Home

Book - University of Massachusetts Amherst

1. AUEdWOD 4no s o41u00 saSeueuJ SUMO ouM Aue noA PART 3 PROJECT PERFORMANCE For Parts 3 and 4 if you answer YES to any question please provide on a separate page a complete explanation Information is to cover the period from the date your most recent annual Sub Bidder Certificate of Eligibility was issued not extended to the date of the bid Include all details project name s and location s names of all parties involved relevant dates etc IF YOU HAVE ANY DOUBT AS TO WHETHER TO ANSWER YES IT IS BETTER TO BE OVER INCLUSIVE AND TO PROVIDE A DETAILED EXPLANATION YES NO 1 Has your firm been terminated on any contract prior to completing a project or has any E officer partner or principal of your firm been an officer partner or principal of another firm that was terminated or failed to complete a project 2 Has your firm failed or refused either to perform or complete any of its work under any contract prior to substantial completion 3 Has your firm failed or refused to complete any punch list work under any contract 4 Has your firm filed for bankruptcy or has any officer principal or individual with financial 1 interest in your current firm been an officer principal or individual with a financial interest in another firm that filed for bankruptcy Has your surety taken over or been
2. NUMBER UMA16 12 Proiect NumBer 1003430 SPEEDTYPE NuMBER 124374 The Commonwealth of Massachusetts University of Massachusetts Amherst CONTRACT FOR Mullins Security Cameras SPECIAL ATTENTION TO BIDDERS gt Bids must be made on the enclosed form 2 Fillin all applicable blank spaces on all pages of this form gt Return complete form intact Bid Express All construction projects at the University of Massachusetts Amherst are available for bidding on the Bid Express website at bidexpress com Submitting bids via the Bid Express website will become mandatory for any bid advertised on or after July 1 2015 Electronic bids may be submitted at the bidexpress com website All electronic bidders must first register on bidexpress com and create an Info Tech Digital ID Registration and Digital ID creation are free It can take up to five business days to process your Digital ID and it is highly recommended that a Digital ID be enabled at least 48 hours in advance of submitting an electronic bid Please plan accordingly A fee of 25 will be incurred for bidding electronically on a pay per solicitation basis alternatively you may subscribe for 50 per month to have access to all solicitations and email notifications Electronic Bid Bonds To utilize the Electronic Bid Bond option please contact either Surety 2000 at 800 660 3263 or help surety2000 com or InSure Vision Technologies at 818 783 3460 or info insur
3. JI ON SJA diusuonejaJ 40 sseuisnq e ysnosy Jaya Auedwod JnoA 40 saseuew SUMO Aue ueduJoo JNOA YUM suosJed 32e3u05 y AUe sa diusuonej a4 ssauisng e ysnosy JO JeuSisap YUM 4no s o41u00 saSeueuJ SUMO ouM Aue AUedwod noA H3NDIS3G PART 3 PROJECT PERFORMANCE For Parts 3 and 4 if you answer YES to any question please provide on a separate page a complete explanation Information is to cover the period from the date your most recent annual Certificate of Eligibility was issued not extended to the date of the bid Include all details project name s and location s names of all parties involved relevant dates etc IF YOU HAVE ANY DOUBT AS TO WHETHER TO ANSWER YES IT IS BETTER TO BE OVER INCLUSIVE AND TO PROVIDE A DETAILED EXPLANATION YES NO 1 Has your firm been terminated on any contract prior to completing a project or has any 8 officer partner or principal of your firm been an officer partner or principal of another firm that was terminated or failed to complete a project 2 Has your firm failed or refused either to perform or complete any of its work under any contract prior to substantial completion
4. 4no s o41u00 SaSeueW SUMO ouM jenpiArpul Aue noA YANSISAG 3NOHd313L NOSH3d LOVLNOD 3INVN ANVdINOO JUU LO3fOHd SNOIAAYd AHL NO 83151 193 Q31314INOO H2V3 NOILVINYOSANI 39N383338 9NIMOTIOH JHL 3GlAO Sd ev OT JO 5 OTOZ OE YEW 9An284J3 5 4eppiq qns 1ueujeSeue A jassy jeydes Jo G39N3ININOO AHL 83HL3HAV YO N3HM 30 5537 938 31VG SIHL NO LOVYLNOD Y3ANN SVH Wald YNOA LVHL 3HOIN 000 0 40 S123fOWd ALVAIYd ANY TIV 151 SLOVYLNOD Q13H ATLNAYYND Z Lu Vd vv H3NDIS3G uU3NMO H3N5IS3G uU3NMO uU3NMO H3NDIS3G H3NMO YANSISAG EEUU 3NOHd313L NOS3d LOVLNOO 3INVN ANVdIN OO JILIL Lo3f Od SNOIAAYd AHL NO 83151 193 31314INOONI H2V3 NOILVINYOANI 39N343338 AHL 3GIAOd OT JO 9 OTOZ OE YEW 9412843 5 4eppiq qns 1ueujeSeue A ssy jeydes ule dxa uonsanb Jau1ie SJA peJaMsue ji ON S3A 3 diusuonejaJ 10 sseuisnq e ysnosy Jaya Auedwod jno 041u09 10 SUMO Aue noA YUM paeje suosJed 19e UOD y AUe 533 L 401 ssauisng e y8nosy JO
5. 3 Has your firm failed or refused to complete any punch list work under any contract E 4 Has your firm filed for bankruptcy or has any officer principal or individual with a financial LI E interest in your current firm been an officer principal or individual with a financial interest in another firm that filed for bankruptcy Has your surety taken over or been asked to complete any of your work under any contract Has a payment or performance bond been invoked against your current firm or has any officer principal or individual with a financial interest in your current firm been an officer principal or individual with a financial interest in another firm that had a payment or performance bond invoked Has your surety made payment to a materials supplier or other party under your payment bond on any contract Has any subcontractor filed a demand for direct payment with an awarding authority for a public project on any of your contracts Have any of your subcontractors or suppliers filed litigation to enforce a mechanic s lien against property in connection with work performed or materials supplied under any of your contracts 10 Have there been any deaths of an employee or others occurring in connection with any of your projects 11 Has any employee or other person suffered an injury in connection with any of your projects resulting in their inability to return to work for a period in excess of one yea
6. 50 13 98 7 85 0 00 0 00 21 83 2 55 15 37 7 85 1 57 0 00 24 79 3 60 16 77 7 85 1 71 0 00 26 33 4 65 18 17 7 85 1 85 0 00 27 87 5 70 19 57 7 85 11 45 0 00 38 87 6 75 20 96 7 85 11 59 0 00 40 40 T 80 22 36 7 85 11 73 0 00 41 94 8 90 25 16 7 85 12 02 0 00 45 03 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 14 43 7 85 0 00 0 00 22 28 2 55 15 87 7 85 1 57 0 00 25 29 3 60 17 31 7 85 1 71 0 00 26 87 4 65 18 75 7 85 1 85 0 00 28 45 5 70 20 20 7 85 11 45 0 00 39 50 6 75 21 64 7 85 11 59 0 00 41 08 7 80 23 08 7 85 11 73 0 00 42 66 8 90 25 97 7 85 12 02 0 00 45 84 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 PAINTER TRAFFIC MARKINGS HEAVY HIGHWAY 06 01 2015 28 49 730 1018 80 00 45 97 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 2899 8730 10 18 80 00 46 47 06 01 2016 82949 7 30 10 18 80 00 46 97 12 01 2016 83024 7 30 10 18 80 00 47 72 For apprentice rates see Apprentice LABORER Heavy and Highway PANEL amp PICKUP TRUCKS DRIVER 12 01 2012 30 28 9 07 8 00 0 00 47 35 TEAMSTERS JOINT COUNCIL NO 10 ZONE B PIER AND DOCK CONSTRUCTOR UNDERPINNING AND 08 31 2015 39 00 9 80 18 17 0 00 66 97 DECK PILE DRIVER LOCAL 56 ZONE 3 PILE DRIVER 08 31 2015 39 00 9 80 18 17 0 00 66 97 PILE DRIVER LOCAL 56 ZONE 3 Issue D
7. END OF SECTION 017700 CONTRACT CLOSEOUT 10 14 2015 017700 9 of 9 16 12 12 4 2012 rev MULLINS SECURITY CAMERAS SECTION 024100 SELECTIVE DEMOLITION PART 1 GENERAL 1 1 A 1 2 GENERAL PROVISIONS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY OF DEMOLITION WORK Extent of selective demolition work is indicated on drawings Types of Selective Demolition Work Demolition required of the selective removal and subsequent offsite disposal by the General Contractor including but not limited to the following 1 Removal of abandoned electrical items 2 Removal of discontinued camera system components Furnish all shoring bracing lintel beams plates etc and all other miscellaneous equipment required for completion of this demolition work Remove all existing construction as indicated on the drawings and as otherwise required Note that drawings are general Demolition includes any incidental existing construction which requires removal in order that the demolition of each existing building or system component is completed in its entirety JOB CONDITIONS Condition of Structures Owner assumes no responsibility for actual condition of items or structures to be demolished 1 Conditions existing at time of commencement of contract will be maintained by
8. Shop Drawings Drawings diagrams details schedules and other data specially prepared for the Work by the Contractor or a Subcontractor Sub subcontractor manufacturer supplier or distributor to illustrate a portion of the Work Site The land and if any building s or space within any such building s on which or in which the Contractor is to perform the Work Specifications The Specifications are that portion of the Contract Documents consisting of the written requirements for materials equipment construction systems standards and workmanship for the Work and performance of related services Subcontractor Person or entity with whom the Contractor contracts in order to perform the Work except as otherwise specifically provided or required herein or by Law Substantial Completion For work subject to M G L c 30 s 39K substantial completion shall occur when 1 the Contractor fully completes the Work or substantially completes the Work so that the value of the Work remaining to be done is in the estimate of the Awarding Authority less than one percent of the original contract price or 2 the Contractor substantially completes the work and the Awarding Authority takes possession for occupancy whichever 94 occurs first For work subject to M G L 30 5 396 substantial completion shall mean either that the work required by the Contract has been fully completed completed except for work having a Contract Price of
9. 2 Construct each sample of mock up complete including work of all Subcontractors required in finished work Samples shall be incorporated into a larger mock up with varied products and Subcontractors if required Unless otherwise specified in the individual Section the General Contractor shall submit two labeled specimens of each Sample Samples shall be of adequate size to permit proper evaluation of material Where variations in color or in other characteristics are to be expected samples shall show the maximum range of variation Materials exceeding the variation of the approved samples will not be approved on the Work Samples which can be conveniently mailed shall be sent directly to the Designer accompanied by transmittal notice On the transmittal notice the General Contractor shall stamp his approval of Samples submitted SUBMITTAL REQUIREMENTS 10 14 2015 013300 2 of 8 12 4 2012 1 4 16 12 MULLINS SECURITY CAMERAS 5 All other Samples shall be delivered at the field office of the UMA Resident Engineer with Sample identification tag attached and properly filled in Transmittal notice of Samples so delivered with the General Contractor s stamp of approval shall be mailed concurrently to the Designer and the UMA Project Manager to confirm their receipt thereof 6 If Sample is rejected by the Designer a new Sample shall be resubmitted in the manner specified herein above This procedure shall be repeated until the S
10. Contractor s protective Owner as additional insured by form CG2010 11 85 ed to the general liability Owner as additional insured to automobile liability umbrella liability and pollution liability General Liability is endorsed with CG2404 Waiver of Subrogation in favor of the Owner 142 Builder s Risk or Installation Floater includes Owner Contractor and subcontractors of any tier as named insured Builder s Risk or Installation floater is on an All Risk basis including earthquake and flood D The Contractor shall file one certified copy of all policies with the Awarding Authority within sixty days after Contract award If the Awarding Authority or the Owner is damaged by the Contractor s failure to maintain such insurance and to comply with the terms of this Article then the Contractor shall be responsible for all costs and damages to the Owner attributable thereto E Termination cancellation or material modification of any insurance required by this Contract whether by the insurer or the insured shall not be valid unless written notice thereof is given to the Awarding Authority at least thirty days prior to the effective date thereof which shall be expressed in said notice 2 Contractor s Commercial General Liability A The Contractor shall provide the following minimum general liability coverage with respect to the operations performed by Contractor and any employee subcontractor or supplier unle
11. If within any guarantee period repairs or changes are required in connection with guaranteed work General Contractor shall promptly upon receipt of notice from UMA and without additional expense to UMA within ten business days 1 Place in satisfactory condition in every particular all guaranteed work and correct all defects 2 Make good all damage to building site equipment or contents thereof including redecoration which in the opinion of the Designer results from the use of material equipment or workmanship which are inferior defective or not in accord with the terms of the Contract If General Contractor after such notice fails to proceed immediately to comply with terms of guarantee UMA may correct defects and hold General Contractor liable for all expenses incurred Promptly after completion of the work obtain from each Subcontractor where a guarantee is required a warranty addressed to and in favor of UMA or the User Agency if directed by UMA Delivery of any warranty required does not relieve the General Contractor from any obligation assumed under other provisions of the Contract Deliver guarantees and warrantees to the Designer before or with the application for Final Payment The general warranty set forth in the General Conditions is in addition to exclusive of and not in substitution of such guarantees as may be required in the Specifications PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used
12. SUMMARY Section Includes 1 Building wires and cables rated 600 V and less 2 Connectors splices and terminations rated 600 V and less ACTION SUBMITTALS Product Data For each type of product INFORMATIONAL SUBMITTALS Field quality control reports PART 2 PRODUCTS 2 1 A B CONDUCTORS AND CABLES Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following 1 Alcan Products Corporation Alcan Cable Division 2 General Cable Technologies Corporation 3 Southwire Incorporated Copper Conductors shall be used Comply with NEMA WC 70 ICEA S 95 658 Conductor Insulation Comply with NEMA WC 70 ICEA S 95 658 for Type THHN 2 THWN 2 and Type XHHW 2 LOW VOLTAGE ELECTRICAL CONDUCTORS AND CABLES 10 14 2015 260519 1 of 4 2 2 2 3 UMA16 12 MULLINS SECURITY CAMERAS Multiconductor Cable Comply with NEMA WC 70 ICEA S 95 658 for metal clad cable Type MC steel armor with ground wire MC shall be used only in concealed spaces and as approved by the Engineer of Record CONNECTORS AND SPLICES Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following 1 AFC Cable Systems Inc 2 Hubbell Power Systems Inc 3 O Z
13. 42103 248H 0130207 9 12 0 42103 9 12 0 42103 248H 9 12 0 42103 248H 9 2 42103 8 31LIL LOAfOUd x LON 83551 SVM ALITI8I5r13 30 31V21I311832D YNOA ALVG AHL JDNIS Q31314INOO SVH Wald YNOA 5133 31VAlid TIV 151 SLO3fOld Q3131dINOO T LuVd oe Y4ANDISIG H3N5IS3Q H3NMO YINOISIO Y4ANDISIG H3N5IS3Q u3NMO 3NOHd313L NOS3d LOVLNOD 3INVN ANVdIN OO JILIL Lo3fO sd 29 29 29 29 SNOIAAYd 83151 193 GALAIdWOD HO2V3 HOd NOILVINYOSANI 39N333338 ONIMOTIOS JHL 3GlAO d Ie ZT 0 S e8eq OTOZ U2Je N 341729443 JUaLUA e S e1epdg 4012864100 juawaseuep jessy e3ide UOLS uonsanb Jayza SJA ON S3A diusuonejaJ 40 sseuisnq e 1 Jaya Auedwod JnoA 40 seS8eueui SUMO Aue JNOA YUM suosJed 32e3u05 y AUe oN su L diusuonejoJ A Iue 40 ssauisng e uSnoJui J012e41uoo JO JeuSisap 19uwo ue YUM Aueduioo 4no s o431u00 seSeueuJ SUMO ouM
14. BRIDGES TANKS Effective Date 07 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 24 28 7 85 0 00 0 00 32 13 2 55 26 71 7 85 3 66 0 00 38 22 3 60 29 14 7 85 3 99 0 00 40 98 4 65 31 56 7 85 4 32 0 00 43 73 5 70 33 99 7 85 14 11 0 00 55 95 6 75 36 42 7 85 14 44 0 00 58 71 7 80 38 85 7 85 14 77 0 00 61 47 8 90 43 70 7 85 15 44 0 00 66 99 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 24 76 7 85 0 00 0 00 32 61 2 55 27 23 7 85 3 66 0 00 38 74 3 60 29 71 7 85 3 99 0 00 41 55 4 65 32 18 7 85 4 32 0 00 44 35 5 70 34 66 7 85 14 11 0 00 56 62 6 75 37 13 7 85 14 44 0 00 59 42 7 80 39 61 7 85 14 77 0 00 62 23 8 90 44 56 7 85 15 44 0 00 67 85 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 19 of 35 Classification Effective Date Base Wage Health Pension Supplemental Total Rate Unemployment PAINTER SPRAY OR SANDBLAST NEW 07 01 2015 32 03 7 85 12 30 0 00 52 18 0 1 1 If 30 or more of surfaces to be painted are new construction 01 01 2016 32 93 7 85 12 30 0 00 53 08 NEW paint rate shall be used PAINTERS LOCAL 35 ZONE 3 07 01 2016 33 78 7 85 12 30 0 00 53 93 01 01 2017 34 68 7 85 12 30 0 00 54 83 Apprentice PAINTER Local
15. MATERIALS AND EQUIPMENT p 108 Materials Generally p 108 Shop Drawings Product Data and Samples p 109 Tests p 110 Or Equal Submissions p 110 Delivery and Storage of Materials Inspection p 111 Defective Damaged Deteriorated Materials and Rejection Thereof p 112 PROSECUTION AND PROGRESS p 113 Beginning Progress Schedule and Completion of Work p 113 Failure To Complete Work On Time Liquidated Damages p 114 Delays Statutory Provisions p 115 Use and Occupancy Prior To Final Acceptance p 116 Certificate of Agency Use and Occupancy p 116 Final Acceptance of the Work p 118 One Year Warranty Repair List and Inspection p 119 87 ARTICLE VII CHANGES IN THE WORK p 119 Change Orders Generally 119 Methods of Computing Equitable Adjustments p 120 Work Performed Under Protest p 121 False Claims Statutory Provisions Regarding Changes p 121 Mandatory Mediation p 123 rg co Se ARTICLE VIII PAYMENT PROVISIONS p 124 Schedule of Values p 124 Payment Liabilities of the Contractor p 124 Retention of Moneys by Awarding Authority p 125 Applications for Payment p 125 Periodic Payments M G L c 30 s 39K p 127 Payment of Subcontractors M G L c 30 s 39F p 129 Contracts for Public Works governed by M G L c 30 s 39G p 132 Final Payment Release of Claims by Contractor p 134 5 5d Bu MU cuc
16. 3 25 2013 rev UMA16 12 MULLINS SECURITY CAMERAS UNIVERSITY OF MASSACHUSETTS DESIGN AND CONSTRUCTION MANAGEMENT TABLE OF CONTENTS DIVISION 01 GENERAL REQUIREMENTS Section 011000 Section 013200 Section 013300 Section 014200 Section 015000 Section 017700 Summary Construction Progress Documentation Submittal Requirements References Temporary Facilities and Controls Contract Closeout DIVISION 02 EXISTING CONDITIONS Section 024100 Selective Demolition DIVISION 26 ELECTRICAL Section 260001 Section 260519 Section 260526 Section 260529 Section 260533 Section 260553 Section 262726 Section 265700 Electrical Work Low Voltage Electrical Power Conductors and Cables Grounding and Bonding for Electrical System Hangers amp Supports for Electrical Systems Raceways and Boxes for Electrical Systems Identification for Electrical Systems Wiring Devices Video Surveillance END OF TABLE OF CONTENTS TABLE OF CONTENTS 000010 1 of 1 10 14 2015 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS SECTION 011000 SUMMARY PART 1 GENERAL 1 1 1 2 z Xcdemovozgcom cocmommonsr GENERAL PROVISIONS A Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications Equality of material article assembly or system other than those named or described in thi
17. 31 12 7 30 11 58 0 00 50 00 12 05 2016 31 80 7 30 11 58 0 00 50 68 For apprentice rates see Apprentice LABORER POWDERMAN amp BLASTER HEAVY amp HIGHWAY 06 01 2015 29 49 7 30 10 18 0 00 46 97 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 99 7 30 10 18 0 00 47 47 06 01 2016 30 49 7 30 10 18 0 00 47 97 12 01 2016 31 24 7 30 10 18 0 00 48 72 For apprentice rates see Apprentice LABORER Heavy and Highway PUMP OPERATOR CONCRETE 06 01 2015 32 97 9 70 81147 80 00 54 14 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS PUMP OPERATOR DEWATERING OTHER 06 01 2015 32 44 9 70 11 47 50 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36 For apprentice rates see Apprentice OPERATING ENGINEERS READY MIX CONCRETE DRIVER 05 01 2015 20 78 9 92 89 09 0 00 39 79 TEAMSTERS LOCAL 404 05 01 2016 21 01 10 23 9 40 0 00 40 64 RESIDENTIAL WOOD FRAME CARPENTER 08 31 2015 26 06 7 20 85 35 0 00 38 61 The Residential Wood Frame Carpenter classification applies 02 29 2016 26 81 7 20 5 35 0 00 39 36 only to the construction of new wood frame residences that do not exceed four stories including the basement CARPENTERS LOCAL 108 HAMPDEN HAMPSHIRE As of 9 1 09 Carpentry work on wood frame residential WEATHERIZATION projects shall be paid the RESIDENTIAL WOOD FRAME CARPENTER rate
18. 37 95 7 30 13 40 0 00 58 65 12 01 2016 38 95 7 30 13 40 0 00 59 65 For apprentice rates see Apprentice LABORER TEST BORING DRILLER HELPER 06 01 2015 35 17 7 30 13 40 0 00 55 87 LABORERS FOUNDATION AND MARINE 12 01 2015 35 92 7 30 13 40 0 00 56 62 06 01 2016 36 67 7 30 13 40 0 00 57 37 12 01 2016 37 67 7 30 13 40 0 00 58 37 For apprentice rates see Apprentice LABORER TEST BORING LABORER 06 01 2015 35 05 87 30 81340 0 00 55 75 LABORERS FOUNDATION AND MARINE 12 01 2015 35 80 7 30 13 40 0 00 56 50 06 01 2016 36 55 7 30 13 40 0 00 57 25 12 01 2016 37 55 7 30 13 40 0 00 58 25 For apprentice rates see Apprentice LABORER TRACTORS 06 01 2705 31 83 8970 51147 0 00 53 00 OPERATING ENGINEERS LOCAL 98 12 01 2015 32 58 9 70 11 47 0 00 53 75 For apprentice rates see Apprentice OPERATING ENGINEERS TRAILERS FOR EARTH MOVING EQUIPMENT 08 01 2015 32 52 10 41 89 33 0 00 52 26 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 32 52 10 41 10 08 0 00 53 01 06 01 2016 33 02 10 41 10 08 0 00 53 51 08 01 2016 33 02 10 91 10 08 0 00 54 01 12 01 2016 33 02 10 91 10 89 0 00 54 82 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 32 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment TUNNEL WORK COMPRESSED AIR 06 01 2015 847 33 730 13 80 80 00 68 43 LABORERS C
19. 45 16 90 8 30 8 90 0 00 34 10 2 50 18 78 8 30 8 90 0 00 35 98 3 60 22 54 8 30 8 90 0 00 39 74 4 70 26 29 8 30 8 90 0 00 43 49 5 80 30 05 8 30 14 90 0 00 53 25 Effective Date 03 17 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 4 17 35 8 30 8 90 0 00 34 55 2 50 19 28 8 30 8 90 0 00 36 48 3 60 23 14 8 30 8 90 0 00 40 34 4 70 26 99 8 30 8 90 0 00 44 19 5 80 30 85 8 30 14 90 0 00 54 05 Notes Steps are 2000 hrs Apprentice to Journeyworker Ratio 1 5 PNEUMATIC CONTROLS TEMP 09 17 2015 37 56 830 14 90 0 00 60 76 PLUMBERS amp PIPEFITTERS LOCAL 104 03 17 2016 38 56 830 14 90 0 00 61 76 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 24 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment For apprentice rates see Apprentice PIPEFITTER or PLUMBER PIPEFITTER PNEUMATIC DRILL TOOL OPERATOR HEAVY amp 06 01 2015 28 74 87 30 10 18 0 00 46 22 HIGHWAY LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway POWDERMAN amp BLASTER 06 01 2015 2975 730 811 58 0 00 48 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 30 43 7 30 11 58 0 00 49 31 06 06 2016
20. 7 30 10 18 0 00 47 72 12 01 2016 30 99 7 30 10 18 0 00 48 47 For apprentice rates see Apprentice LABORER Heavy and Highway ASBESTOS WORKER PIPES amp TANKS 06 01 2015 30 00 81040 5 45 0 00 45 94 HEAT amp FROST INSULATORS LOCAL 6 SPRINGFIELD 12 01 2015 30 94 10 40 5 45 0 00 46 79 ASPHALT RAKER 06 01 2015 29 00 87 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER ASPHALT RAKER HEAVY amp HIGHWAY 06 01 2015 82874 87 30 108 80 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway AUTOMATIC GRADER EXCAVATOR RECLAIMER 06 01 2015 32 97 9 70 11 47 0 00 54 14 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS BACKHOE FRONT END LOADER OPERATOR 06 01 2015 3297 89 70 1147 80 00 54 14 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 2 of 35 Supplemental Classification Effective Date Base Wage Hea
21. 9 20 9 79 0 00 58 80 01 01 2017 40 71 9 20 9 79 0 00 59 70 For apprentice rates see Apprentice ELECTRICIAN HVAC TESTING AND BALANCING AIR 07 01 2015 32 32 9 14 14 92 1 68 58 06 SHEETMETAL WORKERS LOCAL 63 01 01 2016 33 02 9 14 14 92 1 68 58 76 07 01 2016 33 73 9 14 14 96 1 68 59 51 01 01 2017 34 48 9 14 14 96 1 68 60 26 For apprentice rates see Apprentice SHEET METAL WORKER HVAC TESTING AND BALANCING WATER 09 17 2015 37 56 8 30 14 90 0 00 60 76 PLUMBERS amp PIPEFITTERS LOCAL 104 03 17 2016 38 56 8 30 14 90 0 00 61 76 For apprentice rates see Apprentice PIPEFITTER or PLUMBER PIPEFITTER HVAC MECHANIC 09 17 2015 937 566 88 30 1490 80 00 60 76 PLUMBERS amp PIPEFITTERS LOCAL 104 03 17 2016 38 56 8 30 14 90 0 00 61 76 For apprentice rates see Apprentice PIPEFITTER or PLUMBER PIPEFITTER HYDRAULIC DRILLS HEAVY amp HIGHWAY 06 01 2015 2924 730 10 18 0 00 46 72 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 74 7 30 10 18 0 00 47 22 06 01 2016 30 24 7 30 10 18 0 00 47 72 12 01 2016 30 99 7 30 10 18 0 00 48 47 For apprentice rates see Apprentice LABORER Heavy and Highway INSULATOR PIPES amp TANKS 09 01 2015 35 05 811 50 813 80 0 00 60 35 HEAT amp FROST INSULATORS LOCAL 6 SPRINGFIELD 09 01 2016 36 65 11 50 13 80 0 00 61 95 09 01 2017 38 25 11 50 13 80 0 00 63 55 09 01 2018 40 05 11 50 13 80 0 00 65
22. A B A B A B D UMA 16 12 MULLINS SECURITY CAMERAS SYSTEM DESCRIPTION Electrical Components Devices and Accessories Listed and labeled as defined in the Massachusetts Electrical Code by a qualified testing agency and marked for intended location and application Comply with UL 467 for grounding and bonding materials and equipment CONDUCTORS Insulated Conductors Copper wire or cable insulated for 600 V unless otherwise required by applicable Code or authorities having jurisdiction Bare Copper Conductors 1 Stranded Conductors ASTM B 8 2 Bonding Cable 28 kcmil 14 strands of No 17 AWG conductor 1 4 inch in diameter 3 Bonding Conductor 4 or 6 AWG stranded conductor 4 Bonding Jumper Copper tape braided conductors terminated with copper ferrules 1 5 8 inches wide and 1 16 inch thick CONNECTORS Listed and labeled by an NRTL acceptable to authorities having jurisdiction for applications in which used and for specific types sizes and combinations of conductors and other items connected Bolted Connectors for Conductors and Pipes Copper or copper alloy Welded Connectors Exothermic welding kits of types recommended by kit manufacturer for materials being joined and installation conditions Bus Bar Connectors Mechanical type cast silicon bronze solderless compression type wire terminals and long barrel two bolt connection to ground bus bar PART 3 EXEC
23. A COMPLETED AND SIGNED PRIME GENERAL CONTRACTOR UPDATE STATEMENT MUST BE SUBMITTED WITH EVERY PRIME GENERAL BID FOR A CONTRACT PURSUANT TO M G L c 149 844A AND M G L c 149A ANY PRIME GENERAL BID SUBMITTED WITHOUT AN APPROPRIATE UPDATE STATEMENT IS INVALID AND MUST BE REJECTED Caution This form is to be used for submitting Prime General Contract bids It is not to be used for submitting Filed Sub Bids or Trade Sub Bids AWARDING AUTHORITIES If the Awarding Authority determines that the bidder does not demonstrably possess the skill ability and integrity necessary to perform the work on the project it must reject the bid BIDDER S AFFIDAVIT swear under the pains and penalties of perjury that am duly authorized by the bidder named below to sign and submit this Prime General Contractor Update Statement on behalf of the bidder named below that have read this Prime General Contractor Update Statement and that all of the information provided by the bidder in this Prime General Contractor Update Statement is true accurate and complete as of the bid date Enter Bid Date Here Enter Name of Prime General Contractor Here Bid Date Name of Prime General Contractor Enter Project Number Here Enter Business Address Here Project Number or Business Address name if no number Enter Name of Awarding Authority Here Enter Your Telephone Number Here Awarding Authority Telephone Number SIGNATURE gt Bidder s Author
24. Definitions The words defined herein shall have the meaning stated below whenever they appear in this Article Contractor means any person corporation partnership joint venture sole proprietorship or other entity awarded a Contract pursuant to M G L c 30 s 39M M G L c 149 s 44A J and M G L c 7 s 30B P Contract means any Contract awarded or executed pursuant to M G L c 30 s 39M M G L c 149 s 44A J and M G L c 7 s 30B P which is for an amount or estimated amount greater than one hundred thousand dollars Independent Certified Public Account means a person duly registered in good standing and entitled to practice as a certified public accountant under the laws of the place of his her residence or principal office and who is in fact independent In determining whether an accountant is independent with aspect to a particular person appropriate consideration should be given to all relationships between the accountant and that person or any affiliate thereof Determination of an accountant s independence shall not be confined to the relationships existing in connection with the filing of reports with the awarding authority Records means books of original entry accounts checks bank statements and all other banking documents correspondence memoranda invoices computer printouts tapes discs papers and other documents or transcribed information of any type whether expressed in ordinary or machine langua
25. IP settings without the need to reconfigure TCP IP settings The PC based NVR shall record at a rate of up to 960 images per second ips model dependant with real time viewing at up to 30 ips per camera for live video Live ips viewing may be restricted to the IP camera operational ips rate Allow the user to adjust the resolution quality motion sensitivity and number of images per second each camera will record These adjustments shall be configurable per video input Offer the following on board storage hard drive capacity 8 0 Terabytes Be housed in a metal case The case shall be no higher than two 2 rack units 2U Have the ability to easily backup important video to an external media location CD or DVD disk or a USB Drive The unit must not stop recording during the backup process To ensure the integrity of data the NVR shall use a proprietary viewer that can detect image tampering The video clips must be able to be saved as avi files Include backup viewer software that allows the user to play back the exported video in its proprietary format on a PC Include a DVD RW recorder allowing for up to 4 Gigabytes of video data to be stored on each DVD and one 1 front accessible USB input as standard Include the following components USB Mouse USB Keyboard QWERTY NVR Repair Disc Remote Video Software Disc Rack mount attachments with screws NVR front panel key User Manual Digital format Honeywell Mouse pad DVI
26. Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 25 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice CARPENTER Residential Wood Frame 108 Hampden Hampshire Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 15 64 7 20 0 00 0 00 22 84 2 60 15 64 7 20 5 35 0 00 28 19 3 65 16 94 7 20 5 35 0 00 29 49 4 70 18 24 7 20 5 35 0 00 30 79 5 75 19 55 7 20 5 35 0 00 32 10 6 80 20 85 7 20 5 35 0 00 33 40 7 85 22 15 7 20 5 35 0 00 34 70 8 90 23 45 7 20 5 35 0 00 36 00 Effective Date 02 29 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 16 09 7 20 0 00 0 00 23 29 2 60 16 09 7 20 5 35 0 00 28 64 3 65 17 43 7 20 5 35 0 00 29 98 4 70 18 77 7 20 5 35 0 00 31 32 5 35 20 11 7 20 5 35 0 00 32 66 6 80 21 45 7 20 5 35 0 00 34 00 7 85 22 79 7 20 5 35 0 00 35 34 8 90 24 13 7 20 5 35 0 00 36 68 Notes 1 1 5 2 6 8 3 9 11 Apprentice to Journeyworker Ratio RIDE ON MOTORIZED BUGGY OPERATOR 06 01 2015 29 00 7 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice L
27. LC toilets have been installed 1 6 gpf or less Re lamp if permanent lighting system was used during construction As built marked up drawings should be completed and transferred over to the Designer Make final changeover of permanent locks and cores Advise UMA Project Manager of changeover in security provisions Perform landscape repairs Prerequisites for Department of Public Safety DPS Certificate of Inspection and or Certificate of Occupancy Prior to requesting a Department of Public Safety DPS inspection the General Contractor shall provide via transmittal to the UMA Resident Engineer the following closeout submittals 1 Project record documents and as built marked up drawings 2 Approved operating and maintenance O amp M data 3 Extended guarantees and warranties a General Contractor s General Guarantee shall effectively include 1 A written guarantee for one 1 year from date of Substantial Completion of the project against defective workmanship material installation and equipment for all work of the project Repair or replacement of defective workmanship material installation or equipment that develop within this period shall be accomplished promptly upon notification to the General Contractor to the satisfaction of the Operating Agency at no cost 2 Replace or repair material or equipment that requires excessive service during the guarantee period 3 Guarantee shall include 24 hour service
28. PART 7 LIST OF COMPLETED CONSTRUCTION PROJECTS SUBMITTED TO THE DIVISION OF CAPITAL ASSET MANAGEMENT ALONG WITH CERTIFICATION PAGE Attach here a copy of the list of completed construction projects which was submitted with your firm s Application for your most recently issued not extended or amended Sub Bidder Certificate of Eligibility The Attachment must include a complete copy of the entire Section F Completed Projects Section G Completed Projects for firms certified based upon their Prime General Application and the final page Certification Page Section in the Sub bidder Application or Section J in Prime General Application containing the signature and date that the Completed Projects list Section F or G was submitted to the Division of Capital Asset Management Division of Capital Asset Management Sub bidder Update Statement Effective March 30 2010 Page 10 of 10 UMA Number 49 UMA Number 16 12 UNIVERSITY OF MASSACHUSETTS AMHERST FORM FOR GENERAL BID M G L c 149 s 44E as amended The following must be attached to or inserted into this Bid 1 Current Bidder s Certificate of Eligibility issued by the Division of Capital Asset Management and Maintenance showing the Bidder is certified in the category of work specified in the advertisement and the bid documents for this project 2 Completed current Contractor Update Statement Form NOTE All information and the documents
29. Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 19 18 10 18 16 73 0 00 46 09 2 60 23 02 10 18 16 73 0 00 49 93 3 70 26 85 10 18 16 73 0 00 53 76 4 80 30 69 10 18 16 73 0 00 57 60 5 90 34 52 10 18 16 73 0 00 61 43 Effective Date Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate l 50 19 47 10 18 16 73 0 00 46 38 2 60 23 36 10 18 16 73 0 00 50 27 3 70 27 25 10 18 16 73 0 00 54 16 4 80 31 14 10 18 16 73 0 00 58 05 5 90 35 04 10 18 16 73 0 00 61 95 Notes Apprentice to Journeyworker Ratio 1 5 BULLDOZER POWER SHOVEL TREE SHREDDER 06 01 2015 32 97 8970 1147 0 00 54 14 CLAM SHELL OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS CAISSON amp UNDERPINNING BOTTOM MAN 06 01 2015 36 20 7 30 81340 0 00 56 90 LABORERS FOUNDATION AND MARINE 12 01 2015 36 95 7 30 13 40 0 00 57 65 06 01 2016 37 70 7 30 13 40 0 00 58 40 12 01 2016 38 70 7 30 13 40 0 00 59 40 For apprentice rates see Apprentice LABORER CAISSON amp UNDERPINNING LABORER 06 01 2015 35 05 87 30 13 40 80 00 55 75 LABORERS FOUNDATION AND MARINE 12 01 2015 35 80 7 30 13 40 0 00 56 50 06 01 2016 36 55 7 30 13 40 0 00 57 25 12 01 2016 37 55 7 30 13 40 0 00 58 25 For apprentice rates see Apprentice LABORER CAISSON amp UNDERPINNING TOP MA
30. The time frame for the Designer s review will not exceed fourteen 14 calendar days between her his receipt of submittal and contacting the UMA Project Manager After the Designer s and his her consultant engineers review distribution shall be as stated herein 1 If submittal is reviewed no exceptions taken or reviewed make corrections noted the UMA Project Manager shall compose a transmittal indicating the status The UMA Project Manager will then return one 1 copy of the submittal together with the transmittal to the Designer and shall retain one 1 copy for her his records The Designer shall copy and attach the UMA Project Manager s transmittal to each submittal stamp the submittals in concurrence with the status agreed to and transmit back to the General Contractor with one 1 copy sent directly to the UMA Resident Engineer The General Contractor shall then distribute said submittals to appropriate Subcontractors and one 1 copy to the UMA Resident Engineer 2 If submittal is reviewed revise and resubmit or rejected the UMA Project Manager shall compose a transmittal indicating the status The UMA Project Manager will then return one 1 copy of the submittal together with the transmittal to the Designer and shall retain one 1 copy for her his records The Designer shall copy and attach the UMA Project Manager s transmittal to each submittal stamp the submittals in concurrence with the st
31. The undersigned further certifies under penalty of perjury that the said undersigned is not presently debarred from doing public construction work in the Commonwealth under the provisions of section twenty nine F of chapter twenty nine or any other applicable debarment provisions of any other chapter of the General Laws or any rule or regulation promulgated thereunder The undersigned further certifies under penalties of perjury that the undersigned is not debarred from doing public construction work under any law rule or regulation of the federal government The undersigned hereby declares that the undersigned has carefully examined the Advertisement Instructions to Bidders Owner Contractor Agreement General Conditions of the Contract Special Conditions if any Plans and Specifications all other Contract Documents and also the Site upon which the proposed work is to be performed The undersigned further declares that in regard to the conditions affecting the work to be done and the labor and materials needed this proposal is based solely on the undersigned s own investigation and research and not in reliance upon any representation of any employee officer or agent of the Commonwealth 54 The undersigned further certifies under the penalties of perjury that this bid is in all respects bona fide fair and made without collusion or fraud with any other person we are the only persons interested in this proposal that it
32. as submitted by the General Contractor shall be verified by the Designer or his her Consultants Verification by the Designer shall occur during the construction process and prior to the related work being completed and covered up The As built Drawings shall be available at all time for inspection by the UMA Project Manager or Designer All deficiencies noted shall be promptly corrected The following information shall be indicated on the As Built Drawings 1 Record all changes including change orders in the location size number and type both horizontally and vertically of all elements of the project which deviate from those indicated on all the Contract Drawings 2 The tolerance for the actual location of utilities and appurtenances within the building to be marked on the As built Drawings shall be plus or minus two 2 inches 3 The location of all underground utilities and appurtenances referenced to permanent surface improvements both horizontally and vertically at ten 10 ft intervals and at all changes of direction 4 The location of all internal utilities and appurtenances concealed by finish materials including but not limited to valves coils dampers vents cleanouts strainers pipes junction boxes turning vanes variable and constant volume boxes ducts traps and maintenance devices The location of these internal utilities appurtenances and devices shall be shown by offsets to the column grid lines on the Drawing
33. assistance in obtaining insurance bonds or lines of credit in order to perform work under the Contract and shall provide the Awarding Authority with evidence that such efforts were made 5 The Contractor shall provide the Awarding Authority with a statement of the response received from each M WBE solicited including the reason for rejecting any M WBE who submitted a proposal 6 The Contractor shall take any additional measures reasonably requested by the Awarding Authority to meet the M WBE participation goal s established for this Contract including without limitation placing advertisements in appropriate media and trade association publications announcing the Contractor s interest in obtaining proposals from M WBEs and or sending written notification to M WBE economic development assistance agencies trade groups and other organizations notifying them of the project and of the work available to be subcontracted by the Contractor to M WBEs 158 B Ifthe Contractor is unable to meet the M WBE participation goals for this Contract after complying fully with each of the requirements of paragraph A above and the Contractor is otherwise in full compliance with the terms of this Article the Awarding Authority may reduce the M WBE participation goals for this Contract to the extent that such goals cannot be achieved 8 Suspension of Payment and or Performance for Noncompliance A If at any time during the performance of this C
34. requirements of Contract Documents or previous submissions Work that requires submittals shall not commence unless submitted with Designer s stamp and initials or signature indicating review and approval and UMA Project Manager s initials or signature of concurrence indicate review and approval 1 No work shall be started in the shop or on the job or materials delivered to the site until pertinent shop drawings have been approved by the Designer and the UMA Project Manager After aforesaid review and approval distribute copies Maintain one copy of each approved submittal at the project site SUBMISSION REQUIREMENTS General All submittals shall be made to the Designer s Office The Designer will log and distribute submittals for review by his consultant engineers as applicable submittals shall be both 2 hard and 1 electronic copies unless otherwise acceptable to the Designer prior to the transmittal Make submittals promptly in accordance with approved schedules and in such sequence as to cause no delay in the work Submit number of samples specified in each Section of the Specifications SUBMITTAL REQUIREMENTS 10 14 2015 013300 4 of 8 12 4 2012 1 6 16 12 MULLINS SECURITY CAMERAS Submittals shall include 1 3 S 12 13 14 Date and revision dates Project title and number The names of a Designer b General Contractor Su
35. s 39K see below and the payment due shall be 126 computed in accordance with the changes so made The provisions of said section 39K shall govern payments on which the Awarding Authority has made changes E Nocertificate for payment and no progress payment shall constitute acceptance of Work that is not in accordance with the Contract Documents The Contractor and all Subcontractors furnishing labor on this Contract agree to furnish certified payroll reports at no additional expense to the Awarding Authority The Awarding Authority may at all reasonable times audit such reports 5 Periodic Payments M G L c 30 s 39K The Awarding Authority shall make payment to the Contractor in accordance with M G L c 30 s 39K which provides as follows Within fifteen days 30 days in the case of the commonwealth including local housing authorities after receipt from the contractor at the place designated by the awarding authority if such a place is so designated of a periodic estimate requesting payment of the amount due for the preceding month the awarding authority will make a periodic payment to the contractor for the work performed during the preceding month and for the materials not incorporated in the work but delivered and suitably stored at the site or at some location agreed upon in writing to which the contractor has title or to which a subcontractor has title and has authorized the contractor to transfer title to the a
36. thereof from any moneys due or that might become due the Contractor and if such moneys shall be insufficient to cover the liquidated damages then the Contractor or the Surety shall pay to the Awarding Authority the amount due D Permitting the Contractor to continue and finish the Work or any portion of it after the time fixed in the Contract for its completion shall not be deemed as a waiver of any of the Owner s rights hereunder at law or in equity E Liquidated damages or a portion thereof may be waived by the Awarding Authority if the Contractor submits evidence satisfactory to the Awarding Authority that the delay was caused solely by conditions beyond the control of the Contractor and that the Awarding Authority has not suffered any damages as a result of said delay F Failure by the Awarding Authority to specify a sum as liquidated damages in the Owner Contractor Agreement or the insertion of N A or none in the space provided therein for liquidated damages shall not be deemed a waiver of the Awarding Authority s right to recover actual damages arising from the Contractor s failure to complete the Work on time During the period when the Awarding Authority is assessing any cost associated with the failure to meet the substantial completion end date the University of Massachusetts Amherst may create a Unilateral Change Order for an extension of dates to allow for any contractual obligations it has in association with this UMA pr
37. who will be assigned to the project if your firm is awarded the contract Attach the resume of each person listed below NAME TITLE OR FUNCTION PART 6 CHANGES IN BUSINESS ORGANIZATION OR FINANCIAL CONDITION Have there been any changes in your firm s business organization financial condition or bonding capacity since the date your current Certificate of Eligibility was issued If YES attach separate page providing complete details PART 7 LIST OF COMPLETED CONSTRUCTION PROJECTS SUBMITTED TO THE DIVISION OF CAPITAL ASSET MANAGEMENT Attach here a copy of the list of completed construction projects which was submitted with your firm s DCAM application for your most recently issued not extended or amended DCAM Certificate of Eligibility The Attachment must include a complete copy of the entire Section G Completed Projects and the final page Certification Section J containing the signature and date that the Completed Projects list Section G was submitted to the Division of Capital Asset Management Division of Capital Asset Management Prime General Contractor Update Statement Effective March 30 2010 Page 12 Of 12 38 SPECIAL NOTICE TO AWARDING AUTHORITY SUB BIDDERS UPDATE STATEMENTS ARE NOT PUBLIC RECORDS AND ARE NOT OPEN TO PUBLIC INSPECTION M G L C 149 44D Effective March 30 2010 Commonwealth of Massachusetts Division of Capital Asset Management SUB BIDDER
38. 1 20 0 00 26 32 2 60 19 88 8 55 1 20 0 00 29 63 3 70 23 20 8 55 10 78 0 00 42 53 4 75 24 86 8 55 10 78 0 00 44 19 5 80 26 51 8 55 11 98 0 00 47 04 6 80 26 51 8 55 11 98 0 00 47 04 7 90 29 83 8 55 13 18 0 00 51 56 8 90 29 83 8 55 13 18 0 00 51 56 Notes Pre 6 09 Step1 25 50 2 27 11 3 42 36 4 45 60 5 48 84 6 50 46 1 1 5 2 6 8 3 9 11 Steps 6 mos 600 hrs rates by step 7 52 08 8 53 70 Apprentice to Journeyworker Ratio CEMENT MASONRY PLASTERING 07 01 2015 839 05 10 85 813 94 1 30 65 14 BRICKLAYERS LOCAL 3 SPRINGFIELD PITTSFIELD 01 01 2016 39 62 10 85 13 94 1 30 65 71 Apprentice CEMENT MASONRY PLASTERING Springfield Pittsfield Effective Date 07 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 0 0 00 0 00 0 00 0 00 0 00 Notes Apprentice wages shall be no less than the following Steps 1 46 02 2 53 40 3 56 69 4 59 98 5 63 28 6 66 57 7 72 15 Steps 3 4 are 500 hrs All other steps are 1 000 hrs Apprentice to Journeyworker Ratio 1 3 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 6 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment CHAIN SAW OPERATOR 06 01 2015 29 00 7 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30
39. 10 25 1 50 0 00 35 87 5 75 26 31 10 25 2 00 0 00 38 56 6 81 28 50 10 25 2 00 0 00 40 75 7 88 30 70 10 25 8 00 0 00 48 95 8 94 32 89 10 25 8 00 0 00 51 14 Effective Date 06 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 17 79 10 70 1 00 0 00 29 49 2 56 20 01 10 70 1 00 0 00 31 71 3 63 22 24 10 70 1 50 0 00 34 44 4 69 24 46 10 70 1 50 0 00 36 66 5 75 26 69 10 70 2 00 0 00 39 39 6 81 28 91 10 70 2 00 0 00 41 61 7 88 31 13 10 70 8 00 0 00 49 83 8 94 33 36 10 70 8 00 0 00 52 06 Notes Apprentice to Journeyworker Ratio 1 3 GRADER TRENCHING MACHINE DERRICK 06 01 2015 32 97 9 70 11 47 0 00 54 14 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS HVAC DUCTWORK 07 01 2705 3232 914 81492 81 68 58 06 SHEETMETAL WORKERS LOCAL 63 01 01 2016 33 02 9 14 14 92 1 68 58 76 07 01 2016 33 73 9 14 14 96 1 68 59 51 01 01 2017 34 48 9 14 14 96 1 68 60 26 For apprentice rates see Apprentice SHEET METAL WORKER Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 12 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment HVAC ELECTRICAL CONTROLS 06 28 2015 38 06 9 20 9 79 0 00 57 05 ELECTRICIANS LOCAL 7 01 03 2016 38 91 9 20 9 79 0 00 57 90 07 03 2016 39 81
