner incurs that are payable to a separate contractor because of the Contractor s delays improperly timed activities or defective construction ARTICLE 8 TIME 8 3 Delays and Extensions of Time Add the following 8 3 1 1 The time lost due to delays beyond the control of the Contractor will be considered to be equivalent to the number of days the path of critical events is lengthened by the delay regardless of the duration of the delay itself If required by the Architect the Contractor shall indicate this path of critical events by diagram or narrative in such detail as may be necessary to justify the claim and establish the number of days delay The path of critical events is defined as the series of interdependent construction events that must be sequentially performed and that require a longer total time to perform than any other series SUPPLEMENTARY CONDITIONS 00800 4 PTIA Ticket Counter Ceiling Renovation 12 001 000 8 4 Liquidated Damages The Owner and Contractor recognize that time is of the essence with respect to the Contractor s completion of this Contract and that the Owner will suffer financial loss if the Work is not substantially completed within the time specified plus any extensions thereof allowed in accordance with the General Conditions They also recogni
359. ts as may be necessary at the work site and adapting his work to local conditions D Conditions sometimes occur which require certain changes in the Drawings and Specifications In the event that such changes in the Drawings and Specifications are necessary the same are to be made by the Contractor without expense to the Owner providing that such changes do not require furnishing more materials or performing more labor than the true intent and meaning of the Drawings and Specifications It shall be understood that while the Drawings are to be followed as closely as circumstances will permit the Contractor is held responsible for the installation of the system according to the true intent and meaning of the Drawings Anything not entirely clear in the Drawings and Specifications will be fully explained if request is made to the Owner s representative Should conditions arise where in the judgement of the Contractor certain changes will be advisable the Contractor shall communicate with the Owner s representative and secure his approval of these changes before going ahead with the work E Contractor shall visit the work site during bidding and familiarize himself with job conditions No extras will be allowed because of additional work necessitated by or change in plans required because of evident job conditions that are not indicated on the Drawings 3 2 WORKMANSHIP A The Contractor shall furnish the services of an experienced superintenden
360. ture Submit Samples for a final check of these characteristics with other elements and a comparison of these characteristics between the final submittal and the actual component as delivered and installed a Where variation in color pattern texture or other characteristic is inherent in the material or product represented submit at least 3 multiple units that show approximate limits of the variations b Refer to other Specification Sections for requirements for Samples that illustrate workmanship fabrication techniques details of assembly connections operation and similar construction characteristics Cc Refer to other Sections for Samples to be returned to the Contractor for incorporation in the Work Such Samples must be undamaged at time of use On the transmittal indicate special requests regarding disposition of Sample submittals d Samples not incorporated into the Work or otherwise designated as the Owner s property are the property of the Contractor and shall be removed from the site prior to Substantial Completion Submittals Except for Samples illustrating assembly details workmanship fabrication techniques connections operation and similar characteristics submit 2 sets The Architect will return one set marked with the action taken Maintain sets of Samples as returned at the Project Site for quality comparisons 01300 5 PTIA Ticket Counter Ceiling Renovation 12 001 000 throughout the course of constru
361. turn retainage payments to each subcontractor within seven 7 calendar days after the subcontractor s work is satisfactorily completed Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval of the Owner This clause applies to both DBE and non DBE subcontractors NAME OF BIDDER BY TITLE DATE BID FORM 00310 13 PTIA Visitor Information Booths 12 040 000 BID SECURITY BID FORM 00310 14 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 00500 AGREEMENT 1 1 AGREEMENT A The Standard Form of Agreement between Owner and Contractor where the basis of payment is a stipulated sum AIA Document A101 2007 Edition forms the basis of the Contract between the Owner and Contractor END OF SECTION 00500 AGREEMENT 00500 1 AIA Document A101 2007 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum AGREEMENT made as of the day of in the year In words indicate day month and year BETWEEN the Owner Name legal status address and other information Piedmont Triad Airport Authority 1000A Ted Johnson Parkway Greensboro NC 27409 Telephone Number 336 665 5600 and the Contractor Name legal status address and other information She DURES UP for the following Project Name location and