40. 29 9 20 6 52 0 00 41 01 6 70 27 24 9 20 7 52 0 00 43 96 Notes Steps are 800 hours Apprentice to Journeyworker Ratio 1 1 TERRAZZO FINISHERS 08 31 2015 31 76 10 18 16 41 0 00 58 35 BRICKLAYERS LOCAL 3 SPR PITT MARBLE amp TILE 02 29 2016 32 33 1018 16 41 0 00 58 92 09 05 2016 3324 810 18 81648 0 00 59 90 02 27 2017 33 81 10 18 16 48 0 00 60 47 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 31 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice MARBLE TILE TERRAZZO FINISHER Local 3 Marble Tile Spr Pitt Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 15 88 10 18 16 41 0 00 42 47 2 60 19 06 10 18 16 41 0 00 45 65 3 70 22 23 10 18 16 41 0 00 48 82 4 80 25 41 10 18 16 41 0 00 52 00 5 90 28 58 10 18 16 41 0 00 55 17 Effective Date 02 29 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 16 17 10 18 16 41 0 00 42 76 2 60 19 40 10 18 16 41 0 00 45 99 3 70 22 63 10 18 16 41 0 00 49 22 4 80 25 86 10 18 16 41 0 00 52 45 5 90 29 10 10 18 16 41 0 00 55 69 Notes Apprentice to Journeyworker Ratio 1 5 TEST BORING DRILLER 06 01 2015 36 45 7 30 13 40 0 00 57 15 LABORERS FOUNDATION AND MARINE 12 01 2015 37 20 7 30 13 40 0 00 57 90 06 01 2016
41. 31 2015 31 76 10 18 1641 80 00 58 35 BRICKLAYERS LOCAL 3 SPR PITT MARBLE amp TILE 02 29 2016 32 33 10 18 16 41 0 00 58 92 09 05 2016 33 24 10 18 16 48 0 00 59 90 02 27 2017 33 81 10 18 16 48 0 00 60 47 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 16 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice MARBLE TILE TERRAZZO FINISHER Local 3 Marble Tile Spr Pitt Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 15 88 10 18 16 41 0 00 42 47 2 60 19 06 10 18 16 41 0 00 45 65 3 70 22 23 10 18 16 41 0 00 48 82 4 80 25 41 10 18 16 41 0 00 52 00 5 90 28 58 10 18 16 41 0 00 55 17 Effective Date 02 29 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 16 17 10 18 16 41 0 00 42 76 2 60 19 40 10 18 16 41 0 00 45 99 3 70 22 63 10 18 16 41 0 00 49 22 4 80 25 86 10 18 16 41 0 00 52 45 5 90 29 10 10 18 16 41 0 00 55 69 Notes Apprentice to Journeyworker Ratio 1 5 MARBLE MASONS TILELAYERS amp TERRAZZO MECH 08 31 2015 38 36 10 18 16 73 0 00 65 27 BRICKLAYERS LOCAL 3 SPR PITT MARBLE amp TILE 02 29 2016 38 93 10 18 16 73 0 00 65 84 09 05 2016 39 83 10 18 16 81 0 00 66 82 02 27 2017 40 40 10 18 16 81 0 00 67 39 Issue Date 09 17 2015 Wage Req
42. 35 09 01 2019 42 05 11 50 13 80 0 00 67 35 Apprentice ASBESTOS INSULATOR Pipes amp Tanks Local 6 Springfield Effective Date 09 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 17 53 11 50 10 05 0 00 39 08 2 60 21 03 11 50 10 80 0 00 43 33 3 70 24 54 11 50 11 55 0 00 47 59 4 80 28 04 11 50 12 30 0 00 51 84 Effective Date 09 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 18 33 11 50 10 05 0 00 39 88 2 60 21 99 11 50 10 80 0 00 44 29 3 70 25 66 11 50 11 55 0 00 48 71 4 80 29 32 11 50 12 30 0 00 53 12 Notes Steps are 1 year Apprentice to Journeyworker Ratio 1 4 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 13 of 35 Classification Effective Date Base Wage Health Pension Supplemental Total Rate Unemployment IRONWORKER WELDER 09 16 2015 30 44 7 80 819 60 0 00 57 84 IRONWORKERS LOCAL 7 SPRINGFIELD AREA 03 16 2016 31 09 7 80 19 60 0 00 58 49 09 16 2016 31 74 7 80 19 60 0 00 59 14 03 16 2017 32 39 7 80 19 60 0 00 59 79 Apprentice RONWORKER Local 7 Springfield Effective Date 09 16 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 60 18 26 7 80 19 60 0 00 45 66 2 70 21 31 7 80 19 60 0 00 48 71 3 75 22 83 7 80 19 60 0 00 50 23 4 80 24 35 7 80 19 60 0 00 51
43. 35 Zone 3 Spray Sandblast New Effective Date 07 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 16 02 7 85 0 00 0 00 23 87 2 55 17 62 7 85 1 57 0 00 27 04 3 60 19 22 7 85 1 71 0 00 28 78 4 65 20 82 7 85 1 85 0 00 30 52 5 70 22 42 7 85 11 45 0 00 41 72 6 75 24 02 7 85 11 59 0 00 43 46 7 80 25 62 7 85 11 73 0 00 45 20 8 90 28 83 7 85 12 02 0 00 48 70 Effective Date 01 01 2016 Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 16 47 7 85 0 00 0 00 24 32 2 55 18 11 7 85 1 57 0 00 27 53 3 60 19 76 7 85 1 71 0 00 29 32 4 65 21 40 7 85 1 85 0 00 31 10 5 70 23 05 7 85 11 45 0 00 42 35 6 75 24 70 7 85 11 59 0 00 44 14 7 80 26 34 7 85 11 73 0 00 45 92 8 90 29 64 7 85 12 02 0 00 49 51 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 PAINTER SPRAY OR SANDBLAST REPAINT 07 01 2015 29 35 7 85 12 30 0 00 49 50 PAINTERS LOCAL 35 ZONE 3 01 01 2016 30 25 7 85 12 30 0 00 50 40 07 01 2016 31 11 7 85 12 30 0 00 51 26 01 01 2017 32 00 7 85 12 30 0 00 52 15 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 20 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice PAINTER Local 35 Zone 3 Spray Sandblast Repaint Effective Date 07 01 2015 Supplem
44. 42 T 80 39 61 7 85 14 77 0 00 62 23 8 90 44 56 7 85 15 44 0 00 67 85 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 DEMO ADZEMAN 06 01 2015 35 25 7 30 13 20 0 00 55 75 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 36 00 7 30 13 20 0 00 56 50 For apprentice rates see Apprentice LABORER Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 7 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment DEMO BACKHOE LOADER HAMMER OPERATOR 06 01 2015 36 25 7 30 13 20 0 00 56 75 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 37 00 7 30 13 20 0 00 57 50 For apprentice rates see Apprentice LABORER DEMO BURNERS 06 01 2015 36 00 7 30 13 20 0 00 56 50 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 36 75 7 30 13 20 0 00 57 25 For apprentice rates see Apprentice LABORER DEMO CONCRETE CUTTER SAWYER 06 01 2015 36 25 7 30 13 20 0 00 56 75 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 37 00 7 30 13 20 0 00 57 50 For apprentice rates see Apprentice LABORER DEMO JACKHAMMER OPERATOR 06 01 2015 36 00 7 30 13 20 0 00 56 50 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 36 75 7 30 13 20 0 00 57 25 For apprentice rates see Apprentice LABORER DEMO WRECKING LABORER 06 01 2015 35 25 7 30 13 20 0 00 55 75 LABORERS ZONE 3 BUILDING amp SITE 12 01 2015 36 00 7 30 1
45. Aue noA H3NDIS3G ce se ejd 01 zT Aq 3 efo4d ay ui 42 SYZUOW JO y ApIAIp y ui 3j9 SYJUOW ZT ULY 9JOUJ J e T 914A ainpayps yafosd aui S euo SSA Jl e Z uuinjo5 5 6 5 jo 8101 LOVYLNOD 3131dIAOONI TIY 30 ANIVA G3ZNVANNY Aq papiaip 8 102 102 YOM 9 102 X S 02 a1ou 225 3131dWOONI 3131d4WO2 40 INVA ou sa AuO931V2 ONINIVAISY LON 3131dlNOO ddd S31VG NOILVDO1 Q3azr vaNNV SHV3A 30 ON JO ANIVAS LON 96 LOVYLNOD JINGAHDS LYVLS AYOM 3 31LIL LOAOud JYOM AHL YAHLAHM YO N3HM 30 55319 8 7944 SIHL NO LOVYLNOD YAGNN SVH Wald YNOA SL93fOYd NOILINYLSNOD 9NIQINE NON ANY 31VAlld TIV LSN SLOVYLNOD Q13H LuVd H3NMO H3NDIS3G H3NMO H3NDIS3G H3NMO H3NDIS3G H3NMO H3NDIS3G 3NOHd3113L NOS3d L2 V LNOO 3INVN sunpxow _ I23fOud SNOIAAYd AHL NO 93151 L93fO8d 3131d4INOONI H2V3 8Od NOILVINYOANI 39N3333348 ONIMOT1O4 3GIAOd ve ZT 0 8 e8eq OTOZ U2Je N 341729443 25 EJ8u85 aullud juawaseuep jessy e3ide jo ule dxa uonsanb 01 SJA
46. Authority determines that any non filed subcontractor chosen by a Bidder is not qualified or responsible then the Bidder shall obtain another subcontractor satisfactory to Awarding Authority and the contract price shall not be adjusted 9 5 The general Bid price shall be the price set forth in paragraph C of the Form for General Bid No general Bid shall be rejected i because the sum of the prices set forth in Item 1 and 2 does not equal the general Bid price set forth in said paragraph C or ii because of one or more errors in setting forth the name the sub Bid price of a sub Bidder or the total of Item 2 provided that 19 the sub Bidder or sub Bidders designated are clearly identifiable or iii because the plans and specifications do not accompany the Bid or are not submitted with the Bid 9 6 Should the Contract Documents require submission of special data to accompany the Bid the Awarding Authority reserves the right to rule the Bidder s failure to submit such data an informality and to received said data subsequently within a reasonable time as set by the Awarding Authority provided that no such ruling shall result in an unfair advantage to the Bidder 9 7 The Awarding Authority also reserves the right to reject any sub Bid if it determines that such sub Bid does not represent the Bid of a person competent to perform the work as specified or if fewer than three sub Bids are received for a sub trade and the Bid prices are not reas
47. Awarding Authority of the change of responsibility for utility charges and payments upon the issuance of the Certificate of Agency Use and Occupancy 13 Complete final clean up of all Work restoration of damaged finishes and replacement of all damaged and broken glass not listed on the Contractor s Punch List 14 Complete such other items as may be called for in the Supplementary General Conditions if any or in the Specifications After completing the items specified in subsection A above the Contractor shall make a written request for the Designer s inspection for a Certificate of Agency Use and Occupancy in accordance with the Contract Documents The Designer shall review the submittals and the Work and shall either 1 have a state building official sign a Certificate of Agency Use and Occupancy or 2 notify the Contractor of incomplete and or incorrect Work that must be completed and corrected prior to the issuance of the Certificate of Agency Use and Occupancy The Designer shall notify the Contractor of any additions to the Punch List In connection with 117 the execution of the Certificate of Agency Use and Occupancy the Designer shall assign dollar values to each item on the Punch List Failure to include any incomplete or defective item on the Punch List shall not relieve the Contractor of the obligation to complete all Work in accordance with the Contract Documents 6 Final Acceptance of the Work A Prerequisites for Final Acc
48. CONTRACT TABLE OF CONTENTS ARTICLE 1 DEFINITION OF TERMS p 92 ARTICLE 1 EXECUTION OF THE CONTRACT SCOPE OF WORK INTERPRETATION OF CONTRACT DOCUMENTS p 95 m Po mw ARTICLE III ARTICLE IV Execution p 95 Scope of Work p 95 Interpretation p 96 Distribution of Work p 96 Contract Price p 96 CONTROL OF WORK ADMINISTRATION OF THE CONTRACT p 97 Designer p 97 Right of Access to Work p 97 Inspection No Waiver p 97 GENERAL PERFORMANCE OBLIGATIONS OF THE CONTRACTOR p 98 Review of Contract Documents and Field Conditions p 98 Supervision and Construction Procedures Coordination Cutting and Patching p 98 Superintendent p 99 Labor p 99 Notices and Permits p 100 86 ARTICLE V SMES om p ARTICLE VI E HE OBL Se eS Lines Marks Etc p 100 Excavation p 101 Dewatering Hoisting Staging p 101 Corrections to The Work Inspection No Bar To Subsequent Corrections p 101 Sanitary Facilities p 101 Contract Documents at the Site p 102 Telephones p 102 Health Safety and Accident Prevention p 103 Debris and Chemical Waste p 105 Weather Protection p 106 Furnishings and Equipment p 106 Form for Sub Contract p 106 Sales Tax Exemption and Other Taxes p 106 Final Cleaning p 107 Maintenance Data p 107 Closeout Procedures p 108 Risk of Loss p 108 LEED Requirements p 108
49. CONTRACTORS SHALL MEET THE FOLLOWING GUIDELINES WHEN SUBMITTING COST BREAKDWONS FOR LABOR a The Contractor must designate the name of trade and the number of hours times the base journeyman rate The foreman rate should only used and pro rated as provided for in the union rules b Insurance and payroll taxes shall be identified as a percentage applied to the total labor rate The University of Massachusetts allows 30 to be used for insurance and taxes Any increase in this percentage must be supported by a written breakdown of all insurance and taxes applied to each particular trade No overhead and profit is allowed on insurance and taxes see General Conditions Article VII section 2 c Hourly benefit amounts such as health welfare and pensions must be identified separately d When overtime work is involved insurance charges and benefits are based on straight time only e If travel is involved it should be submitted as provided by the union regulations this in most cases is based on mileage No overhead and profit will be paid on travel f Whenever a subcontractor is involved a complete and separate breakdown must be submitted by the subcontractor for its portion of work Non filed subcontractors should not include overhead and profit on their breakdown g All breakdowns should be legible submitted on letterhead and signed by an authorized representative of the Contractor This applies to all Subcontractors and General Con
50. Campus Center Way Amherst MA 01003 PROCEDURE FOR PAYMENTS TO CONTRACTORS l APPLICATION AND DISTRIBUTION This bulletin is effective on all construction projects Chapter 149 and Chapter 30 subject to the control of the University of Massachusetts Amherst Facilities Planning hereinafter referred to as the Division as provided by Chapter 7 G L Section 39A through 43G as amended This form is available to all General Contractors Sub contractors Designers Resident Engineers and on request to any party of interest This form constitutes a method of contractual procedure noted in the General Conditions of the Contract and is not a rule or regulation as defined by the STATE ADMINISTRATIVE PROCEDURE ACT M G L c 30a S 5 No deviation from the procedure set forth in this form may be made without the express authorization of the University of Massachusetts Amherst UMASS Il STATUTORY REFERENCES DEFINITIONS ETC M G L 30 s 39K Non Building Contracts University of Massachusetts Amherst Standard Vertical Construction Contract as amended All General Contractors Sub Contractors Designers and Resident Engineers University of Massachusetts Amherst Project Managers should thoroughly familiarize themselves with said contract Ill PREPARATION AND PROCESSING OR PERIODIC PAYMENT Periodic payment requests shall be submitted monthly for the preceding month corresponding to the date of the contract Submission in this manner st
51. Endorsement and shall name the Owner as an Additional Insured 143 4 Pollution Liability The Contractor shall provide coverage for bodily injury and property damage resulting from liability arising out of pollution related exposures such as asbestos abatement lead paint abatement tank removal removal of contaminated soil etc The Awarding Authority and the Owner shall be named as an additional insured and coverage must be on an occurrence basis The amount of coverage shall be 1 000 000 per occurrence and 3 000 000 in the aggregate unless a higher amount is specified in Exhibit A to the Owner Contractor Agreement in which case the Contractor shall provide the additional coverage 5 Worker s Compensation A The Contractor shall provide the following coverage in accordance with M G L c 149 834A and c 152 as amended unless a higher coverage is specified in Exhibit B to the Owner Contractor Agreement in which case the Contractor shall provide the higher coverage Worker s Compensation Provide Statutory Minimum Part One 500 000 each accident Employer s Liability 500 000 disease per employee Part Two 500 000 disease policy aggregate B If specified in Exhibit A to the Owner Contractor Agreement the policy must be endorsed to cover United States Longshoremen amp Harborworkers Act USLHW Maritime Liability for 51 000 000 51 000 000 or Federal Employer s Liability Act liability 6 Builder s Risk Installation Float
52. For apprentice rates see Apprentice OPERATING ENGINEERS SELF POWERED ROLLERS AND COMPACTORS 06 01 2015 31 83 9 70 11 47 0 00 53 00 TAMPERS 12 01 2015 32 58 9 70 11 47 0 00 53 75 OPERATING ENGINEERS LOCAL 98 For apprentice rates see Apprentice OPERATING ENGINEERS SELF PROPELLED POWER BROOM 06 01 2015 29 21 9 70 11 47 0 00 50 38 OPERATING ENGINEERS LOCAL 98 12 01 2015 29 96 9 70 11 47 0 00 51 13 For apprentice rates see Apprentice OPERATING ENGINEERS SHEETMETAL WORKER 07 01 2015 932 32 9 14 14 92 81 68 58 06 SHEETMETAL WORKERS LOCAL 63 01 01 2016 33 02 9 14 14 92 1 68 58 76 07 01 2016 33 73 9 14 14 96 1 68 59 51 01 01 2017 34 48 9 14 14 96 1 68 60 26 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 27 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice SHEET METAL WORKER Local 63 Effective Date Supplemental Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate 45 14 54 5 88 4 08 0 00 24 50 2 50 16 16 6 18 4 53 0 00 26 87 3 55 17 78 6 47 8 15 0 97 33 37 4 60 19 39 6 77 8 15 1 03 35 34 5 65 21 01 7 06 8 15 1 09 37 31 6 70 22 62 7 36 8 15 1 14 39 27 7 75 24 24 7 66 8 15 1 20 41 25 8 80 25 86 7 95 13 88 1 43 49 12 9 85 27 47 8 25 14 01 1 49 51 22 10 90 29 09 8 55 14 01 1 55 53 20 Effective Date Supplemental Step percent
53. Gedney a brand of the EGS Electrical Group Description Factory fabricated connectors and splices of size ampacity rating material type and class for application and service indicated SYSTEM DESCRIPTION Electrical Components Devices and Accessories Listed and labeled as defined in NFPA 70 by a qualified testing agency and marked for intended location and application Comply with NFPA 70 PART 3 EXECUTION 3 1 A B 3 2 CONDUCTOR MATERIAL APPLICATIONS Feeders Copper stranded for No 8 AWG and larger Branch Circuits Copper stranded for No 12 AWG and larger CONDUCTOR INSULATION AND MULTICONDUCTOR CABLE APPLICATIONS AND WIRING METHODS Service Entrance Type THHN 2 THWN 2 single conductors in raceway Exposed Feeders Type THHN 2 THWN 2 single conductors in raceway Feeders Concealed in Ceilings Walls Partitions and Crawlspaces Type THHN 2 THWN 2 single conductors in raceway Exposed Branch Circuits Type THHN 2 THWN 2 single conductors in surface mounted metallic raceway LOW VOLTAGE ELECTRICAL CONDUCTORS AND CABLES 10 14 2015 260519 2 of 4 3 3 3 4 3 5 3 6 UMA 16 12 MULLINS SECURITY CAMERAS INSTALLATION OF CONDUCTORS Conceal conductor in concrete plank decks were possible Where exposed install in steel surface mounted raceway system as indicated on the drawings Confirm wire fill of all raceways with the manufacturer before ordering Notify UMASS Project Manager if wire fi
54. OFFICE Previous Net Total a Operating Agency Letter attached not req d b For the amount requested or corrected to This Change Extended as requested or corrected to Calendar Days d This change is in the best interest of the Commonwealth and constitutes an Total To Date equitable adjustment to the contract in compliance with Art VII of the contract Contract Completion Date Authorized Signature Date Upon signature by the Office this request becomes a formal change order for Extended to Date Immediate distribution If applicable to Phase of Contract DCAM FORM 5 Office Change Order Approval 4 10 02 OFFICE COPY ___ COMPTROLLER PROJECT ENGINEER DESIGNER 170 UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING PHYSICAL PLANT BUILDING 360 CAMPUS CENTER WAY AMHERST MASSACHUSETTS 01003 INSTRUCTIONS REGARDING CHANGE ORDERS AND CONTRACT MODIFICATIONS SECTION 1 STATUTORY AND CONTRACTUAL PROVISIONS 1 01 This instruction form supplements Article of the University of Massachusetts Amherst General Conditions of the Contract but is not intended to supersede or modify any of the provisions contained therein It is available for general distribution and is applicable to all projects under the jurisdiction of the University of Massachusetts Amherst The Statutory authorities for a change in the plans specifications and or contract are provided in Mass G L Chapter 7 Section 42E 421 and i
55. Operation and Maintenance Manual Labeling shall indicate source panelboard identification circuit number and location Apply labels to disconnect switches and protection equipment central or master units control panels control stations terminal cabinets and racks of each system Systems include power lighting control communication signal monitoring and alarm systems unless equipment is provided with its own identification 1 Labeling Instructions a Indoor Equipment Self adhesive engraved laminated acrylic or melamine label Unless otherwise indicated provide a single line of text with 1 2 inch high letters on 1 1 2 inch high label where two lines of text are required use labels 2 inches high 2 Equipment to Be Labeled a Panelboards Typewritten directory of circuits in the location provided by panelboard manufacturer Panelboard identification shall be self adhesive engraved laminated acrylic or melamine label b Enclosures and electrical cabinets Access doors and panels for concealed electrical items d Switchgear Switchboards END OF SECTION 260553 IDENTIFICATION FOR ELECTRICAL SYSTEMS 260553 4 of 4 10 14 2015 16 21 MULLINS SECURITY CAMERAS SECTION 262726 WIRING DEVICES PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 1 2 1 3 1 4 1 5 A w on pi RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all
56. Page 2 of 10 Iv OT 40 eSed OTOZ OE YEW INPI 5 4eppiq qns juawaseuep jessy e3ide Jappiq qns siu Jo Wed ees aq ysn uoneuejdxe ue pue 32641002 Aue JOM 531 pesnjaJ JO pale Seu 40 at 03 pafoud e seu J y JI sjaays jeuonippe Qq3131dINOO 31VG 31VG LYVLS 39214 LOVYLNOD YOM 8 FILIL L23fOHd LON AINSSI SVM ALINIG19173 40 3121411930 43aaig 8ns LNIYYND YNOA ILYA JHL 3ONIS Q3131dIWOO SVH YNOA LVHL IYON YO 000 025 30 5193 31VAIHd ANY TIV 1511 SLO3fOld Q3131dINOO T LuVd OT JO t eSed OTOZ OE YEW 9412843 5 4eppiq qns juawaseuey ssy jeydes uorsiAIq uonsanb Jayuya 01 SJA pasamsue no J ON S3A diusuonejaJ 10 sseuisnq e ysnosy Jaya Auedwod JnoA 041u09 40 seS8eueui SUMO Aue noA YUM suosJed 9e U0D aui AUe ON SJA diysuoljzejas ssauisng e u8noJui 8 JO JaUBISAap YUM
57. Priority Contract Modifications Second Priority Owner Contractor Agreement Third Priority General Conditions of the Contract Fourth Priority Drawings and Specifications the most stringent shall apply 4 Distribution of Work The distribution of the Work is intended to be described under the appropriate trades and except for filed sub bid work may be redistributed except as directed herein provided that such redistribution shall cause no controversy among the trades and no delay in the progress of the Work 5 Contract Price The Contract Price constitutes full compensation to the Contractor for everything to be performed and furnished in connection with the Work and for all damages arising out of the performance of the Work and or the action of the elements and constitutes the maximum compensation regardless of any difficulty incurred by the Contractor in connection with the Work or in consequence of any suspension or discontinuance of the Work 96 ARTICLE IIl CONTROL OF WORK ADMINISTRATION OF THE CONTRACT 1 Designer Notwithstanding anything to the contrary expressed or implied in this Contract any of the powers rights and duties of the Designer may be exercised by the Awarding Authority provided that the Awarding Authority shall be under no obligation to do so The Awarding Authority may rely on the Designer for the performance and exercise of its rights and obligations hereunder and shall be presumed to so rel
58. SECURITY CAMERAS B Remove debris from the work site on a daily basis and dispose of same at any private or public DEP approved dump that the General Contractor may choose providing that the General Contractor shall make all arrangements and obtain all approvals and permits necessary from the owner or officials in charge of such dumps Proposed dump site shall be submitted to be approved by UMA prior to start of demolition During disposal process copies of daily receipts from dumpsite shall be submitted on a regular basis 1 10 SAFETY PROTECTION A At no time shall the work be left unattended without proper safety protection and shall not be left unprotected to the weather and accessible to the public It is the responsibility of the General Contractor to maintain proper safety protection for the public while work is in progress or unattended 1 11 SHUT DOWN NOTICE Contractor shall notify the U M A Project Manager at least fourteen 14 working days in advance of the need for University personnel to shut down or modify any utilities or building systems If due to University emergencies or staffing shortages the Physical Plant personnel are unable to provide the required shut down or modifications the contractor shall reschedule their work at no cost to the University PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION 015000 TEMPORARY FACILITIES AND CONTROLS 10 14 2015 015000 4 of 4 4 5 201
59. Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY Section Includes 1 Receptacles receptacles with integral GFCI and associated device plates DEFINITIONS EMI Electromagnetic interference GFCI Ground fault circuit interrupter Pigtail Short lead used to connect a device to a branch circuit conductor RFI Radio frequency interference TVSS Transient voltage surge suppressor UTP Unshielded twisted pair ADMINISTRATIVE REQUIREMENTS Coordination 1 Receptacles for Owner Furnished Equipment Match plug configurations 2 Cord and Plug Sets Match equipment requirements ACTION SUBMITTALS Product Data For each type of product WIRING DEVICES 10 14 2015 262726 1 of 5 1 6 1 7 B C A A 16 21 MULLINS SECURITY CAMERAS Shop Drawings List of legends and description of materials and process used for premarking wall plates Samples One for each type of device and wall plate specified in each color specified INFORMATIONAL SUBMITTALS Field quality control reports CLOSEOUT SUBMITTALS Operation and Maintenance Data For wiring devices to include in all manufacturers packing label warnings and instruction manuals that include labeling conditions PART 2 PRODUCTS 2 1 2 2 w MANUFACTURERS Manufacturers Names Shortened versions shown in parentheses of the follow
60. Wage Health Pension Apprentice BOILERMAKER Local 29 Effective Date Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 65 26 21 6 97 10 54 0 00 43 72 2 65 26 21 6 97 10 54 0 00 43 72 3 70 28 22 6 97 11 35 0 00 46 54 4 75 30 24 6 97 12 16 0 00 49 37 5 80 32 26 6 97 12 97 0 00 52 20 6 85 34 27 6 97 13 78 0 00 55 02 7 90 36 29 6 97 14 59 0 00 57 85 8 95 38 30 6 97 15 40 0 00 60 67 Effective Date Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 65 27 05 6 97 10 54 0 00 44 56 2 65 27 05 6 97 10 54 0 00 44 56 3 70 29 13 6 97 11 35 0 00 47 45 4 75 31 22 6 97 12 16 0 00 50 35 5 80 33 30 6 97 12 97 0 00 53 24 6 85 35 38 6 97 13 78 0 00 56 13 7 90 37 46 6 97 14 59 0 00 59 02 8 95 39 54 6 97 15 40 0 00 61 91 Notes Apprentice to Journeyworker Ratio 1 5 BRICK STONE ARTIFICIAL MASONRY INCL MASONRY 08 31 2015 38 36 10 18 16 73 0 00 65 27 Ni ocd d 02 29 2016 38 93 10 18 16 73 0 00 65 84 09 05 2016 39 83 10 18 16 81 0 00 66 82 02 27 2017 40 40 10 18 16 81 0 00 67 39 Wage Request Number 20150917 043 Issue Date 09 17 2015 Page 4 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment Apprentice BRICK PLASTER CEMENT MASON Local 3 Springfield Pittsfield Effective Date
61. a statement of all payments thereafter made to such claimants Each such statement shall be sworn to and contain a detailed breakdown required by M G L c 30 s 39F d and e Unless such statements are so filed by the Contractor the amount shown by the claims filed shall at the option of the Awarding Authority be conclusively deemed to be the accurate amount due from the Contractor therefore in all accounting with the Awarding Authority If the moneys retained under this Contract are insufficient to pay the sums found by the Awarding Authority to be due under the claims for labor and materials filed as aforesaid the Awarding Authority may at its discretion pay the same and the Contractor shall repay to the Awarding Authority all sums paid out The Awarding Authority may also at its discretion use any moneys retained due or to become due under this Contract for the purpose of paying for both labor and materials used or employed in the Work for which claims have not been filed with the Awarding Authority C moneys retained under the provisions of this Article shall be held to be statutory security for the payment of claims filed in accordance with the provisions of M G L c 149 s 29 as amended for which security is provided by bond 4 Applications for Payment A The Contractor shall once in each month for the preceding months on the day of the month corresponding to the day of the month specified in the Notice to Proceed referenced
62. and Terminations For power and control wiring use numbered terminal strips in junction pull and outlet boxes terminal cabinets and equipment enclosures Tighten electrical connectors and terminals according to manufacturer s published torque tightening values If manufacturer s torque values are not indicated use those specified in UL 486A 486B Grounding Provide independent signal circuit grounding as recommended by manufacturer All fiber and Cat 6 wiring shall be supported per MEC above suspended ceilings Exposed locations shall be installed in raceway Jacket color shall be unique to other similar wiring in the building Terminate all cables in equipment rooms on rack mounted switches Connectors shall be compatible with system switches and cable type Label every jack with remote equipment location VIDEO SURVEILLANCE SYSTEM INSTALLATION Install cameras and infrared illuminators level and plumb Install cameras at mounting heights shown on the drawings with minimum clear space below cameras and their mountings Change type of mounting to achieve required clearances Set pan unit and pan and tilt unit stops to suit final camera position and to obtain the field of view required for camera Connect all controls and alarms and adjust Install power supplies and other auxiliary components at control stations as shown on the drawings Provide to the Owner 12 spare power supply fuses copies of system software and all tools or co
63. and cell phone number fax number and description of the products or services they will provide to the project Agenda Discuss items of significance that affect progress including the following Tentative construction schedule Phasing Critical work sequencing Designation of responsible personnel The Contractor shall identify a contractor safety representative to interface with the University Construction Safety Officer CSO This person may also fill other roles within the contractor s project area e g project manager superintendent foreman etc Procedures for processing field decisions and Change Orders Procedures for processing Applications for Payment Distribution of the Contract Documents Submittal procedures Preparation of Record Documents Use of the premises Safety The UMA CSO will attend the pre construction meeting for the purpose of orienting the contractor to policies specific to the University discuss the contractor s site specific safety plan as well as to emphasize recognized safety practices expected on campus The Contractor Safety Representative is responsible to ensuring this information is disseminated to all contractor subcontractor employees If the UMA CSO is unable to attend the UMA CSO may send a designee to cover this portion of the meeting or the UMA CSO and UMA Project Manager will schedule a separate time when this review may be completed Responsibility for temporary facilities and
64. approval by the UMA Project Manager and the Designer and shall include but not be limited to 1 The Term By Others shall not be used on shop drawings the General Contractor shall state by whom the related items are to be furnished and or installed 2 The Designer reserves the right to reject and return to the General Contractor without examination any shop drawings which have not been previously checked and certified as outlined above which carry the term by other or such vague reference which are difficult to read which have arrived by FAX or which in any way are obviously not in conformity with Contract Requirements 3 Shop drawings shall show materials design dimensions connections and other details necessary to ensure that they accurately interpret the Contract Documents and shall also show adjoining work in such detail as required to provide proper connection with same 4 The Designer will check and approve shop drawings only for conformance with the design concept and for compliance with information given in the Contract Documents Approval of shop drawings by the Designer will not release the General Contractor from SUBMITTAL REQUIREMENTS 10 14 2015 013300 3 of 8 12 4 2012 1 5 16 12 MULLINS SECURITY CAMERAS his responsibility for furnishing same of proper dimensions size quantity and quality to effectively perform the work and carry out the requirements and intent of Contract Documents 5 Such approva
65. arc ROUEN ARTICLE IX GUARANTEES AND WARRANTIES p 134 1 General Warranty p 135 2 Special Guarantees and Warrantees p 135 ARTICLE X MISCELLANEOUS LEGAL REQUIREMENTS p 135 1 Contractor to Be Informed p 135 2 Compliance with All Laws p 135 ARTICLE XI CONTRACTOR S ACCOUNTING METHOD REQUIREMENTS M G L c 30 s 39R p 139 Definitions p 139 Record Keeping p 140 Statement of Management Controls p 140 Annual Financial Statement p 141 Bid Pricing Materials p 141 ARTICLE EQUAL EMPLOYMENT OPPORTUNITY NON DISCRIMINATION AND AFFIRMATIVE ACTION PROGRAM p 142 See Appendix A 88 ARTICLE XIII GOALS FOR PARTICIPATION BY MINORITY BUSINESS ENTERPRISES AND WOMEN BUSINESS ENTERPRISES EXECUTIVE ORDER 390 p 142 See Appendix B ARTICLE XIV INSURANCE REQUIREMENTS p 142 Insurance Generally p 142 Contractor s Commercial General Liability p 143 Vehicle Liability p 143 Pollution Liability p 144 Worker s Compensation p 144 Builder s Risk Installation Floater Stored Materials p 144 Umbrella Coverage p 145 Additional Types of Insurance p 145 Sa mne MI ARTICLE XV INDEMNIFICATION p 145 1 Generally p 145 2 Designer s Action p 146 3 Survival p 146 ARTICLE XVI PERFORMANCE AND PAYMENT BONDS p 146 1 Contractor Bonds p 146 2 Subcontractor Bonds p 147 ARTICLE XVII
66. as an agent of and providing qualified services as defined in MGL Ch 64H sec 6 tt to a governmental body or agency described in MGL Ch 64H sec 6 d Attach Form ST 2 If Form ST 2 is not available enter agency s exemption number To the best of my knowledge and belief the quantities of tangible personal property noted on the reverse side are exempt from the sales use tax under the provisions of MGL Ch 64 sec 6 tt The purchaser has been authorized under the above contract by a governmental body Regardless of the exemption claimed will maintain adequate records to show the disposition of all property purchased under this certifi cate understand that am fully liable for the payment of any sales use tax due in the event that the property purchased under this cer lificate is used in a non exempt manner Signed under the penalties of perjury M 8 erent ante tn s Signature Title Location and description of project and description of kInd and quantity of property or recelpts invoices must be attached or noted on the back of this form This form is approved by the Commissioner of Revenue and may be reproduced 199 BID PACKAGE PART IV SUPPLEMENTARY GENERAL CONDITIONS AND SPECIFICATIONS TECHNICAL SPECIFICATIONS MULLINS MEMORIAL CENTER SECURITY CAMERAS UNIVERSITY OF MASSACHUSETTS AMHERST MASSACHUSETTS PROJECT NO 1003430 UMA 16 12 October 14 2015
67. as otherwise noted Payment is hereby authorized and is properly chargeable to the designated appropriation Architect Engineer Date Resident Engineer Project Manager Date 195 UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING Physical Plant Building 360 Campus Center Way Amherst 01003 CERTIFICATE 2 ne lt O 270 lt gt FROM AWARDING AUTHORITY University of Massachusetts Amherst TO General Contractor RE UMA No Project No Title Location 196 AUTHORITY M G L c 30 s 39K Article VI General Conditions of Contract Pursuant to the authority noted above you are notified that the University of Massachusetts Amherst is satisfied that the portion of the above noted project as hereinafter enumerated is ready for Use and or Occupancy Identify portions to be used and or occupied The University of Massachusetts Amherst through its undersigned representatives hereby accepts from the Contractor subject to Contract stipulations said portion of the project effective as of Midnight the dayof __ 20 The Contractor is relieved of responsibility for performing further work or supplying further materials equipment or items with the exception of the attached Append a complete list of all incomplete or unsatisfactory items of contract work which in the opinion of the University of Massachusetts Amherst are attributable to the fault negligence
68. available by the Bidder for subcontracting to M WBEs to all M WBEs qualified to perform such work The Bidder shall identify i each M WBE solicited and ii each M WBE listed in the SOMWBA directory under the applicable trade category that was not solicited and reasons therefor The Bidder shall also state the dates that notices were mailed and provide a copy of the written notice s sent Evidence that the Bidder made reasonable efforts to follow up the written notices sent to M WBESs with telephone calls or personal visits in order to determine with certainty whether the M WBEs were interested in performing the work Phone logs or other documentation must be submitted A statement of the response received from each M WBE solicited including the reason for rejecting any M WBE who submitted a bid or proposal Evidence of efforts made to assist M WBEs that needed assistance in obtaining bonding or insurance or lines of credit with suppliers if the inability of M WBEs to obtain bonding insurance or lines of credit is the reason given for the Bidder s inability to meet the M WBE goals The Bidder may also submit any other information supporting its request for a waiver or reduction in the M WBE participation goals including without limitation evidence that the Bidder placed advertisements in appropriate media and trade association publications announcing the Bidder s interest in obtaining bids or proposals from M WBEs and or sent writ
69. be drilled New and existing holes must be enlarged by drilling if required no breaking of concrete slab 2 Fire safe at ALL penetrations new and existing as part of this section with Hilti FS ONE High Performance S Intumescent 1 1 2 hour sealant or equal END OF SECTION 024100 SELECTIVE DEMOLITION 10 14 2015 024100 3 of 3 2 13 2012rev PART 1 GENERAL UMA 16 12 MULLINS SECURITY CAMERAS DIVISION 26 ELECTRICAL WORK SECTION 260001 ELECTRICAL WORK 1 1 GENERAL PROVISIONS A Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications Reference Drawings E 1 E 2 E 3 E 4 E 5 ARENA GROUND FLOOR CAMERA SYSTEM ARENA FIRST FLOOR CAMERA SYSTEM PRACTICE RINK GROUND FLOOR CAMERA SYSTEM PRACTICE RINK FIRST FLOOR CAMERA SYSTEM CAMERA SYSTEM SCHEMATIC SCHEDULES AND SYMBOLS The following sections are included in and part of Section 260001 260519 260526 260529 260533 260553 262726 265700 Low Voltage Electrical Power Conductors and Cables Grounding and Bonding For Electrical Systems Hangers and Supports for Electrical Systems Raceways and Boxes for Electrical Systems Identification for Electrical System Wiring Devices Video Surveillance 1 2 DESCRIPTION AND REQUIREMENTS A Work Included Provide labor materials and equipment necessary to complete the work of th
70. become airborne must first check for the existence and location of heat or smoke detectors and other types of fire protection system equipment which may be affected by the work The contractor shall request isolation or deactivation of such equipment through the UMA Project Manager Such isolation deactivation and notification shall occur prior to commencing work Upon completion of the work the contractor shall request reactivation of such equipment through the Project Manager UMA EH amp S may require that smoke detectors be bagged on a daily basis if smoke or dust particles may affect them In this event bags must be removed at the end of the day Notify the U M A Environmental Health and Safety Fire Prevention officer prior to isolation or deactivation of such equipment All construction will comply strictly with the Massachusetts State Building Code Article 30 780 CMR 30 Required fencing sidewalk sheds storage of flammables portable fire extinguishers fire standpipe operation and rubbish removal will be enforced by Environmental Health amp Safety SUMMARY 10 14 2015 011000 17 of 20 5 1 2015 rev 1 16 12 MULLINS SECURITY CAMERAS Confined Space Requirements Permit Required Confined Spaces PRCS If work under this Contract specifically or incidentally requires this Contractor or any of his Sub Contractors to enter spaces that are meeting the definition provided in 1910 146 of a Permit Required Confined S
71. by the Department of Public Utilities of the Commonwealth of Massachusetts or other agency of the State of Federal government which may be authorized by law to set rates or otherwise regulate the use of such vehicles The Contractor expressly assumes the risk of any additional expense inclusive of fuel charges for use of common or contract motor carrier and trucks owned that may arise by reason of any change in such minimum rates and charges and rules and regulations and shall be entitled to no additional compensation or reimbursement by reason thereof J Anti Boycott Covenant Executive Order 130 The Contractor warrants represents and agrees that during the time this Contract is in effect neither it nor any affiliated company as hereafter defined participates in or cooperates with an international boycott as defined in Section 999 b 3 and 4 of the Internal Revenue Code of 1954 as amended or engages in conduct declared to be unlawful by M G L 151E s 2 If there shall be a breach in the 137 warranty representation or agreement contained in this paragraph then without limiting such other rights as it may have the Awarding Authority shall be entitled to rescind this contract As used herein an affiliated company shall be any business entity of which at least 51 of the ownership interests are directly or indirectly owned by the Contractor or by a person or persons or business entity or entities directly or indirectly owning at l
72. called for in the update statement must be supplied All information provided must be complete and accurate A defect or omission in the Update Statement may result in the rejection of the Bid Part 5 MUST list the NAMES of all supervisory personnel for this project 3 Bid deposit meeting the requirements of Section 5 13 and 5 14 of the Instructions to Bidders 50 UMA Number 16 12 FORM FOR GENERAL BID To the Awarding Authority A The undersigned proposes to furnish all labor and materials required for UMA No 20 2 Project No 1003430 Project Name Mullins Security Cameras in Amherst Massachusetts in accordance with the accompanying plans and specifications prepared by name of architect or engineer for the contract price specified below subject to additions and deductions according to the terms of the specifications B This bid includes addenda numbered list all addenda C The proposed contract price is total bid in words dollars For Alternate No 1 Add Subtract For Alternate No 2 Add Subtract For Alternate No 3 Add Subtract For Alternate No 4 Add Subtract For Alternate No 5 Add Subtract Name of General Bidder 51 D The subdivision of the proposed contract price is as follows Item 1 The work of the general contractor being all work other than that covered by Item 2 dollars 5 total bid in words Item 2 Sub bids as follows Section Subtrade Name of Su
73. date of Substantial Completion provide on site assistance in adjusting system to suit actual occupied conditions Provide up to three visits to Project during other than normal occupancy hours for this purpose Tasks shall include but are not limited to the following 1 Check cable connections Check proper operation of cameras and lenses Verify operation of auto iris lenses and adjust back focus as needed Adjust all preset positions consult Owner s personnel VIDEO SURVEILLANCE 10 14 2015 265700 8 of 9 16 12 MULLINS SECURITY CAMERAS 4 Recommend changes to cameras lenses and associated equipment to improve Owner s use of video surveillance system 5 Provide a written report of adjustments and recommendations 3 6 CLEANING A Clean installed items using methods and materials recommended in writing by manufacturer B Clean video surveillance system components including camera housing windows lenses and monitor screens 3 7 DEMONSTRATION A Contractor shall engage factory authorized service representative to train Owner s maintenance personnel to adjust operate and maintain video surveillance equipment Training shall be scheduled through the UMA project manager and shall consist of two 2 three hour sessions at the convenience of the owner END OF SECTION 265700 VIDEO SURVEILLANCE 10 14 2015 265700 9 of 9
74. encoded and delivered onto the network for processing and control by the IP video management software 6 All system interconnect cables switches UPS s power supplies PTZ joysticks and network intermediate devices shall be provided for full performance of specified system PART 3 EXECUTION 3 1 3 2 A B C A B EXAMINATION Examine pathway elements intended for cables Check raceways and other elements for compliance with space allocations installation tolerance hazards to camera installation and other conditions affecting installation Examine roughing in for LAN WAN and IP network before device installation Proceed with installation only after unsatisfactory conditions have been corrected WIRING Comply with requirements in Section 260533 Raceways and Boxes for Electrical Systems Wiring Method Install cables in raceways unless otherwise indicated 1 Except raceways are not required in accessible indoor ceiling spaces and attics VIDEO SURVEILLANCE 10 14 2015 265700 6 of 9 3 3 3 4 UMA 16 12 MULLINS SECURITY CAMERAS 2 Except raceways are not required in hollow gypsum board partitions 3 Conceal raceways and wiring except in unfinished spaces Wiring within Enclosures Bundle lace and train conductors to terminal points with no excess and without exceeding manufacturer s limitations on bending radii Provide and use lacing bars and distribution spools Splices Taps
75. estimate for the NOI or Form 5 is less than 5 000 SECTION 5 MISCELLANEOUS DIRECTIONF FOR COMPUTING COSTS FOR CHANGES IN WORK 5 01 5 02 5 03 SHIPPING STORAGE AND HANDLING COSTS AND MATERIALS AND EQUIPMENT INVOLVED INA CHANGE IN WORK MAY BE INCLUDED IN THE COSTS FOR CHANGE IF ITEMIZED AND ACCOMPANIED BY COPIES OF PAID INVOICES THE ALLOWANCE FOR OVERHEAD PROVIDED IN ARTICLE VII SECTION 2 SHALL BE CONSIDERED TO INCLUDE ALL HAND AND POWER TOOLS NORMALLY REQUIRED IN THE PERFORMANCE OF THE BASE BID WORK THE COST OF THE CONTRACTOR S SUPERINTENDENT THE CONTRACTOR S ADMINISTRATION COSTS AND THE CONTRACTOR S ESTIMATING COSTS MAJOR ITEMS OF EQUIPMENT SPECIALIZED TOOLS AND ORDINARY MATERIALS AND EQUIPMENT USED OR CONSUMED ON THE CHANGE ORDER WORK WHETHER RENTED OR 176 5 04 OWNED BY THE CONTRACTOR ME BE INCLUDED IN THE COST OF THE CHANGE PROVIDED CURRENT RENTAL RATES AND MATERIAL COSTS SUPPORTED BY PAID INVOICES ARE SUBMITTED AS BACKUP TO THE CHANGE WHEN ITEMIZED THE UNIVERSITY OF MASSACHUSETTS PM MAY APPROVE LUMP SUM CHANGE ORDER REQUESTS ON CHANGES COSTING 1 000 OR LESS WITHOUT REQUIRING THE CONTRACTOR TO PROVIDES A BREAKDOWN FOR THE COSTS INCURRED ON THE CHANGE THE UNIVERSITY OF MASSACHUSETTS PM RESERVES THE RIGHT TO REQUIRE COST BREAKDOWN AND INVOICES FROM THE CONTRACTOR ON ALL CHANGES BREAKDOWNS ARE REQUIRED FOR ALL UNIT PRICE CHANGES COST PER ITEM AND TIME AND MATERIAL CHANGE ORDERS REGARDLESS OF THE COST
76. executed this agreement the day and year first above written SEAL ATTEST Name of Subcontractor By SEAL ATTEST Name of Contractor By City and State 84 BID PACKAGE PART III GENERAL CONDITIONS OF THE CONTRACT General Conditions of the Contract Appendix A Equal Employment Opportunity Non Discrimination and Affirmative Action Program Appendix B Goals for Participation by Minority Business Enterprises and Women Business Enterprises Appendix C Commonly Used Forms Procedure for Payment to Contractors Daily Time and Material Report for Change Orders Notice of Intent Request and Agreement for a Change in the Plans Specifications and or Contract UMA Form 5 Instructions Regarding Change Orders and Contract Modifications DCAM Form 13 Contractor s Weekly Workforce Report Minorities Women in Contractor s Weekly Workforce Report Weekly Payroll Report Form and Statement of Compliance Quarterly Projected Workforce Table Certification of Payment by Contractor to MBE WBE and Instructions Certificate of Completion by Minority Women Business Enterprise Form for Transfer of Title Work Not Incorporated UMA Form 16 Certificate of Agency Use and Occupancy E 1 Certificate of Final Inspection Release and Acceptance E 2 Form ST 5C 85 UNIVERSITY OF MASSACHUSETTS AMHERST STANDARD VERTICAL CONSTRUCTION CONTRACT For Projects over 100 000 Subject to M G L c 149 s 44A F GENERAL CONDITIONS OF THE
77. for work under each section of the Specifications The schedule shall be prepared in such form and supported by such data to substantiate its accuracy as the Designer or the Awarding Authority may require Each item in the schedule shall include its proper share of overhead and profit When Approved by the Designer and the Awarding Authority it shall constitute the Schedule of Values and shall be used only as a basis for the Contractor s requests for payments 2 Payment Liabilities of Contractor A The Contractor shall pay to the Owner all expenses losses and damages as determined by the Awarding Authority or the Designer incurred in consequence of any default defect omission or mistake of the Contractor or his employees or Subcontractors or the making good thereof B Ifthe Work or a portion thereof is not completed to Substantial Completion and the Contractor has not satisfied the requirements for the issuance of a Certificate of Agency Use and Occupancy by the date specified in Article 2 of the Owner Contractor Agreement the Contractor shall pay to the Owner liquidated damages as provided in Article VI Section 2 of these General Conditions of the Contract 124 3 Retention of Moneys by Awarding Authority A The Awarding Authority may keep any moneys which would otherwise be payable at any time hereunder and apply the same or so much as may be necessary therefore to 1 the Owner s expenditures for the Contractor s account
78. has given bonds in connection with this Contract 1 The Contractor has filed a petition or a petition has been filed against the Contractor with its consent under any federal or state law concerning bankruptcy reorganization insolvency or relief from creditors or if such a petition is filed against the Contractor without its consent and is not dismissed within sixty 60 days or if the Contractor is generally not paying its debts as they become due or if the Contractor becomes insolvent or if the Contractor consents to the appointment of a receiver trustee liquidate custodian or the like of the Contractor or of all or any substantial portion of its assets and such appointment or possession is not terminated within sixty 60 days or if the Contractor makes an assignment for the benefit of creditors 2 The Contractor refuses or fails except in cases for which extension of time is provided under this Contract s express terms to supply enough properly skilled workers or proper materials to perform its obligations under this Contract or the Designer has determined that the rate of progress required for the timely completion of the Work is not being met 3 The Contractor fails to make prompt payment to Subcontractors or for materials equipment or labor 4 All or a part of the Work has been abandoned 5 The Contractor has sublet or assigned all or any portion of the Work the Contract or claims thereunder without the prior wri
79. is made without any connection with any other person making any bid for the same work and without directly or indirectly influencing or attempting to influence any other person to bid or to refrain from bidding or to influence the amount of the bid of any other person or corporation that no person acting for or employed by the Commonwealth of Massachusetts is directly or indirectly interested in this proposal or in any contract which be made under it or in expected profits to arise therefrom As used above the word person shall mean natural person joint venture partnership corporation or other business or legal entity The undersigned certifies that it shall comply with the provisions of the Equal Employment Opportunity Non Discrimination and Affirmative Action Program set forth in Article of the General Conditions of the Contract Should the Contract Documents require submission of special data to accompany the bid the Awarding Authority reserves the right to rule the bidder s failure to submit such data an informality and to receive said data subsequently within a reasonable time as set by the Awarding Authority Date 20 Name of General Bidder By Print Name Title of Person Signing Bid Signature Business Address City and State Telephone Number Facsimile Number 55 The following information is furnished by the Bidder for the information of the University of Massachusetts Amherst Is Bi
80. listed below l Outdoors UV stabilized nylon 2 In Spaces Handling Environmental Air Plenum rated 3 2 IDENTIFICATION SCHEDULE A Accessible Raceways and Metal Clad Cables 600 V or Less for Service and Feeders Identify with self adhesive vinyl label Install labels at 10 foot maximum intervals IDENTIFICATION FOR ELECTRICAL SYSTEMS 10 14 2015 260553 3 of 4 UMA 16 12 MULLINS SECURITY CAMERAS Accessible Raceways and Cables within Buildings Identify the covers of each junction and pull box of the following systems with self adhesive vinyl labels with the wiring system legend and system voltage Power Circuit Conductor Identification 600 V or Less For conductors in vaults pull and junction boxes manholes and handholes use color coding conductor tape to identify the phase 1 Color Coding for Phase Identification 600 or Less Use colors listed below for ungrounded conductors a Colors for 208 120 V Circuits 1 Phase A Black 2 Phase B Red 3 Phase C Blue b Field Applied Color Coding Conductor Tape Apply in half lapped turns for a minimum distance of 6 inches from terminal points and in boxes where splices or taps are made Apply last two turns of tape with no tension to prevent possible unwinding Locate bands to avoid obscuring factory cable markings Equipment Identification Labels On each unit of equipment install unique designation label that is consistent with wiring diagrams schedules and the
81. of complete system s during guarantee period at no additional cost 4 Provide manufacturer s engineering and technical staff at site promptly to analyze and rectify problems that develop during guarantee period If problems cannot be rectified promptly to the satisfaction of the User Agency advise the Designer in writing describe efforts to rectify situation and provide analysis of cause of problem Manufacturer s Guarantee or Warranty 1 In addition to guarantee requirements above obtain manufacturers written installation equipment and material warranties for time periods indicated in the various Specification Sections of the Contract Documents Such manufacturers warranties contained within the Specification Sections together with any other warranties offered in manufacturers published data are to be transferred to the User Agency Evidence of compliance with requirements of governing authorities including without limitations the following 1 Certificate of Inspection in form of signed permits from the electrical plumbing gas fire department boiler and any other required inspectors 2 Evidence of test and approval for Department of Environmental Protection DEP and Department of Public Health DPH when applicable Prerequisites for Department of Public Safety DPS Certificate of Inspection and or Certificate of Occupancy Prior to requesting a Department of Public Safety DPS inspection the Designer shal
82. of requests for periodic payments to contractors and under no circumstances are these requests to be delayed The Resident Engineer Project Managers and the Designer shall rigidly adhere to the instructions contained in this Bulletin and immediately expedite certification in order that the period payment requests may be delivered by the Contractor to Facilities Planning without delay The Resident Engineer Project Managers and the Designer shall process the payment expeditiously 164 UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING PHYSICAL PLANT BUILDING 360 CAMPUS CENTER WAY AMHERST MA 01003 DAILY TIME AND MATERIAL REPORT FOR ALL CHANGE ORDER WORK OR WORK DONE UNDER PROTEST UMA Project Number Project Number Date Project Title Contractor Change Order No Or work under protest Sheet of Was any contract work performed today other than Change Order concerned Y N If Yes list on Daily Progress Report Labor Change Order or Alleged Extra Work Done Under Protest Trade Name of Worker Hrs Remarks 165 Submitted by Superintendent Subcontractors Resident Engineer University of Massachusetts Project Manager note any discrepancy in above Report Resident Engineer University of Massachusetts Project Manager The signature of the Resident Engineer Project Manager is for verification of lab
83. only N A or leaving the alternate blank 5 6 The lowest Bidder will be determined on the basis of the sum of the base Bid and the accepted alternates 5 7 If the space for indicating a requirement for payment and performance bonds for filed subcontractors is left blank by the general Bidder on the Form for General Bid the Awarding Authority shall interpret this as a No 5 8 Costs for subcontractors bond premiums shall be paid for by the general Contractor in accordance with M G L c 149 8 44F unless the project is a project in which contractor and subcontractor prequalification are required pursuant to M G L 149 88 44D1 2 or 44D3 4 13 5 9 If the general Bidders are instructed to carry an amount for a given sub trade listed under Item 2 general Bidders shall list the sub trade and the amount provided by the Awarding Authority The line under bonds required on the Form for General Bid should be left blank or marked N A in order for subsection 5 10 to apply 5 10 Upon solicitation of a subcontractor to perform the work required with respect to a sub trade referenced in subsection 5 9 the general Bidder s Contract Price shall be adjusted by the following a the difference between the subcontract amount and the amount carried in the general Bid b the total cost of the subcontractor s bonds if the general Bidder requires such bonds after the solicitation is completed and if the general Bidder complied with 5 9 above c the do
84. or materials have been previously overlooked or misjudged by the Designer and accepted for payment If the Work or any part thereof shall be found defective at any time before the Final Acceptance of the whole Work the Contractor shall forthwith cease the performance of any defective work in progress and whether or not such work is still in progress shall forthwith correct such defect in a manner satisfactory to the Designer If any material brought upon the Site for use in the Work or selected for the same shall be rejected by the Designer as unsuitable or not in conformity with the Contract Documents or as damaged by casualty or deteriorated due to improper storage at the Site or to any other factor the Contractor shall forthwith remove such materials from the Site The Contractor shall pay for the cost of making good all work or property of other contractors or of the Owner destroyed or damaged by such removal or replacement repair any injury defect omission or mistake in the Work as soon as it is discovered finish and immediately make good any defect omission or mistake in the Work and complete and leave the Work in perfect condition 10 Sanitary Facilities Except as otherwise specified in the Supplementary General Conditions or Specifications the Contractor shall provide and maintain sanitary facilities for all persons employed on the Work beginning with the first worker at the Site Said facilities shall meet the following requirement
85. or oversight of the Contractor his subcontractor material suppliers agents servants or employees The use of any portion of the project or the occupancy of any building or portion thereof by the University of Massachusetts Amherst shall not constitute a final acceptance of any work not performed in accordance with the Contract nor relieve the Contractor of liability to perform any work required by the Contract or of liabilities with respect to any warranties guarantees indemnifications insurance or other items that are required by the Contract to survive the issuance of this certificate The undersigned recommend the issuance of this Certificate of Agency Use and Occupancy UMass Amherst Project Manager Signature Date 197 E 2 FINAL ACCEPTANCE CERTIFICATE OF FINAL INSPECTION RELEASE AND ACCEPTANCE UMA State Project No lt gt Project No lt gt Title Location Contractor This is to certify that a complete inspection of the above entitled project was made on lt gt by the undersigned and the entire work was completed in accordance with the plans and specifications The undersigned recommends acceptance of the project Designer Authorized Signature CERTIFICATE OF RELEASE The undersigned hereby certifies that all work has been completed in accordance with the Plans Specifications and Contract Documents and that all Change Orders have been supported pursuant to Articles and VIII of the Gene
86. or payment bond each of a surety company qualified to do business under the laws of the Commonwealth and satisfactory to the awarding authority and each in the sum of the contract price the premiums for which are to be paid by the general contractor and are included in the contract price provided however that if there is more than 1 surety company the surety companies shall be jointly and severally liable The undersigned hereby certifies that it is able to furnish labor that can work in harmony with all other elements of labor employed or to be employed on the work that all employees to be employed at the worksite will have successfully completed a course in construction safety and health approved by the United States Occupational Safety and Health Administration that is at least 10 hours in duration at the time the employee begins work and who shall furnish documentation of successful completion of said course with the first certified payroll report for 53 each employee and that it will comply fully with all laws and regulations applicable to awards made subject to section forty four A of Chapter 149 of the General Laws The undersigned further certifies under the penalties of perjury that this bid is in all respects bona fide fair and made without collusion or fraud with any other person As used in this subsection the word person shall mean any natural person joint venture partnership corporation or other business or legal entity
87. projects must meet the minimum energy performance standards for advanced buildings established by the Commonwealth of Massachusetts Sustainable Design Roundtable Furthermore Contractor understands that the Massachusetts LEED silver standard or a higher LEED standard applies to all projects overseen by the University of Massachusetts Amherst as well as all projects built on state land for use by state agencies Contractor must document compliance with this executive order and Project LEED certification standards as described in the project specifications ARTICLE V MATERIALS AND EQUIPMENT 1 Materials Generally A Unless otherwise specifically provided in the Contract Documents the Contractor shall provide and pay for materials equipment tools construction equipment and machinery water heat utilities transportation and other facilities and services necessary for proper execution and completion of the Work whether temporary or permanent and whether or not incorporated or to be incorporated in the Work B Materials and equipment to be installed as part of the Work both or either of which are hereinafter referred to as materials shall be new unused of recent manufacture assembled and used in accordance with the best construction practices The Contractor shall inform himself as to and shall comply with the provisions of M G L c 7 s 23A as amended and shall abide by the same and all applicable rules regulations and order
88. request must demonstrate to the satisfaction of the Awarding Authority that it is not feasible for a non MBE or non WBE general Bidder to meet the goals established for this Contract based upon any or all of the following i actual M WBE availability ii the geographic location of the project to the extent related to M WBE availability iii the scope of the work iv the percentage of work available for subcontracting to M WBEs and or v other relevant factors including a documented inability by the prospective Bidder to obtain commitments from M WBE subcontractors sufficient to meet the M WBE goals after having made a diligent good faith effort to do so All of the foregoing documentation shall accompany the Bidder s request for a reduction or waiver of the M WBE participation goals Such documentation shall include at a minimum the following 16 A list of all items of work under the Contract that the Bidder made available for subcontracting to M WBEs The Bidder shall identify all items of work other than work to be performed by filed sub Bidders that the Bidder did not make so available and shall state the reasons for not making such work available for subcontracting to M WBEs The Bidder shall also demonstrate that where commercially reasonable subcontracts were divided into units capable of being performed by M WBEs Evidence that the Bidder sent written notices soliciting Bids or proposals to perform the items of work made
89. require any portion of the Work to be inspected tested or approved the General Contractor shall give the Designer the UMA Project Manager or his her designated representative and such Authority timely notice 5 business days minimum of its readiness so the Designer may observe such inspecting testing or approval Prior to the start of construction the General Contractor shall complete application to the applicable Building Code enforcement authority for a Building Permit Such Permit shall be displayed in a conspicuous location at the project site The building permit fee shall be paid by the Contractor Unless otherwise specified under the Sections of the Specifications the General Contractor shall pay such proper and legal fees to public officers and others as may be necessary for the due and faithful performance of the work and which may arise incidental to the fulfilling of this Contract As such all fees charges and assessments in connection with the above shall be paid by the General Contractor The General Contractor shall maintain at the site for the duration of construction operations at least one 1 up to date copy of all relevant codes and standards listed in the Contract Documents or determined to be applicable to the work One 1 copy of such SUMMARY 10 14 2015 011000 10 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS codes shall be for the exclusive use of UMA and the Designer and its Consultants an
90. shall subject to the provisions of section thirty nine J be conclusive for the purposes of this section Notwithstanding the provisions of this section at any time after the value of the work remaining to be done is in the estimation of the awarding authority less than 1 per cent of the adjusted contract price or the awarding authority has determined that the contractor has substantially completed the work and the awarding authority has taken possession for occupancy the awarding authority may send to the general contractor by certified mail return receipt requested a complete and final list of all incomplete and unsatisfactory work items including for each item on the list a good faith estimate of the fair and reasonable cost of completing such item The general contractor shall then complete all such work items within 30 days of receipt of such list or before the contract completion date whichever is later If the general contractor fails to complete all incomplete and unsatisfactory work items within 45 days after receipt of such items furnished by the awarding authority or before the contract completion date whichever is later subsequent to an additional 14 days written notice to the general contractor by certified mail return 128 receipt requested the awarding authority may terminate the contract and complete the incomplete and unsatisfactory work items and charge the cost of same to the general contractor and such termination s
91. shall do or cause his agents to do all cutting fitting adjusting and repair necessary in order to make the several parts of the work come together properly Examine Contract Documents in advance of start of construction and identify in writing questions irregularities or interference to the UMA Project manager in writing Failure to identify and address such issues in advance becomes the sole responsibility of the SUMMARY 10 14 2015 011000 6 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS General Contractor A conflict that would cause the reduction of the normal ceiling height of any occupied space is considered to be an interference Execute the work in an orderly and careful manner with due regard to the occupants of the facility the public the employees and the normal function of the facility The work sequence shall follow planning and schedule established by the General Contractor as approved by the Designer and the UMA Project Manager The work upon the site of the project shall commence promptly and be executed with full simultaneous progress Work operations which require the interruption of utilities service and access shall be scheduled so as to involve minimum disruption and inconvenience and to be expedited so as to insure minimum duration of any periods of disruption or inconvenience The General Contractor shall review the tolerances established in the specifications for each type of work and as estab
92. submit its Application for Certificate of Eligibility so as to allow sufficient time for DCAM s evaluation of the application and issuance of a Certificate of Eligibility prior to the deadline for bidding 2 3 The Contractor Update Statement is not a public record as defined in M G L c 4 8 7 and will not be open to public inspection 11 SECTION 3 FILED SUB BIDDERS CERTIFICATE OF ELIGIBILITY AND UPDATE STATEMENT 3 1 Every Filed Sub Bidder must submit the following with each filed sub bid A current Certificate of Eligibility issued by the Division of Capital Asset Management and Maintenance DCAM for that sub bid trade showing that the Sub Bidder has been approved to bid on projects of the category of work required A fully completed current Sub Bidder Update Statement 3 2 It is the Sub Bidder s responsibility to obtain the necessary forms from DCAM and to submit its Application for Sub bidder Certificate of Eligibility so as to allow sufficient time for DCAM s evaluation of the application and issuance of a Sub Bidder Certificate of Eligibility prior to the deadline for bidding 3 3 The Sub Bidder Update Statement is not a public record as defined in M G L c 4 7 and will not be open to public inspection SECTION 4 REQUESTS FOR INTERPRETATION 4 1 Any questions by prospective Bidders concerning interpretation of the Contract Documents must be submitted in writing to the Awarding Authority and should be in its po
93. substitute for a material named or described in the Contract Documents such submission shall be made at least one hundred twenty 120 days prior to the date the materials will be used in the Work In no event shall the Contractor maintain a claim for delays based upon the Designer s review of such substituted materials if the Contractor has failed to comply with the one hundred twenty 120 day submission requirement D The Contractor shall save the written calculations pricing information and other data that the Contractor used to calculate the General Bid the Bid Pricing Materials for at least six years after the Awarding Authority makes Final Payment under this Contract No increase in the Contract Price shall be allowed for any material later found to have been improperly rejected as not being equal unless the Contractor can show persuasive evidence that the rejection increased the Contractor s costs over those provided for in the Bid Pricing Materials net of all savings the Contractor obtained by substituting other or equal items Without limiting the foregoing if the Awarding Authority rejects a proposed substitution on the basis that the item is not equal and if after the Contractor complies with the appeal procedures required by law DCAM regulation and by the Contract Documents the appropriate authority finds that the proposed substitution was equal the Contract Price may be increased only to the extent that 1 the item that the Co
94. the Board of Directors of the Corporation held on in a which a quorum Date Location was present and voting it was voted to authorize Name of the Corporation to execute Officer Title and deliver on behalf of the Corporation the following contract and to act as principal to execute bonds in connection therewith which contract and bonds were presented to and made a part of the records of said meeting UMA Number Project Title further certify that is duly qualified and acting Name of Corporate Officer of the Corporation and that said vote Officer Title has not been repealed rescinded or amended Name Date CORPORATE SEAL SUBSCRIBED AND SWORN TO THIS DAY OF 20 BEFORE ME Notary Public My Commission Expires 17 CERTIFICATE OF JOINT VENTURE INCLUDING SIGNATURE AUTHORITY This certificate is being given in connection with the execution by the Joint Venture of the following construction contract with the University of Massachusetts Amherst In connection with the execution of the contract the Contract the parties to the Joint Venture represent and warrant as follows 1 Exhibit A attached hereto is a true and complete copy of the Joint Venture Agreement between the parties dated Said Joint Venture Agreement is in full force and effect and has not been modified amended revoked or terminated 2 The principal place of business of the Joint Venture is as follows 3 The Manageme
95. the Contract in whole or in part unless the Contractor or any Subcontractor is able to demonstrate as approved by the Awarding Authority within a specified time his compliance with the terms of the contract 4 The denial to the Contractor or any subcontractor of the right to participate in any future contracts awarded by the Awarding Authority for a period of up to three years B If at any time after the imposition of one or more of the above sanctions a Contractor is able to demonstrate that it is in compliance with this Article the Contractor may request the Awarding Authority in consultation with the Commission to suspend the sanctions conditionally pending a final determination by the Commission as to whether the Contractor is in compliance Upon final determination of the Commission the Awarding Authority based on the recommendation of the Commission shall either lift the sanctions or impose them again C Sanctions recommended by the Commission and enumerated under Section 4 above shall not be imposed by the Awarding Authority except after an adjudicatory proceeding as that term is used M G L c 30A has been conducted No investigation by the Commission or its agent shall be initiated without prior notice to the Contractor D Notwithstanding the provisions of 4A 4C above if the Awarding Authority determines after investigation that the Contractor or any Subcontractor is not in compliance with the terms of this Article it may
96. the preceding sentence shall preclude the Contractor from subsequently claiming any time extension due to said delay D If inthe opinion of the Designer or the Awarding Authority the Contractor fails to comply with the Progress Schedule the Awarding Authority may give the Contractor a notice specifying the time limits and performance standards that the Contractor is failing to meet whereupon 1 the Contractor shall if the notice requires discontinue all or any portion of the Work which discontinuance shall neither terminate the Contract nor give the Contractor any claim for an increase in the Contract Price damages or an extension of any completion deadlines or 2 at Contractor s sole cost increase the work force equipment and plant or any of them employed on the whole or any part of the Work to the extent required by such notice and employ the same from day to day until the completion of the Work or such part thereof or until the failure regarding the rate of progress in the opinion of the Designer or the Awarding Authority shall have been sufficiently corrected E If in the opinion of the Awarding Authority the Contractor fails to comply with the Progress Schedule and whether or not the Awarding Authority shall have given the Contractor a notice described in D above the Awarding Authority may but shall not be required to give the Contractor notice of such failure and five days to cure the same Unless the Contractor shall with
97. the total labor rate computed in accordance with subparagraph a above c plus an allowance equal to 2096 of the amount of a above for overhead superintendence and profit In the case of 1 work which is the work of the Contractor and all his non filed Subcontractors said 2096 allowance shall be paid to the Contractor and said non filed Subcontractors shall agree upon the distribution of this amount as a matter of contract between them In the case of Item 2 work which is work performed by a Subcontractor filed pursuant to M G L c 149 s 44F said 20 allowance shall be paid to the filed Subcontractor it being understood that this provision does not apply to other Subcontracors including sub Subcontractors listed under paragraph E of the form for sub Bid d plus for work performed by a Subcontractor filed pursuant to M G L c 149 s 44F an additional allowance equal to 796 of the sum of a through c above as full compensation to the Contractor for processing forms and assuming full responsibility for the faithful performance of such work by said filed Subcontractor s e plus or minus the actual direct additional premium costs and expenses incurred as a result of collective bargaining agreements or other agreements between organized labor and employers and plus or minus the actual direct premium cost of payment and performance bonds required of Contractor and filed Subcontractors for this Contract B If the net ch
98. unreasonable or excessive 6 If applicable make a recommendation on the Contractor s request for additional time 7 Ifthe work was performed under protest pertinent correspondence shall be attached to the original Form 5 8 References to date and amount of any NOl s or any previously approved not to exceed Form 5 s issued applicable to the change If recommending approval forward the four 4 original green sheets plus the 2 copies of the Form 5 all with original signatures to the University of Massachusetts Amherst along with the Designer s recommendation If the Designer disapproves the request the Designer shall within seven 7 calendar days attach a detailed letter setting forth its reasons for disapproval Forward the four 4 originals of Form 5 and two 2 copies without the Designer s signature on the form along with its letter detailing its reason for disapproval to the University of Massachusetts Amherst UNIVERSITY OF MASSACHUSETTS AMHERST PM SHALL 175 a Notify all parties if funds are insufficient to cover the change and return to the Contractor through the Resident Engineer if applicable any request that is incomplete without proper details or recommendations b The Form 5 shall be logged and given a change request number The numbering will be in numerical sequence c Ifthe Form 5 is approved the University of Massachusetts Amherst PM shall issue a Purchase Order to the General Contractor d Ifthe Un
99. welding RNC and fittings Expansion Joint Fittings 1 Install expansion fittings at all locations where conduits cross building or structure expansion joints RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 260533 5 of 6 V Flexible Conduit Connections Comply with NEMA RV 3 Use a maximum of 72 inches of flexible conduit for equipment subject to vibration noise transmission or movement and for transformers and motors 1 Use LFMC in damp or wet locations subject to severe physical damage 2 Use LFMC or LFNC in damp or wet locations not subject to severe physical damage W Mount boxes at heights indicated on Drawings If mounting heights of boxes are not individually indicated give priority to ADA requirements X Recessed Boxes in Masonry Walls Saw cut opening for box in center of cell of masonry block and install box flush with surface of wall Prepare block surfaces to provide a flat surface for a raintight connection between box and cover plate or supported equipment and box Y Horizontally separate boxes mounted on opposite sides of walls so they are not in the same vertical channel 2 Locate boxes so that cover plate will not span different building finishes AA Support boxes of three gangs or more from more than one side by spanning two framing members or mounting on brackets specifically designed for the purpose BB Fasten junction and pull boxes to or support from building structure Do not support boxes
100. work in public or private ways and in any utility company right of way or easement by calling 811 or online at http www digsafe com 4 The Contractor shall comply with M G L 149 s 129A relative to shoring and bracing of trenches H Without limiting the Contractor s responsibilities described above the Contractor shall take all reasonable precautions for the safety of and the prevention of injury or damage to 1 all agents and employees and contractors on the Work and all other persons who may be affected thereby including the general public 2 all the Work and all materials and equipment to be incorporated therein whether in storage on or off the Site under the care custody or control of the Contractor or any of its Subcontractors or any contractors directly or indirectly contracting through any of them and 3 other property at the Site or adjacent thereto including but not limited to trees shrubs lawns walks pavements roadways structures and utilities not designated for removal relocation or replacement in the course of the Work The Contractor shall promptly remedy all damage or loss to any such property caused in whole or in part by the Contractor any Subcontractor or anyone directly or indirectly contracted or employed by any of them or by anyone for whose acts any of them may be liable Without limiting the foregoing the Contractor shall 1 post and maintain adequate danger signs and other warnings against haza
101. your firm been brought concluded or settled relating to the procurement or performance of any construction contract including but not limited to actions to obtain payment brought by subcontractors suppliers or others Have any criminal proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to the procurement or performance of any construction contract including but not limited to any of the following offenses fraud graft embezzlement forgery bribery falsification or destruction of records or receipt of stolen property Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state s or federal procurement laws arising out of the submission of bids or proposals Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of M G L Chapter 268A the State Ethics Law Division of Capital Asset Management Sub bidder Update Statement Effective March 30 2010 Page 8 of 10 47 PART 4 Legal or Administrative Proceedings Compliance with Laws continued YES NO 5 Have any judicial or administrative proceedings involving your firm or a princ
102. 0 24 55 2 50 19 01 7 45 0 00 0 00 26 46 3 55 20 91 8 52 6 30 0 00 35 73 4 60 22 81 8 52 6 30 0 00 37 63 5 65 24 71 8 52 6 55 0 00 39 78 6 70 26 61 8 52 6 55 0 00 41 68 7 75 28 51 8 52 6 55 0 00 43 58 8 80 30 41 8 52 6 55 0 00 45 48 9 85 32 31 8 52 6 55 0 00 47 38 10 90 34 21 8 52 6 55 0 00 49 28 Notes Apprentice to Journeyworker Ratio 1 1 TELECOMMUNICATION TECHNICIAN 06 28 2015 38 06 9 20 9 79 0 00 57 05 ELECTRICIANS LOCAL 7 01 03 2016 38 91 9 20 9 79 0 00 57 90 07 03 2016 39 81 9 20 9 79 0 00 58 80 01 01 2017 40 71 9 20 9 79 0 00 59 70 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 30 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice TELECOMMUNICATION TECHNICIAN Local 7 Effective Date 06 28 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 40 15 22 5 00 0 46 0 00 20 68 2 45 17 13 5 00 0 46 0 00 22 59 3 50 19 03 9 20 5 51 0 00 33 74 4 55 20 93 9 20 5 51 0 00 35 64 5 65 24 74 9 20 6 51 0 00 40 45 6 70 26 64 9 20 7 51 0 00 43 35 Effective Date 01 03 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 40 15 56 5 00 0 47 0 00 21 03 2 45 17 51 5 00 0 47 0 00 22 98 3 50 19 46 9 20 5 52 0 00 34 18 4 55 21 40 9 20 5 52 0 00 36 12 5 65 25
103. 0 36 12 5 65 25 29 9 20 6 52 0 00 41 01 6 70 27 24 9 20 7 52 0 00 43 96 Notes Pre 5 31 11 Begins at Step 3 37 78 4 39 68 5 44 10 6 46 19 Steps 1 2 are 1000 hrs Steps 3 6 are 1500 hrs Apprentice to Journeyworker Ratio 2 3 ELEVATOR CONSTRUCTOR 01 01 2015 847 73 813 58 1421 80 00 75 52 ELEVATOR CONSTRUCTORS LOCAL 41 bpm Sean dai 181496 000 01 01 2017 549 90 1528 15 71 0 00 80 89 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 9 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice ELEVATOR CONSTRUCTOR Local 41 Effective Date 01 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 23 87 13 58 14 21 0 00 51 66 2 55 26 25 13 58 14 21 0 00 54 04 3 65 31 02 13 58 14 21 0 00 58 81 1 70 33 41 13 58 14 21 0 00 61 20 5 80 38 18 13 58 14 21 0 00 65 97 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 24 39 14 43 14 96 0 00 53 78 2 55 26 82 14 43 14 96 0 00 56 21 3 65 31 70 14 43 14 96 0 00 61 09 4 70 34 14 14 43 14 96 0 00 63 53 5 80 39 02 14 43 14 96 0 00 68 41 Notes Steps 1 2 are 6 mos Steps 3 5 are 1 year Apprentice to Journeyworker Ratio 1 1 ELEVATOR CONSTRUCTOR HELPER 01 01 2015 33 41 13 58 814 21 0 00 61 20 ELEVATOR CONSTRUCTORS LOCAL 41 01 01 2
104. 016 34 14 14 43 14 96 0 00 63 53 01 01 2017 34 93 15 28 15 71 0 00 65 92 For apprentice rates see Apprentice ELEVATOR CONSTRUCTOR FENCE amp GUARD RAIL ERECTOR HEAVY amp HIGHWAY 06 01 2015 28 74 7 30 10 18 0 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway FIELD ENG INST ROD BLDG SITE HVY HWY 06 01 1999 18 84 4 80 4 10 0 00 27 74 OPERATING ENGINEERS LOCAL 98 FIELD ENG PARTY CHIEF BLDG SITE HVY HWY 06 01 1999 21 33 4 80 4 10 0 00 30 23 OPERATING ENGINEERS LOCAL 98 FIELD ENG SURVEY CHIEF BLDG SITE HVY HWY 06 01 1999 22 33 4 80 4 10 0 00 31 23 OPERATING ENGINEERS LOCAL 98 FIRE ALARM INSTALLER 06 28 2015 38 06 8920 9 79 0 00 57 05 ELECTRICIANS LOCAL 7 01 03 2016 38 91 9 20 9 79 0 00 57 90 07 03 2016 39 81 9 20 9 79 0 00 58 80 01 01 2017 40 71 9 20 9 79 0 00 59 70 For apprentice rates see Apprentice ELECTRICIAN FIRE ALARM REPAIR MAINTENANCE 06 28 2015 38 06 89 20 9 79 0 00 57 05 COMMISSIONING ELECTRICIANS LOCAL 01 03 2016 38 91 9 20 9 79 0 00 57 90 07 03 2016 39 81 9 20 9 79 0 00 58 80 01 01 2017 40 71 9 20 9 79 0 00 59 70 For apprentice rates see Apprentice TELECOMMUNICATIONS TECHNICIAN Issue Date 09 17 2015 Wage Request Number
105. 06 01 2015 28 75 7 30 11 58 0 00 47 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 43 7 30 11 58 0 00 48 31 06 06 2016 30 12 7 30 11 58 0 00 49 00 12 05 2016 30 80 7 30 11 58 0 00 49 68 For apprentice rates see Apprentice LABORER LABORER TREE REMOVER 06 01 2015 28 75 7 30 811 58 0 00 47 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 43 7 30 11 58 0 00 48 31 06 06 2016 30 12 7 30 11 58 0 00 49 00 12 05 2016 30 80 7 30 11 58 0 00 49 68 This classification applies to all tree work associated with the removal of standing trees and trimming and removal of branches and limbs when the work is not done for a utility company for the purpose of operation maintenance or repair of utility company equipment For apprentice rates see Apprentice LABORER LASER BEAM OPERATOR 06 01 2015 29 00 7 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER LASER BEAM OPERATOR HEAVY amp HIGHWAY 06 01 2015 28 74 7 30 10 18 0 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway MARBLE amp TILE FINISHERS 08
106. 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER COMPRESSOR OPERATOR 06 01 2015 32 44 9 70 11 47 0 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36 For apprentice rates see Apprentice OPERATING ENGINEERS CRANE OPERATOR 06 01 2015 36 47 9 70 11 47 0 00 57 64 OPERATING ENGINEERS LOCAL 98 12 01 2015 37 22 9 70 11 47 0 00 58 39 For apprentice rates see Apprentice OPERATING ENGINEERS DELEADER BRIDGE 07 01 2015 48 56 7 85 16 10 0 00 72 51 PAINTERS LOCAL 35 ZONE 3 01 01 2016 49 51 7 85 16 10 0 00 73 46 07 01 2016 50 46 7 85 16 10 0 00 74 41 01 01 2017 51 41 7 85 16 10 0 00 75 36 Apprentice PAINTER Local 35 BRIDGES TANKS Effective Date 07 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 24 28 7 85 0 00 0 00 32 13 2 55 26 71 7 85 3 66 0 00 38 22 3 60 29 14 7 85 3 99 0 00 40 98 4 65 31 56 7 85 4 32 0 00 43 73 5 70 33 99 7 85 14 11 0 00 55 95 6 75 36 42 7 85 14 44 0 00 58 71 7 80 38 85 7 85 14 77 0 00 61 47 8 90 43 70 7 85 15 44 0 00 66 99 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 24 76 7 85 0 00 0 00 32 61 2 55 27 23 7 85 3 66 0 00 38 74 3 60 29 71 7 85 3 99 0 00 41 55 4 65 32 18 7 85 4 32 0 00 44 35 5 70 34 66 7 85 14 11 0 00 56 62 6 75 37 13 7 85 14 44 0 00 59
107. 2 to secure the Awarding Authority s remedies against the Contractor for the Contractor s breach of its obligations under this Contract or the breach of any person performing any part of the Work and 3 the payment of any expenses losses or damages incurred by the Awarding Authority or any agency of the Commonwealth as a result of the failure of the Contractor to perform its obligations hereunder The Awarding Authority may retain until all claims are settled such moneys as the Awarding Authority estimates to be the fair value of the Awarding Authority s claims against the Contractor and of all claims for labor performed or furnished and for materials used or employed in or in connection with the Work and for the rental of vehicles appliances and equipment employed and for the employment of substitute contractors and labor in connection with the Work filed in accordance with M G L 30 s 39A and s 39F The Awarding Authority may make such settlements and apply thereto any moneys retained under this Contract B The Contractor shall each week examine all claims so filed and if the same are in any respect incorrect or do not correctly show the amount due from the Contractor to the claimant for such labor and materials the Contractor shall forthwith file with the Awarding Authority a separate written statement of all inaccuracies in each claim and of the correct amount due from the Contractor to each claimant therefore and shall immediately file
108. 20150917 043 Page 10 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment FIREMAN 06 01 2015 32 44 9 70 1147 80 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36 Apprentice OPERATING ENGINEERS Local 98 Class 3 Effective Date 06 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 60 519 46 9 70 11 47 0 00 40 63 2 70 22 71 9 70 11 47 0 00 43 88 3 80 25 95 9 70 11 47 0 00 47 12 4 90 29 20 9 70 11 47 0 00 50 37 Effective Date 12 01 2015 Supplemental Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 19 91 9 70 11 47 0 00 41 08 2 70 23 23 9 70 11 47 0 00 44 40 3 80 26 55 9 70 11 47 0 00 47 72 4 90 29 87 9 70 11 47 0 00 51 04 Notes Steps 1 2 are 1000 hrs Steps 3 4 are 2000 hrs Apprentice to Journeyworker Ratio 1 6 FLAGGER amp SIGNALER HEAVY amp HIGHWAY 06 01 2015 20 50 7 30 10 18 0 00 37 98 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 20 50 7 30 10 18 0 00 37 98 06 01 2016 20 50 7 30 10 18 0 00 37 98 12 01 2016 20 50 7 30 10 18 0 00 37 98 For apprentice rates see Apprentice LABORER Heavy and Highway FLOORCOVERER 09 01 2015 832 389 88 55 1433 80 00 55 27 FLOORCOVERERS LOCAL 2168 ZONE III Apprentice LOORCOVERER Local 2168 Zone III Effective Date 09 01 2015 Supplementa
109. 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER WAGON DRILL OPERATOR HEAVY amp HIGHWAY 06 01 2015 28 74 730 81018 80 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway WATER METER INSTALLER 06 17 2015 837 566 88 30 1490 0 00 60 76 PLUMBERS amp PIPEFITTERS LOCAL 104 03 17 2016 38 56 8 30 14 90 0 00 61 76 For apprentice rates see Apprentice PLUMBER PIPEFITTER or PLUMBER GASFITTER Outside Electrical West EQUIPMENT OPERATOR 08 30 2015 842 16 820 8926 0 00 59 62 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 For apprentice rates see Apprentice LINEMAN GROUNDMAN 08 30 2015 828 87 8820 8 87 0 00 45 94 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 For apprentice rates see Apprentice LINEMAN GROUNDMAN TRUCK DRIVER 08 30 2015 37 73 8820 89 13 0 00 55 06 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 For apprentice rates see Apprentice LINEMAN Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 33 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment HEAVY EQUIPMENT OPERATOR 08 30 2015 4437 8820 9 33 0 00 61 90 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 For apprentice rate
110. 3 00 7 30 11 58 0 00 41 88 4 90 25 88 7 30 11 58 0 00 44 76 Effective Date 12 07 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 17 66 7 30 11 58 0 00 36 54 2 70 20 60 7 30 11 58 0 00 39 48 3 80 23 54 7 30 11 58 0 00 42 42 90 26 49 7 30 11 58 0 00 45 37 Notes Apprentice to Journeyworker Ratio 1 5 LABORER HEAVY amp HIGHWAY 06 01 2015 28 49 7 30 10 18 0 00 45 97 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 28 99 7 30 10 18 0 00 46 47 06 01 2016 29 49 7 30 10 18 0 00 46 97 12 01 2016 30 24 7 30 10 18 0 00 47 72 Apprentice LABORER Heavy amp Highway Zone 3 Effective Date 06 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 17 09 7 30 10 18 0 00 34 57 2 70 19 94 7 30 10 18 0 00 37 42 3 80 22 79 7 30 10 18 0 00 40 27 4 90 25 64 7 30 10 18 0 00 43 12 Effective Date 12 01 2015 Supplemental Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 60 17 39 7 30 10 18 0 00 34 87 2 70 20 29 7 30 10 18 0 00 37 77 3 80 23 19 7 30 10 18 0 00 40 67 4 90 26 09 7 30 10 18 0 00 43 57 Notes Apprentice to Journeyworker Ratio 1 5 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 15 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment LABO
111. 3 20 0 00 56 50 For apprentice rates see Apprentice LABORER DIVER 08 01 2015 60 34 9 80 18 17 0 00 88 31 PILE DRIVER LOCAL 56 ZONE 3 DIVER TENDER 08 01 2015 43 10 9 80 18 17 0 00 71 07 PILE DRIVER LOCAL 56 ZONE 3 DIVER TENDER EFFLUENT 08 01 2015 64 65 9 80 18 17 0 00 92 62 PILE DRIVER LOCAL 56 ZONE 3 DIVER SLURRY EFFLUENT 08 01 2015 90 51 9 80 18 17 0 00 118 48 PILE DRIVER LOCAL 56 ZONE 3 ELECTRICIAN Including Core Drilling 06 28 2015 38 06 9 20 9 79 0 00 57 05 ELECTRICIANS LOCAL 7 01 03 2016 38 91 9 20 9 79 0 00 57 90 07 03 2016 39 81 9 20 9 79 0 00 58 80 01 01 2017 40 71 9 20 9 79 0 00 59 70 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 8 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice ELECTRICIAN Local 7 Effective Date 06 28 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 40 15 22 5 00 0 46 0 00 20 68 2 45 17 13 5 00 0 46 0 00 22 59 3 50 19 03 9 20 5 51 0 00 33 74 4 55 20 93 9 20 5 51 0 00 35 64 5 65 24 74 9 20 6 51 0 00 40 45 6 70 26 64 9 20 7 51 0 00 43 35 Effective Date 01 03 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 40 15 56 5 00 0 47 0 00 21 03 2 45 17 51 5 00 0 47 0 00 22 98 3 50 19 46 9 20 5 52 0 00 34 18 4 55 21 40 9 20 5 52 0 0
112. 31 94 10 41 810 08 0 00 52 43 06 01 2016 32 44 1041 810 08 0 00 52 93 08 01 2016 32 44 10 91 810 08 0 00 53 43 12 01 2016 32 44 10 91 810 89 0 00 54 24 SPECIALIZED EARTH MOVING EQUIP gt 35 TONS 08 01 2015 32 23 10 41 89 33 0 00 51 97 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 32 23 10 41 810 08 0 00 52 72 06 01 2016 32 73 10 41 810 08 0 00 53 22 08 01 2016 32 73 10 91 810 08 0 00 53 72 12 01 2016 32 73 10 91 810 89 0 00 54 53 SPRINKLER FITTER 04 01 2015 38 01 8 52 11 98 0 00 58 51 SPRINKLER FITTERS LOCAL 669 01 01 2016 38 01 8 52 12 13 0 00 58 66 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 29 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice SPRINKLER FITTER Local 669 Effective Date 04 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 45 17 10 7 45 0 00 0 00 24 55 2 50 19 01 7 45 0 00 0 00 26 46 3 55 20 91 8 52 6 15 0 00 35 58 4 60 22 81 8 52 6 15 0 00 37 48 5 65 24 71 8 52 6 40 0 00 39 63 6 70 26 61 8 52 6 40 0 00 41 53 T 75 28 51 8 52 6 40 0 00 43 43 8 80 30 41 8 52 6 40 0 00 45 33 9 85 32 31 8 52 6 40 0 00 47 23 10 90 3421 8 52 6 40 0 00 49 13 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 45 17 10 7 45 0 00 0 0
113. 3rev 1 1 1 2 UMA 16 12 MULLINS SECURITY CAMERAS SECTION 017700 CONTRACT CLOSEOUT GENERAL PROVISIONS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications FINAL CLEANING In addition to instructions specified under the various Sections of the Specifications the General Contractor shall perform final cleaning operations as herein specified prior to final inspection Maintain project site free from accumulations of waste debris and rubbish caused by operations At completion of work remove waste materials rubbish tools equipment machinery and surplus materials and clean all sight exposed surfaces leave project clean and ready for occupancy Cleaning shall include all surfaces interior and exterior in which the General Contractor has had access whether existing or new Refer to Sections of the Specifications for cleaning of specific products or work Use only those materials which will not create hazards to health or property and which will not damage surfaces Use only those cleaning materials and methods that are recommended by the manufacturer of surface material to be cleaned Employ experienced workmen or professional cleaners for final cleaning operations Remove grease mastic adhesives dust dirt stains fingerprints labels and other foreign materials from sight expo
114. 75 5 85 25 87 7 80 19 60 0 00 53 27 6 90 27 40 7 80 19 60 0 00 54 80 Effective Date 03 16 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 60 18 65 7 80 19 60 0 00 46 05 2 70 21 76 7 80 19 60 0 00 49 16 3 75 23 32 7 80 19 60 0 00 50 72 4 80 24 87 7 80 19 60 0 00 52 27 5 85 26 43 7 80 19 60 0 00 53 83 6 90 27 98 7 80 19 60 0 00 55 38 Notes Structural 1 6 Ornamental 1 4 Apprentice to Journeyworker Ratio JACKHAMMER amp PAVING BREAKER OPERATOR 06 01 2015 29 00 7 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER LABORER 06 01 2015 28 75 7 30 811 58 0 00 47 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 43 7 30 11 58 0 00 48 31 06 06 2016 30 12 7 30 11 58 0 00 49 00 12 05 2016 30 80 7 30 11 58 0 00 49 68 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 14 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice LABORER Zone 3 Building amp Site Effective Date 06 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 60 17 25 7 30 11 58 0 00 36 13 2 70 20 13 7 30 11 58 0 00 39 01 3 80 2