362. ty fifth 25th day of the following month If an Application for Payment is received by the Architect after the application date fixed above payment shall be made by the Owner not later than Forty five 45 days after the Architect receives the Application for Payment Federal state or local laws may require payment within a certain period of time 5 1 4 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents The schedule of values shall allocate the entire Contract Sum among the various portions of the Work The schedule of values shall be prepared in such form and supported AIA Document A101 2007 Copyright 1915 1918 1925 1937 1951 1958 1961 1963 1967 1974 1977 1987 1991 1997 and 2007 by The American Institute of Architects All rights reserved WARNING This AIA Document is protected by U S Copyright Law and International Treaties Unauthorized reproduction or distribution of this AIA Document or any portion of it may result in severe civil and criminal penalties and will be prosecuted to the maximum extent possible under the law This draft was produced by AIA software at 20 54 41 on 11 25 2012 under Order No 9534359756_1 which expires on 10 02 2013 and is not for resale User Notes 1162824017 by such data to substantiate its accuracy as the Architect may require This schedule unless objected to b
363. ubmit product data under provisions of Section 15010B Shop Drawings B Submit test results verifying nominal efficiency and power factor for three phase motors larger than 1 2 horsepower C Submit manufacturer s installation instructions OPERATION AND MAINTENANCE DATA A Submit operation and maintenance data under provisions of Section 15010B B Include assembly drawings bearing data including replacement sizes and lubrication instructions QUALIFICATIONS Manufacturer Company specializing in manufacture of electric motors for industrial use and their accessories with minimum three years documented product development testing and manufacturing experience REGULATORY REQUIREMENTS A Conform to applicable electrical code B Conform to local energy code DELIVERY STORAGE AND HANDLING A Deliver products to site and store under provisions of Section 15010B B Contractor is to protect motors stored on site from weather and moisture by maintaining factory covers and suitable weather proof covering For extended outdoor storage remove motors from equipment and store separately WARRANTY Contractor shall provide one year warranty from date of final inspection and acceptance under provisions of Section 15010B for all motors PART 2 PRODUCTS 2 1 MANUFACTURERS MOTORS TO 3 0 HORSEPOWER Baldor Electric General Electric Lincoln Electric Reliance Electric Magnetek Century Marathon MO OW gt MOTORS 1504
364. uction or operation Steel members shall be installed as required to support and anchor pipelines Supports anchors or stays which may deform or alter the shape of the piping during or after installation shall not be used All changes in size and direction shall be made with proper pipe fittings no miter fittings or joints will be accepted without prior approval of the Owner s representative Notching of copper tubing or plastic piping for connections will not be permitted All piping shall be cleaned and blown out just before installation Provide globe ball or butterfly type valves for throttling or drain service Valves shall be installed with stems vertical horizontal or inclined upward Valves shall not PIPE PIPE FITTINGS AND VALVES 15060B 3 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 3 3 3 4 3 5 be arranged with stem below body Protect all water systems against freezing throughout the progress of the installation until final acceptance All water piping shall be protected in an approved manner from freezing at any future time under normal operating circumstances All water piping shall be installed in such a manner that the entire system can be completely drained Protect pipes which are to receive a vapor barrier insulation from pipe hangers by using pipe saddles specifically designed for this purpose Closed Recirculating Systems Do not install devices which allow gas or
365. uding Owned hired non owned Bodily injury 250 000 00_ each person 500 000 00_ each accident Property damage 100 000 00 Bodily injury and property damage combined 100 000 00 4 Excess liability Umbrella Form Bodily injury and property damage combined single limit 5 000 000 00 each occurrence 5 Aircraft liability owned and non owned when applicable With limits proposed by the Contractor for Owner s approval 11 4 Performance and Other Bonds 11 4 1 Delete entirely and substitute the following 11 4 1 The Contractor shall furnish Performance and Payment Bonds each an amount at least equal to the Contract Sum as security for the faithful performance and payment of all the Contractor s obligations under the Contract Documents The Contractor shall also furnish such other Bonds as may be required by these Conditions The Performance and Payment Bonds shall be in the respective forms prescribed by Article 3 of Chapter 44A of the North Carolina General Statutes and shall obligate the Surety to the full extent and for the full term provided therein All Bonds to be provided hereunder shall be executed by such Sureties as are licensed to conduct business in North Carolina All Bonds signed by an agent must be accompanied by a certified copy of the authority to act If the Surety on any Bond furnished by the Contractor is declared a bankrupt or becomes insolvent or its right to do business is terminated in North Carolina t