115. 9 pricing data used was accurate complete and current If the Awarding Authority subsequently determines that the data submitted by the Contractor was incomplete incorrect or not current the Awarding Authority may exclude such data from consideration under the equitable adjustment request 2 Methods of Computing Equitable Adjustments A Equitable adjustments in the Contract Price shall be determined according to one of the following methods or a combination thereof as determined by the Awarding Authority 1 fixed price basis provided that the fixed price shall be inclusive of items a through e below and shall be computed in accordance with those provisions 2 estimated lump sum basis to be adjusted in accordance with Contract unit prices or other agreed upon unit prices provided that the unit prices shall be inclusive of all costs related to such equitable adjustment 3 time and materials basis to be subsequently adjusted on the basis of actual costs but subject to a predetermined not to exceed limit calculated as follows a the direct cost or credit for labor at the minimum wage rates established for this Contract pursuant to M G L c 149 s 26 27H and the direct cost for material and use of equipment b plus or minus the cost of Workmen s Compensation Insurance Liability Insurance Federal Social Security and Massachusetts Unemployment Compensation or as an alternative the Contractor may elect to use a flat 3096 of
116. ABORER ROLLER OPERATOR 06 01 2015 31 83 9 70 11 47 80 00 53 00 OPERATING ENGINEERS LOCAL 98 12 01 2015 32 58 9 70 11 47 0 00 53 75 For apprentice rates see Apprentice OPERATING ENGINEERS ROOFER Coal tar pitch 07 16 2015 20 75 9 00 13 25 80 00 52 00 ROOFERS LOCAL 248 For apprentice rates see Apprentice ROOFER ROOFER Inc Roofer Waterproofng amp Roofer Damproofg 07 16 2015 29 25 9 00 12 75 0 00 51 00 ROOFERS LOCAL 248 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 26 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice ROOFER Local 248 Effective Date 07 16 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 17 55 9 00 0 00 0 00 26 55 2 65 19 01 9 00 12 75 0 00 40 76 3 70 20 48 9 00 12 75 0 00 42 23 4 75 21 94 9 00 12 75 0 00 43 69 5 80 23 40 9 00 12 75 0 00 45 15 6 85 24 86 9 00 12 75 0 00 46 61 7 90 26 33 9 00 12 75 0 00 48 08 8 95 27 79 9 00 12 75 0 00 49 54 Notes Steps are 750 hrs Roofer Tear Off 1 1 Same as above Apprentice to Journeyworker Ratio 1 3 ROOFER SLATE TILE PRECAST CONCRETE 07 16 2015 29 75 9 00 13 25 0 00 52 00 ROOFERS LOCAL 248 For apprentice rates see Apprentice ROOFER SCRAPER 06 01 2015 32 44 9 70 11 47 0 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36
117. AL SYSTEMS PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 A 1 2 1 3 RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY This Section includes the following 1 Hangers and supports for electrical equipment and systems 2 Construction requirements for concrete bases ACTION SUBMITTALS Product Data For each type of product 1 Include construction details material descriptions dimensions of individual components and profiles and finishes for the following Hangers Steel slotted support systems Nonmetallic support systems Trapeze hangers Clamps Turnbuckles Sockets Eye nuts Saddles Brackets cr pga op 2 Include rated capacities and furnished specialties and accessories Shop Drawings Show fabrication and installation details and include calculations for the following Trapeze hangers Include Product Data for components Steel slotted channel systems Include Product Data for components Nonmetallic slotted channel systems Include Product Data for components Equipment supports TU EE HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 10 14 2015 260529 1 of 4 16 12 MULLINS SECURITY CAMERAS PART 2 PRODUCTS 2 1 SUPPORT ANCHORAGE AND ATTACHMENT COMPONENTS X Steel Slotted
118. Apprentice Base Wage Health Pension Unemployment Total Rate 45 14 86 5 88 4 08 0 00 24 82 2 50 16 51 6 18 4 53 0 00 27 22 3 55 18 16 6 47 8 15 0 97 33 75 4 60 19 81 6 77 8 15 1 03 35 76 5 65 21 46 7 06 8 15 1 09 37 76 6 70 23 11 7 36 8 15 1 14 39 76 7 75 24 77 7 66 8 15 1 20 41 78 8 80 26 42 7 95 13 88 1 43 49 68 9 85 28 07 8 25 14 01 1 49 51 82 10 90 29 72 8 55 14 01 1 55 53 83 Notes Apprentice to Journeyworker Ratio 1 3 SIGN ERECTOR 06 01 2013 25 81 7 07 87 05 0 00 39 93 PAINTERS LOCAL 35 ZONE 3 Wage Request Number 20150917 043 Issue Date 09 17 2015 Page 28 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice SIGN ERECTOR Local 35 Zone 3 Effective Date 06 01 2013 Supplemental Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 12 91 7 07 0 00 0 00 19 98 2 55 14 20 7 07 2 45 0 00 23 72 3 60 15 49 7 07 2 45 0 00 25 01 4 65 16 78 7 07 2 45 0 00 26 30 5 70 18 07 7 07 7 05 0 00 32 19 6 75 19 36 7 07 7 05 0 00 33 48 7 80 20 65 7 07 7 05 0 00 34 77 8 85 21 94 7 07 7 05 0 00 36 06 9 90 23 23 7 07 7 05 0 00 37 35 Notes Steps are 4 mos Apprentice to Journeyworker Ratio 1 1 SPECIALIZED EARTH MOVING EQUIP lt 35 TONS 08 01 2015 31 94 10 41 89 33 0 00 51 68 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015
119. C or RMC for raceways 2 Use a conduit bushing or insulated fitting to terminate stub ups not terminated in hubs or in an enclosure Threaded Conduit Joints Exposed to Wet Damp Corrosive or Outdoor Conditions Apply listed compound to threads of raceway and fittings before making up joints Follow compound manufacturer s written instructions RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 260533 4 of 6 UMA16 12 MULLINS SECURITY CAMERAS Raceway Terminations at Locations Subject to Moisture or Vibration Use insulating bushings to protect conductors including conductors smaller than No 4 AWG Terminate threaded conduits into threaded hubs or with locknuts on inside and outside of boxes or cabinets Install bushings on conduits up to 1 1 4 inch trade size and insulated throat metal bushings on 1 1 2 inch trade size and larger conduits terminated with locknuts Install insulated throat metal grounding bushings on service conduits Install raceways square to the enclosure and terminate at enclosures with locknuts Install locknuts hand tight plus 1 4 turn more Do not rely on locknuts to penetrate nonconductive coatings on enclosures Remove coatings in the locknut area prior to assembling conduit to enclosure to assure a continuous ground path Cut conduit perpendicular to the length For conduits 2 inch trade size and larger use roll cutter or a guide to make cut straight and perpendicular to the length Install pull wires
120. DENTIFICATION LABELS A Self Adhesive Engraved Laminated Acrylic or Melamine Label Adhesive backed with white letters on a dark gray background Minimum letter height shall be 3 8 inch PART 3 EXECUTION 3 1 INSTALLATION A Verify identity of each item before installing identification products B Location Install identification materials and devices at locations for most convenient viewing without interference with operation and maintenance of equipment c Apply identification devices to surfaces that require finish after completing finish work D Self Adhesive Identification Products Clean surfaces before application using materials and methods recommended by manufacturer of identification device E Attach signs and plastic labels that are not self adhesive type with mechanical fasteners appropriate to the location and substrate F Attach plastic raceway and cable labels that are not self adhesive type with clear vinyl tape with adhesive appropriate to the location and substrate G System Identification Color Coding Bands for Raceways and Cables Each color coding band shall completely encircle cable or conduit Place adjacent bands of two color markings in contact side by side Locate bands at changes in direction at penetrations of walls and floors at 50 foot maximum intervals in straight runs and at 25 foot maximum intervals in congested areas H Cable Ties For attaching tags Use general purpose type except as
121. Energy amp Environmental Design USGBC Maple Flooring Manufacturers Association Inc National Association of Architectural Metal Manufacturers North American Insulation Manufacturers Association National Building Granite Quarries Association Inc National Concrete Masonry Association Northeastern Lumber Manufacturers Association National Electrical Manufacturers Association NFPA National Fire Protection Association National Fenestration Rating Council NOFMA The Wood Flooring Manufacturers Association Formerly National Oak Flooring Manufacturers Association National Roofing Contractors Association NSF International National Sanitation Foundation International National Terrazzo amp Mosaic Association Inc The National Wood Window and Door Association Now WDMA Steel Deck Institute Steel Door Institute Safety Glazing Certification Council Steel Joist Institute Sheet Metal and Air Conditioning Contractors National Association Specialty Steel Industry of North America SSPC The Society for Protective Coatings Tile Council of America Inc REFERENCES 10 14 2015 014200 3 of 4 16 12 12 4 2012 rev MULLINS SECURITY CAMERAS UL Underwriters Laboratories Inc USGBC U S Green Building Council WCLIB West Coast Lumber Inspection Bureau WDMA Window amp Door Manufacturers Association Formerly NWWDA National Wood Window and Door Association WWPA Western Wood Products Association B Code Agenci
122. General Contractor cannot comply with the noted corrections fabrication shall not proceed and General Contractor shall resubmit following procedures outlined in this Section 3 Stamped REVIEWED REVISE AND RESUBMIT OR REJECTED a General Contractor shall revise and resubmit for review Fabrication shall not proceed Manufacturer s Instruction 1 When required in individual Specification Section submit manufacturer s printed instructions for delivery storage assembly installation start up adjusting and finishing in quantities specified for product data with two 2 additional copies submitted to the UMA Project Manager and one 1 copy to the UMA Resident Engineer Certificates of Compliance Submit certificates of compliance with the associated Shop Drawings Product Data and Samples required for the product in quantities specified for certificates of compliance with two 2 additional copies submitted to the UMA Project Manager and one 1 copy to the UMA Resident Engineer Field Samples Provide field samples of finishes at the project as required by individual Specification Section Install sample complete and finished Patterns and Colors Submit accurate color charts and pattern charts to the Designer for review and selection whenever a choice of color or pattern is available in a specified product unless the exact color and pattern of a product are indicated in the Contract Documents Color and Pattern char
123. HEDULE A General Contractor shall prepare and submit for Designer and UMA s information a Progress Schedule for the work of the project Said schedule will be coordinated with the Designer s Work Plan to include sequencing of the project work B Schedule shall be updated weekly and submitted at the weekly project meeting for review Progress Payments to General Contractor a The Construction Schedule shall be an integral part and basic element of the estimate upon which progress payments shall be made The General Contractor CONSTRUCTION PROGRESS DOCUMENTS 10 14 2015 013200 1 of 2 16 12 12 4 2012 rev MULLINS SECURITY CAMERAS shall be entitled to progress payment only upon approval of estimates as determined from the currently approved updated computer produced schedule Payments will be made against activity items shown on the computer produced schedule and as reflected on UMA approved format payment forms which shall be used The General Contractor shall produce the Schedule of Values and the Standard Payment forms by following the guidelines of UMA staff This shall include entering the Net Amount Paid to Subcontractors against the appropriate activities 1 Contract time can only be extended by authorized approved change order b Whereas time is of the essence in the performance of work under the contract each request for change in any contract completion date shall be submitted by the General Contractor to UMA at
124. IN CONSTRUCTION SAFETY AND HEALTH APPROVED BY THE UNITED STATES OCCUPATIONAL SAFETY AND HEALTH ADMINISTRATION THAT IS AT LEAST 10 HOURS IN DURATION AT THE TIME THE EMPLOYEE BEGINS WORK AND ALL CONTRACTORS SUBCONTRACTORS AND OTHERS WORKING AT THE SITE SHALL FURNISH DOCUMENTATION OF SUCCESSFUL COMPLETION OF SAID COURSE WITH THE FIRST CERTIFIED PAYROLL REPORT FOR EACH EMPLOYEE ATTENTION FILED SUB BIDDERS EFFECTIVE JANUARY 1 2006 A VALID SUB BIDDER CERTIFICATE OF ELIGIBILITY ISSUED BY THE DIVISION OF CAPITAL ASSET MANAGEMENT DCAM IN THE CATEGORY OF WORK OF YOUR SUB BID AND A COMPLETED SUB BIDDER UPDATE STATEMENT MUST ACCOMPANY EACH AND EVERY FILED SUB BID SUBMITTED TABLE OF CONTENTS FOR UNIVERSITY OF MASSACHUSETTS AMHERST BID PACKAGE PART I Instructions to Bidders Attachment A Minimum Wage Rates page 23 Attachment B Forms Used During Bidding page 24 Sample Certificate of Eligibility Prime Bidder page 25 Sample Certificate of Eligibility Sub bidder page 26 Update Statement Prime Bidder Update Statement Sub bidder Form for General Bid Form for Sub Bid PART II Owner Contractor Agreement Exhibit A Additional Insurance Provisions if any page 68 Exhibit B Forms Used During Contract Award and Execution page 69 Payment Bond Performance Bond Schedule for Participation by Minority Women Business Enterprises Letter of Intent Certificate of Corporate Vote Certificate of Joint Ventu
125. ION 3 1 APPLICATION A Comply with NECA 1 NECA 101 for application of hangers and supports for electrical equipment and systems except if requirements in this Section are stricter w Comply with requirements for raceways and boxes specified in Section 260533 Raceways and Boxes for Electrical Systems C Maximum Support Spacing and Minimum Hanger Rod Size for Raceway Space supports for EMT IMC and RMC as per the Massachusetts Electrical Code Minimum rod size shall be 1 4 inch in diameter D Multiple Raceways or Cables Install trapeze type supports fabricated with steel slotted support system sized so capacity can be increased by at least 25 percent in future without exceeding specified design load limits 1 Secure raceways and cables to these supports with two bolt conduit clamps E Spring steel clamps designed for supporting single conduits without bolts may be used for 1 1 2 inch and smaller raceways serving branch circuits and communication systems above suspended ceilings and for fastening raceways to trapeze supports 3 2 SUPPORT INSTALLATION A Comply with NECA 1 and NECA 101 for installation requirements except as specified in this Article HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 10 14 2015 260529 3 of 4 16 12 MULLINS SECURITY CAMERAS B Raceway Support Methods In addition to methods described in NECA 1 EMT IMC and RMC may be supported by openings through structure members as permitted
126. ITY OF MASSACHUSETTS AMHERST UMA Project No Project No Project Name Project Location Name of General Contractor Check here if this is a final report Name of Contractor Filing Report Address Week Ending Report No Date Work Began Date work completed Employee Work Employer Contributions F G Name amp Address Classific B C D E A F C D Health amp Hourly Weekly Welfare Pension Total Wage Total prev wage Amount NOTE Every contractor and subcontractor is required to submit a copy of their weekly payroll records to University of Massachusetts Amherst Handwritten payroll records will not be accepted The undersigned states under the pains amp penalties of perjury that the above provided and attached information is a true and accurate record of each person employed on the project and the hours worked and wages paid to each such employee including payments to the referenced benefits M G L c 149 827B Authorized signature Print Name Print Title Mail to University of Massachusetts Amherst Purchasing Manager Administrative Services Physical Plant Building 360 Campus Center Way Amherst MA 01003 182 THE COMMONWEALTH OF MASSACHUSETTS EXECUTIVE OFFICE OF LABOR AND WORKFORCE DEVELOPMENT DEPARTMENT OF LABOR STANDARDS Prevailing Wage Rates D BAKER As determined by the Director under the provisions of the m M Overnor ecretary Massachusetts General Laws Chapter 149 Se
127. N 06 01 2015 835 05 87 30 1340 80 00 55 75 LABORERS FOUNDATION AND MARINE 12 01 2015 35 80 7 30 13 40 0 00 56 50 06 01 2016 36 55 7 30 13 40 0 00 57 25 12 01 2016 37 55 7 30 13 40 0 00 58 25 For apprentice rates see Apprentice LABORER CARBIDE CORE DRILL OPERATOR 06 01 2015 829 00 87 30 811 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 5 of 35 Supplemental Classification Effective Date Base Wage Health Pension Total Rate Unemployment CARPENTER 08 31 2015 32 39 8 55 14 38 80 00 55 32 CARPENTERS LOCAL 108 HAMPDEN HAMPSHIRE 02 29 2016 33 14 8 55 14 38 0 00 56 07 Apprentice CARPENTER Local 108 Hampden Hampshire Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 16 20 8 55 1 20 0 00 25 95 2 60 19 43 8 55 1 20 0 00 29 18 3 70 22 67 8 55 10 78 0 00 42 00 4 75 24 29 8 55 10 78 0 00 43 62 5 80 25 91 8 55 11 98 0 00 46 44 6 80 25 91 8 55 11 98 0 00 46 44 7 90 29 15 8 55 13 18 0 00 50 88 8 90 29 15 8 55 13 18 0 00 50 88 Effective Date 02 29 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 16 57 8 55
128. OMPRESSED AIR 12 01 2015 48 08 7 30 13 80 0 00 69 18 06 01 2016 48 83 7 30 13 80 0 00 69 93 12 01 2016 49 83 7 30 13 80 0 00 70 93 For apprentice rates see Apprentice LABORER TUNNEL WORK COMPRESSED AIR HAZ WASTE 06 01 2015 849 33 87 30 13 80 0 00 70 43 LABORERS COMPRESSED AIR 12 01 2015 50 08 7 30 13 80 0 00 71 18 06 01 2016 50 83 7 30 13 80 0 00 71 93 12 01 2016 51 83 7 30 13 80 0 00 72 93 For apprentice rates see Apprentice LABORER TUNNEL WORK FREE AIR 06 01 2015 839 40 730 13 80 0 00 60 50 LABORERS FREE AIR TUNNEL 12 01 2015 40 15 7 30 13 80 0 00 61 25 06 01 2016 40 90 7 30 13 80 0 00 62 00 12 01 2016 41 90 7 30 13 80 0 00 63 00 For apprentice rates see Apprentice LABORER TUNNEL WORK FREE AIR HAZ WASTE 06 01 2015 841 40 87 30 13 80 0 00 62 50 LABORERS FREE AIR TUNNEL 12 01 2015 42 15 7 30 13 80 0 00 63 25 06 01 2016 42 90 7 30 13 80 0 00 64 00 12 01 2016 43 90 7 30 13 80 0 00 65 00 For apprentice rates see Apprentice LABORER VAC HAUL 08 01 2015 31 94 81041 89 33 0 00 51 68 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 31 94 10 41 10 08 0 00 52 43 06 01 2016 32 44 10 41 10 08 0 00 52 93 08 01 2016 32 44 10 91 10 08 0 00 53 43 12 01 2016 32 44 10 91 10 89 0 00 54 24 WAGON DRILL OPERATOR 06 01 2015 829 00 87 30 811 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06
129. Owner insofar as practicable However variations within structure may occur by Owners removal and salvage operations prior to start of selective demolition work 2 remaining items that are scheduled to be removed shall be the property of the General Contractor and removed from the site Partial Demolition and Removal Items indicated to be removed but of salvageable value to Contractor may be removed as work progresses Transport salvaged items from site as they are removed 1 Storage sale of removed items on site will not be permitted 2 The University of Massachusetts Amherst has first right of refusal on all salvageable items of value and to have Contractor deliver such to a site on campus Protections Provide temporary barricades and other forms of protection as required to protect personnel and general public from injury due to selective demolition work SELECTIVE DEMOLITION 10 14 2015 024100 1 of 3 12 4 2012 rev 16 12 MULLINS SECURITY CAMERAS 1 Provide protective measures as required to provide free and safe passage of personnel and general public to and from occupied portions of the site 2 Provide interior and exterior shoring bracing or support to prevent movement work to remain Remove protections at completion of work 4 Provide and maintain watertight protection of all demolition work exposed to the weather Damages Promptly repair damages caused by demolition work at no cost to Own
130. PTACLES General Description 1 Straight blade feed through type Comply with NEMA WD 1 NEMA WD 6 UL 498 UL 943 Class A and FS W C 596 3 Include indicator light that shows when the GFCI has malfunctioned and no longer provides proper GFCI protection WALL PLATES Single and combination types shall match corresponding wiring devices Plate Securing Screws Metal with head color to match plate finish Material for Finished Spaces Stainless Steel Material for Unfinished Spaces Galvanized steel Material for Damp Locations Thermoplastic with spring loaded lift cover and listed and labeled for use in wet and damp locations eS Wet Location Weatherproof Cover Plates NEMA 250 complying with Type 3R weather resistant thermoplastic with lockable cover FINISHES Device Color 1 Wiring Devices Connected to Normal Power System Shall match device color in existing space Wall Plate Color Stainless Steel WIRING DEVICES 10 14 2015 262726 3 of 5 16 21 MULLINS SECURITY CAMERAS PART 3 EXECUTION 3 1 A INSTALLATION Comply with NECA 1 including mounting heights listed in that standard unless otherwise indicated Coordination with Other Trades 1 Protect installed devices and their boxes Do not place wall finish materials over device boxes and do not cut holes for boxes with routers that are guided by riding against outside of boxes 2 Keep outlet boxes free of plaster drywall join
131. Proceed The Contractor shall begin Work at the Site within ten days of said date unless otherwise ordered in writing by the Awarding Authority B Within ten days after the Work has commenced the Contractor shall submit to the Designer and to the Awarding Authority a progress schedule detailed and computer generated for the term of the Contract as required by the Contract Documents showing in detail his proposed progress for the construction of the various parts of the Work and the proposed times for receiving required materials Upon Approval by the Awarding Authority said schedule shall constitute the Progress Schedule The Contractor shall at the end of each month or more often if required furnish to the Designer and to the Awarding Authority a schedule meeting the requirements of the Specifications showing the actual progress of the parts of the Work in comparison with the Progress Schedule C Timeis of the essence of this Contract The Work shall be completed within the time specified in Article 2 of the Owner Contractor Agreement Should the Contractor require additional time to complete the Work the Contractor shall document the reasons therefore and submit a written request for an extension of time within 20 days of the occurrence of the event alleged to be the cause of the delay as provided in this Article and in Article VII of these General Conditions of the Contract Failure to submit said written request within the time required by
132. QUIREMENTS 10 14 2015 013300 6 of 8 12 4 2012 16 12 MULLINS SECURITY CAMERAS required to anticipate review time including time for possible rejection and resubmission in establishing Schedule dates a The aforementioned time provided the Designer for checking shop drawings is from the date of receipt of shop drawings by the Designer to the mailing date of shop drawings returned to the General Contractor by the Designer 5 The Designer will process the submission and indicate the appropriate action on the submission and the transmittal Incomplete or erroneous transmittals will be returned without action 6 The Designer will fill out transmittal in the following sequence Date received from General Contractor Date forwarded to UMA Project Manager Date received from UMA Project Manager Date returned to General Contractor Action taken on submission Distribution including number of copies distributed and type of material distributed i e print brochure or sample etc g Designer s remarks note major deviations from the Contract Documents Designer s Review Procedure 1 Stamped REVIEWED NO EXCEPTIONS TAKEN a No corrections or resubmissions required fabrication may proceed 2 Stamped REVIEWED MAKE CORRECTIONS NOTED a If General Contractor complies with noted corrections fabrication may proceed Submit corrected print for final review b If for any reason the
133. RER CARPENTER TENDER 06 01 2015 28 75 7 30 11 58 0 00 47 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 43 7 30 11 58 0 00 48 31 06 06 2016 30 12 7 30 11 58 0 00 49 00 12 05 2016 30 80 7 30 11 58 0 00 49 68 For apprentice rates see Apprentice LABORER LABORER CEMENT FINISHER TENDER 06 01 2015 29 00 7 30 11 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER LABORER HAZARDOUS WASTE ASBESTOS REMOVER 06 01 2015 828 85 730 11 58 0 00 47 73 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 53 7 30 11 58 0 00 48 41 For apprentice rates see Apprentice LABORER LABORER MASON TENDER 06 01 2015 829 75 87 30 811 58 0 00 48 63 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 30 43 7 30 11 58 0 00 49 31 06 06 2016 31 12 7 30 11 58 0 00 50 00 12 05 2016 31 80 7 30 11 58 0 00 50 68 For apprentice rates see Apprentice LABORER LABORER MASON TENDER HEAVY amp HIGHWAY 06 01 2015 28 74 7 30 10 18 0 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway LABORER MULTI TRADE TENDER
134. Subcontractors and suppliers to illustrate materials or equipment for some portion of the Work Product data also include any such information or instructions produced by the manufacturer or distributor of such materials or equipment and made readily available by said manufacturer or distributor Progress Schedule The progress schedule Approved by the Designer and the Awarding Authority in accordance with Article VI of these General Conditions of the Contract Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by the Owner or by separate contractors Project Manager The Awarding Authority s representative assigned to the Project Bill Lizotte 413 577 4768 Punch List A list of items determined by the Awarding Authority to be minor incomplete or unsatisfactory work items that do not materially impair the usefulness of the Work for its intended purpose Resident Engineer The on Site representative of the Awarding Authority Samples Samples are physical examples that illustrate materials equipment or workmanship and establish standards by which the Work will be judged Schedule of Values The schedule Approved by the Awarding Authority pursuant to Article VIII of these General Conditions of the Contract which allocates the Contract Price to the various portions of the Work and is used as a basis for payments to the Contractor
135. Support Systems Comply with MFMA 4 factory fabricated components for field assembly 1 Available Manufacturers Subject to compliance with requirements manufacturers offering products that may be incorporated into the Work include but are not limited to the following Allied Tube amp Conduit Cooper B Line Inc a division of Cooper Industries ERICO International Corporation GS Metals Corp Thomas amp Betts Corporation Unistrut Tyco International Ltd 2 Metallic Coatings Hot dip galvanized after fabrication and applied according to 4 3 Painted Coatings Manufacturer s standard painted coating applied according to MFMA 4 4 Channel Dimensions Selected for applicable load criteria B Conduit and Cable Support Devices Steel hangers clamps and associated fittings designed for types and sizes of raceway or cable to be supported C Support for Conductors in Vertical Conduit Factory fabricated assembly consisting of threaded body and insulating wedging plug or plugs for non armored electrical conductors or cables in riser conduits Plugs shall have number size and shape of conductor gripping pieces as required to suit individual conductors or cables supported Body shall be malleable iron D Structural Steel for Fabricated Supports and Restraints ASTM A 36 A 36M steel plates shapes and bars black and galvanized E Mounting Anchoring and Attachment Components Items for fast
136. TERMINATION OF THE CONTRACT p 147 1 Termination for Cause p 147 2 Termination for Convenience p 149 3 Contractor s Duties upon Termination for Convenience p 149 ARTICLE XVIII MISCELLANEOUS PROVISIONS p 149 No Assignment by Contractor p 149 Non Appropriation p 149 Claims by Others Not Valid p 150 No Personal Liability by Public Officials p 150 Severability p 150 Choice of Laws p 150 Standard Forms p 150 N O Im ge Msc Ee 89 8 No Waiver of Subsequent Breach p 150 9 Remedies Cumulative p 150 10 Notices p 151 APPENDIX A EQUAL EMPLOYMENT OPPORTUNITY NON DISCRIMINATION AND AFFIRMATIVE ACTION PROGRAM p 152 Compliance Generally p 152 Non Discrimination and Affirmative Action p 152 Liaison Committee Reports and Records p 153 Sanctions p 154 a wI APPENDIX B GOALS FOR PARTICIPATION BY MINORITY BUSINESS ENTERPRISES AND WOMEN BUSINESS ENTERPRISES EXECUTIVE ORDER 390 p 156 Goals p 156 M WBE Participation Credit p 156 Establishing M WBE Status p 157 Subcontractors With M WBES p 157 Performance of Contract Work by M WBES 157 Notification of Changes in M WBE Work p 157 Actions Required If There Is A Reduction in M WBE Participation p 158 Suspension of Payment and or Performance for Noncompliance 159 Liquidated Damages Termination p 159 10 Reporting Requirements p 159 11 Awardi
137. TION 013300 SUBMITTAL REQUIREMENTS 10 14 2015 013300 8 of 8 12 4 2012 rev 16 12 MULLINS SECURITY CAMERAS SECTION 014200 REFERENCES PART 1 GENERAL 1 1 1 2 A GENERAL PROVISIONS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications DEFINITIONS General Basic Contract definitions are included in the Conditions of the Contract including but not limited to the following 1 UMA 2 The Designer the Architect of Record or Engineer of Record as applicable 3 The UMA Project Manager 4 The UMA Resident Engineer 5 The General Contractor Reviewed When used to convey Designers action on General Contractor s submittals applications and requests reviewed is limited to Designer s duties and responsibilities as stated in the Conditions of the Contract Directed command or instruction by Designer Other terms including requested authorized selected approved required and permitted have the same meaning as directed Indicated Requirements expressed by graphic representations or in written form on Drawings in Specifications and in other Contract Documents Other terms including shown noted scheduled and specified have the same meaning as indicated Regulations Laws ordinances statutes and lawful orders issued by author
138. The Contractor shall make the repairs and or replacements listed within 30 days of the issuance of the Warranty Repair List unless otherwise agreed by the Awarding Authority in writing ARTICLE VII CHANGES IN THE WORK 1 Change Orders Generally A Nochanges in the Work shall be made in absence of a Change Order defined in Article of these General Conditions of the Contract directing the Contractor to perform such changes A request for a change in the provisions of this Contract may be submitted to the Awarding Authority by the Contractor Designer Project Manager Resident Engineer or User Agency The request must be made in writing and in accordance with the provisions of this Contract Laws and the procedures of the Awarding Authority B AChange Order may be issued by the Awarding Authority for changes in the Work within the scope of the Contract including but not limited to changes in 1 the Plans and Specifications 2 the method or manner of performance of the Work 3 the Owner furnished facilities equipment materials services or Site 4 the schedule for performance of the Work C The Contractor shall immediately perform any Change Order work that is ordered by the Awarding Authority D Whenever a Change Order is issued and said Change Order will cause a change in the Contractor s cost the Contractor or the Awarding Authority may request an equitable adjustment in the Contract Price A request for such an adjustment shal
139. UPDATE STATEMENT TO ALL SUB BIDDERS TRADE CONTRACTORS AND AWARDING AUTHORITIES A COMPLETED AND SIGNED SUB BIDDER UPDATE STATEMENT MUST BE SUBMITTED WITH EVERY FILED SUB BID PURSUANT TO M G L 149 44F AND EVERY TRADE SUB BID PURSUANT TO M G L c 149A ANY FILED SUB BID OR TRADE SUB BID SUBMITTED WITHOUT AN APPROPRIATE SUB BIDDER UPDATE STATEMENT IS INVALID AND MUST BE REJECTED Caution This form is to be used for submitting Filed Sub Bids and Trade Sub Bids It is not to be used for submitting Prime General Contract bids AWARDING AUTHORITIES If the Awarding Authority determines that the sub bidder is not competent to perform the work as specified on the project it should reject the bid SUB BIDDER S AFFIDAVIT swear under the pains and penalties of perjury that am duly authorized by the bidder named below to sign and submit this Sub bidder Update Statement on behalf of the bidder named below that have read this Sub bidder Update Statement and that all of the information provided by the bidder in this Sub bidder Update Statement is true accurate and complete as of the bid date Enter Bid Date Here Enter Name of Sub bidder or Contractor Bid Date Print Name of Sub bidder or Trade Contractor Project Number Enter Business Address Project Number or Business Address name if no number Awarding Authority Contractor s Telephone Number Awarding Authority Telephone Number SIGNATURED Bidder s Authorize
140. UTION 3 1 A B C APPLICATIONS Conductors Install stranded conductors for No 12 AWG and larger unless otherwise indicated Isolated Grounding Conductors Green colored insulation with continuous yellow stripe On feeders with isolated ground identify grounding conductor where visible to normal inspection with alternating bands of green and yellow tape with at least three bands of green and two bands of yellow Conductor Terminations and Connections GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 10 14 2015 260526 2 of 4 3 2 3 3 3 4 16 12 MULLINS SECURITY CAMERAS 1 Pipe and Equipment Grounding Conductor Terminations Bolted connectors 2 Underground Connections Welded connectors except at test wells and as otherwise indicated 3 Connections to Ground Rods at Test Wells Bolted connectors 4 Connections to Structural Steel Welded connectors GROUNDING AT THE SERVICE Equipment grounding conductors and grounding electrode conductors shall be connected to the ground bus Install a main bonding jumper between the neutral and ground buses EQUIPMENT GROUNDING Install insulated equipment grounding conductors with all feeders and branch circuits Install insulated equipment grounding conductors with the following items in addition to those required by the Massachusetts Electrical Code 1 Feeders and branch circuits 2 Lighting circuits 3 Receptacle circuits 4 Single phase motor and appli
141. Work 6 Lines Marks etc The Contractor shall furnish batter boards and stakes and shall cause to be placed and maintained thereon so as to be easily read such lines marks and directions relating to the Work as the Designer shall from time to time direct The Designer shall establish base lines and benchmarks on the Drawings for the locations of the Work but all other lines and grades shall be determined by the Contractor 100 7 Excavation The Contractor shall prevent by sheeting and shoring or bracing if necessary any caving or bulging of the sides of any excavation made by the Contractor leaving sheeting and shoring in place or if any is removed filling solid the spaces left thereby 8 Dewatering Hoisting Staging The Contractor shall provide pumping drainage and disposal of all water and other flows so that no puddle nuisance or damage will be caused by water or flooding The Contractor shall provide all hoisting equipment and machinery required for the proper execution of the Work The Contractor shall provide all exterior and interior staging required to be over eight feet in height except as may be otherwise provided in the Contract Documents 9 Corrections to the Work Inspection No Bar to Subsequent Corrections The Designer s inspection of the Work shall not relieve the Contractor of its responsibilities to fulfill the Contract obligations Defective work may be rejected by the Designer whether or not such work and
142. __ _ _________________ Purchaser CIcontractor J subcontractor Co G B ttn Address Date Vendor registration number if applicable E Contract subcontract number Contracl subcontract dale 2 Estimated of completion Spy ee M Part C To be completed by purchasing contractor or subcontractor claiming exemption See instructions claim the exemption corresponding to the box checked below and certify as follows check appropriate box below 1 Exemption under MGL Ch 64H sec 6 d or e Contractor as Agent of Exempt Entity certify that the purchaser is a contractor or subcontractor engaged in the performance of the above described contract and that the purchaser is acting as an agent of one the entities described below check appropriate box in purchasing tangible personal property other than building materials and supplies de scribed in MGL Ch 64H sec 6 f 0 Governmental body or agency described in MGL Ch 64H sec 6 d local public school city town government state agency etc Attach Form ST 2 Certificate of Exemption If Form ST 2 is not available enter agency s exemption number L Tax exempt organization under IRC Section 501 c 3 as described in MGL Ch 64H sec 6 e parochial school Scout troop PTO etc Attach Form ST 2 Certificate of Ex
143. able consideration paid by the University of Massachusetts Amherst and receipt thereof is hereby acknowledged do hereby grant sell transfer and deliver unto the said University of Massachusetts Amherst clear title to and beneficial ownership of the following goods and chattels namely as per attached bills belonging to us now on the job site in location Massachusetts or at which location has been agreed to in writing To have and to hold all and singular the said goods and chattels to the University of Massachusetts Amherst and to its own use and behoof forever And we hereby covenant and represent under pains and penalties of perjury that we are the lawful owner of the said goods and chattels and that they are free from all liens and encumbrances And the undersigned individual executing this document on behalf of the transferor represents and warrants that he or she is legally authorized to execute this document on behalf of said transferor In Witness whereof we the said hereunto set Contractor or Subcontractor s Firm Name our hand and seal this day of in the year two thousand and 193 Contractor or Subcontractor s Name By Title hereunto duly authorized UNIVERSITY OF MASSACHUSETTS AMHERST ss Then appeared the said to me known or proven to be the of and acknowledged the foregoing to be his free act and deed and the free act and deed of before me Notary Public My Commission Expires The G
144. abor and materials required for the completion of all work specified in Section No of the Specifications for Name of Sub trade and the Plans referred to therein and addenda No for the complete title of the project and project no taken from the title page of the Specifications 82 all as prepared by Name of Architect or Engineer for the sum of S and the Contractor agrees to pay the Subcontractor said sum for said work This price includes the following alternates and other items set forth in the sub bid Alternate No s j a The Subcontractor agrees to be bound to the Contractor by the terms of the hereinbefore described Plans Specifications including all general conditions stated herein and addenda No and and and to assume to the Contractor all the obligations and responsibilities that the Contractor by those documents assumes to the hereinafter called the Awarding Awarding Authority Authority except to the extent that provisions contained herein are by their terms or by law applicable only to the Contractor b The contractor agrees to be bound to the Subcontractor by the terms of the hereinbefore described documents and to assume to the Subcontractor all the obligations and responsibilities that the Awarding Authority by the terms of the hereinbefore described documents assumes to the Contractor except to the extent that provisions contained therein are by their terms or b
145. act is made as of the day of 20 by and between the Commonwealth of Massachusetts acting by and through the Awarding Authority identified above with a principal place of business at and with a principal place of business at J hereinafter called the Contractor Terms used in this Owner Contractor Agreement which are defined in the General Conditions of the Contract shall have the meanings designated therein The Awarding Authority and the Contractor agree as follows 64 Article 1 Scope of Work The Work under this Contract is defined as all work required by the Contract Documents for the construction of UMA Number Project Number in accordance with and as described in the Plans and Specifications dated 20 prepared by Designer as modified by Addenda Nos dated 20 Article 2 Time for Completion The Contractor shall commence the Work under this Contract on the date specified in the written Notice to Proceed and shall within days after such date bring the Work to Substantial Completion and to the point at which a Certificate of Agency Use and Occupancy may be issued and shall bring the Work to Final Acceptance within 30 days after the date specified for Substantial Completion Article 3 Contract Price The Awarding Authority shall pay the Contractor in current funds for the performance of the Work subject to additions and deductions by Approved Change Order s the Contract Price
146. act documents which must be submitted by the Contractor on a weekly basis contains a statement that the Form 1 9 process was faithfully completed for all employees listed on the weekly certified payroll report By the signature of the Contractor s Authorized Signatory on the I 9 Certificate the Contractor certifies under the pains and penalties of perjury that the Contractor shall not knowingly use undocumented workers in connection with the performance of this contract that pursuant to federal requirements the Contractor shall verify the immigration status of all workers assigned to the contract without engaging in unlawful discrimination and that the Contractor shall not knowingly or recklessly alter falsify or accept altered or falsified documents from any such worker The Contractor understands and agrees that breach of any of these terms during the period of a contract may be regarded as a material breach subjecting the Contractor to sanctions including but not limited to monetary penalties withholding of payments contract suspension or termination B Veterans Preference In the employment of mechanics and apprentices teamsters chauffeurs and laborers in the performance of Work in the Commonwealth preference shall first be given to citizens of the Commonwealth who have been residents of the Commonwealth for at least six months at the commencement of their employment and who are veterans as defined M G L c 4 s 7 34 and who are qua
147. act is executed in accordance with a prior approval of the University of Massachusetts Amherst and further certifies under the penalties of perjury that all the applicable provisions of M G L c 149 s 44J have been complied with Application of Executive Orders This agreement is funded by state appropriation and accordingly the University of Massachusetts is using the State Standard Contract terms and conditions for the purposes of this agreement Chapter 75 of the Massachusetts General Laws empowers the Board of Trustees of the University of Massachusetts with the authority to govern and manage its affairs without supervision or subject to the control of any other entity of the Commonwealth unless specifically set forth in the Massachusetts General Laws Therefore the provisions of the State Executive Orders included in this agreement are not applicable to the University of Massachusetts All Contracts By Name Title Vice Chancellor for Administration amp ___ Date 67 EXHIBIT A Additional Insurance Provisions Insert provision specifying deductible amounts if any 68 Exhibit B Forms Used During Contract Award and Execution Payment Bond Performance Bond Certificate of Corporate Vote Certificate of Joint Venture Certificate of Compliance with State Tax Laws Form for Subcontract 69 PAYMENT BOND Know all men by these presents that as principal and as surety are held and firmly bound u
148. actor Structural value or integrity of any element of the Project Integrity or effectiveness of weather exposed or moisture resistant elements or systems Efficiency operational life maintenance or safety of operational elements Visual qualities of sight exposed elements Request shall include a Identification of the Project b Description of affected work SUMMARY 10 14 2015 011000 12 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS The necessity for cutting alteration or excavation Effect on work of UMA or any separate General Contractor or on structural or weatherproof integrity of Project Description of proposed work Alternatives to cutting and patching Cost proposal when applicable Written permission of any separate General Contractor whose work will be affected Should conditions of Work or the schedule indicate a change of products from original installation General Contractor shall submit request for substitution Submit written notice to Designer designating date and time the work will be uncovered a minimum of three business days in advance 09 Performance Execute cutting and patching by methods which will prevent damage to other work and will provide proper surfaces to receive installation of repairs a In general where mechanical cutting is required cut work with sawing and grinding tools not with hammering and chopping tools Core drill openings through con
149. actor s proposal it shall promptly issue and NOI using the University of Massachusetts NOI form and forward the NOI to the Contractor with copies to the Designer and the Resident Engineer It is mandatory that upon receipt of said NOI the Contractor proceed with the order of work If the University of Massachusetts Amherst PM does not agree with the request for change or the Contractor s proposal it shall notify the requestor and all other parties in writing 173 SECTION 3 SUBMISSION AND DISPOSITION OF UNIVERSITY OF MASSACHUSETTS AMHERST FORM 5 UMA FORM 5 3 01 3 02 SHALL THE CONTRACTOR SHALL a Complete applicable portions of Section of Form 5 one 1 original green sheet unless otherwise instructed by the Awarding Authority b If there is sufficient room the space provided under section b of the Form 5 attach to the form a statement giving reasons for location of and a general description of the proposed change including a reference to the plans and specifications if possible c Submit proposed method of compensation as set forth in Article VII of the General Conditions of the Contract and in Section of the Form 5 Submit a cost breakdown with the requested change as outlined in Article VII of the General conditions of the Contract The breakdown of all filed sub contractors shall be separated from the General Contractor s breakdown and both are required to be on properly identifiable letterhead stationary a
150. ages During this one year guarantee period any corrective work shall be performed under all the applicable terms of this Contract and if Change Orders are issued in accordance with the terms of this Contract the Contractor shall be entitled to compensation for special insurance as required This one year guarantee shall not limit any express guaranty or warranty provided elsewhere in the Contract 2 Special Guarantees and Warrantees A The Contractor s obligation to correct Work as set forth in paragraph 1 above is in addition to and not in substitution of such guarantees or warranties as may be required in the various sections of the Specifications B Guarantees and warranties required in the various sections of the Specifications must be delivered to the Designer before final payment to the Contractor may be made or in the case of guarantees and warranties which originate with a subcontractor s section of the Work before final payment for the amount of that subtrade or for the phase of Work to which the guarantee or warranty relates C The failure to deliver a required guarantee or warranty shall constitute a failure to fully complete the Work in accordance with the Contract Documents ARTICLE X MISCELLANEOUS LEGAL REQUIREMENTS 1 Contractor to be Informed The Contractor shall inform itself of all existing and future Laws in any manner affecting those engaged or employed in the Work or the materials used or employed in the Work
151. aggers the receipt of invoices in the University of Massachusetts Amherst office and expedites processing contractor payments All invoices must include The Contractor s Name The UMA Contract Number The UMA Project Number The Project Name The Purchase Order Number Must clearly state that the invoice requisition is exactly that not a statement Invoice Number or Requisition Number Invoice Date Period for which the work was completed Schedule of Values Approved Original Signatures Notary GONE NRO 162 The General Contractor and his sub contractors the Designer and the Resident Engineer s and University of Massachusetts Amherst Project Manager s shall approve prior to the date of submission for each periodic payment request as to the percentage value of work completed All questions as to the value of the work performed and as to payment for materials not incorporated into the work should be resolved in advance of the submission of the formal request for periodic payment It is suggested that a job meeting conference is the most effective way of resolving any questions of matters of dispute The General Contractor shall submit to the Resident Engineer or in the absence of a Resident Engineer the University of Massachusetts Amherst Project Manager PM for the Resident Engineer s approval well in advance of the submission of the first periodic estimate a breakdown of the various items of work corresponding to th
152. al definitions of terms abbreviations and references refer to the Supplementary General Conditions or Specifications ARTICLE 11 EXECUTION OF THE CONTRACT SCOPE OF WORK INTERPRETATION OF CONTRACT DOCUMENTS 1 Execution The execution of the Owner Contractor Agreement by the Contractor is a representation that the Contractor has visited the Site has become familiar with local conditions under which the Work is to be performed and has correlated personal observations with requirements of the Contract Documents 2 Scope of Work The Work consists of the Work identified in the Contract Documents The Work comprises the completed construction required by the Contract Documents and includes all labor tools materials supplies equipment permits approvals paperwork calculations submittals and certificates necessary to develop construct and complete the Work in accordance with all Laws and all construction and other services required to be supervised overseen performed or furnished by Contractor or that the Contract Documents require the Contractor to cause to be 95 supervised overseen performed or furnished The Contractor shall provide and perform for the Contract Price all of the duties and obligations set forth in the Contract Documents 3 Interpretation A The Plans and Specifications and other Contract Documents are to be considered together and are intended to be mutually complementary so that any work shown on t
153. al completion estimate an amount equal to the sum of all demands for direct payments filed by subcontractors and not yet paid to subcontractors or deposit d in joint accounts pursuant to section thirty nine F but no contract subject to said section thirty nine F shall contain any other provision authorizing the awarding authority to deduct any amount by virtue of claims asserted against the Contract by subcontractors material suppliers or others If the awarding authority fails to prepare and send to the contractor any substantial completion estimate required by this section on or before the date herein above set forth the awarding authority shall pay to the contractor interest on the amount which would have been due to the 132 contractor pursuant to such substantial completion estimate at the rate of three percentage points above the rediscount rate then charged by the Federal Reserve Bank of Boston from such date to the date on which the awarding authority sends that substantial completion estimate to the contractor for acceptance or to the date of payment therefor whichever occurs first The awarding authority shall include the amount of such interest in the substantial completion estimate Within fifteen days after the effective date of the declaration of substantial completion the awarding authority shall send to the contractor by certified mail return receipt requested a complete list of all incomplete or unsatisfactory work items and
154. all be used except with the written permission of the Designer Should the Contractor fail to remove rejected material within a reasonable time the Designer and or Awarding Authority may in addition to any other available remedies remove and or replace the rejected material and to deduct the cost of such removal and or replacement from any moneys due or to become due the Contractor No extra time shall be allowed for completion of Work by reason of such rejection The inspection of the Work shall not relieve the Contractor of any of its obligations herein prescribed and any defective Work shall be corrected Work not conforming to the Contract Documents may be rejected notwithstanding that such Work and materials have been previously overlooked or misjudged by the Designer and accepted for payment If the Work or any part thereof shall be found defective at any time before Final Acceptance of the whole Work the Contractor shall forthwith make good such defect in a manner satisfactory to the Designer Nothing in the Contract shall be construed as vesting in the Contractor any property rights in the materials used after they have been attached or affixed to the Work or the Site but all such materials shall upon being so attached or affixed become a property of the Owner 112 ARTICLE VI PROSECUTION AND PROGRESS 1 Beginning Progress Schedule and Completion of Work A Contract time shall commence upon the date specified in the Notice to
155. ally scanned including the associated transmittals and where applicable the Designer of Record s and UMA s comments as a pdf document scanned approved submittals shall be included on a CD The electronic file names for each approved submittal shall contain the following information a For APPROVED or APPROVED AS NOTED Shop Drawings CONTRACT CLOSEOUT 10 14 2015 017700 7 of 9 4 5 2013rev 1 7 16 12 MULLINS SECURITY CAMERAS 1 Project Number Submittal s Date APPROVED Submittal Name Submittal s Specification Section Name and Number and Submittal s Revision Number 2 As an example the file name of an approved submittal for Concrete a Design Mix DFS991DC1 030106 APPROVED Concrete Design Mix Cast In Place Concrete 033000 Rev0 PDF b For Shop Drawings submitted for information only e g welders certificate the electronic file name shall contain the following information 1 Project Number Submittal s Date FORINFO Submittal Name Submittal s Specification Section Name and Number and Submittal s Revision Number 2 As an example the file name of a for information only submittal for a welder s certificate a DFS991DC1 030106 FOR INFO Welders Certificate Quality Requirements 014000 RevO PDF Unless otherwise stated all submitted documents shall include an electronic scanned image as noted above d The electronic file name shall be printed on every shop drawing page 14 The UMA Project Ma
156. alth approved by the United States Occupational Safety and Health Administration that is at least 10 hours in duration at the time the employee begins work and the Contractor and each of its subcontractors and others working on the Project shall furnish documentation of successful completion of said course by employees working with the first certified payroll report for each employee The 99 Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them Whenever the Designer shall notify the Contractor in writing that any worker is in the Designer s opinion incompetent unfaithful disorderly or otherwise unsatisfactory such employee shall be discharged from the Work and shall not again be employed on the Project except with the consent of the Designer B The Contractor shall employ a sufficient number of workers to carry on the Work with all proper speed in accordance with Laws the requirements of the Contract Documents and the Progress Schedule C The Contractor shall procure materials from such sources and shall manage its own forces and the forces of its Subcontractors and any sub subcontractors in such a manner as will result in harmonious labor relations on the Project Site If union and nonunion workers are employed to perform any part of the Work the Contractor shall establish and maintain separate entrances to the Site for the use of union and nonunion workers The Contractor shall cause pe
157. ame amp Address MBE or Describe MBE WBE Total Dollar WBE Scopes of Work Value of Participation _______ ___ ____ _ ________ B o E 7j p po T Eo o o o o JL JL d 0 mL o T 1 E S S 1 jJ 73 MBE Goal 5 Total Dollar Value of MBE Commitment 5 WBE Goal 5 Total Dollar Value of WBE Commitment 5 The undersigned hereby certifies that he she has read the terms and conditions of the contract with regard to MBE WBE participation and is authorized to bind the General Contractor to the commitment set forth above Name of General Contractor Business Address Name print Title Authorized Signature Telephone No Fax No Date 74 LETTER OF INTENT MINORITY WOMEN BUSINESS ENTERPRISES PARTICIPATION UNIVERSITY OF MASSACHUSETTS AMHERST be completed by MBE WBE and submitted by the General Bidder within five 5 working days of the opening of General Bids or by Filed Sub bidder with its bid UMANumber 16 12 indicate SOMWBA Certification Project oO MBE Project mwee Name of General Bidder Sub bidder 1 This firm intends to perform work in connection with the above project 2 This firm is currently certified by SOMWBA to perform the work identified below and has not changed its minority women ownership control or management without notifying SOMWBA within thirty 30 days of such a change 3 This firm understands th
158. ample is approved in writing by the Designer 7 Samples will not be returned unless return is requested at the time of submission The right is reserved to require submission of Samples whether or not specified in the Specifications at no additional cost to the Commonwealth Mock ups Erect at project site at location acceptable to Designer and the UMA Project Manager a mock up complete including work of all Subcontractors required in finished work GENERAL CONTRACTOR S RESPONSIBILITIES Review shop drawings Product Data and Samples prior to submission Verify Field measurements Field construction criteria Catalog numbers and similar data Conformance with Specifications Integration with adjoining work Delivery schedule Is the product an equal to the product specified or a substitution If either of these occur a comparison sheet must be submitted comparing the proposed product to the product specified SO ie ee All shop drawings prepared by Subcontractors shall be processed through the General Contractor The General Contractor shall check all the shop drawings for conformity with the Contract Documents and particularly for field measurements and proper fit with adjoining work prior to submitting same to the Designer for approval Certification shall appear on each shop drawing stating that the General Contractor has made his her check Format and content of the General Contractor s certification stamp shall be subject to
159. ance branch circuits 5 Three phase motor and appliance branch circuits 6 Flexible raceway runs 7 Metal clad cable runs INSTALLATION Grounding Conductors Route along shortest and straightest paths possible unless otherwise indicated or required by Code Avoid obstructing access or placing conductors where they may be subjected to strain impact or damage Bonding Straps and Jumpers Install in locations accessible for inspection and maintenance except where routed through short lengths of conduit 1 Bonding to Structure Bond straps directly to basic structure taking not to penetrate any adjacent parts 2 Bonding to Equipment Mounted on Vibration Isolation Hangers and Supports Install bonding so vibration is not transmitted to rigidly mounted equipment 3 Use exothermic welded connectors for outdoor locations if a disconnect type connection is required use a bolted clamp Grounding and Bonding for Piping 1 Metal Water Service Pipe Install insulated copper grounding conductors in conduit from building s main service equipment or grounding bus to main metal water service entrances to building Connect grounding conductors to main metal water service pipes use a bolted clamp connector or bolt a lug type connector to a pipe flange by using one of GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 10 14 2015 260526 3 of 4 3 5 16 12 MULLINS SECURITY CAMERAS the lug bolts of the flange Where a dielect
160. ance with M G L 23 ss 1 1E 11L All steps are six months 1000 hours Ratios are expressed in allowable number of apprentices to journeymen or fraction thereof unless otherwise specified Multiple ratios are listed in the comment field APP to JM 1 1 2 2 2 3 3 4 4 4 4 5 4 6 5 7 6 7 6 8 6 9 7 10 8 10 8 11 8 12 9 13 10 13 10 14 etc APP to JM 1 1 1 2 2 3 2 4 3 5 4 6 4 7 5 8 6 9 6 10 7 11 8 12 8 13 9 14 10 15 10 16 etc Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 35 of 35 Weekly Payroll Report Revised 10 01 WEEKLY PAYROLL RECORDS REPORT amp STATEMENT OF COMPLIANCE In accordance with Massachusetts General Law c149 section 27B a true and accurate record must be kept of all persons employed on the public works construction project for which the enclosed rates have been provided The Weekly Payroll Report Form includes all the information required to be kept by law Every contractor or subcontractor is required to keep these records and preserve them for a period of three years from the date of completion of the project In addition every contractor and subcontractor is required to submit a copy of their weekly payroll records to the awarding authority This is required to be done on a weekly basis Once collected the awarding authority is also required to preserve those records for three years In addition each such contractor subcontractor or public body shall fu
161. ance with the following sub paragraphs 1 and 2 below 1 Ifthe Contractor claims compensation for a change in the Work that is not deemed by the Project Manager to be a change or to warrant additional compensation as claimed by the Contractor the Contractor shall on or before the first working day following the commencement of any such work or the sustaining of any such damage submit to the Designer Resident Engineer and the Awarding Authority a written statement of the nature of such work or claim The Contractor shall not be entitled to additional compensation for any work performed or damage sustained for which written notice is not given within the time limit specified in the preceding sentence even though similar in character to work or damage with respect to which notice is timely given 2 On or before the second working day after the commencement of such work or the sustaining of such damage and daily thereafter the Contractor shall file to the extent possible with the Resident Engineer the Designer and the Awarding Authority itemized statements of the details and costs of such work performed or damage sustained The Contractor shall use the DCAM Daily Time and Materials Report found in DCAM Form 13 to record all labor and material used If the Contractor shall fail to make such statements to the extent possible then the Contractor shall not be entitled to additional compensation for any such work or damages 4 False Claims Statut
162. and disposal of health and safety materials Collection and disposal of contaminated disposable supplies shall be at no additional cost 1 25 LIST OF DRAWINGS A w 2 A m E 1 Arena Ground Floor Camera System E 2 Arena First Floor Camera System E 3 Practice Rink Ground Floor Camera System E 4 Practice Rink First Floor Camera System E 5 Camera System Schematic Schedules and Symbols SUMMARY 10 14 2015 011000 19 of 20 UMA 16 12 5 1 2015 rev MULLINS SECURITY CAMERAS PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION 011000 SUMMARY 10 14 2015 011000 20 of 20 16 12 12 4 2012 rev MULLINS SECURITY CAMERAS SECTION 013200 CONSTRUCTION PROGRESS DOCUMENTATION PART 1 GENERAL 1 1 GENERAL PROVISIONS A Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications 1 2 REQUIREMENTS INCLUDED A Procedures and requirements for submission and review of progress schedules and reports 1 3 RELATED SECTIONS A CONTRACT AND GENERAL CONDITIONS 1 Failure to complete the Work on time liquidated damages B Section 011000 SUMMARY 1 Project meetings C Section 013300 SUBMITTAL REQUIREMENTS 1 Project reports 2 Schedule of values 3 Shop drawings product data and samples D Section 015000 TEMPORARY FACILITIES AND CONTROLS 1 4 CONSTRUCTION SC
163. ange is an addition to the Contract Price it shall include the Contractor s overhead superintendence and profit On any change that involves a net credit no allowance for overhead superintendence and profits shall be included For any change that does not include labor performed or materials installed in the project there will be no markup for the Contractor s overhead superintendence and profit even though there may be a net increase 120 in the Contract Price Charges for small tools known as tools of the trade are not to be computed in the amount of any change in the Contract Price C Statutory Contract adjustments made under the provisions of M G L c 149 s 44F shall not be considered Change Orders and shall not entitle the Contractor to any adjustments for overhead profit and superintendence although the Awarding Authority may require that such Contract adjustments be processed on standard Change Order and equitable adjustment forms 3 Work Performed Under Protest The Contractor agrees to perform all Work as directed by the Awarding Authority and if the Project Manager determines that certain Work that the Contractor believes to be or to warrant a Change Order under this Article does not represent a change in the Work the Contractor shall perform said Work The Contractor shall be deemed to have concurred with the Project Manager s determination as aforesaid unless the Contractor shall perform Work under protest in compli
164. any party the court shall advance for speedy trial any petition filed as provided in this paragraph Sections fifty nine and fifty nine B of chapter two hundred thirty one shall apply to such petitions The court shall enter an interlocutory decree upon which execution shall issue for any part of a claim found due pursuant to sections fifty nine and fifty nine B and upon motion of any party shall advance for speedy trial the petition to collect the remainder of the claim Any party aggrieved by such interlocutory decree shall have the right to appeal therefrom as from a final decree The court shall not consolidate for trial the petition of any subcontractor with the petition of one or more subcontractors or the same general Contract unless the court finds that a substantial portion of the evidence of the same events during the course of construction other than the fact that the claims sought to be consolidated arise under the same general contract is applicable to the 131 petitions sought to be consolidated and that such consolidation will prevent unnecessary duplication of evidence A decree in any such proceeding shall not include interest on the disputed amount deposited in excess of the interest earned for the period of any such deposit No person except a subcontractor filing a demand for direct payment for which no funds due the general contractor are available for direct payment shall have a right to file a petition in court of equity against
165. argaining agreements or understandings between organized labor and employers shall be included for the purpose of establishing minimum wage rates as herein provided The aforesaid rates of wages in the schedule of wage rates shall include payments by employers to health and welfare plans pension plans and supplementary unemployment benefit plans as provided in said section twenty six and such payments shall be considered as payments to persons under this section performing work as herein provided Any employer engaged in the construction of such works who does not make payments to a health and welfare plan a pension plan and a supplementary unemployment benefit plan where such payments are included in said rates of wages shall pay the amount of said payments directly to each employee engaged in said construction 23 ATTACHMENT B Forms Used During Bidding Sample Certificate of Eligibility Prime Bidder Sample Certificate of Eligibility Sub Bidder Update Statement Prime Bidder Update Statement Sub Bidder Blanket Deposit Bond Form of General Bid Form of Sub Bid 24 25 26 SPECIAL NOTICE TO AWARDING AUTHORITY BIDDERS UPDATE STATEMENTS ARE NOT PUBLIC RECORDS AND ARE NOT OPEN TO PUBLIC INSPECTION M G L C 149 44D Effective March 30 2010 Commonwealth of Massachusetts Division of Capital Asset Management PRIME GENERAL CONTRACTOR UPDATE STATEMENT TO ALL BIDDERS AND AWARDING AUTHORITIES
166. articipation used to meet the project M WBE goals must be pre approved by the Director of Facilities Planning responsible for this project and a Revised M WBE Schedule of Participation will be required Contact the University of Massachusetts Amherst Facilities Planning Project Manager immediately if you anticipate or have had any changes in M WBE participation on this project WORK PERFORMED Include a brief description of the work performed by each subcontractor listed The description should match the M WBE Letter of Intent and approved Schedule of Participation M WBEs must be SOMWBA certified in the category of work performed on this project for firms used to meet the project M WBE goals SUBCONTRACT AMOUNT Include the contract or subcontract amounts listed on the M WBE Letters of Intent and approved Schedule of Participation If the value of a MBE WBE contract or subcontract has decreased or increased for any reason you must contact the University of Massachusetts Amherst Facilities Planning Project Manager responsible for this project immediately If additional M WBE firms not listed on the Schedule for Participation worked on this project list the amount of their subcontracts PAYMENTS THIS QUARTER Include the amount you paid the M WBE subcontractor either directly or indirectly for work performed on this project during the three month period covered by this Certification of Payment If the amount paid was zero please indicate that Do no
167. artment of Homeland Security Requirements in hiring any and all Employees to be employed in the Project who are required to be listed in the certified payroll reports for the Project Such compliance shall include but not be limited to the faithful completion of the Federal Department of Homeland Security Form 1 9 process by company for each of its Employees Company shall require each of its subcontractors to execute and provide to Company a Certificate of Compliance with Employment Eligibility Verification Requirements 1 9 Certificate with the execution of each subcontract and Company shall forward a copy of each such I 9 Certificate to the General Contractor for filing with the University of Massachusetts Amherst In addition Company is aware that the weekly workforce report form contained in the contract documents which must be submitted by the Company on a weekly basis contains a statement that the Form 1 9 process was faithfully completed for all employees listed on the weekly certified payroll report Company therefore acknowledges that the Company and all of its subcontractors will be required to certify that the Form 1 9 process was faithfully completed for all Employees listed on each certified payroll report when submitted By the signature of the Contractor s Authorized Signatory below the contractor certifies under the pains and penalties of perjury that the Contractor shall not knowingly use undocumented workers in connection with
168. ases shall be borne by the Contractor 105 15 Weather Protection M G L 149 s 44G and 44F 1 The Contractor shall furnish and install weather protection which means temporary protection of that Work adversely affected by moisture wind and cold Weather protection shall be achieved by covering enclosing and or heating working areas such that a minimum temperature of 40 degrees Fahrenheit is maintained at the working surface during the months of November through March in order to permit construction to be carried on during such period in accordance with the Progress Schedule After the building or portion thereof is completely enclosed by either permanent construction or substantial temporary materials having a resistance comparable to the specified permanent construction the Contractor shall provide heat therein of not less than 55 degrees F nor more than 75 degrees F The foregoing provisions do not supersede any specific requirements for methods of construction curing of materials and the like Such weather protection shall be consistent with the Progress Schedule shall permit the continuous progress of the Work necessary to maintain an orderly and efficient sequence of construction operations shall include one thermometer for every 2 000 square feet of floor space or fraction thereof shall be subject to the Approval of the Awarding Authority and shall meet such additional requirements as may be set forth in the Supplementary Genera
169. asked to complete any of your work under any contract Has a payment or performance bond been invoked against your current firm or has any officer principal or individual with a financial interest in your current firm been an officer principal or individual with a financial interest in another firm that had a payment or performance bond invoked Has your surety made payment to a materials supplier or other party under your payment bond on any contract Has any subcontractor filed a demand for direct payment with an awarding authority for a public project on any of your contracts Have any of your subcontractors or suppliers filed litigation to enforce a mechanic s lien against property in connection with work performed or materials supplied under any of your contracts 10 Have there been any deaths of an employee or others occurring in connection with any of your projects 11 Has any employee or other person suffered an injury in connection with any of your projects resulting in their inability to return to work for a period in excess of one year Division of Capital Asset Management Sub bidder Update Statement Effective March 30 2010 Page 7 of 10 46 PART 4 Legal or Administrative Proceedings Compliance with Laws Please answer the following questions Information is to cover all judicial and administrative proceedings involving bidder s firm which were instituted or concluded adversely or otherwise f
170. at as principal and as surety are held and firmly bound unto the University of Massachusetts Amherst in the sum of in lawful money of the United States of America to be paid to the University of Massachusetts Amherst for which payments well and truly to be made we bind ourselves our respective heirs executors administrators successors and assigns jointly and severally firmly by these presents Whereas the said principal has made a Contract with the University of Massachusetts Amherst Awarding Authority bearing date of 20 for construction of UMA Number Project Name Now the condition of this obligation is such that if the principal shall well and truly keep and perform all the undertakings covenants agreements terms and conditions of said Contract and any extensions thereof that may be granted by the University of Massachusetts Amherst with or without notice to the surety and during the life of any guarantee required under the Contract and shall also well and truly keep and perform all the undertakings covenants agreements terms and conditions of any and all duly authorized modifications alterations changes or additions to said Contract that may hereafter be made notice to the surety of such modifications alterations changes or additions being hereby waived then this obligation shall become null and void otherwise it shall remain in full force and virtue In the event that the Contract is abandoned b
171. at Draper Hall 545 2682 A Hot Works permit is not required for work performed outside unless it is in a temporary enclosure such as a tent Contractor must provide a minimum of one operable fire extinguisher approved by a recognized testing laboratory and rated for the intended purpose near each Hot Work operation At least one employee of the contractor shall remain on the site for one hour after the hot work has ceased to ensure against the outbreak of fire Use of Liquefied Propane Gas LPG and containers on site must be approved by and a permit must be secured through the local Fire Department Conformance to State Fire Prevention Regulations 527 CMR 6 and National Fire Protection Association standard on LPG NFPA 58 1998 Contractor must provide a minimum of one operable 20 BC rated fire extinguisher approved by a recognized testing laboratory near each LPG operation Use of torches or other flame producing devices for the removal of paint from buildings or the application or removal of roofing materials must conform with the State Fire Marshal s regulations 527 CMR 10 24 Permit must be secured through the local Fire Department and UMA EH amp S An approved and operable fire extinguisher must be kept in the work area At least one 1 workman must remain at the work area for 1 hour after the use of the torch or flame producing device has ceased Contractors performing work in buildings that will cause smoke or dust particles to
172. at if the General Bidder Sub bidder referenced above is awarded the contract the Bidder intends to enter into an agreement with this firm to perform the activity described below for the prices indicated This firm also understands that the above referenced firm as General Bidder Sub bidder will make substitutions only as allowed by Article XIII of the Contract 4 This firm understands that under the terms of Article XIII of the contract only work actually performed by an MBE WBE will be credited toward MBE WBE participation goals and this firm cannot assign or subcontract out any of its work without prior written approval of the DCAM Compliance Office and that any such assignment or subcontracting will not be credited toward MBE WBE participation goals 75 MBE WBE PARTICIPATION Section Item Number if applicable Describe MBE WBE Scopes of Work clarify Labor Only Material Only or Labor and Material If Supplier Indicate Total Value of Supplies 1096 of total counts toward Participation Dollar Value of Participation Name of MBE WBE Firm Authorized Signature Business Address Print Name Title Telephone No Date Letter of Intent Revised 10 01 Fax No 76 Total Dollar Value CERTIFICATE OF CORPORATE VOTE 20 hereby certify that am the clerk assistant clerk of the Corporation and that at a Name of Corporation duly authorized meeting of
173. ate 09 17 2015 Wage Request Number 20150917 043 Page 23 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice PILE DRIVER Local 56 Zone 3 Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 0 0 00 0 00 0 00 0 00 0 00 Notes Apprentice wages shall be no less than the following Steps Same as set in Zone 1 1 50 05 2 54 25 3 58 46 4 60 56 5 62 66 6 62 66 7 66 87 8 66 87 Apprentice to Journeyworker Ratio 1 3 PIPELAYER 06 01 2015 29 00 7 30 811 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER PIPELAYER HEAVY amp HIGHWAY 06 01 2015 28 14 87 30 10 18 80 00 46 22 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 24 7 30 10 18 0 00 46 72 06 01 2016 29 74 7 30 10 18 0 00 47 22 12 01 2016 30 49 7 30 10 18 0 00 47 97 For apprentice rates see Apprentice LABORER Heavy and Highway PLUMBER amp PIPEFITTER 09 17 2015 837 56 8830 1490 80 00 60 76 PLUMBERS amp PIPEFITTERS LOCAL 104 03 17 2016 38 56 8 30 14 90 0 00 61 76 Apprentice PLUMBER PIPEFITTER Local 104 Effective Date 09 17 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate
174. ated by him as the on Site equal employment opportunity officer shall recognize the Liaison Committee as an affirmative action body and shall establish a continuing working relationship with the Liaison Committee consulting with the Liaison Committee on all matters related to minority recruitment referral employment and training B The Contractor shall prepare projected staffing tables on a quarterly basis These shall be broken down into projections by week of workers required in each trade Copies shall be 153 furnished one week in advance of the commencement of the period covered and also when updated to the Awarding Authority and Liaison Committee The Contractor shall prepare weekly reports in a form approved by the Awarding Authority of hours worked in each trade by each employee identified as minority or non minority Copies of these shall be provided at the end of each such week to the Awarding Authority and to the Liaison Committee C Records of employment referral orders prepared by the Contractor shall be made available to the Awarding Authority and to the Liaison Committee on request D A designee of the Awarding Authority and a designee of the Liaison Committee shall each have right to access to the Site E The Contractor shall comply with the provisions of M G L c 151B as amended of the Massachusetts General Laws both of which are herein incorporated by reference and made a part of this Contract F The Contract
175. ation agreed upon in writing to which the contractor 133 has title or to which a subcontractor has title and has authorized the contractor to transfer title to the awarding authority upon certification by the contractor that he is the lawful owner and that the materials are free from all encumbrances The awarding authority shall include with each such payment interest on the amount due pursuant to such periodic estimate at the rate herein above provided from the due date In the case of periodic payments the contracting authority may deduct from its payment a retention based on its estimate of the fair value of its claims against the contractor a retention for direct payments to subcontractors based on demands for same in accordance with the provisions of section thirty nine F and a retention to secure satisfactory performance of the contractual work not exceeding five per cent of the approved amount of any periodic payment and the same right to retention shall apply to bonded subcontractors entitled to direct payment under section thirty nine F of chapter thirty provided that a five per cent value of all items that are planted in the ground shall be deducted from the periodic payments until final acceptance No periodic substantial completion or final estimate or acceptance or payment thereof shall bara contractor from reserving all rights to dispute the quantity and amount of or the failure of the awarding authority to approve a quantity an
176. ation that the work has been substantially completed or an itemized list of incomplete or unsatisfactory work items required by the contract sufficient to demonstrate that the work has not been substantially completed The awarding authority may include with such list a notice setting forth a reasonable time which shall not in any event be prior to the contract completion date within which the contractor must achieve substantial completion of the work In the event that the awarding authority fails to respond by presentation of a written declaration or itemized list as aforesaid to the contractor s certification within the twenty one day period the contractor s certification shall take effect as the awarding authority s declaration that the work has been substantially completed Within sixty five days after the effective date of a declaration of a substantial completion the awarding authority shall prepare and forthwith send to the contractor for acceptance a substantial completion estimate for the quantity and price of the work done and all but one percent retainage on that work including quantity price and all but one percent retainage for the undisputed part of each work item and extra work item in dispute but excluding the disputed part thereof less the estimated cost of completing all incomplete and unsatisfactory work items and less the total periodic payments made to date for the work The awarding authority also shall deduct from the substanti
177. atus agreed to and transmit back to the General Contractor for resubmission A copy of the transmittal indicating that a submittal was disapproved and returned to the General Contractor will be forwarded from the Designer to the UMA Project Manager with an additional copy forwarded from the Designer to the UMA Resident Engineer for their records 3 If a submittal is reviewed no exceptions taken reviewed make corrections noted by the Designer or approved as noted by the Designer but the UMA Project Manager does not concur a meeting between the Designer and the UMA Project Manager will immediately be established to resolve the impasse within the overall review period time frame 21 calendar days The UMA Project Manager will have final authority as to the disposition of the submission The Designer s position of approval or disapproval must be based on the contractual criteria of design intent function structure and durability The UMA Project Manager s contrary position must also be based on these criteria 4 The combined review period for the Designer and the UMA Project Manager will not exceed twenty one 21 calendar days from the established date of each submission indicated on the Schedule of Shop Drawings Product Data and Samples plus the additional time if any for distribution by the General Contractor and receipt of submissions by the Designer and UMA Project Manager The General Contractor is SUBMITTAL RE
178. ause its Subcontractors to comply with Massachusetts General Law c 149 s 27B which requires that a true and accurate record be kept of all persons employed on the a project for 136 which the prevailing wage rates have been provided The Contractor and all Subcontractors shall keep these records and preserve them for a period of three years from the date of completion of the Contract Such records shall be open to inspection by any authorized representative of the Owner at any reasonable time and as often as may be necessary The Contractor shall and shall cause its subcontractors to submit weekly copies of their weekly payroll records to the Awarding Authority In addition the Contractor and each Subcontractor shall furnish to the Executive Department of Labor within fifteen days after completion of its portion of the Work a signed statement in the form required by the Awarding Authority E Vehicle operators If the Director of the Department of Labor and Workforce Development has established a Schedule of wage rates to be paid to the operators of trucks vehicles or equipment for the Work the Contractor shall be obligated to pay such operators at least the minimum wage rate contained on such Schedule See M G L c 149 s 26 27H Eight Hour Day The Contractor shall comply with M G L 149 5 30 34 and 34A which provide that no laborer workman mechanic foreman or inspector working within the Commonwealth in the employ of the Co
179. awarding authorities and to pay no less than these rates to covered workers The annual update requirement is not applicable to 27F rental of equipment contracts Every contractor or subcontractor which performs construction work on the project is required to submit weekly payroll reports and a Statement of Compliance directly to the awarding authority by mail or email and keep them on file for three years Each weekly payroll report must contain the employee s name address occupational classification hours worked and wages paid Do not submit weekly payroll reports to DLS A sample of a payroll reporting form may be obtained at http www mass gov dols pw e Contractors with questions about the wage rates or classifications included on the wage schedule have an affirmative obligation to inquire with DLS at 617 626 6953 Employees not receiving the prevailing wage rate set forth on the wage schedule may report the violation to the Fair Labor Division of the office ofthe Attorney General at 617 727 3465 e Failure of a contractor or subcontractor to pay the prevailing wage rates listed on the wage schedule to all employees who perform construction work on the project is a violation of the law and subjects the contractor or subcontractor to civil and criminal penalties Issue Date 09 17 2015 Wage Request Number 20150917 043 Supplemental Classification Effective Date Base Wage Health Pension Total Rat
180. b Bidder Amount Bonds required indicated by Ves or No Total of Item 2 The undersigned agrees that each of the above named sub bidders will be used for the work indicated at the amount stated unless a substitution is made The undersigned further agrees to pay the premiums for the performance and payment bonds furnished by sub bidders as requested herein and that all of the cost of all such premiums is included in the amount set forth in Item 1 of this bid The undersigned agrees that if it is selected as general contractor it will promptly confer with the awarding authority on the question of sub bidders and that the awarding authority may substitute for any sub bid listed above a sub bid filed with the awarding authority by another sub bidder for the sub trade against whose standing and ability the undersigned makes no objection and that the undersigned will use all such finally selected sub bidders at the amounts named in their respective sub bids and be in every way as responsible for them and their work as if they had been originally named in this general bid the total contract price being adjusted to conform thereto E The undersigned agrees that if it is selected as general contractor it will within five days Saturdays Sundays and legal holidays excluded after presentation thereof by the awarding authority execute a contract in accordance with the terms of this bid and furnish a performance bond and also a labor and materials
181. bcontractor d Supplier e Manufacturer f Separate detailer when pertinent Identification of product or material Location of work and relation to adjacent structure or materials Field dimensions clearly identified as such Specification Section number and specific paragraph under which item is specified Submission number Applicable standards such as ASTM number A blank space five inch by four inch for the Designer s stamp General Contractor s remarks Identify exceptions or deviations from Contract Documents and reasons for them a If shop drawings submitted by the General Contractor indicate a departure from the Contract and the Designer deems it to be minor adjustment in the interest of UMA subject to concurrence by the General Contractor stating it does not involve a change in Contract Price or extension of time the Designer may approve the submission but the approval shall be subject to UMA review and acceptance of the Designer s recommendation b The approval of UMA shall be inferred to contain in substance the following The change is so ordered with the understanding that it does not involve any change in the Contract Price or Time and that it is subject generally to all contract stipulations and covenants and is without prejudice to any and all rights of UMA under the Contract General Contractors stamp initialed or signed certifying review and approval of submittal Any other items as called for by t
182. been brought concluded or settled relating to a violation of M G L Chapter 268A the State Ethics Law Division of Capital Asset Management Prime General Contractor Update Statement Effective March 30 2010 Page 10 of 12 PART 4 Legal or Administrative Proceedings Compliance with Laws continued YES NO 5 Have any judicial or administrative proceedings involving your firm or a principal or EL officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state or federal law regulating hours of labor unemployment compensation minimum wages prevailing wages overtime pay equal pay child labor or worker s compensation Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state or federal law prohibiting discrimination in employment Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a claim of repeated or aggravated violation of any state or federal law regulating labor relations Have any proceedings by a municipal state or federal agency been brought concluded or settled relating to decertification debarment or suspension of your firm or any principal or officer
183. by conduits 3 3 SLEEVE AND SLEEVE SEAL INSTALLATION FOR ELECTRICAL PENETRATIONS A Install sleeves and sleeve seals at penetrations of exterior floor and wall assemblies 3 4 FIRESTOPPING A Install firestopping at penetrations of fire rated floor and wall assemblies 35 PROTECTION A Protect coatings finishes and cabinets from damage and deterioration 1 Repair damage to galvanized finishes with zinc rich paint recommended by manufacturer 2 Repair damage to paint finishes with matching touchup coating recommended by manufacturer END OF SECTION 260533 RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 UMA16 12 MULLINS SECURITY CAMERAS 2 Install each expansion joint fitting with position mounting and piston setting selected according to manufacturer s written instructions for conditions at specific location at time of installation Install conduit supports to allow for expansion movement 260533 6 of 6 UMA16 12 MULLINS SECURITY CAMERAS SECTION 260553 IDENTIFICATION FOR ELECTRICAL SYSTEMS PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 A 1 2 1 3 1 4 w E m p 1 5 RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY Section Includes 1 Identification of power and control cables 2 Identification fo
184. ce coverage for the time periods provided in the Contract Documents and any other obligations which are intended to survive Final Acceptance and or the termination of the Contract General Bid The completed bid form submitted by the Contractor in accordance with the requirements of M G L c 149 Laws All applicable statutes regulations ordinances codes laws orders decrees approvals certificates and requirements of governmental and quasi governmental authorities Neutral An impartial third party not having an interest in the Owner the Designer the Contractor or the Project Notice to Proceed The written notice provided by the Awarding Authority to the Contractor which authorizes the Contractor to commence the Work as of a date specified therein from which date the time of completion specified in Article 2 of the Owner Contractor Agreement is measured Or equal or words of like import Equal in the opinion of the Awarding Authority determined pursuant to the provisions of M G L c 30 s 39M and the provisions of these General Conditions of the Contract 93 Owner The University of Massachusetts Amherst or other instrumentality that will own the Work including but not limited to the following UMBA and the Commonwealth Plan s Drawing s Product Data Product Data are illustrations standard schedules performance charts instructions brochures diagrams and other information furnished by the Contractor or its
185. ceiving the deposit The bank shall pay the amount in the account including accrued interest as provided in an agreement between the general contractor and the subcontractor or as determined by decree of a court of competent jurisdiction g All direct payments and all deductions from demands for direct payments deposited in an interest bearing account or accounts in a bank pursuant to subparagraph 6 shall be made out of amounts payable to the general contractor at the time of receipt of a demand for direct payment from a subcontractor and out of amounts which later become payable to the General contractor and in the order of receipt of such demands from subcontractors All direct payments shall discharge the obligation of the awarding authority to the general contractor to the extent of such payment h The awarding authority shall deduct from payments to a General contractor amounts which together with the deposits in interest bearing accounts pursuant to subparagraph 6 are sufficient to satisfy all unpaid balances of demands for direct payment received from subcontractors All such amounts shall be earmarked for such direct payments and the subcontractors shall have a right in such deductions prior to any claims against such amounts by creditors of the general contractor 130 i If the subcontractor does not receive payment as provided in subparagraph 1 or if the general contractor does not submit a periodic estimate for the value of th
186. ch M WBE Subcontractor which has executed a Letter of Intent Approved by the Awarding Authority ii cause its Subcontractors to execute a sub subcontract with each M WBE sub subcontractor and iii furnish the Awarding Authority with a signed copy of each such subcontract and sub subcontract 5 Performance of Contract Work by M WBEs A The Contractor shall not perform with its own organization or subcontract or assign to any other firm work designated to be performed by any W MBE in the Letters of Intent or Schedule of M WBE Participation without the prior Approval of the Awarding Authority nor shall any M WBE assign or subcontract to any other firm or permit any other firm to perform any of its M WBE Work without the prior Approval of the Awarding Authority Any such unapproved assignment subcontracting sub subcontracting or performances of M WBE Work by others shall be a change in the M WBE Work for the purposes of this Contract The Awarding Authority WILL NOT APPLY TO THE M WBE PARTICIPATION GOAL S ANY SUMS ATTRIBUTABLE TO SUCH UNAPPROVED ASSIGNMENTS SUB CONTRACTS SUB SUBCONTRACTS OR PERFORMANCE OF M WBE WORK BY OTHERS B The Contractor shall be responsible for monitoring the performance of M WBE Work to ensure that each scheduled M WBE performs its own M WBE Work with its own workforce C The Contractor and each M WBE shall provide the Awarding Authority with all information and documentation that the Awarding Authority determines i