366. ult Owner s representative if the design pressure for a particular zone is in question Flanging refers to the roll back operation to form a flange using the pipe wall It shall not be construed as the welding of a flange fitting to the end of a pipe the coupling of pipes or the coupling of pipes and fittings by means of flange fittings Furnace butt welded or butt welded pipe refers to a particular pipe manufacturing process The term shall not be construed as the joining of steel pipe by means of a butt weld or as the suitability of a particular type of pipe for butt welding Outside shall mean 5 feet beyond the perimeter of buildings Inside shall mean inside buildings and within 5 feet of the perimeter of buildings except that footing drains are excluded Protected pipe refers to the coating or covering of an uninsulated pipe to make it suitable for exposure to outside weather for direct burial in dry or wet earth or for submarine installations in direct contact with water 1 5 QUALITY ASSURANCE A Welding procedures and each welder shall be qualified in accordance with ASME Boiler and Pressure Vessel Code Section IX latest edition or shall have proof of test satisfactory to Owner s representative Each welder s certificate shall be made available at the work site and available to the Owner s representative upon request Each welder on the project shall be assigned a unique number traceable to him by name Each indivi
367. vation DIVISION 12 FURNISHINGS NOT USED DIVISION 13 SPECIAL CONSTRUCTION NOT USED DIVISION 14 CONVEYING SYSTEMS NOT USED DIVISION 15A PLUMBING NOT USED DIVISION 15B MECHANICAL On Drawings DIVISION 16 ELECTRICAL On Drawings DIVISION 15B MECHANICAL 12 001 000 15010B MECHANICAL GENERAL PROVISIONS 15035B MECHANICAL IDENTIFICATION 15042B TESTS 15045B MOTORS 15060B PIPE PIPE FITTINGS AND VALVES 15060SB PIPING SCHEDULE SERVICE amp MATERIAL SYSTEM 15080B HYDRONIC SPECIALTIES 15090B SUPPORTS ANCHORS AND SEALS 15201B VIBRATION ISOLATION 15250B INSULATION 15767B FAN COIL UNITS 15840B DUCTWORK 15840SB DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM 15870B AIR OUTLETS amp INLETS DISTRIBUTION 15900B FMS CONTROLS AND INSTRUMENTATION DIVISION 16 ELECTRICAL 16010 ELECTRICAL GENERAL REQUIREMENTS 16060 GROUNDING AND BONDING 16070 HANGERS AND SUPPORTS 16075 ELECTRICAL IDENTIFICATION 16080 ELECTRICAL TESTING 16120 CONDUCTORS AND CABLES 16130 CONDUIT AND BOXES 16140 WIRING DEVICES 16410 DISCONNECT SWITCHES AND FUSING 16440 PANELBOARDS 16500 LIGHTING TABLE OF CONTENTS PAGE TC 2 PTIA Ticket Counter Ceiling Renovation 12 001 000 SECTION 00020 INVITATION TO BID To All Interested Parties The Piedmont Triad Airport Authority 1000 A Ted Johnson Parkway Greensboro North Carolina 27409 will receive sealed bids in the Stanley Frank Board Room at the Piedmont Triad Internati
368. ve and procedural requirements for submittals required for performance of the Work including the following Contractor s construction schedule Submittal schedule Daily construction reports Shop Drawings Product Data Samples Quality assurance submittals Approved Equal submittals D O OTTE OO Ie B Administrative Submittals Refer to other Division 1 Sections and other Contract Documents for requirements for administrative submittals Such submittals include but are not limited to the following Permits Applications for Payment Performance and payment bonds Insurance certificates List of subcontractors Or a G Related Sections The following Sections contain requirements that relate to this Section 1 Division 1 Section Coordination specifies requirements governing preparation and submittal of required Coordination Drawings 1 3 DEFINITIONS A Field samples are full size physical examples erected on site to illustrate finishes coatings or finish materials Field samples are used to establish the standard by which the Work will be judged B Mockups are full size assemblies for review of construction coordination testing or operation they are not Samples 1 4 SUBMITTAL PROCEDURES SUBMITTALS 01300 1 PTIA Ticket Counter Ceiling Renovation 12 001 000 A Coordination Coordinate preparation and processing of submittals with performance of construction activities Transmit each submittal suffic