187. ch end with identity number and location of other end of conductor and identify as spare conductor SLEEVE AND SLEEVE SEAL INSTALLATION FOR ELECTRICAL PENETRATIONS Install sleeves and sleeve seals at penetrations of exterior floor and wall assemblies LOW VOLTAGE ELECTRICAL CONDUCTORS AND CABLES 10 14 2015 260519 3 of 4 UMA 16 12 MULLINS SECURITY CAMERAS 3 7 FIRESTOPPING A Apply firestopping to electrical penetrations of fire rated floor and wall assemblies to restore original fire resistance rating of assembly 3 8 FIELD QUALITY CONTROL A Manufacturer s Field Service Engage a factory authorized service representative to test and inspect components assemblies and equipment installations including connections B Perform the following tests and inspections and prepare test written reports 1 After installing conductors and cables and before electrical circuitry has been energized test for compliance with requirements 2 Perform each visual and mechanical inspection and electrical test stated in NETA Acceptance Testing Specification Certify compliance with test parameters C Test and Inspection Reports Prepare a written report to record the following Submit to Project Manager upon request 1 Procedures used 2 Results that comply with requirements 3 Results that do not comply with requirements and corrective action taken to achieve compliance with requirements D Cables will be considered defective if they do
188. cluding list of spare parts b Name address and telephone number of Installer or supplier Maintenance procedures d Maintenance and service schedules for preventive and routine maintenance Maintenance record forms f Sources of spare parts and maintenance materials g Copies of maintenance service agreements h Copies of warranties and bonds 1 Name address and telephone numbers of repair and service companies for each of the systems installed 7 Names addresses and telephone numbers of all Subcontractors and suppliers together with repair and service companies for each of the major systems installed under this contract Non Availability of operating and maintenance manuals or inaccuracies therein may be grounds for cancellation and postponement of any scheduled final inspection by the UMA Project Manager until such time as the discrepancy has been corrected CONTRACT CLOSEOUT 10 14 2015 017700 3 of 9 4 5 2013rev 1 5 1 6 A UMA 16 12 MULLINS SECURITY CAMERAS DEMONSTRATION AND TRAINING Instruction Instruct University s personnel to adjust operate and maintain systems subsystems and equipment not part of a system 1 Provide instructors experienced in operation and maintenance procedures Provide instruction at mutually agreed on times For equipment that requires seasonal operation provide similar instruction at the start of each season Schedule training with Physical Plant per
189. completion until the date on which the awarding authority sends the final estimate to the contractor for acceptance or the date or payment therefore whichever occurs first provided that the awarding authority s inspection shows that no work items required by the contract remain incomplete or unsatisfactory Interest shall not be paid hereunder on amounts for which interest is required to be paid in connection with the substantial completion estimate as hereinabove provided The awarding authority shall include the amount of the interest required to be paid hereunder in the final estimate The awarding authority shall pay the amount due pursuant to any substantial completion or final estimate within thirty five days after receipt of written acceptance for such estimate from the contractor and shall pay interest on the amount due pursuant to such estimate at the rate hereinabove provided from that thirty fifth day to the date of payment Within 15 days 30 days in the case of the commonwealth after receipt from the contractor at the place designated by the awarding authority if such place is designated of a periodic estimate requesting payment of the amount due for the preceding periodic estimate period the awarding authority shall make a periodic payment to the contractor for the work performed during the preceding periodic estimate period and for the materials not incorporated in the work but delivered and suitably stored at the site or at some loc
190. controls Parking and construction limits Office work and storage areas Equipment deliveries and priorities SUMMARY 10 14 2015 011000 8 of 20 5 1 2015 rev 16 17 18 19 20 21 22 16 12 MULLINS SECURITY CAMERAS First aid Security Progress cleaning Working hours Emergency phone numbers Payment procedures and Schedule of Values Material deliveries Reporting Minutes of the meeting shall be prepared by the Designer or designated representative and shall be distributed to each party present The General Contractor shall be responsible for distributing the minutes to all Filed Sub Contractor 1 13 PROJECT MEETINGS A Project meetings shall be held on a regular basis and as required subject to the discretion of the UMA Project Manager Attendees In addition to the U M A Project Manager and Designer each contractor subcontractor supplier and other entity concerned with current progress or involved in planning coordination or performance of future activities shall be represented at these meetings All participants at the conference shall be familiar with Project and authorized to conclude matters relating to the Work Agenda Review and correct or approve minutes of previous progress meeting Review other items of significance that could affect progress Include topics for discussion as appropriate to status of Project Contractor s Construction Schedule Review progress since t
191. crete work Employ original installer or fabricator to perform cutting and patching for a Weather exposed or moisture resistant elements b Sight exposed finished surfaces Execute fitting and adjustment of products to provide a finished installation to comply with specified products functions tolerances and finishes Restore work which has been cut or removed install new products matching existing to provide completed Work in accordance with requirements of Contract Documents Fit work airtight to pipes sleeves ducts conduit and other penetrations through surfaces Patch with seams which are durable and as invisible as possible Flash and seal all penetration of exterior work Comply with specified tolerances for the work Restore exposed finishes of patched areas and where necessary extend finish restoration onto retained work adjoining in a manner which will eliminate evidence of patching a Where patch occurs in a smooth painted surface extend final paint coat over the entire unbroken surface containing the patch Refinish entire surfaces as necessary to provide an even finish to match adjacent finishes a For continuous surfaces refinish to nearest intersection b For an assembly refinish entire unit Existing Utilities Services Interruptions to critical existing utility services will not be allowed except as scheduled per Section 015000 Temporary Facilities and Controls The General Contractor shall not ob
192. ctions 26 to 27H ALLAND CHINE KARYN E POLITO Lt Governor Awarding Authority University of Massachusetts Amherst Contract Number 16 12 City Town AMHERST Description of Work Mullins Security Camera Works Job Location UMASS Amherst Information about Prevailing Wage Schedules for Awarding Authorities and Contractors This wage schedule applies only to the specific project referenced at the top of this page and uniquely identified by the Wage Request Number on all pages of this schedule An Awarding Authority must request an updated wage schedule from the Department of Labor Standards DLS if it has not opened bids or selected a contractor within 90 days of the date of issuance of the wage schedule For CM AT RISK projects bid pursuant to G L c 149A the earlier of a the execution date of the GMP Amendment or b the bid for the first construction scope of work must be within 90 days of the wage schedule issuance date wage schedule shall be incorporated in any advertisement or call for bids for the project as required by M G L 149 27 The wage schedule shall be made a part of the contract awarded for the project The wage schedule must be posted in a conspicuous place at the work site for the life of the project in accordance with M G L c 149 8 27 The wages listed on the wage schedule must be paid to employees performing construction work on the project whether they are employed by t
193. cumented increased costs for the general Bidder s bonds if any attributable to the incremental difference between the amount carried for the given sub trade and the actual subcontract amount 5 11 Overhead and profit for supervision of the sub trade mentioned in subsections 5 9 and 5 10 above shall be included by all general Bidders in Item 1 of the subdivision of the Contract Price No additional overhead or profit will be paid on the incremental difference between the amount carried for the sub trade and the subcontract amount as stated in M G L c 149 44F 4 a 2 5 12 Sub Bidders should not list Paragraph E sub subcontractors unless requested to do so by the Awarding Authority 5 13 Each general Bid and each Bid of a filed subcontractor must be accompanied by a bid deposit in the form of a bid bond a check certified by or a treasurer s or cashier s check issued by a responsible bank or trust company payable to the University of Massachusetts Amherst Any bid bond shall be a in a form satisfactory to the Awarding Authority b with a surety company qualified to do business in the Commonwealth and c conditioned upon the faithful performance by the principal of the agreements contained in the Bid 5 14 The amount of such bid deposit shall be 5 five per cent of the value of the Bid including alternates 14 SECTION 6 SUBMISSION OF BIDS 6 1 Each sub Bid including the bid deposit Sub Bidder Certificate of Eligibility and pr
194. curement Office Room 407 Goodell Building and copies may be obtained by depositing a company treasurer s cashier s or bank check in the sum of 50 00 per set payable to the University of Massachusetts A refund will be made to those returning the documents in satisfactory condition within 10 working days after the general bid opening Otherwise this deposit shall become the property of the University CLOSING Should the University of Massachusetts Amherst close the campus for any reason on the scheduled day of the bid opening the bid opening date will be extended to the next normal business day for the University at the same time same place It is the bidder s responsibility to verify by going to the University closing website at www umass edu closing or by public announcements 16 12 The filed sub trades for this project are as follows Section Filed Sub trade All Bid Deposits 5 of Bid Amount Sub bid forms pages 60 64 N A As used herein capitalized terms shall have the meaning assigned to them in the General Conditions of the Contract and the Owner Contractor Agreement unless the context clearly indicates otherwise 10 SECTION I BIDDER S REPRESENTATION 1 1 Each general bidder or sub bidder hereinafter sometimes referred to as Bidder by making a bid or sub bid hereinafter sometimes referred to as Bid represents and warrants that Bidder has visited the site and examined the Contract Documents that Bid
195. d The failure to include any items on such list does not alter the responsibility of the General Contractor to complete all work in accordance with contract Documents The General Contractor s list shall be accompanied with certificates that will be required as prerequisites for applying for a DPS inspection a NOTE Substantially Complete means that less than one percent 1 of all contract work including change orders remains to be done and that none of the remaining work will affect health safety or function Upon receipt of the General Contractor s list of items to be completed or corrected the Designer will promptly make a thorough inspection together with representatives of UMA and the Operating Agency and prepare a punch list setting forth in accurate detail any items on the General Contractor s list and additional items that are not CONTRACT CLOSEOUT 10 14 2015 017700 4 of 9 4 5 2013rev UMA 16 12 MULLINS SECURITY CAMERAS acceptable Concurrently the General Contractor will arrange for a DPS inspection Amherst Fire Department Town of Amherst Electrical and other required inspections through UMA EH amp S or as directed by UMA Project Manager When the punch list has been prepared and any DPS Inspector comments have been included the Designer will arrange a meeting with the General Contractor and Subcontractors and the UMA Project Manager to identify and explain all punch list items and answer questi
196. d shall be kept in the General Contractor s site office The General Contractor shall furnish and install all information required by the building official and shall secure the general building permit for the work promptly on award of the Contract The General Contractor shall conform to all conditions and requirements of the permit and code enforcement authority The General Contractor shall provide names and license numbers of its responsible representatives to complete the application for permit and shall receive the permit and promptly distribute copies to UMA and the Designer General Contractor and specialized Subcontractors as applicable shall identify all permits other than general building permit required from Authorities having jurisdiction over the Project for the construction and occupancy of the work The General Contractor shall prepare the necessary applications and submit required plans and documents to obtain such permits in a timely manner and shall furnish the required information to the Building Official and obtain the required permits as early as practicable after award of the Contract The General Contractor shall display all permit cards as required by the Authorities and shall deliver legible photocopies of all permits to UMA s Project Manager and the Designer promptly upon their receipt The General Contractor shall arrange for all inspections testing and approvals required for all permits and shall notify the Desig
197. d Representative Division of Capital Asset Management Edited by UMass Amherst 1 19 2011 Page 1 of 10 39 INSTRUCTIONS TO SUB BIDDERS e This form must be completed and submitted by all Filed Sub Bidders bidding on projects pursuant to M G L c 149 844F and Trade Contractors bidding on projects pursuant to M G L c 149A e You must give complete and accurate answers to all questions and provide all of the information requested MAKING A MATERIALLY FALSE STATEMENT IN THIS SUB BIDDER UPDATE STATEMENT IS GROUNDS FOR REJECTING YOUR BID AND FOR DEBARRING YOU FROM ALL PUBLIC CONTRACTING e Information is to cover the period from the date your most recent annual Sub bidder Certificate of Eligibility was issued not extended to the date of the bid e You must use this official form of Sub bidder Update Statement Copies of this form may be obtained from the awarding authority and from the DCAM Web Site www mass gov cam e If additional space is needed please copy the appropriate page of this Sub bidder Update Statement and attach it as an additional sheet INSTRUCTIONS TO AWARDING AUTHORITIES Determination of Sub Bidder Qualifications It is the awarding authority s responsibility to determine each responsible bidder You must consider all of the information in the bidder s Sub bidder Update Statement in making this determination Remember this information was not available to the Division of Capital Asset Management at the time
198. d amount of all or part of any work item or extra work item Substantial completion for the purposes of this section shall mean either that the work required by the contract has been completed except for work having a contract price of less than one percent of the then adjusted total contract price or substantially all of the work has been completed and opened to public use except for minor incomplete or unsatisfactory work items that do not materially impair the usefulness of the work required by the contract 8 Final Payment Release of Claims by Contractor Upon Final Acceptance of the Work the Contractor shall be entitled to payment of the balance of the Contract Price Final payment shall be as provided in this Article above and in accordance with any process set forth in the Supplementary General Conditions The Contractor agrees to execute a Certificate of Final Inspection Release with Contractor s own exceptions listed thereon and Acceptance as a condition precedent to Final Payment The acceptance by the Contractor of the Final Payment made as aforesaid or the execution of the Certificate of Final Acceptance by the Contractor shall constitute a release of the Owner the Awarding Authority the Designer and every member and agent of any of them from all claims of and liability to the Contractor for anything done or furnished for or relating to the Work or for any act or neglect of the Owner the Designer or of any person relating
199. d by the differing Site conditions A request for such an adjustment shall be in writing and shall be delivered by the party making such claim to the other party as soon as possible after such conditions are discovered Upon receipt of such a claim from a contractor or upon its own initiative the contracting authority shall make an investigation of such physical conditions and if they differ substantially or materially from those shown on the plans or indicated in the contract documents or from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the plans and contract documents and are of such a nature as to cause an increase or decrease in the cost of performance of the work or a change in the construction methods required for the performance of the work which results in an increase or decrease in the cost of the work the contracting authority shall make an equitable adjustment in the contract price and the contract shall be modified in writing accordingly C Timely Decision By Awarding Authority M G L 30 s 39P Every contract subject to section thirty nine M of this chapter or section forty four A of chapter one hundred forty nine which requires the awarding authority any official its architect or engineer to make a decision on interpretation of the specifications approval of equipment material or any other approval or progress of the work shall require that the decision be made
200. d equipment furnished shall be of current production by manufacturers regularly engaged in the manufacture of such items for which replacement parts shall be available When more than one unit of the same class of equipment is required such units shall be the product of a single manufacturer Equipment Assemblies and Components 1 Components of an assembled unit need not be products of the same manufacturer 2 Manufacturers of equipment assemblies which include components made by others shall assume complete responsibility for the final assembled unit 3 Components shall be compatible with each other and with the total assembly for the intended service 4 Constituent parts which are similar shall be the product of a single manufacturer Factory wiring shall be identified on the equipment being furnished and on all wiring diagrams When Factory Testing Is Specified ELECTRICAL WORK 10 14 2015 260001 3 of 5 2 13 2012rev UMA 16 12 MULLINS SECURITY CAMERAS 1 The University shall have the option of witnessing factory tests The contractor shall notify the University Project Manager a minimum of 15 working days prior to the manufacturers making the factory tests 2 Four copies of certified test reports containing all test data shall be furnished to the Project Engineer prior to final inspection and not more than 90 days after completion of the tests 3 When equipment fails to meet factory test and re inspection is
201. dder corporation __If so incorporated in what state President Secretary or Clerk Treasurer If Bidder is a foreign corporation is it registered to do business in Massachusetts If Bidder is a foreign corporation and is selected Bidder is required under M G L c 30 s 39L to obtain from the Massachusetts Secretary of State One Ashburton Place 17th floor a certificate stating that the corporation is registered to do business in Massachusetts and to furnish said certificate to the awarding authority prior to the award Is Bidder a general partnership or joint venture If so name each partner or venturer Is Bidder a limited partnership Is Bidder registered in Massachusetts If so name each general partner If Bidder is a foreign limited partnership and is selected Bidder is required under M G L c 30 s 39L to obtain from the Massachusetts Secretary of State One Ashburton Place 17th floor a certificate stating that the partnership is registered to do business in Massachusetts and to furnish said certificate to the awarding authority prior to the award For each general partner or venturer that is a corporation provide the following information use additional sheets if necessary Name of corporation State of incorporation President Secretary or Clerk 30 Treasurer Name of corporation State of incorporation President Secretary or Clerk Treasurer Is Bidder an individual Residence Address Name u
202. delay in the progress of the Work nor an undue accumulation of materials that are not to be used within a reasonable time and so that their security quality and fitness of the materials for the Work is preserved B Materials stored off Site shall be insured and stored at the expense of the Contractor so as to guarantee the preservation of their security quality and fitness for the Work Without derogating from the Contractor s responsibilities in the previous sentence when necessary to avoid deterioration or damage material on or off Site shall be placed on wooden platforms or other hard clean surfaces and not on the ground and shall be properly protected 111 C Expenses for inspection of material by the Designer and or the Awarding Authority personnel including travel quarters and subsistence shall be borne by the Contractor requesting the inspection of material stored outside the Commonwealth of Massachusetts as part of the Contract Price The policy of the Awarding Authority precludes the payment for material stored outside the boundaries of Massachusetts except in extremely limited circumstances with the express written consent of the Awarding Authority If the Contractor requests an inspection of material stored outside the Commonwealth of Massachusetts the Awarding Authority will initially pay for all expenses of inspecting the material incurred by the Designer and or Awarding Authority s personnel including travel quarters and sub
203. der is familiar with the local conditions under which the Work is to be performed that Bidder has correlated personal observations with the requirements of the Contract Documents and that where the Contract Documents require in any part of the Work a given result to be produced the Contract Documents are adequate and that Bidder will produce the required result within the Bid price and that the Bid is made in accordance therewith 1 2 Failure to so examine the Contract Documents and the Site will not relieve any Bidder from any obligation under the Bid as submitted Neither the University of Massachusetts nor the Designer will be responsible for errors omissions and or charges for extra work arising from Bidder s failure to familiarize itself with the Contract Documents or existing conditions SECTION 2 GENERAL BIDDERS CERTIFICATE OF ELIGIBILITY AND UPDATE STATEMENT 2 1 Every general Bidder must submit the following with its general Bid A current Certificate of Eligibility issued by the Division of Capital Asset Management and Maintenance DCAM DCAM Form CO 7 showing that the Bidder has been approved to bid on projects of the category of work required and that the Bidder has a single project limit in an amount no lower than the amount of its Bid including all add alternates A fully completed current Contractor Update Statement DCAM Form CQ3 2 2 It is the Bidder s responsibility to obtain the necessary forms from DCAM and to
204. der s submissions If the apparent low Bidder has not submitted an appropriate Schedule For M WBE Participation and appropriate Letters of Intent and SOMWBA certification letters establishing that the M WBE participation goal for the project will be met the apparent low Bidder will be considered ineligible for Award of the Contract and the Awarding Authority will Award the Contract to the second lowest Bidder subject to said Bidder s compliance with these conditions 8 7 The Bidder s attention is called to Article XIII of the General Conditions of the Contract which requires the Contractor to submit within 30 days of the Contract Date signed subcontracts with all subcontractors or a purchase order or invoice from each material supplier and or manufacturer listed on the Schedule For M WBE Participation 18 8 8 A filed sub Bidder is not required to submit a Schedule of M WBE Participation with its Bid A filed sub Bidder may at its option submit a Letter of Intent with its Bid if it is SOMWBA certified M WBE If a filed sub Bidder intends to sub subcontract work to a SOMWBA certified M WBE and the filed sub Bidder wishes that sub subcontract to be credited toward the participation goals for this Contract the filed sub Bidder should submit a Letter of Intent from that M WBE with its Bid A filed sub Bidder can subcontract out up to 2096 of its work to M WBESs unless such work is designated as sub sub contract Paragraph E work in the Bid Documen
205. develop with the participation of the Designer and the Awarding Authority the Punch List identifying those items of unfinished or unacceptable Work that remain to be performed or corrected under the Contract B Before the Work shall be deemed completed to the point where it is ready for the issuance of a Certificate of Agency Use and Occupancy the Contractor shall 1 Provide Contractor s proposed Punch List containing a statement of the reason for each item listed thereon 2 Advise the Awarding Authority of proposed changes in insurance in accordance with the provisions of this Contract and provide to the Awarding Authority evidence of Contractor s Completed Operations insurance coverage to the extent required by the Contract Documents 116 3 Execute and submit a notarized warranty on a form provided by the Awarding Authority meeting the requirements of Article IX of these General Conditions of the Contract to commence upon the date of the issuance of the Certificate of Agency Use and Occupancy for the Work or the designated portion thereof unless otherwise provided in the Certificate of Agency Use and Occupancy 4 Submit signed special warranties and warranties of longer than one year as required by the Contract Documents 5 Submit signed maintenance agreements for all portions of the Work specified to receive maintenance after the issuance of the Certificate of Agency Use and Occupancy 6 Submit all preliminary record Drawi
206. dstorm false work testing and startup temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements and shall cover reasonable compensation for Architect s and Contractor s services and expenses required as a result of such insured loss This policy and or installation floater shall indicate if Stored Materials coverage is provided as required below 144 C The Contractor shall maintain insurance on delivered and or stored material designated to be incorporated in the Work against fire theft or other hazards Any loss or damage of whatever nature to such material while stored at some approved off Site location shall be forthwith replaced by the Contractor at no expense to the Awarding Authority D The policy or policies shall specifically state that they are for the benefit of and payable to the Awarding Authority Owner the Contractor and all persons furnishing labor or labor and materials for the Contract Work as their interests may appear The policy or policies shall list the Awarding Authority Owner the Contractor and Subcontractors of any tier as named insured E Coverage shall include any costs for work performed by the Designer or any consultant as the result of a loss experienced during the term of this Contract F Coverage shall include temporary occupancy and waiver of subrogation and shall waive all rights of recovery by subrogation against the University of Massachu
207. dware information pertaining to system recording successes and failures and other related information The user shall have the ability to export the log information Be pre configured for fast and seamless integration within existing IT infrastructures The unit must offer the following network setup options The ability to throttle the bandwidth of the NVR to ensure that images and system messages are delivered as quickly as possible within the capabilities of the network s available bandwidth The ability to view the IP configuration of the NVR Include a System Log to record and display information pertaining to alarm events NVR reboots and other related information record display hardware information pertaining to system recording successes and failures and other related information The user shall have the ability to export the log information Include a video loss alarm function to allow an alarm event to occur when a camera loses the signal for any reason e g camera power failure cable being cut camera damage etc When a video loss event occurs the operator shall have the option to enable an alarm output Include Alarm Monitor software to stream video across a LAN to a client PC when an alarm is detected on the unit The operator shall have the ability to stop play forward and backward frame by frame or at real speed the video that streams across The program must constantly monitor for a signal from the NVR and when an alarm
208. e General Contractors or Subcontractors failure to familiarize themselves with the contract documents The General Contractor and Subcontractor acknowledge that they are familiar with the conditions and requirements of the contract documents where they require in any part of the work a given result to be produced and that the contract documents are adequate and will produce the required results SUMMARY 10 14 2015 011000 2 of 20 5 1 2015 rev 1 5 1 6 1 7 UMA 16 12 MULLINS SECURITY CAMERAS Contact The Designer will be present at the pre bid conference This will be the only time available for viewing the site any further questions preceding the submission of the bid shall be directed to Peter Royer by email procurement admin umass edu No questions from Bidders will be accepted within 5 days of the Bid opening Questions will be answered in the form of an addendum which will be posted to the Procurement website http www umass edu procurement constructionprojects htm Any information provided by other than the designated contact person identified above should be disregarded in the preparation of Bids CONTRACT METHOD A Work under this contract shall be lump sum price for the scopes of work as described in these specifications and shown on the Drawings WORK SEQUENCE A NS Dh E US The Work will be conducted in the following sequence of demolition construction Disconnect and remove existing camera syste
209. e Unemployment Construction 2 AXLE DRIVER EQUIPMENT 08 01 2015 31 65 1041 9 33 0 00 51 39 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 31 65 10 41 10 08 0 00 52 14 06 01 2016 32 15 10 41 10 08 0 00 52 64 08 01 2016 32 15 10 91 10 08 0 00 53 14 12 01 2016 32 15 10 91 10 89 0 00 53 95 3 AXLE DRIVER EQUIPMENT 08 01 2015 31 72 1041 9 33 0 00 51 46 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 31 72 10 41 10 08 0 00 52 21 06 01 2016 32 22 10 41 10 08 0 00 52 71 08 01 2016 32 22 10 91 10 08 0 00 53 21 12 01 2016 32 22 10 91 10 89 0 00 54 02 4 amp 5 AXLE DRIVER EQUIPMENT 08 01 2015 31 84 1041 9 33 0 00 51 58 TEAMSTERS JOINT COUNCIL NO 10 ZONE B 12 01 2015 31 84 10 41 10 08 0 00 52 33 06 01 2016 32 34 10 41 10 08 0 00 52 83 08 01 2016 32 34 10 91 10 08 0 00 53 33 12 01 2016 32 34 10 91 10 89 0 00 54 14 ADS SUBMERSIBLE PILOT 08 01 2015 90 51 9 80 18 17 0 00 118 48 PILE DRIVER LOCAL 56 ZONE 3 AIR TRACK OPERATOR 06 01 2015 29 50 87 30 11 58 80 00 48 38 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 30 18 7 30 11 58 0 00 49 06 06 06 2016 30 87 7 30 11 58 0 00 49 75 12 05 2016 31 55 7 30 11 58 0 00 50 43 For apprentice rates see Apprentice LABORER AIR TRACK OPERATOR HEAVY amp HIGHWAY 06 01 2015 29 24 7 30 10 18 0 00 46 72 LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 74 7 30 10 18 0 00 47 22 06 01 2016 30 24
210. e Contract assuming that the term Contractor refers to the sub bidder and that the term Contract Price refers to the sub bidder s price stated in paragraph 1 of the statutory form of Subcontract 18 Sales Tax Exemption and Other Taxes All building materials and supplies as well as the rental charges for construction vehicles equipment and machinery rented exclusively for use on the Site or while being used exclusively for the transportation of materials for the Work are entitled to an exemption from sales taxes under M G L c 64H s 6 f The Contractor shall take all action required to obtain the benefit of 106 such sales tax exemption under the University of Massachusetts Amherst Form ST 5C Contractor s Sales Tax Exemption Purchase Certificate E 043 167 352 The Contractor shall bear the cost of any sales taxes that Contractor incurs in connection with the Work and the Awarding Authority shall not reimburse the Contractor for any such taxes A copy of the Form ST 5C is provided with this contract 19 Final Cleaning At the completion of the Work the Contractor shall remove all waste materials rubbish tools equipment machinery and surplus materials and professionally clean all sight exposed surfaces so that the Work is clean and ready for occupancy Subsequent to installation of User Agency furniture telephones and equipment the Contractor shall provide such additional cleaning as may be necessary to remove any
211. e a diligent good faith effort to make up the shortfall in M WBE participation as follows 1 The Contractor shall identify all items of the Work remaining to be performed under the Contract that may be made available for subcontracting to W MBEs The Contractor shall send a list of such items of work to the Awarding Authority together with a list of the remaining items of the Work that was not made available to M WBEs and the reason for not making such work available for subcontracting to M WBEs 2 Contractor shall send written notices soliciting proposals to perform the items of the Work that may be made available for subcontracting to W MBEs to all W MBEs qualified to perform such work The Contractor shall advise the Awarding Authority of i each W MBE solicited and ii each W MBE listed in the SOMWBA directory under the applicable trade category who was not solicited and the reasons therefor The Contractor shall also advise the Awarding Authority of the dates notices were mailed and provide a copy of the written notice s sent 3 Contractor shall make reasonable efforts to follow up the written notices sent to M WBEs with telephone calls or personal visits in order to determine with certainty whether the M WBEs were interested in performing the work Phone logs or other documentation must be submitted to the Awarding Authority evidencing this effort 4 The Contractor shall make reasonable efforts to assist M WBEs that need
212. e and unsatisfactory items of work the subcontractor may demand direct payment of that balance from the awarding authority The demand shall be by a sworn statement delivered to or sent by certified mail to the awarding authority and a copy shall be delivered to or sent by certified mail to the general contractor at the same time The reply shall contain a detailed breakdown of the balance due under the subcontract and also a statement of 129 the status of completion of the subcontract work Any demand made after substantial completion of the subcontract work shall be valid even if delivered or mailed prior to the seventieth day after the subcontractor has substantially completed the subcontract work Within ten days after the subcontractor has delivered or so mailed the demand to the awarding authority and delivered or so mailed a copy to the general contractor the general contractor may reply to the demand The reply shall be by a sworn statement to or sent by certified mail to the awarding authority and a copy shall be delivered to or sent by certified mail to the subcontractor at the same time The reply shall contain a detailed breakdown of the balance due under the subcontract including any amount due for extra labor and materials furnished to the general contractor and of the amount due for each claim made by the general contractor against the subcontractor e Within fifteen days after receipt of the demand by the awarding authority but in n
213. e familiar with industry standards applicable to its construction activity Copies of applicable standards are not bound with the Contract Documents 1 Where copies of standards are needed to perform a required construction activity obtain copies directly from publication source and have available on site for reference ABBREVIATIONS AND ACRONYMS Industry Organizations Where abbreviations and acronyms are used in Specifications or other Contract Documents they shall mean the recognized name of the entities indicated in Gale Research s Encyclopedia of Associations or in Columbia Books National Trade amp Professional Associations of the U S AA Aluminum Association Inc The AAMA American Architectural Manufacturers Association AASHTO American Association of State Highway and Transportation Officials ABAA Air Barrier Association of America ACI ACI International American Concrete Institute AGC Associated General Contractors of America The AIA American Institute of Architects The AISC American Institute of Steel Construction AISI American Iron and Steel Institute ALSC American Lumber Standard Committee Incorporated AMCA Air Movement and Control Association International Inc ANSI American National Standards Institute APA APA The Engineered Wood Association ARMA Asphalt Roofing Manufacturers Association ASCE American Society of Civil Engineers ASHRAE American Society of Heating Refrigerating and Air Conditioning E
214. e labor or materials performed or furnished by the subcontractor and the subcontractor does not receive payment for same when due less the deductions provided for in subparagraph 1 the subcontractor may demand direct payment by following the procedure in subparagraph 4 and the general contractor may file a sworn reply as provided in that same subparagraph A demand made after the first day of the month following that for which the subcontractor performed or furnished the labor and materials for which the subcontractor seeks payment shall be valid even if delivered or mailed prior to the time payment was due on a periodic estimate from the general contractor Thereafter the awarding authority shall proceed as provided in subparagraph e f g and h 2 Any assignment by a subcontractor of the rights under this section to a surety company furnishing a bond under the provisions of section twenty nine of chapter one hundred forty nine shall be invalid The assignment and subrogation rights the surety to amounts included in a demand for direct payment which are in the possession of the awarding authority or which are on deposit pursuant to subparagraph 6 shall be subordinate to the rights of all subcontractors who are entitled to be paid under this section and who have not been paid in full 3 subcontractor as used in this section I for contracts awarded as provided in sections forty four A to forty four L inclusive of chapter one
215. e requested change is or is not covered under the contract d Review both quantities and prices of labor and materials and recommend corrections or changes Check to make sure the required breakdowns are attached from all sub contractors on properly identifiable letterhead e If any request is inaccurate incomplete contains insufficient credits due to the University of Massachusetts or is otherwise unacceptable the Resident Engineer shall note the return of the Form 5 in the record of NOIs Change Orders diary daily report and return the Form 5 to the General Contractor for correction unsigned by the Resident Engineer and detail the reasons for returning the Form 5 f Maintain accurate records indicating particulars involving additional work credit due substitutions delays work stoppage and other conditions associated with any potential or actual request for a change NOI or Change Order 174 3 03 3 04 g h If the Resident Engineer recommends approval of the Form 5 the Resident Engineer shall sign Section IIl of the Form 5 and attach a written statement addressing each of the eight 8 questions listed in the following section Section 3 03 If the Resident Engineer does not recommend approval of the request he or she shall attach a detailed letter setting forth the reasons for disapproval Forward the four 4 originals of Form 5 and two 2 copies without the Resident Engineer s signature on the form along with the
216. e sections of the specification making up the lump sum for item 1 Work of the General Contractor and each section under Item 2 Sub bids of the contract In addition the General Contractor and each sub contractor shall furnish the Resident Engineer with two 2 copies of any necessary sub breakdowns of each section and such other detailed information as required by the Resident Engineer to evaluate properly the percentage of the work performed The Resident Engineer shall submit one copy to the Division as approved by the Resident Engineer upon request The General Contractor shall prepare its formal request for periodic payment on the standard AIA form G702 1992 Application and Certificate for payment or other periodic payment form approved by the Awarding Authority The General Contractor shall prepare sufficient copies of the request for periodic payment for submission to the University of Massachusetts Amherst Project Manager To be distributed by the Awarding Authority as follows Original University of Massachusetts Amherst Accounts Payable Copy 1 Facilities Planning Copy 2 University of Massachusetts Amherst Project Manager Copy 3 Designer Copy 4 Resident Engineer Copy 5 Contractor Copy 6 7 Required on Federally Aided projects only IV CERTIFICATION The General Contractor shall sign all copies of the invoice requisition and present same to the University of Massachusetts Amherst Project Manager certifying the value of
217. e that each of the Subcontractors clean up during and immediately upon completion of their work Clean up includes the following tasks Remove all rubbish waste tools equipment appurtenances caused by and used in the execution of work Prevent the accumulation of debris at the construction site storage areas parking areas and along access roads and haul routes Provide containers for deposit of debris and schedule periodic collection and disposal of debris Prohibit overloading of trucks to prevent spillage on access and haul routes The General Contractor shall be responsible for proper disposal of all construction debris leaving the site 1 17 FIELD MEASUREMENTS A Although care has been taken to ensure their accuracy the dimensions shown for existing items and structures are not guaranteed It is the responsibility of the General Contractor to verify these dimensions in the field before fabricating any construction component No claims for extra payment due to incorrect dimensions will be considered by the Commonwealth 1 18 EMERGENCY PROCEDURES A The Contractor shall thoroughly familiarize himself review with U M A Project Manager amp S and Public Safety with U M A Emergency Procedures and inform all subcontractors of same Note that on campus Dialing 911 may reach Amherst Police or UMass Police depending on the phone used Therefore always identify your location as being as UMass Amherst includin
218. ealth and rated in Best s Insurance Guide or any successor thereto or replacement thereof as having a general policy holder rating of A or better and a financial rating of at least 9 or otherwise acceptable to the Awarding Authority C Contractor shall submit three originals of each certificate of insurance acceptable to the Awarding Authority simultaneously with the execution of this Contract Certificates shall show the Awarding Authority and the Owner as an additional insured as to all policies of liability insurance and shall state that Contractor has paid all premiums and that none of the coverage shall be cancelled terminated or materially modified unless and until 30 days prior notice is given in writing to the Awarding Authority The awarding authority is the University of Massachusetts and the owner is the University of Massachusetts Amherst or other instrumentality that will own the work including but not limited to the following UMBA and the Commonwealth Contractor shall submit updated certificates prior to the expiration of any of the policies referenced in the certificates so that the Awarding Authority shall at all time possess certificates indicating current coverage Certificates shall indicate that the contractual liability coverage and Contractor s Protective Liability coverage is in force Certificates shall include specific acknowledgment that the following coverage are included in the policies Contractual liability
219. east 51 of the Ownership interests of the Contractor or which directly or indirectly owns at least 51 of the Ownership interests of the Contractor K L Contractor s Agreements with Suppliers Anti Boycott Provisions 1 The Contractor shall not purchase or rent any materials equipment machinery vehicles or supplies for or in connection with the Work from any person or entity who does not sign under pains and penalties of perjury a certificate that recites The undersigned warrants represents and agrees that during the time its agreement with insert contractor s name is in effect for materials supplies or equipment to be used in connection with the insert the name of the Awarding Authority Project No insert project number neither the undersigned or any affiliated company as hereafter defined participates in or cooperates with an international boycott as defined in Section 999 b 3 and 4 of the Internal Revenue Code of 1954 as amended or engages in conduct declared to be unlawful by Section 2 of Chapter 151E of the Massachusetts General Laws As used herein an affiliated company shall be any business entity of which at least 51 of the ownership interests are directly or indirectly owned by the undersigned or by a person or persons or business entity or entities directly or indirectly owning at least 51 of the ownership interests of the undersigned or which directly or indirectly owns at least 51 of the ownership int
220. ection the word person shall mean any natural person joint venture partnership corporation or other business or legal entity 61 The undersigned further certifies under penalties of perjury that the said undersigned is not presently debarred from doing public construction work in the Commonwealth under the provisions of section twenty nine F of chapter twenty nine or any other applicable debarment provisions of any other chapter of the General Laws or any rule or regulation promulgated thereunder Date Name of Sub Bidder By Title and Name of Person Signing Bid Business Address Business Telephone No 62 BID PACKAGE PART Il OWNER CONTRACTOR AGREEMENT Owner Contractor Agreement Exhibit A Additional Insurance Requirements if any Exhibit B Forms Used During Contract Award and Execution Payment Bond Performance Bond Schedule for Participation by Minority Women Business Enterprises Letter of Intent Certificate of Corporate Vote Certificate of Joint Venture Certificate of Compliance with State Tax Laws Form of Subcontract Document ID EC IN MI RII ee Contractor s DCAM Certification Number Contractor s Vendor Code Number 63 UNIVERSITY OF MASACHUSETTS AMHERST STANDARD VERTICAL CONSTRUCTION CONTRACT For Projects Over 25 000 Subject to M G L 149 s 44A F OWNER CONTRACTOR AGREEMENT Awarding Authority Department Code This agreement Contr
221. ecution of the Contract The Contractor shall remain responsible for satisfactory performance of all Work sublet or assigned Consent of the Awarding Authority shall not be deemed to constitute a representation or waiver of any right hereunder by the Awarding Authority as to the qualifications or the responsibility of the Contractor or Subcontractor s 2 Non Appropriation If the Awarding Authority is unable to obtain an appropriation of funds sufficient to discharge its obligations under this Agreement for any fiscal year during the term of this Agreement the Awarding Authority shall not be obligated to make any further payments and this Agreement 149 may be terminated immediately by either the Awarding Authority or the Contractor provided that the Awarding Authority shall make payment to the Contractor for obligations incurred during the period for which funding was included in an annual or supplemental appropriation Delay by the General Court in enacting an annual or supplemental appropriation bill shall not be grounds for termination of this Agreement pursuant to this Section unless such annual or supplemental appropriation bill as enacted and signed by the Governor contains insufficient funding for obligations pursuant to this Agreement 3 Claims by Others Not Valid No person other than the Contractor shall acquire any interest in this Contract or claim against the Awarding Authority or Owner hereunder and no claim by any other pers
222. ed national origin age sexual orientation or sex and to eliminate and remedy any effects of such discrimination in the past Such affirmative action shall entail positive and aggressive measures to ensure equal opportunity in the areas of hiring upgrading demotion or transfer recruitment layoff or termination rate of compensation and in service or apprenticeship training programs This affirmative action shall include all action required to guarantee equal employment opportunity for all persons regardless of race color religious creed national origin age sexual orientation or sex A purpose of this provision is to ensure to the fullest extent possible an adequate supply of skilled tradesmen for future public construction projects D Ifthe Contractor shall use any subcontractor on any work performed under this Contract the Contractor shall take affirmative steps to negotiate with qualified minority and women subcontractors These affirmative steps shall cover both pre bid and post bid periods It shall include notification to the State Office of Minority and Women Business Assistance or its designee while bids are in preparation of all products work or services for which the Contractor intends to negotiate bids In all solicitations either by competitive bidding or negotiation made by the Contractor either for work to be performed under a subcontract or for the procurement of materials or equipment each potential subcontractor or suppl
223. ed and labeled as defined in NFPA 70 by a qualified testing agency and marked for intended location and application Surface Metal Raceways Galvanized steel with snap on covers complying with UL 5 Manufacturer s standard enamel finish in color selected by Architect 1 Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following Hubbell Incorporated Wiring Device Kellems RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 260533 2 of 6 2 3 A 16 12 MULLINS SECURITY CAMERAS b Panduit Corp Wiremold Legrand BOXES and ENCLOSURES Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following Cooper Technologies Company Cooper Crouse Hinds Hoffman a Pentair company Hubbell Incorporated Killark Division RACO a Hubbell Company Spring City Electrical Manufacturing Company Thomas amp Betts Corporation Wiremold Legrand SQN Goto General Requirements for Boxes Enclosures and Cabinets Boxes enclosures and cabinets installed in wet locations shall be listed for use in wet locations Sheet Metal Outlet and Device Boxes Comply with NEMA OS 1 and UL 514A Small Sheet Metal Pull and Junction Boxes NEMA OS 1 Cast M
224. ed in paragraph A above C The Contractor may include in a periodic estimate the value of materials or equipment delivered at the Site or at some location agreed to in writing only upon delivery to the Awarding Authority of 1 an acceptable transfer of title on the form provided by the Awarding Authority 2 written certification by the Contractor or applicable subcontractor on the form provided by the Awarding Authority that the Contractor or the Subcontractor which executed the transfer of title is the lawful owner and that the materials or equipment are free from all encumbrances accompanied by receipted invoices or other acceptable proof of prior payment for such materials 3 a stored materials insurance binder that covers the materials for which payment is requested that names the Owner as an insured party should the stored materials be subjected to any casualty loss or theft prior to their inclusion in the Work The material s or equipment must in the judgment of the Designer 1 meet the requirements of the Contract including prior shop drawing product data and sample approval 2 be ready for use and 3 be properly stored by the Contractor and be adequately protected until incorporated into the Work See also Article V 5 C of these General Conditions of the Contract concerning the cost of inspections D The Awarding Authority may make changes in any periodic estimate submitted by the Contractor in accordance with M G L c 30
225. ell Building Amherst MA 01003 and must be received on or before the date and time appointed as the deadline for the receipt of Bids 7 2 A Bidder may withdraw its Bid without penalty at any time up to the time of Award as defined below in subsection 9 1 only upon demonstrating to the satisfaction of the Awarding Authority that a death or disability has occurred or a bona fide clerical or mechanical error of a substantial nature was made during the preparation of the bid Failure to demonstrate conclusively that a bona fide clerical or mechanical error of a substantial nature was made may result in forfeiture of the Bid deposit 7 3 The Awarding Authority reserves the right to waive any informality in or to reject any and all Bids if it is in the public interest to do so Without limiting the foregoing the Awarding Authority reserves the right to reject unit prices which it deems unduly high or unduly low as unbalanced SECTION 8 MBE AND WBE PARTICIPATION 8 1 The apparent low Bidder s compliance with the requirements of this Section 8 is a prerequisite for receiving the Award of the Contract 8 2 The MBE and WBE participation goals for this Contract are as set forth on the first page of these Instructions to Bidders The Awarding Authority reserves the right to reduce or waive the MBE or WBE participation goals established for this Contract upon written request made by a general Bidder within the time frame set forth in Section 8 3 Such written
226. ementation of Contractor s Safety Plan referenced below and preventing accidents C The Contractor shall maintain an accurate record of exposure data on all accidents incident to the Work resulting in death traumatic injury occupational disease or damage to property materials supplies or equipment and shall report this data in the manner prescribed by 29 CFR Part 1904 Without limiting the foregoing the Contractor shall submit to the Awarding Authority without delay verbal and written reports of all accidents involving bodily injury or property damage arising in connection with the Work D In any emergency affecting the safety of persons or property the Contractor shall immediately act in the exercise of reasonable judgment to prevent threatened damage injury or loss The Contractor shall immediately notify the Awarding Authority of such emergency E The Contractor shall be responsible for its Subcontractors compliance with the provisions of this Section 14 F Before commencing any portion of the Work the Contractor shall submit a written Project specific plan for implementing this Section 14 The plan shall include an analysis of the significant hazards to life limb and property inherent in the performance of the Work and a plan for controlling these hazards G Without limiting the foregoing provisions of this Section 14 the Contractor shall comply with all health and safety Laws applicable to the Work Without limitation 1 I
227. emption If Form ST 2 is not available enter agency s exemption number To the best of my knowledge and belief the quantities of tangible personal property noted on the reverse side are exempt from the sales use tax under the provisions of MGL Ch 64 H sec 6 d or e as they are purchased by a purchaser acting as an agent for either a Massachusetts governmental body or for a tax exempt organization under IRC section 501 c 3 2 J Exemption under MGL Ch 64H sec 6 f Building Materials and Supplies certify that the purchaser is a contractor or subcon tractor engaged in the performance of a contract for the construction reconstruction alteration remodeling or repair of a building or structure for a governmental body or agency or for a certified IRC Section 501 c 3 exempt organization or other project described In MGL Ch 64H sec 6 the best of my knowledge and belief the described quantities of building materials and supplies noted on ihe reverse side are exempt from sales use tax under the provisions of MGL Ch 64H sec 6 f and the described quantities of these materials and supplies are being purchased for use exclusively in the above contract 3 Cl Exemption under MGL Ch 64H sec 6 tt Consulting Operating Contractor as Agent of Governmental Entity certify that the pur chaser is a consulting or operating contractor or subcontractor as defined in MGL Ch 64H sec 6 tt and that the purchaser is authorized and acting
228. ender the general Contractor liable to the Awarding Authority for the sum of any Bid deposit released by the Awarding Authority with respect to a filed sub Bidder that fails to execute its subcontract Any other documents that the Awarding Authority may reasonably require in connection with the Contractor s execution of the Contract 10 3 Please note that no part of the General Contractor s work may be subcontracted without the prior written approval of the Awarding Authority If the General Contractor desires to subcontract any part of the Work other than work covered by Item 2 filed sub Bidders the General Contractor must promptly forward to the Awarding Authority a list in triplicate designating the work to be performed and the name of each proposed subcontractor for approval by the Awarding Authority Approved subcontractors are eligible for direct payments under M GL 30 39F as amended Material suppliers not involving site labor need not be submitted for approval SECTION 11 RETURN OF BID DEPOSITS 11 1 All Bid deposits of general Bidders except those of the three 3 lowest responsible and eligible general Bidders shall be returned within five 5 days Saturdays Sundays and legal holidays excluded after the opening of the general Bids The Bid deposits of the three 3 lowest responsible and eligible general Bidders shall be returned upon the execution and delivery of the General Contractor if no award is made upon the expirat
229. eneral Contractor hereby certifies under penalties of perjury that the goods and chattels transferred above meet the requirements of the Plans and Specifications and will shortly be needed for the Work that the General Contractor can and will adequately protect them in accordance with the Contract Documents until they are incorporated in the Work that said goods and chattels are insured as required by the Contract Documents that acceptance of these goods and chattels by the University of Massachusetts Amherst shall not constitute a waiver of any claim arising out of the construction contract between the parties nor of any claims for breach of warranty express or implied or otherwise arising out of this sale that it is understood that the University of Massachusetts Amherst reserves the right to give notice of any of the aforesaid breaches at any time subsequent to said sale when said breach first appears to the University of Massachusetts Amherst In Witness whereof we the said hereunto set Contractor s Firm Name our hand and seal this day of in the year two thousand and Contractor s Name Name of Surety Company By Authorized Signature for Surety 194 Title hereunto duly authorized hereby certify under the penalties of perjury that the articles or services listed have been received and are in keeping with the specifications or are to be received in accordance with customary trade practices and are in good order except
230. ening electrical items or their supports to building surfaces include the following 1 Powder Actuated Fasteners Threaded steel stud for use in hardened portland cement concrete steel or wood with tension shear and pullout capacities appropriate for supported loads and building materials where used a Available Manufacturers Subject to compliance with requirements manufacturers offering products that may be incorporated into the Work include but are not limited to the following 1 Hilti Inc 2 ITW Ramset Red Head a division of Illinois Tool Works Inc 3 MKT Fastening LLC 4 Simpson Strong Tie Co Inc Masterset Fastening Systems Unit HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 10 14 2015 260529 2 of 4 16 12 MULLINS SECURITY CAMERAS 2 Concrete Inserts Steel or malleable iron slotted support system units similar to MSS Type 18 complying with MFMA 4 or MSS SP 58 3 Clamps for Attachment to Steel Structural Elements MSS SP 58 type suitable for attached structural element 4 Through Bolts Structural type hex head and high strength Comply with ASTM A 325 5 Toggle Bolts All steel springhead type 6 Hanger Rods Threaded steel 2 2 FABRICATED METAL EQUIPMENT SUPPORT ASSEMBLIES A Description Welded or bolted structural steel shapes shop fabricated to fit dimensions of supported equipment B Materials Comply with requirements in Section for steel shapes and plates PART 3 EXECUT
231. ental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 14 68 7 85 0 00 0 00 22 53 2 55 16 14 7 85 1 57 0 00 25 56 3 60 17 61 7 85 1 71 0 00 27 17 4 65 19 08 7 85 1 85 0 00 28 78 5 70 20 55 7 85 11 45 0 00 39 85 6 75 22 01 7 85 11 59 0 00 41 45 7 80 23 48 7 85 11 73 0 00 43 06 8 90 26 42 7 85 12 02 0 00 46 29 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 15 13 7 85 0 00 0 00 22 98 2 55 16 64 7 85 1 57 0 00 26 06 3 60 18 15 7 85 1 71 0 00 27 71 4 65 19 66 7 85 1 85 0 00 29 36 5 70 21 18 7 85 11 45 0 00 40 48 6 75 22 69 7 85 11 59 0 00 42 13 7 80 24 20 7 85 11 73 0 00 43 78 8 90 27 23 7 85 12 02 0 00 47 10 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 PAINTER TAPER BRUSH NEW 07 01 2015 30 63 7 85 12 30 0 00 50 78 If 30 or more of surfaces to be painted are new construction 12 30 0 00 NEW paint rate shall be used PAINTERS LOCAL 35 ZONE 3 0101 2016 3153 97 83 391 08 07 01 2016 32 38 7 85 12 30 0 00 52 53 01 01 2017 33 28 7 85 12 30 0 00 53 43 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 21 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice PAINTER Local 35 Zone 3 BRUSH NEW Effective Date 07 01 2015 Supp
232. enter into this Contract the Bid Pricing Materials for at least six years after the Awarding Authority makes final payment under this Contract 141 ARTICLE EQUAL EMPLOYMENT OPPORTUNITY NON DISCRIMINATION AND AFFIRMATIVE ACTION PROGRAM This Contract includes the provisions of the Awarding Authority s Equal Employment Opportunity Non Discrimination and Affirmative Action Program attached as Appendix to these General Conditions of the Contract and incorporated herein by reference ARTICLE XIII GOALS FOR PARTICIPATION BY MINORITY BUSINESS ENTERPRISES AND WOMEN BUSINESS ENTERPRISES This Contract includes the provisions of the Awarding Authority s program relating to Goals for Participation by Minority Business Enterprises and Women Business Enterprises attached as Appendix B to these General Conditions of the Contract and incorporated herein by reference ARTICLE XIV INSURANCE REQUIREMENTS 1 Insurance Generally A Contractor shall take out and maintain the insurance coverage listed in this Article with respect to the operations as well as the completed operations of this Contract This insurance shall be provided at the Contractor s expense and shall be in full force and effect for the full term of the Contract or for such longer period as this Article requires B All policies shall be written on an occurrence basis and be issued by companies authorized to write that type of insurance under the laws of the Commonw
233. eptance After the issuance of a Certificate of Agency Use and Occupancy for the entire Work and after the Contractor has completed all of the Work required by this Contract including Change Orders and Punch List Items the Contractor shall submit the following completed items to the Awarding Authority together with such additional items as may be specified in the Contract Documents 1 A completed Final Application for Payment showing a final accounting of all changes in the Work on the form provided by the Awarding Authority 2 Certification and satisfactory evidence that all taxes fees and similar obligations have been paid 3 Consent of the Surety to Final Payment executed by applicable bonding companies 4 Certified copy of the Punch List stating that the Contractor has completed or corrected every item listed 5 Evidence of Contractor s continuing Completed Operations Insurance coverage to the extent required by the Contract Documents 6 All final record Drawings and documents in the forms specified by the Contract Documents 7 A notarized certification that all purchases made under the tax exemption certificate were legitimate and entitled to exemption 8 Written certifications from the Department of Public Safety or if the Awarding Authority is a municipality the building department having jurisdiction and the Designer to the effect that a the Work has been inspected for compliance with the Contract Documents and
234. er Traffic Conduct selective demolition operations and debris removal in a manner to ensure minimum interference with roads streets walks and other adjacent occupied or used facilities 1 Do not close block or otherwise obstruct streets walks or other occupied used facilities without written permission from authorities having jurisdiction Provide alternate routes around closed or obstructed traffic ways if required by governing regulations PART 2 PRODUCTS Not Applicable PART 3 EXECUTION 3 01 A 3 02 3 03 INSPECTION Prior to commencement of selective demolition work inspect areas in which work will be performed Photograph existing conditions and equipment which could be misconstrued as damage resulting from selective demolition work file with Owner s Representative prior to starting demolition or other work DEMOLITION Perform selective demolition work in a systematic manner Use such methods as required to complete work indicated on Drawings in accordance with demolition schedule and governing regulations If unanticipated mechanical electrical or structural elements which conflict with intended function or design and encountered investigate and measure both nature and extent of the conflict Submit report to Owner s Representative in written accurate detail Pending receipt of directive from Owner s Representative rearrange selective demolition schedule as necessary to continue overall job prog
235. er Contractor Agreement B The Contractor and all Subcontractors sub subcontractors and materials suppliers shall comply with all of the terms and conditions of this Article which include the provisions pertaining to M WBE participation set forth in the Owner Contractor Agreement in order to meet the M WBE participation goals established for this Contract 2 M WBE Participation Credit A Ifthe Contractor is itself an MBE or WBE M WBE participation credit shall be given in an amount equal to the entire Contract Price If the Contractor is not an MBE or WBE then M WBE participation credit will be given for the value of the Work that is actually performed by each MBE or WBE subcontractor or sub subcontractor B Ifthe Contractor is a joint venture with one or more M WBE joint ventures M WBE participation credit shall be given to the joint venture as follows 1 Ifthe joint venture is certified by SOMBWA as an MBE or WBE M WBE participation credit shall be given in an amount equal to the entire Contract Price 2 Ifthe joint venture is not certified as an MBE or WBE by SOMWBA M WBE participation credit shall be given to the joint venture for the value of the Work that is performed by the M WBE joint ventures and for the value of the Work that is actually performed by each MBE or WBE subcontractor or sub subcontractor C Ifan M WBE supplies but does not install equipment or materials M WBE participation credit shall be given only
236. er Stored Materials A The Contractor shall provide coverage against loss or damage on all Work included in this Contract in an amount equal to the Contract Price Such coverage shall be written on an all risks basis or equivalent form and shall include without limitation insurance against perils of fire with extended coverage and physical loss or damage including without duplication of coverage theft vandalism malicious mischief collapse earthquake flood if the project is not in an A or a V flood Zone windstorm false work testing and startup temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements and shall cover reasonable compensation for Architect s and Contractor s services and expenses required as a result of such insured loss This policy and or installation floater shall indicate if Stored Materials coverage is provided as required below B When Work will be completed on existing buildings owned by the Owner the Contractor shall provide an installation floater in the full amount of the Contract Price Such coverage shall be written on an all risks basis or equivalent form and shall include without limitation insurance against perils of fire with extended coverage and physical loss or damage including without duplication of coverage theft vandalism malicious mischief collapse earthquake flood if the project is not in an A or a V flood Zone win
237. eral contractor shall forthwith pay to the subcontractor the full amount received from the awarding authority less any amount specified in any court proceedings barring such payment and also less any amount claimed due from the subcontractor by the general contractor c Each payment made by the awarding authority to the general contractor pursuant to subparagraphs a and b of this paragraph for the labor performed and the materials furnished by a subcontractor shall be made to the general contractor for the account of that subcontractor and the awarding authority shall take reasonable steps to compel the general contractor to make each such payment to each such subcontractor If the awarding authority has received a demand for direct payment from a subcontractor for any amount which has already been included in a payment to the general contractor or which is to be included payment to the general contractor for payment to the subcontractor as provided in subparagraphs 1 and 2 the awarding authority shall act upon the demand as provided in this section d If within seventy days after the subcontractor has substantially completed the subcontract work the subcontractor has not received from the general contractor the balance due under the subcontract including any amount due for extra labor and materials furnished to the general contractor less any amount retained by the awarding authority as the estimated cost of completing the incomplet
238. erests of the undersigned 2 The Awarding Authority shall not be obligated to pay the Contractor for the cost of any materials supplies or equipment purchased or rented from any individual or entity from whom the Contractor has not previously obtained and delivered to the Awarding Authority the certificate that the previous paragraph requires The Contractor will immediately terminate its contract with any supplier who breaches the warranty representation and agreement contained in the previous paragraph 3 The Contractor shall include in the Contractor s agreement with any person or entity from whom the Contractor intends to purchase or rent any materials equipment machinery vehicles or supplies for or in connection with the Work a a notice that this Contract obligates the Contractor to terminate the supply contract upon discovery of such breach of the sworn certificate delivered under subparagraph 1 and such termination shall be without liability to the Contractor or the Awarding Authority and b a provision which states The Governor or his designee the secretary of administration and finance and the state auditor or his designee shall have the right at reasonable times and upon reasonable notice to examine the books records and other compilations of the undersigned vendor which pertain to the performance and requirements of this agreement to provide materials of any nature to the undersigned contractor in connection with State Pro
239. es Where abbreviations and acronyms are used in Specifications or other Contract Documents they shall mean the recognized name of current edition of Codes in the Commonwealth of Massachusetts PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION 014200 REFERENCES 10 14 2015 014200 4 of 4 12 4 2012 rev 1 1 1 2 1 3 1 4 16 12 MULLINS SECURITY CAMERAS SECTION 015000 TEMPORARY FACILITIES AND CONTROLS GENERAL PROVISIONS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications REQUIREMENTS INCLUDED Temporary Facilities and Controls including the following 1 Maintenance of Access 2 Dust Control 3 Noise Control 4 Indoor Air Quality TAQ Management 5 Cleaning During Construction 6 Parking 7 Debris Control and Removal 8 Safety Protection 9 Shut Down Notice MAINTENANCE OF ACCESS The General Contractor shall provide and maintain for the duration of his contract a means of access to around and within the site as indicated on the Contract Drawings for vehicular traffic and authorized personnel This means of access shall be construed to sustain the weight of equipment customarily engaged for use in construction projects of this type and magnitude The General Contractor shall without additional compensation from the Commonwealth f
240. essary cutting coring drilling grouting and patching required to fit together the several parts of the Work shall be done by the Contractor except as may be specifically noted otherwise under any particular filed sub bid section of the Specifications D The Contractor shall be responsible to the Awarding Authority for the acts and omissions of the Contractor s employees agents and Subcontractors and their agents and respective contractors employees and other persons performing portions of the Work or supplying materials therefore E The Contractor shall be responsible for the inspection of portions of the Work already performed under this Contract to determine that such portions are in proper condition to receive subsequent Work Contractor shall employ a registered land surveyor to perform any engineering required for establishing grades lines levels dimensions layouts and reference points for the trades The Contractor shall be responsible for maintaining benchmarks and other survey marks and shall replace any benchmarks or survey marks that may have become disturbed or destroyed The Contractor shall verify the materials shown on the Drawings before laying out the Work and shall be responsible for any error resulting from its failure to exercise this precaution 98 G Unless otherwise required by the Supplementary General Conditions or the Plans and Specifications or directed in writing by the Designer Work shall be pe
241. etal Access Pull and Junction Boxes Comply with NEMA FB 1 and UL 1773 galvanized cast iron with gasketed cover Box extensions used to accommodate new building finishes shall be of same material as recessed box Hinged Cover Enclosures Comply with UL 50 and NEMA 250 Type 1 with continuous hinge cover with flush latch unless otherwise indicated 1 Metal Enclosures Steel finished inside and out with manufacturer s standard enamel 2 Interior Panels Steel all sides finished with manufacturer s standard enamel PART 3 EXECUTION 3 1 A RACEWAY APPLICATION Indoors Apply raceway products as specified below unless otherwise indicated Exposed in mechanical spaces Not Subject to Physical Damage EMT Exposed and Subject to Severe Physical Damage GRC Concealed in Ceilings and Interior Walls and Partitions EMT Connection to Vibrating Equipment Including Transformers and Hydraulic Pneumatic Electric Solenoid or Motor Driven Equipment FMC except use LFMC in damp or wet locations Toup RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 260533 3 of 6 3 2 UMA16 12 MULLINS SECURITY CAMERAS 5 Boxes and Enclosures NEMA 250 Type 1 Minimum Raceway Size 3 4 inch trade size Raceway Fittings Compatible with raceways and suitable for use and location 1 Rigid and Intermediate Steel Conduit Use threaded rigid steel conduit fittings unless otherwise indicated Comply with NEMA FB 2 10 2 EMT Use s
242. etnam era veterans or background Executive Order 478 is herein incorporated by reference and made a part of this Contract Pursuant to Executive Order 478 the Contractor and any subcontractors may not engage in discriminatory employment practices and the Contractor must certify that it is in compliance with all applicable federal and state laws rules and regulations governing fair labor and employment practices and commit to purchasing supplies and services from certified minority or women owned businesses small businesses or businesses owned by socially or economically disadvantaged persons or persons with disabilities These provisions shall be enforced through the contracting agency the Operational Services Division and or the Massachusetts Commission Against Discrimination Any breach shall be regarded as a material breach of Contract that may subject Contractor to appropriate sanctions The Contractor shall comply with the provisions of Executive Order No 246 entitled Revoking and Superseding Executive Orders Numbers 143 and 150 with respect to affirmative action programs for handicapped individuals which is herein incorporated by reference and made a part of this Contract 152 C In connection with the performance of the Work the Contractor shall undertake in good faith affirmative action measures designed to eliminate any discriminatory barriers in the terms and conditions of employment on the grounds of race color religious cre
243. etscrew or compression steel fittings Comply with NEMA FB 2 10 3 Flexible Conduit Use only fittings listed for use with flexible conduit Comply with NEMA FB 2 20 Do not install aluminum conduits boxes or fittings in contact with concrete or earth INSTALLATION Comply with NECA 1 and NECA 101 for installation requirements except where requirements on Drawings or in this article are stricter Comply with NECA 102 for aluminum conduits Comply with NFPA 70 limitations for types of raceways allowed in specific occupancies and number of floors Keep raceways at least 6 inches away from parallel runs of flues and steam or hot water pipes Install horizontal raceway runs above water and steam piping Complete raceway installation before starting conductor installation Comply with requirements in Section 260529 Hangers and Supports for Electrical Systems for hangers and supports Arrange stub ups so curved portions of bends are not visible above finished slab Install no more than the equivalent of three 90 degree bends in any conduit run except for control wiring conduits for which fewer bends are allowed Support within 12 inches of changes in direction Conceal conduit and EMT within finished walls ceilings and floors unless otherwise indicated Install conduits parallel or perpendicular to building lines Support conduit within 12 inches of enclosures to which attached Stub ups to Above Recessed Ceilings 1 Use EMT IM
244. evision com For additional guidance please contact the Bid Express team at toll free 888 352 2439 select option 1 or at support bidexpress com Traditional Paper Bid Bonds or Certified Check If you choose not to utilize the Electronic Bond Option you may upload a scanned copy of your Bond or Certified Check when submitting your bid the scanned copies must be followed up with a hard copy delivered to the Procurement Main Office 407 Goodell Building 140 Hicks Way Amherst MA 01003 within 72 hours after the bid opening Failure to submit a hard copy of your bid bond or certified check within the specified time period will result in the rejection of your bid Note that failure to submit a hard copy of your bid bond or certified check more than two times ina twelve month period will result in a twelve month ban on submitting bids to the University During the introductory period only one copy of your bid should be submitted either through Bid Express or a hard copy delivered to Procurement in the event that a company submits a bid both on Bid Express and a hard copy to Procurement then the Bid Express bid will be considered the official bid and the hard copy will not be considered Attention Contractors Effective July 1 2013 UMASS Amherst is a Tobacco Free campus Starting July 1 2013 the University of Massachusetts will prohibit tobacco use everywhere on campus inside buildings and throughout the grounds The policy applies to everyo
245. f Massachusetts Amherst Project Manager or alternatively the home office of the Division of Facilities Planning University of Massachusetts Amherst Physical Plant Building 360 Campus Center Way Amherst MA 01003 Payment shall be due and payable within thirty 30 days after receipt by the designee Request for periodic payment not in the required form containing arithmetical computations which are not correct will within seven 7 days be returned to the contractor and the prescribed period for payment shall commence upon the date which the corrected periodic estimate is received at the University of Massachusetts Amherst Division of Facilities Planning Attention is directed to the provision of M G L c 30 s 39K which provides that the awarding authority may make changes in any periodic estimate submitted by the contractor VI INQUIRY AS TO PERIODIC REQUESTS FOR PAYMENT PAYMENT FLOW All inquiries as to the value of the work performed certified and due to the General Contractor its Sub Contractors and suppliers shall be directed to the Resident Engineer or University of Massachusetts Amherst Project Manager This invoice is public information and shall be requested via Public Records Requests to the business office of the Division VII SPECIAL INSTRUCTION TO EMPLOYEES PROJECT MANAGERS RESIDENT ENGINEERS amp DESIGNERS The Resident Engineer Project Managers and the Designer shall give their immediate attention to the certification
246. f the Owner Contractor Agreement As directed As permitted as required as determined or words of like effect The direction permission requirement or determination of the Designer or the Awarding Authority Similarly approved acceptable satisfactory or words of like import shall mean approved by or acceptable or satisfactory to the Designer except as may be otherwise determined by the Awarding Authority Awarding Authority The public agency awarding and administering this Contract identified as the Awarding Authority in the Owner Contractor Agreement Where the Awarding Authority is an agency of the Commonwealth references to the Awarding Authority shall also include the Commonwealth and its agencies Building Code All applicable rules and regulations to which the Awarding Authority is subject and which are contained or referenced in the code authorized by M G L c 143 s 93 et seq including all amendments thereto Certificate of Agency Use and Occupancy A certificate signed by the Designer and the Awarding Authority pursuant to the requirements of Article VI of these General Conditions of the Contract indicating that the Awarding Authority has determined that 1 the Work has been completed in accordance with the Contract Documents except for Punch List items 2 certificates of inspection testing and or approval including a certificate of occupancy under the Building Code operating permits for any mechanical apparatu
247. fication location and circuit number Use hot stamped or engraved machine printing with black filled lettering on face of plate and durable wire markers or tags inside outlet boxes FIELD QUALITY CONTROL Tests for Convenience Receptacles Line Voltage Acceptable range is 105 to 132 V Percent Voltage Drop under 15 A Load A value of 6 percent or higher is unacceptable Ground Impedance Values of up to 2 ohms are acceptable GFCI Trip Test for tripping values specified in UL 1436 and UL 943 Using the test plug verify that the device and its outlet box are securely mounted Tests shall be diagnostic indicating damaged conductors high resistance at the circuit breaker poor connections inadequate fault current path defective devices or similar problems Correct circuit conditions remove malfunctioning units and replace with new ones and retest as specified above QNUM b por Wiring device will be considered defective if it does not pass tests and inspections Prepare test and inspection reports END OF SECTION 262726 WIRING DEVICES 10 14 2015 262726 5 of 5 UMA 16 12 MULLINS SECURITY CAMERAS SECTION 265700 VIDEO SURVEILLANCE PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 1 2 1 3 1 4 A w E ud pi RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of
248. for M WBE Work performed under this Contract as determined by the Awarding Authority the parties agreeing that the damages for failure to meet the M WBE participation goals are difficult to determine and that the foregoing amount to be retained by the Awarding Authority represents the parties best estimate of such damages Any liquidated damages will be assessed separately for MBE and WBE participation B Before exercising its rights and remedies hereunder the Awarding Authority may but the Awarding Authority shall not be obligated to give the Contractor and any other interested party another opportunity to present evidence to the Awarding Authority that the Contractor is in compliance with the requirements of this Article or that there is some justifiable reason for waiving the requirements of this Article in whole or in part The Awarding Authority may invite SOMWBA and the Massachusetts Commission Against Discrimination to participate in any proceedings undertaken hereunder 10 Reporting Requirements The Contractor shall submit to the Awarding Authority all information or documentation that is necessary in the judgment of the Awarding Authority to ascertain whether or not the Contractor has complied with any of the provisions of this Article 11 Awarding Authority s Right to Waive Provisions of this Article in Whole or In Part The Awarding Authority reserves the right to waive any provision or requirement of this Article if the Award
249. fthe Contractor uses stores or encounters toxic or hazardous substances it shall comply with M G L 111F s 2 the Right to Know law and regulations promulgated by the Department of Public Health 105 CMR 670 the Department of Environmental Protection 310 CMR 33 and the Department of Labor and Workforce Development 441 CMR 21 and shall post a Workplace Notice obtainable from the Department of Labor and Workforce Development 2 The Contractor shall comply with the Federal Resource Conservation and Recovery Act the Federal Comprehensive Environmental Response Compensation and Liability Act M G L c 21C M G L c 21E and any other Laws affecting toxic or 103 hazardous materials solid special or hazardous waste collectively Hazardous Materials Laws Should the Contractor discover unforeseen materials subject to Hazardous Materials Laws at the Site the Contractor shall immediately comply with any and all requirements for dealing with such materials and notify all required governmental authorities and the Awarding Authority of such discovery 3 The Contractor shall be responsible for the location of all utilities in connection with the Work Without limiting the foregoing the Contractor shall comply with Dig Safe Laws Dig Safe is the Utility Underground Plant Damage Prevention System 331 Montvale Road Woburn MA 01801 1 888 344 7233 The Contractor shall notify Dig Safe of contemplated excavation demolition or explosive
250. g agency and marked for intended location and application VIDEO SURVEILLANCE 10 14 2015 265700 2 of 9 1 9 A UMA 16 12 MULLINS SECURITY CAMERAS WARRANTY Special Warranty Manufacturer s standard form in which manufacturer agrees to repair or replace components of cameras equipment related to camera operation and control station equipment that fail in materials or workmanship within specified warranty period 1 Warranty Period Three years from date of Substantial Completion PART 2 PRODUCTS 2 1 2 2 2 3 2 4 A A A B CAMERAS Cameras shall be manufactured by Honeywell as shown on the drawings and shall be UL listed and 100 compatible with the existing campus Honeywell Fusion DVR system Cameras shall be powered PoE with final aiming as directed by Owner POWER SUPPLIES Low voltage power supplies matched for voltage and current requirements of PTZ cameras and accessories as shown on the drawings or equal as recommended by the equipment manufacturer CAMERA SUPPORTING EQUIPMENT Camera supports and mounting brackets shall be as recommended and approved by the camera manufacturer Pan Units Motorized automatic scanning units arranged to provide remote controlled manual and automatic camera panning action and equipped with matching mounting brackets Pan and Tilt Units Motorized units arranged to provide remote controlled aiming of cameras with smooth and silent operation and equipped wi
251. g the project building address and or names of adjacent roads and or buildings SUMMARY 10 14 2015 011000 14 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS Dialing 5 2121 on a campus phone or 413 545 2121 on an outside phone reaches the UMass Police General Business UMass Police can facilitate obtaining necessary services for the emergency Emergencies In the event of an emergency on site telephone for emergency services ambulance fire department or police assistance Telephone for Emergency Service See 1 20A above Call 911 or 545 2121 and inform them if confined space rescue equipment is required or if hazardous material is involved If live steam electricity or other utilities need to be shut off call the U M A Physical Plant switchboard 545 0600 and ask them to contact the appropriate shop If live steam electricity or other utilities need to be shut off call the U M A Physical Plant switchboard 545 0600 and ask them to contact the appropriate shop Make the scene safe Render First Aid if possible Preserve evidence Call the UMA Project Manager Call the UMA Project Manager and UMA EH amp S 413 545 2682 for significant incidents injuries beyond first aid including situations that have the potential to cause significant personal injury or damage to UMass property All spills of hazardous materials regardless of quantity shall be reported to EH amp S The University EHS office is responsib
252. ge Audit when used in regard to financial statements means an examination of records by an independent certified public accountant in accordance with generally accepted accounting principles and auditing standards for the purpose of expressing a certified opinion thereon or in the alternative a qualified opinion or a declination to express an opinion for stated reasons or other person or persons primarily responsible for the financial and operational policies and practices of the Contractor 139 Accounting terms unless otherwise defined herein shall have a meaning in accordance with generally accepted accounting principles and auditing standards 2 Record Keeping A The Contractor shall make and keep for at least six years after final payment books records and accounts that in reasonable detail accurately and fairly reflect the transactions and dispositions of the Contractor B Until the expiration of six years after final payment the Inspector General DCAM and the Awarding Authority shall have the right to examine any books documents papers or records of the Contractor and Subcontractors that directly pertain to and involve transactions relating to the Contractor and Subcontractors C The Contractor shall describe any change in the method of maintaining records or recording transactions which materially affects any statements filed with the Awarding Authority including the date of the change and reasons therefore and sha
253. hall be without prejudice to any other rights or remedies the awarding authority may have under the contract The awarding authority shall note any such termination in the evaluation form to be filed by the awarding authority pursuant to the provisions of section 44D of chapter 149 6 Payment of Subcontractors M G L c 30 s 39F The Contractor shall make payments to Subcontractors in accordance with M G L c 30 s 39F which is quoted in this section below For the purposes of this Contract the word forthwith appearing in paragraph 1 a of the quoted provision shall be deemed to mean within five 5 business days 1 a Forthwith after the general contractor receives payment on account of a periodic estimate the general Contractor shall pay to each subcontractor the amount paid for the labor performed and the materials furnished by that subcontractor less any amount specified in any court proceedings barring such payment and also less any amount claimed due from the subcontractor by the general contractor b Not later than the sixty fifth day after each subcontractor substantially completes his work in accordance with the Plans and Specifications the entire balance due under the subcontract less amounts retained by the awarding authority as the estimated cost of completing the incomplete and unsatisfactory items of work shall be due the subcontractor and the awarding authority shall pay that amount to the general contractor The gen
254. has satisfied the Department of Public Safety b all equipment and systems included in the Work have been tested in the presence of the Designer and are operational and satisfactory c the Work is completed and ready for final inspection 9 Such other items as may be required by the Contract Documents B Reinspection Final Acceptance After notification from the Contractor that all remaining contract exceptions omissions and incompletions have been completed with the exception of Contractor s continuing warranty insurance indemnification and such other obligations as are intended by the terms of the Contract Documents to extend beyond the date of Final Acceptance the Awarding Authority and the Designer shall inspect the Work to verify the completion of the same If the Work is satisfactory the Awarding Authority shall prepare a Certificate of Final Acceptance or shall notify Contractor of items which remain to be completed prior to Final Acceptance 118 7 One Year Warranty Repair List and Inspection Approximately 30 days prior to the expiration of the comprehensive one year warranty period the Contractor shall schedule an appointment with the Awarding Authority for a re inspection of the Work with the Awarding Authority and shall thereafter inspect the work at the time scheduled Based on this inspection and on prior inspections the Awarding Authority shall issue a Warranty Repair List of items to be corrected by the Contractor
255. have against each other As used in the statutory language of a and b below contract means this Contract general contractor means the Contractor and awarding authority means the Awarding Authority a The awarding authority may order the general contractor in writing to suspend delay or interrupt all or any part of the work for such period of time as it may determine to be 115 appropriate for the convenience of the awarding authority provided however that if there is a suspension delay or interruption for fifteen days or more or due to a failure of the awarding authority to act within the time specified in this contract the awarding authority shall make an adjustment in the contract price for any increase in the cost of performance of this contract but shall not include any profit to the general contractor on such increase and provided further that the awarding authority shall not make any adjustment in the contract price under this provision for any suspension delay interruption or failure to act to the extent that such is due to any cause for which this contract provides for an equitable adjustment of the contract price under any other contract provisions b The general contractor must submit the amount of a claim under provision a to the awarding authority in writing as soon as practicable after the end of the suspension delay interruption or failure to act and in any event not later than the date of final payment u
256. have been established Equipment and materials which are not covered by UL Standards will be accepted provided equipment and material is listed labeled certified or otherwise determined to meet safety requirements of a nationally recognized testing laboratory Equipment of a class which no nationally recognized testing laboratory accepts certifies lists labels or determines to be safe will be considered if inspected or tested in accordance with national industrial standards such as NEMA or ANSI Evidence of compliance shall include certified test reports and definitive shop drawings Definitions 1 Listed equipment or device of a kind mentioned which a Is published by a nationally recognized laboratory which makes periodic inspection of production of such equipment b States that such equipment meets nationally recognized standards or has been tested and found safe for use in a specified manner 2 Labeled equipment or device is when It embodies valid label symbol or other identifying mark of a nationally recognized testing laboratory such as Underwriters Laboratories Inc b The laboratory makes periodic inspections of the production of such equipment The labeling indicates compliance with nationally recognized standards or tests to determine safe use in a specified manner 3 Certified equipment product is which a Has been tested and found by a nationally recognized testing laboratory to meet nationally recogni