369. water to leak or which may encourage tampering with the closed to oxygen integrity of the system Equip all closed system pumps with mechanical seals Install manual not automatic air vents at the tops of all risers at all high points and at points that will tend to trap air for the purpose of purging during initial fill and adjustment only Do not pitch horizontal runs of closed system piping unless specifically required on Drawings Install runs of closed system piping to facilitate ganged hanging Do not install piping in a manner that creates pockets unless specifically shown on the Drawings LAYOUT CUTTING AND FITTING UP Pipe and tubing shall be cut accurately to suit field conditions Pipe ends that are to be butt welded shall be beveled in accordance with ANSI B16 25 Burrs shall be removed by reaming and other objectionable defects shall be removed by machining chipping or grinding Laterals Y fittings shall be used for branch connections in drainage piping unless otherwise indicated CONCEALED PIPE A In general all pipe in finished spaces shall be run concealed in floors walls partitions and above ceilings Under no circumstances shall gas piping be run in floors or walls or above concealed ceiling spaces Concealment and covering of pipe shall not be done until authorized by the Owner s representative after proper tests have been made This applies to all interior work and exterior work OPENINGS SLEEVE
370. wing for each tile a USG Corporation Olympia Micro Ceiling products shall match existing so substitutions will not be accepted 1 Type ASTM E 1264 Type Ill Form 2 2 Materials Wet formed Mineral Fiber 3 Pattern Clima Plus 4 Edge Detail FLB 5 Size 24 x 24 x 5 8 6 Finish Factory applied 7 Color As selected by Architect from manufacturers standard color palette 8 Use Suspension System USG Donn Fineline DXF 2 ACT 2 b Armstrong Fine Fissured Ceiling products shall match existing so substitutions will not be accepted ONOORWN reer at r NS NS 2 Suspension Systems A Type 1 accessories be accepted Type ASTM E 1264 Type Ill Form 2 Materials Wet formed Mineral Fiber Pattern 1728 Edge Detail Square Lay in Size 24 x 24 x 5 8 Finish Factory applied Color As selected by Architect from manufacturers standard color palette Use Suspension System Armstrong Prelude XL USG Corporation Donn Fineline DXF Grid System main runners hangers and Suspension system products shall match existing so substitutions will not 2 Armstrong Prelude XL 15 16 Exposed Tee System B Available Products Subject to compliance with requirements products that may be incorporated in the Work include but are not limited to the products specified in each Acoustical Tile Ceiling Product C Products Subject Data Sheet at the end of thi
371. without adhesives into a corrosive resistant galvanized steel helix formed on the ducts outside surface The duct shall be a ULL listed 181 Class 1 duct material and shall comply with NFPA 90A and 90B The material shall have a positive pressure rating of not less than 6 w c through a temperature range of 20 to 250 F The duct material shall be factory wrapped in a thick blanket of fiberglass insulation with a C factor of 0 23 or less The insulation shall be encased in a fire retardant reinforced aluminum material vapor retarder with a perm rating of not over 0 02 15840B 9 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 The duct shall be rated for 4000 fpm duct velocity Provide adjustable diameter type self locking nylon clamps as manufactured by Panduit or equal Flexible duct shall be Type 5M as manufactured by Flexmaster or equal by Thermaflex Take offs for flexible ductwork shall be made using conical bell mouth type spin in fittings with integral balancing damper Flexmaster Model CB D or equal 2 24 DAMPERS A DUCTWORK Control dampers for HVAC systems shall be provided to allow effective modulation or close off of air flow as required for each fan system Damper frames shall be constructed to facilitate field assembly of several individual sections into larger damper area and shall be provided with openings or mounting clips to allow secure fastening of damper frame to the sur
372. wn on the Drawings C The raceway system shall not be relied on for ground continuity A green grounding conductor properly sized per NEC shall be run in all raceways PART 2 PRODUCTS 2 1 MATERIALS A Grounding and bonding conductors building wire color green Refer to Section 16120 and the Drawings B All products shall be new and wherever possible UL listed for the use intended 2 2 ACCEPTABLE MANUFACTURERS OF GROUNDING CONNECTORS A Bolted Clamp Type or Compression Type 1 Burndy 2 OZ 3 Anderson 4 Substitutions Under provisions of Section 01600 PART 3 EXECUTION 3 1 GENERAL INSTALLATION A Provide a separate green insulated copper equipment grounding conductor in feeder and branch circuits Terminate each end on a grounding lug bus bushing etc to each motor control switch receptacle junction box panelboard lighting fixture etc B Ground all raceway systems and equipment in accordance with Section 250 of the latest edition of NEC and in accordance with the Drawings and these Specifications C Boxes with concentric eccentric or oversized knockouts shall be provided with bonding bushings and jumpers The jumper shall be sized per NEC Table 250 66 and lugged to the box D Bond together exposed non current carrying metal parts of electrical equipment metal raceway system ground conductor in raceways and cables and receptacle ground connectors END OF SECTION 16060 GROUNDING AND BONDING
373. work Material Hanger Materials Insulation Jacket Pressure Class in Seal Class Notes Relief Air Temperature Range Ductwork Material Hanger Materials Insulation Jacket Pressure Class in Seal Class Notes DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM AHU 18 19 See Spec Section 15841B 55 F 85 F GS GS 2 0 B 1 10 F 95 F GS GS 100B A 4 0 15840SB 3 12 0001 000 Exhaust Fans ALL 55 F 85 F GS Insulation not GS required in 150C shaft or on A branch ducts 2 0 B 1 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 END OF SECTION 15840SB DUCTWORK SCHEDULE SERVICE amp MATERIAL SYSTEM 15840SB 4 Ticket Counter Ceilings Piedmont Triad International Airport 12 0001 000 SECTION 15870B AIR OUTLETS amp INLETS DISTRIBUTION PART 1 GENERAL 1 1 1 2 1 3 1 4 1 5 1 8 CONTRACT DOCUMENTS The Contract Documents apply to this section DEFINITIONS A Diffusers are ceiling mounted air supply outlets with built in volume and flow direction adjustments Diffusers are intended to rapidly mix supply air with room air B Linear diffusers have one or more long slot type air supply outlets with built in volume and flow direction adjustments Linear diffusers may be ceiling wall or floor mounted C Supply grilles and registers are ceiling wall or floor mounted air supply outlets with adjustable vertical and or horizontal ai
374. y the Architect shall be used as a basis for reviewing the Contractor s Applications for Payment 5 1 5 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment 5 1 6 Subject to other provisions of the Contract Documents the amount of each progress payment shall be computed as follows 1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values less retainage of Five percent 5 00 Pending final determination of cost to the Owner of changes in the Work amounts not in dispute shall be included as provided in Section 7 3 9 of AIA Document A201 2007 General Conditions of the Contract for Construction 2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction or if approved in advance by the Owner suitably stored off the site at a location agreed upon in writing less retainage of Five percent 5 00 Subtract the aggregate of previous payments made by the Owner and Subtract amounts if any for which the Architect has withheld or nullified a Certificate for Payment as provided in Section
375. yment constituting the entire unpaid balance of the Contract Sum shall be paid by the Owner to the Contractor when the Work has been completed the Contract fully performed and a final Certificate for Payment has been issued by the Architect In addition to the other submittals required by Section 9 10 2 the Contractor shall also submit to the Owner as a condition for final payment and for the payment of any remaining retainers 6 a final sales tax report in the format required by Section 3 6 1 and 7 a final report of Minority Business participation in the Work in such form and with such detail as the Owner shall reasonably require For this purpose Minority Business participation in the Work shall be determined in accordance with Section 143 128 2 of the North Carolina General Statutes 9 11 No Interest on Disputed Sums No interest shall accrue on any sum alleged to be due from the Owner for so long as a bonafide dispute exists between the parties as to the Contractor s right to payment of such sum SUPPLEMENTARY CONDITIONS 00800 5 PTIA Ticket Counter Ceiling Renovation 12 001 000 ARTICLE 11 INSURANCE AND BONDS 11 1 Contractor s Liability Insurance 11 1 2 Delete entirely and substitute the following 11 1 2 The insurance required by Section 11 1 1 shall be provided on an occurrence basis and shall be written for not less than the limits of liability specified in Section 11 1 5 or required by law whichever coverage is
376. ze the delays expense and difficulties involved determining in a legal or arbitration proceeding the actual loss suffered by the Owner if the Work is not substantially completed on time Accordingly instead of requiring any such proof but not as a penalty the Contractor shall pay the Owner liquidated damages equal to the following amount multiplied by the number of days that expire after the time specified for substantial completion until the Work is substantially complete Single Prime Contract 1 000 00 ARTICLE 9 PAYMENTS AND COMPLETION 9 10 Final Completion and Payment 9 10 1 Delete entirely and substitute the following 9 10 1 9 10 1 1 Add the following 9 10 2 1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment the Architect will promptly make such inspections and when the Architect finds the Work acceptable under the Contract Documents and the Contract fully performed the Architect will promptly upon approval of the Owner issue a final Certificate for Payment stating that to the best of the Architect s knowledge information and belief and on the basis of the Architect s observations and inspections the Work has been completed in accordance with the terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor and noted in said final Certificate is due and payable Final pa

Document A101TM - Morlando Construction LLC

Contents

Download Pdf Manuals

Related Search

Related Contents