257. he Awarding Authority a statement prepared and signed by an independent certified public accountant stating that the accountant has examined the statement of management on internal accounting controls and expressing an opinion as to 1 whether the representations of management in response to subparagraph 3 above are consistent with the results of management s evaluation of the system of internal accounting controls and 140 2 whether such representations of management are reasonable with respect to transactions and assets in amounts which would be material when measured in relation to the applicant s financial statement 4 Annual Financial Statement A Every Contractor awarded a contract shall annually file with DCAM during the term of the Contract a financial statement prepared by an independent certified public accountant on the basis of an audit by such accountant The final statement filed shall include the date of final payment All statements shall be accompanied by an accountant s report B The office of Inspector General DCAM shall have the right to enforce the provisions of this Article A Contractor s failure to satisfy any of the requirements of this section may be grounds for debarment pursuant to M G L c 149 s 44C 5 Bid Pricing Materials The Contractor shall save the written calculations pricing information and other data that the Contractor used to calculate the bid that induced the Awarding Authority to
258. he Designer the UMA Project Manager or required by the manufacturers The Designer reserves the right to ask for shop drawings for any or all items on the project whether or not requested in individual specification sections at no additional cost to the Commonwealth RESUBMISSION REQUIREMENTS Resubmission Resubmission procedure shall follow the same procedures as the initial submittal with the following exceptions Shop Drawings l Transmittal shall contain the same information as the first transmittal except that the submission number shall change sequentially The drawing number description shall be identical as the first transmittal but the date shall be the revised date for that submission No new material should be included on the same transmittal for the resubmission SUBMITTAL REQUIREMENTS 10 14 2015 013300 5 of 8 12 4 2012 1 7 16 12 MULLINS SECURITY CAMERAS 3 Indicate on drawings any changes which may have been made other than those requested by the Designer Product Data and Samples 1 Submit any new data and samples as required from previous submittal THE UMA PROJECT MANAGER S AND DESIGNER S REVIEWS AND DISTRIBUTION OF SUBMISSIONS The UMA Project Manager and or his her designees will review submittals concurrently with the Designer and his her consultant engineers The Designer and the UMA Project Manager shall communicate within the aforesaid review period time frame 21 calendar days
259. he Plans though not specified in the Specifications and any work specified in the Specifications though not shown on the Plans is to be executed by the Contractor as a part of this Contract B Allthings that in the opinion of the Designer may be reasonably inferred from the Plans Specifications and other Contract Documents are to be executed by the Contractor The Designer shall determine whether the detail Plans conform to the general Plans and Contract Documents except as may be otherwise determined by the Awarding Authority C Thetables of contents titles headings and marginal notes or sub scripts contained herein are solely to facilitate references are not intended to be construed as provisions of the Contract and in no way affect the interpretation of the provisions to which they refer D Where reference is made in the Contract Documents to publications standards or codes issued by associations or societies such reference shall be interpreted to mean the current edition of such publications standards or codes including revisions in effect on the date of the Advertisement notwithstanding any reference to a particular date The foregoing sentence shall not apply to the dates if any specified with respect to insurance policy endorsement forms E Incase of any conflict among the Contract Documents unless the context clearly otherwise requires the Contract Documents shall be construed according to the following priorities First
260. he last meeting Determine whether each activity is on time ahead of schedule or behind schedule in relation to Contractor s Construction Schedule Determine how construction behind schedule will be expedited secure commitments from parties involved to do so Discuss whether schedule revisions are required to ensure that current and subsequent activities will be completed within the Contract Time Review present and future needs of each entity present including the following Interface requirements Sequence of operations Status of submittals Deliveries Off site fabrication Access Site utilization Temporary facilities and controls Manpower Hazards and risks Progress cleaning Quality and work standards Change Orders Documentation of information for payment requests PH oR ooo op SUMMARY 10 14 2015 011000 9 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS AS a prerequisite for monthly payments ordering schedules shop drawing submitted schedules and coordination meeting schedules shall be prepared and maintained by the General Contractor and shall be revised and updated on a monthly basis and a copy shall be submitted to the UMA Project Manager and Designer In order to expedite construction progress on this project the General Contractor shall order all materials immediately after the approval of shop drawings and shall obtain a fixed date of delivery to the project site for all
261. he prime contractor a filed sub bidder or any sub contractor All apprentices working on the project are required to be registered with the Massachusetts Division of Apprentice Standards DAS Apprentice must keep his her apprentice identification card on his her person during all work hours on the project An apprentice registered with DAS may be paid the lower apprentice wage rate at the applicable step as provided on the prevailing wage schedule If an apprentice rate is not listed on the prevailing wage schedule for the trade in which an apprentice is registered with the DAS the apprentice must be paid the journeyworker s rate for the trade wage rates will remain in effect for the duration of the project except in the case of multi year public construction projects For construction projects lasting longer than one year awarding authorities must request an updated wage schedule Awarding authorities are required to request these updates no later than two weeks before the anniversary of the date the contract was executed by the awarding authority and the general contractor For multi year CM AT RISK projects awarding authority must request an annual update no later than two weeks before the anniversary date determined as the earlier of a the execution date of the GMP Amendment or b the execution date of the first amendment to permit procurement of construction services Contractors are required to obtain the wage schedules from
262. hours shall submit an impairment plan to the UMA Project Manager and EH amp S The Contractor is required to obtain trenching permits from UMA EH amp S for any excavations or trenches that are greater than 36 inches in depth three working days prior to start of work The General Contractor shall be required to keep a copy of the State Building Code with latest amendments at the job site at all times Any construction sites disturbing greater than one acre require a notice of intent to the EPA and will require a written a stormwater pollution prevention plan A Notice of Termination must then be filed when sediment controls are no longer required 1 15 CUTTING CORING AND PATCHING UNLESS OTHERWISE INDICATED A Qv qst cs The General Contractor shall coordinate all cutting coring fitting and patching of the work that may be required to make its several parts come together properly and fit it to receive or be received by work of the Subcontractors shown on the Drawings and Specifications The General Contractor shall coordinate that the work of the Subcontractor is not endangered by any cutting coring excavating or otherwise altering of the work and shall not allow the cutting or altering the work of any Subcontractor except with the written consent of the Designer Submit a written request to Designer at least three 3 business days in advance of executing any cutting or alteration which affects Work of UMA or separate Contr
263. hundred forty nine shall mean a person who files a sub bid and received a subcontract as a result of that filed sub bid or who is approved by the awarding authority in writing as a person performing labor or both performing labor and furnishing materials pursuant to a contract with the general contractor ii for contracts awarded as provided in paragraph 1 of section thirty nine M of chapter thirty shall mean a person approved by the awarding authority in writing as a person performing labor or both performing labor and furnishing materials pursuant to a contract with the general contractor and iii for contracts with the commonwealth not awarded as provided in sections forty four A to forty four L inclusive of chapter one hundred forty nine shall also mean a person contracting with the general contractor to supply materials used or employed in a public works project for a price in excess of five thousand dollars 4 A general contractor or a subcontractor shall enforce a claim to any portion of the amount of a demand for direct payment deposit as provided in subparagraph 6 by a petition in equity in the superior court against the other and the bank shall not be a necessary party A subcontractor shall enforce a claim for direct payment or a right to require a deposit as provided in subparagraph 6 by a petition in equity in the superior court against the awarding authority and the general contractor shall not be a necessary party Upon motion of
264. idated damages PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SECTION 013200 CONSTRUCTION PROGRESS DOCUMENTS 10 14 2015 013200 2 of 2 12 4 2012 16 12 MULLINS SECURITY CAMERAS SECTION 013300 SUBMITTAL REQUIREMENTS PART 1 GENERAL 1 1 1 2 1 3 GENERAL PROVISIONS A Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications REQUIREMENTS INCLUDED A Shop drawings products data samples submittal logs shop drawings and samples RFI NOI PCO CO and SK drawings weather protection if applicable and schedule of values SHOP DRAWINGS PRODUCTS DATA AND SAMPLES A General 1 Review and submit to the Designer and where outlined below to the UMA Project Manager shop drawings project data and samples required by Specifications Sections in hard and electronic copies 2 No submissions made by FAX will be accepted oF The General Contractor within the time frame stated in project schedule and the Pre Construction Meeting shall prepare and submit for the Designer and the UMA Project Manager s approval a Schedule of Shop Drawings Product Data and Samples required to be submitted for the Work The schedule shall indicate by Subcontractor the date by which final approval of each item must be obtained and shall be revised as required by conditio
265. ier shall be notified in writing by the Contractor of the Contractor s obligations under this Contract relative to non discrimination and affirmative action E As part of its obligation of remedial action under this Article the Contractor shall maintain on this project not less than the percent ratio set forth in the Owner Contractor Agreement of minority employee worker hours to total worker hours in each job category including but not limited to bricklayers carpenters cement masons electricians ironworkers operating engineers and those classes of work enumerated in M G L c 149 s 44F F Inthe hiring of minority journeypersons apprentices trainees and advanced trainees the Contractor shall rely on referrals from a multi employer affirmative action program approved by the Commission traditional referral methods utilized by the construction industry and referrals from agencies not more than three in number at any one time designated by the Liaison Committee or the Awarding Authority 3 Liaison Committee Reports and Records A Atthe option of the Awarding Authority there may be established for the term of this Contract a body to be known as the Liaison Committee The Liaison Committee shall be composed of one representative each from the Awarding Authority the Commission and such other representatives as may be designated by the Commission in conjunction with the Awarding Authority The Contractor or his agent if any design
266. if the M WBE supplier is regularly engaged in sales of equipment or supplies to the construction industry from an established place of business M WBE participation credit shall be given the full amount of the purchase order only if the M WBE supplier manufactures the goods or substantially alters them before resale In all other cases M WBE participation credit shall be given for 1096 of the purchase order D MBE participation credit shall be given for the work performed by MBEs only and WBE participation credit shall be given for the work performed by WBEs only MBE participation may not be substituted for WBE participation nor may WBE participation be substituted for MBE participation 156 3 Establishing M WBE Status A minority owned business shall be considered an MBE only if it has been certified as a minority business enterprise by the State Office of Minority and Women Business Assistance SOMWBA B Awoman owned business shall be considered a WBE only if it has been certified as a woman business enterprise by SOMWBA C Certification as a disadvantaged business enterprise DBE certification as an M WBE by any agency other than SOMWBA or submission of an application to SOMWBA for certification as an M WBE shall not confer M WBE status on a firm for the purposes of this Contract 4 Subcontracts With M WBEs Within thirty 30 days after the award of this Contract the Contractor shall i execute a subcontract with ea
267. if units were operated without filters during construction 3 Leave pipe and duct spaces plenums furred spaces and the like clean of debris and materials subject to decay f Provide a properly working lock for the medical environmental closets if applicable g Assure that exterior and interior fire rated and egress doors are operating properly and have the proper hardware h Assure that fire rating labels are on doors and frames that are supposed to have them Assure that smoke barriers are properly installed and located Assure that the spare set of each type of sprinkler head and a head removal tool have been provided Assure that floors drain properly Assure that proper hot water temperatures are provided Unless otherwise specified or required by a User Agency the temperature set on building master controllers of hot water shall apply 1 HW to toilet rooms and janitors closets shall be 140 F 2 HW to individual tubs or showers shall be controlled in addition to the master controller above with thermostatic valves set to furnish HW at a temperature not exceeding 110 F and equipped with anti scald feature 3 HW rinse water to dishwashers shall be controlled at 180 F m Assure that proper water pressure is provided for the sprinkler system ome w CONTRACT CLOSEOUT 10 14 2015 017700 5 of 9 4 5 2013rev q T UMA 16 12 MULLINS SECURITY CAMERAS Assure that low consumption
268. ility of the appropriate Subcontractor The General Contractor shall verify that Subcontractors have visited the site and included all costs associated with the location of the project and any restriction or limitations the location of the project may pose The Subcontractors shall at all times conduct their operations in a courteous professional manner while on the project or in the vicinity of the project Harassment offensive language or behavior will not be permitted on the site The University of Massachusetts Amherst can neither accept nor assume responsibility for the security of the Contractor s material or equipment which is lost stolen or vandalized The Contractor is advised to exert caution in placement and storage of his equipment and material Parking Parking spaces on Campus are very limited and the University will not provide designated parking lot spaces near the construction site for the Contractor s use The Contractor shall contact Parking Services 545 0065 to determine the location of the nearest available parking spaces The Contractor will be required to pay all fees for parking The Contractor shall state his her parking and staging area requirements during the Pre construction Meeting The area s for materials storage will then be agreed to between the Contractor and the UMA Project Manager The limits of material storage will be delineated by the Contractor with construction fencing and enforced throughout the Co
269. in Article 2 of the Owner Contractor Agreement on forms provided and in the manner prescribed by the Awarding Authority submit to the Awarding Authority a statement showing the total amount of Work done to the time of such estimate and the value thereof as approved by the Resident Engineer and the Designer It shall be the sole responsibility of the Contractor to deliver or cause to be delivered to the Resident Engineer the designee as 125 provided by M G L c 30 s 39K said periodic estimate in proper form approved as provided above and arithmetically correct All periodic estimates shall contain such certifications and other evidence supporting the Contractor s right to payment as the Awarding Authority may require including without limitation lien waivers and other evidence on such forms as the Awarding Authority may require establishing that title to the equipment or materials is unencumbered and has been transferred to the Owner If there is no Resident Engineer assigned to the Contract the Designer shall be the designee If there is neither a Resident Engineer nor a Designer the designee shall be a person designated by the Awarding Authority at the project field office or alternatively the home office of the Awarding Authority The Contractor shall include in such periodic estimate only such materials as are incorporated in the Work except as provided in paragraph C below The Awarding Authority shall retain five percent of such e
270. in empty raceways Use polypropylene or monofilament plastic line with not less than 200 16 tensile strength Leave at least 12 inches of slack at each end of pull wire Cap underground raceways designated as spare above grade alongside raceways in use Surface Raceways 1 Install surface raceway with a minimum 2 inch radius control at bend points Secure surface raceway with screws or other anchor type devices at intervals not exceeding 48 inches and with no less than two supports per straight raceway section Support surface raceway according to manufacturer s written instructions Tape and glue are not acceptable support methods Install raceway sealing fittings at accessible locations according to NFPA 70 and fill them with listed sealing compound For concealed raceways install each fitting in a flush steel box with a blank cover plate having a finish similar to that of adjacent plates or surfaces Install raceway sealing fittings according to NFPA 70 Install devices to seal raceway interiors at accessible locations Locate seals so no fittings or boxes are between the seal and the following changes of environments Seal the interior of all raceways at the following points 1 Where conduits pass from warm to cold locations such as boundaries of refrigerated spaces 2 Where an underground service raceway enters a building or structure Where otherwise required by NFPA 70 Comply with manufacturer s written instructions for solvent
271. in that five days take all necessary steps to do so including if the Awarding Authority requires increasing its forces equipment and plant and continue to do so until in the opinion of the Awarding Authority the failure is corrected the Awarding Authority may at the Contractor s expense and without terminating this Contract take exclusive or joint possession of all or a portion of the Site and employ and direct the labors of existing or such additional forces equipment and plant as may in the Designer s or Awarding Authority s opinion be necessary to 113 insure the completion of the Work or such part thereof within the time specified in the Contract Documents or at the earliest possible date thereafter The Awarding Authority may exercise its rights under this Article at any time and from time to time without waiving any of its rights under this Contract at law or in equity including without limitation the right to deem this Contract terminated or to order the Contractor to discontinue the Work at any time thereafter The Contractor shall continue to perform the remaining Work under this Contract even if the Awarding Authority elects to have another contractor perform a portion of the Work under this Article F The Awarding Authority shall deduct the cost of any actions the Awarding Authority takes under this Article from any amount then due or which might have become due to the Contractor under this Contract had the Contractor performed as
272. in the Massachusetts Electrical Code Strength of Support Assemblies Where not indicated select sizes of components so strength will be adequate to carry present and future static loads within specified loading limits Minimum static design load used for strength determination shall be weight of supported components plus 200 Ib D Mounting and Anchorage of Surface Mounted Equipment and Components Anchor and fasten electrical items and their supports to building structural elements by the following methods unless otherwise indicated by code 1 To Wood Fasten with lag screws or through bolts To New Concrete Bolt to concrete inserts 3 Masonry Approved toggle type bolts on hollow masonry units and expansion anchor fasteners on solid masonry units 4 To Existing Concrete Expansion anchor fasteners 5 Instead of expansion anchors powder actuated driven threaded studs provided with lock washers and nuts may be used in existing standard weight concrete 4 inches thick or greater Do not use for anchorage to lightweight aggregate concrete or for slabs less than 4 inches thick 6 To Steel Beam clamps MSS Type 19 21 23 25 or 27 complying with MSS SP 69 To Light Steel Sheet metal screws 8 Items Mounted on Hollow Walls and Nonstructural Building Surfaces Mount cabinets panelboards disconnect switches control enclosures pull and junction boxes transformers and other devices on slotted channel racks attached to s
273. inal connections from service lines to equipment will be by the Owner unless otherwise indicated 1 23 UMA OCCUPANCY A Beneficial Use and Occupancy Refer to requirements in Section 017700 CONTRACT CLOSEOUT Par 1 6 Use and Occupancy When the project is Substantially Complete with all work affecting health safety and function totally completed and with less than one percent lt 1 of the contract value remaining and ready for Use and Occupancy as determined by the Designer the UMA Project Manager and the Operating Agency then the UMA will take control of their building area s and be responsible for operating costs and security 1 24 SPECIAL REQUIREMENTS A 1 The General Contractor shall prepare a Health and Safety Plan that addresses protection of employee and public health and safety The minimum contents of the Plan are specified in Section 013300 SUBMITTAL REQUIREMENTS The General Contractor shall be solely responsible for implementing the procedures specified in the Plan The General Contractor shall make available complete sets of personal protective equipment and clothing to UMA for use during site observations inspections by UMA and the Designer These shall be supplied and maintained at no cost to UMA and the Designer and shall be returned to the General Contractor upon the completion of work except for disposable protective clothing The General Contractor shall provide a repository for collection
274. ined by the Designer and the UMA Project Manager may be grounds for postponement of the final inspection or delay the processing of final payment until such inaccuracies are corrected by the General Contractor OPERATING AND MAINTENANCE REQUIREMENTS At least two weeks prior to the time of turning over this contract to the Operating Agency for Use and Occupancy or Final Acceptance the General Contractor shall secure and deliver to the Operating Agency via the Designer three 3 complete indexed files and three 3 CD or DVD copies containing approved operating and maintenance manuals shop drawings record of paint colors floor and ceiling materials and other data as follows 1 Operating manuals and operating instructions for each model and type of equipment in each of the various systems Include operating instructions for systems integrating several pieces of equipment 2 Catalog data sheets for each item of mechanical or electrical or equipment actually installed including performance curves rating data and parts lists 3 Catalog sheets maintenance manuals and approved shop drawings of all mechanical or electrical equipment controls and fixtures with all details clearly indicated including size of lamps and other maintenance supplies 4 Operating procedures including startup shutdown seasonal and weekend operations 5 Description of controls and sequence of operations 6 Maintenance Data a Manufacturer s information in
275. ing case number date action was commenced date judgment or decision was entered fines or penalties imposed etc IF YOU HAVE ANY DOUBT AS TO WHETHER TO ANSWER YES IT IS BETTER TO BE OVER INCLUSIVE AND TO PROVIDE A DETAILED EXPLANATION YES NO Have any civil judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to the procurement or performance of any construction contract including but not limited to actions to obtain payment brought by subcontractors suppliers or others Have any criminal proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to the procurement or performance of any construction contract including but not limited to any of the following offenses fraud graft embezzlement forgery bribery falsification or destruction of records or receipt of stolen property Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state s or federal procurement laws arising out of the submission of bids or proposals Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm
276. ing manufacturers names are used in other Part 2 articles Cooper Wiring Devices Division of Cooper Industries Inc Cooper Hubbell Incorporated Wiring Device Kellems Hubbell Leviton Mfg Company Inc Leviton Pass amp Seymour Legrand Pass amp Seymour Iun Source Limitations Obtain each type of wiring device and associated wall plate from single source from single manufacturer GENERAL WIRING DEVICE REQUIREMENTS Wiring Devices Components and Accessories Listed and labeled as defined in NFPA 70 by a qualified testing agency and marked for intended location and application Comply with NFPA 70 Devices that are manufactured for use with modular plug in connectors may be substituted under the following conditions 1 Connectors shall comply with UL 2459 and shall be made with stranding building wire 2 Devices shall comply with the requirements in this Section WIRING DEVICES 10 14 2015 262726 2 of 5 2 3 2 4 2 5 2 6 16 21 MULLINS SECURITY CAMERAS STRAIGHT BLADE RECEPTACLES Convenience Receptacles 125 V 20 A Comply with NEMA WD 1 NEMA WD 6 Configuration 5 20R UL 498 Supplement SD and FS W C 596 1 Products Subject to compliance with requirements available products that may be incorporated into the Work include but are not limited to the following 8300 b Hubbell HBL8300SGA Leviton 8300 SGG d Pass amp Seymour 63H GFCI RECE
277. ing Authority determines that such waiver is justified and in the public interest No such waiver shall be effective unless in writing and signed by a representative of the Awarding Authority s Compliance Procurement Office or the office of its General Counsel No other action or inaction by the Awarding Authority shall be construed as a waiver of any provision of this Article 160 APPENDIX C to the General Conditions of the Contract INDEX OF COMMONLY USED FORMS Forms used during bidding are located in Attachment B to the Instructions to Bidders Procedure for Payment to Contractors Daily Time and Material Report for Change Orders Notice of Intent Request and Agreement for a Change in the Plans Specifications and or Contract UMA Form 5 Instructions Regarding Change Orders and Contract Modifications UMA Form 13 Contractor s Weekly Workforce Report Minorities Women in Contractor s Weekly Workforce Report Weekly Payroll Report Form and Statement of Compliance Quarterly Projected Workforce Table Certification of Payment by Contractor to MBE WBE and Instructions Certificate of Completion by Minority Women Business Enterprise Form for Transfer of Title Work Not Incorporated UMA Form 16 Certificate of Agency Use and Occupancy E 1 Certificate of Final Inspection Release and Acceptance E 2 Form ST 5C 161 THE COMMONWEALTH OF MASSACHUSETTS THE UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING Physical Plant Building 360
278. ing the site or to suppliers employees who are making deliveries Documentation records shall be initially compiled by the General Contractor and Subcontractors as part of their certified payrolls and the General Contractor shall create and maintain a copy of the documentation on site at all times On site documentation shall be filed in alphabetical order and immediately available to UMA s Project Manager and OSHA inspectors Fines imposed for non compliance shall be promptly paid by the General Contractor at no additional expense to UMA Delays in the progress of the Work caused by such non compliance will not be acceptable as the basis for an extension of contract time or change order request 1 21 DAMAGE RESPONSIBILITY A The General Contractor shall repair at no cost to UMA any damage to building elements site appurtenances landscaping utilities etc caused during demolition operation and work of this Contract 1 22 OWNER FURNISHED PRODUCTS A Products indicated N I C Not in Contract or O Equipment by Owner or O F O I Owner Furnished Owner Installed or other similar acronyms as defined in the contract documents will be furnished and installed by the Owner Coordination and provision of service lines for such products shall be included under these Construction SUMMARY 10 14 2015 011000 18 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS Contract Documents if indicated F
279. inimum Wage Rates Attachment B Forms Used During Bidding Sample Certificate of Eligibility Prime Bidder Sample Sub bidder Certificate of Eligibility Update Statement Prime Bidder Sub bidder Update Statement Form for General Bid Form for Sub Bid UNIVERSITY OF MASSACHUSETTS AMHERST INSTRUCTIONS TO BIDDERS Awarding Authority University of Massachusetts Amherst Procurement Department Ath Level 407 Goodell Building Amherst MA 01003 Telephone 413 545 0361 UMA No 16 12 Project No 1003430 Title Mullins Security Cameras Category of Work Electrical Project Description and Scope Electrical Note Final Completion date is 45 days after executed contract date Pre Bid Meeting Information if any October 20 2015 at 10 00 a m at Mullins Arena North Entrance Lobby 200 Commonwealth Avenue Amherst MA Deadline for filing filed Sub bids is 12 00 noon on N A 20 October 28 Deadline for filing General bids is 2 00 p m on 2015 The list of filed subtrades for this project is found at Page 10 of these Instructions to Bidders The minimum wage rate requirements for this Contract are located in Attachment A to these Instructions to Bidders Pursuant to M G L c 30 39S a 2 all employees to be employed on the worksite must have successfully completed a course in construction safety and health approved by OSHA and of at least 10 hours in duration The Contractor must provide written verification a
280. intention of the University of Massachusetts Amherst and the applicable statutory provision that whenever possible the parties should agree upon an equitable adjustment in the contract price before commencement of the pertinent work All parties shall negotiate in a professional manner and agree upon the particulars associated with the change in the work thereby facilitating an approved change order It is the responsibility of the Contractor to substantiate clearly the costs associated with all changes If the Contractor refuses to provide the project manager within ten 10 days of proposed requests for change cost estimates for a proposed change in the work the project manager may unilaterally determine the reasonable cost for the change and the Contractor must proceed with the work based upon the project manager s established cost SECTION 2 SUBMISSION AND DISPOSITION OF THE UNIVERSITY OF MASSACHUSETTS AMHERST NOTICE OF INTENT NOI 2 01 AUTHORIZED REQUESTORS a General Contractor including Sub Contractor b Designer c University of Massachusetts Amherst Project Manager Assistant Directors or Director of Facilities Planning 2 02 THE REQUESTOR SHALL a Initially discuss the proposed request for change with all interested parties b If the Designer or the University of Massachusetts Amherst is the requestor forward to the contractor a written request for proposal c Ifthe Contractor is the requestor see Section 2 03 belo
281. ion of the time prescribed in M G L c 149 44A for making an award except that if any general Bidder fails to perform its agreement to execute the Contract and furnish Performance and Payment Bonds as Stated in its Bid then said general Bidder s Bid deposit shall become the property of the Commonwealth as liquidated damages provided that the amount of the Bid deposit that 21 becomes the property of the Commonwealth shall not exceed the difference between the Contractor s Bid price and the Bid price of the next lowest responsible and eligible Bidder and provided further that in the case of death disability bona fide clerical or mechanical error of a substantial nature or other similar unforeseen circumstances affecting the general Bidder such general Bidder s Bid deposit shall be returned 11 2 All Bid deposits of sub Bidders except i those of the sub Bidders named in the general Bids of the three 3 lowest responsible and eligible general Bidders and ii those of the three 3 lowest responsible and eligible sub Bidders for each sub trade shall be returned within five 5 days Saturdays Sundays and legal holidays excluded after the opening of the general Bids The Bid deposits of sub Bidders not returned pursuant to the provisions of the preceding sentence shall be returned within five 5 days Saturdays Sundays and legal holidays excluded after the execution of the General Contract except that if a selected sub Bidder fail
282. ion shall be as close as practical to locations shown on the drawings B Working spaces shall not be less than specified in the MEC for all voltages specified 1 Where the University determines that the Contractor has installed equipment not within proper working clearances the equipment shall be removed and reinstalled as directed at no additional cost to the University C Inaccessible Equipment 1 Where the University determines that the Contractor has installed equipment not within proper working clearances or not conveniently accessible for operation and maintenance the equipment shall be removed and reinstalled as directed at no additional cost to the University 1 10 SINGULAR NUMBER A Where any device or part of equipment is referred to in these specifications in the singular number e g the switch this reference shall be deemed to apply to as many such devices as are required to complete the installation as shown on the drawings END OF SECTION 260001 ELECTRICAL WORK 10 14 2015 260001 5 of 5 UMA16 12 MULLINS SECURITY CAMERAS SECTION 260519 LOW VOLTAGE ELECTRICAL POWER CONDUCTORS AND CABLES PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 A 1 2 A 1 3 A 1 4 A RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications
283. ipal or officer anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state or federal law regulating hours of labor unemployment compensation minimum wages prevailing wages overtime pay equal pay child labor or worker s compensation Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of any state or federal law prohibiting discrimination in employment Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a claim of repeated or aggravated violation of any state or federal law regulating labor relations Have any proceedings by a municipal state or federal agency been brought concluded or settled relating to decertification debarment or suspension of your firm or any principal or officer or anyone with a financial interest in your firm from public contracting Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of state or federal law regulating the environment Has your firm been fined by OSHA or any other state or federal age
284. is Section including but not limited to the following 1 2 Remove existing security camera system and related conductors as shown on the plans Install new cameras and related equipment in locations shown on the plans Install control equipment and all camera system video power and fiber wiring and conductors Reuse existing raceways where possible Construction shall meet the timeframe described in Section 011000 Summary Wiring ampacities specified or shown on the drawings are based on copper conductors with the conduit and raceways accordingly sized Aluminum conductors are prohibited The Electrical Contractor shall carry the costs for all permits and fees in his her bid ELECTRICAL WORK 10 14 2015 260001 1 of 5 2 13 2012rev UMA 16 12 MULLINS SECURITY CAMERAS In the case of an inconsistency between Drawings and the Project Manual or within either document which is not clarified by addendum the product of greater quality or greater quantity of work shall be provided in accordance with the Designer s interpretation 1 3 MINIMUM STANDARDS A References to the Massachusetts Electrical Code MEC Underwriters Laboratories Inc UL and National Fire Protection Association NFPA are minimum installation requirement standards All materials and equipment shall be listed labeled or certified by a nationally recognized testing laboratory to meet Underwriters Laboratories Inc standards where test standards
285. ities having jurisdiction and rules conventions and agreements within the construction industry that control performance of the Work Furnish Supply and deliver to Project site ready for unloading unpacking assembly installation and similar operations Install Operations at Project site including unloading temporarily storing unpacking assembling erecting placing anchoring applying working to dimension finishing curing protecting cleaning and similar operations Provide Furnish and install complete and ready for the intended use REFERENCES 10 14 2015 014200 1 of 4 12 4 2012 rev 1 3 1 4 I 16 12 MULLINS SECURITY CAMERAS Project Site Space available for performing construction activities subject to UMA approval The extent of Project site is shown on Drawings and may or may not be identical with the description of the land on which Project is to be built INDUSTRY STANDARDS Applicability of Standards Unless the Contract Documents include more stringent requirements applicable construction industry standards have the same force and effect as if bound or copied directly into the Contract Documents to the extent referenced Such standards are made a part of the Contract Documents by reference Publication Dates Comply with standards in effect as of date of the Contract Documents unless otherwise indicated Copies of Standards Each entity engaged in construction on Project should b
286. ive or railroad or coal mining company and b for the purpose of operating maintaining or repairing the utility company s equipment and c by a person who is using hand or mechanical cutting methods and is not on the ground This classification does not apply to wholesale tree removal TREE TRIMMER GROUNDMAN 02 01 2015 15 92 3 55 0 00 0 00 19 47 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 01 31 2016 16 32 3 55 0 00 0 00 19 87 This classification applies only to tree work done a for a utility company R E A cooperative or railroad or coal mining company and b for the purpose of operating maintaining or repairing the utility company s equipment and c by a person who is using hand or mechanical cutting methods and is on the ground This classification does not apply to wholesale tree removal Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 34 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Additional Apprentice Information Minimum wage rates for apprentices employed on public works projects are listed above as a percentage of the pre determined hourly wage rate established by the Commissioner under the provisions of the M G L 149 ss 26 27D Apprentice ratios are established by the Division of Apprenticeship Training pursuant to M G L c 23 ss LIE 11L All apprentices must be registered with the Division of Apprenticeship Training in accord
287. iversity of Massachusetts PM disapproves the request it shall notify the Contractor the Resident Engineer and the Designer in writing In such an event the Contractor may within 30 days from receipt of notice appeal such action to the Director of Facilities Planning see G L chapter 7 section 42G Failure to appeal within 30 days shall preclude any further claim of the Contractor for a contract adjustment The Director of Facilities Planning shall be considered the chief executive officer referred to in G L Chapter 30 Section 39Q 1 a e Further change order appeal proceedings shall be governed by the provisions of G L Chapter section 39Q and by the terms of the Contract including Article VII Section 5 relating to mandatory mediation procedures SECTION 4 AUTHORITY TO APPROVE REQUESTS FOR CHANGE 4 01 4 02 THE DIRECTOR OF FACILITIES PLANNING S APPROVAL SHALL BE REQUIRED WHENEVER a The cumulative cost of previously approved NOIs and approved Form 5s exceeds five percent of the original contract award price or b The estimate for the work on the NOI or Form 5 exceeds 5 000 WITH THE PRIOR WRITTEN APPROVAL OF THEIR ASSISTANT DIRECTOR FOR FACILITIES PLANNING THE UNIVERSITY OF MASSACHUSETTS AMHERST PM SHALL APPROVE CHANGE ORDERS FOR THE UNIVERSITY OF MASSACHUSETTS AMHERST WHEN a The cumulative cost of previously approved NOls and approved Form 5s is less than five percent of the original contract award price or b The
288. ividual telephone service and pay for all calls relating to the Work Service and equipment shall meet the requirements if any of the Supplementary General Conditions and Specifications and shall include provisions for incoming and outgoing calls 1 in the Contractor s field office for the use of its authorized agents and 2 in the Resident Engineer s office for the use of the Designer and authorized agents of the Owner 102 13 Health Safety and Accident Prevention A In performing the Work the Contractor shall 1 Ensure that no laborer or mechanic shall be required to work in surroundings or under working conditions which are unsanitary hazardous or dangerous to his her health and or safety as determined under construction safety and health standards promulgated by the U S Secretary of Labor by regulation 2 Protect the lives health and safety of other persons and 3 Prevent damage to property materials supplies and equipment B For these purposes the Contractor shall 1 Comply with 84 Stat 1590 the Occupational Safety and Health Act of 1970 OSHA and with regulations and standards issued by the U S Secretary of Labor at 29 CFR Part 1926 and 2 Include the terms of this Section 14 in every subcontract so that such terms will be binding on each subcontractor 3 Designate by notice to the Awarding Authority a responsible member of its organization at the Site whose duties shall include ensuring safety impl
289. ized Representative Division of Capital Asset Management Edited by UMass Amherst 1 19 2011 Page 1 of 12 INSTRUCTIONS INSTRUCTIONS TO BIDDERS 27 e This form must be completed and submitted by all Prime General contractors bidding on projects pursuant to M G L c 149 844A and M G L c 149A e You must give complete and accurate answers to all questions and provide all of the information requested MAKING A MATERIALLY FALSE STATEMENT IN THIS UPDATE STATEMENT IS GROUNDS FOR REJECTING YOUR BID AND FOR DEBARRING YOU FROM ALL PUBLIC CONTRACTING e Information is to cover the period from the date your most recent annual Certificate of Eligibility was issued not extended to the date of the bid e You must use this official form of Update Statement Copies of this form may be obtained from the awarding authority and from the Asset Management Web Site www mass gov cam e fadditional space is needed please copy the appropriate page of this Update Statement and attach it as an additional sheet e See the section entitled Bidding Limits in the Instructions to Awarding Authorities for important information concerning your bidding limits INSTRUCTIONS TO AWARDING AUTHORITIES Determination of Bidder Qualifications e tisthe awarding authority s responsibility to determine who is the lowest eligible and responsible bidder You must consider all of the information in the low bidder s Update Statement in making this deter
290. ject No insert project number Access to Contractor s Records Executive Order 195 The Governor or his designee the secretary of administration and finance and the state auditor or his designee shall have the right at reasonable times and upon reasonable notice to examine the books records and other 138 compilations of data of the Contractor which pertain to the performance and requirements of this Contract M Northern Ireland M G L c 7 8 22C Pursuant to G L c 7 s 22C for state agencies state authorities the House of Representatives or the state Senate the Contractor certifies that it does not employ ten or more employees in an office or other facility in Northern Ireland and if the Contractor employs ten or more employees in an office or other facility located in Northern Ireland the Contractor certifies that it does not discriminate in employment compensation or the terms conditions and privileges of employment on account of religious or political belief and it promotes religious tolerance within the work place and the eradication of any manifestations of religious and other illegal discrimination and the Contractor is not engaged in the manufacture distribution or sale of firearms munitions including rubber or plastic bullets tear gas armored vehicles or military aircraft for use or deployment in any activity in Northern Ireland ARTICLE XI CONTRACTOR S ACCOUNTING METHOD REQUIREMENTS M G L c 30 s 39R 1
291. king all safety devices to verify that they have come back on line after interruption This requirement will not be waived C The General Contractor shall schedule as per Section 015000 Temporary Facilities and Controls the shutting down or interrupting any utilities services or facilities which may affect the operation of the building outside the area of work or other buildings services or facilities of the UMA D Coordinate with UMA and the Designer work in connection with adjacent driveways walks or other facilities which would prevent access thereto or interrupt restrict or otherwise infringe upon the Operating Agency s use thereof E The General Contractor shall be aware of the sensitivity of the neighborhood organizations to noise dust debris vibration and site maintenance and take appropriate precautions to avoid conflict F Damage to existing work if caused by the General Contractor s operations under this Contract shall be repaired at the General Contractor s expense 1 An existing conditions survey shall be conducted with the Designer the UMA Project Manager and UMA representatives at which existing conditions will be videotaped by the General Contractor A copy of the videotape will be provided to the UMA Project Manager G Trenching and other work outside construction limits shall be expedited to fullest extent and carried out with minimum of inconvenience to normal operation of the Operating Agency and p
292. l Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 16 20 8 55 1 20 0 00 25 95 2 55 17 81 8 55 1 20 0 00 27 56 3 60 19 43 8 55 10 73 0 00 38 71 4 65 21 05 8 55 10 73 0 00 40 33 5 70 22 67 8 55 11 93 0 00 43 15 6 75 24 29 8 55 11 93 0 00 44 77 7 80 25 91 8 55 13 13 0 00 47 59 8 85 27 53 8 55 13 13 0 00 49 21 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 11 of 35 Classification Effective Date Base Wage Health Pension Supplemental Total Rate Unemployment FORK LIFT 06 01 2015 32 66 89 70 11 47 80 00 53 83 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 41 9 70 11 47 0 00 54 58 For apprentice rates see Apprentice OPERATING ENGINEERS GENERATORS LIGHTING PLANTS 06 01 2015 29 21 9 70 11 47 0 00 50 38 OPERATING ENGINEERS LOCAL 98 12 01 2015 29 96 9 70 11 47 0 00 51 13 For apprentice rates see Apprentice OPERATING ENGINEERS GLAZIER GLASS PLANK AIR BARRIER INTERIOR 06 01 2015 35 08 1025 8 00 0 00 53 33 SYSTEMS 06 01 2016 35 58 10 70 8 25 0 00 54 53 GLAZIERS LOCAL 1333 Apprentice GLAZIER Local 1333 Effective Date 06 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 17 54 10 25 1 00 0 00 28 79 2 56 19 73 10 25 1 00 0 00 30 98 3 63 21 93 10 25 1 50 0 00 33 68 4 69 24 12
293. l if the mediation process fails submit the dispute to a third party Neutral or Dispute Review Board which shall within sixty days render a non binding advisory opinion Unless the parties have previously agreed in writing to a process for submitting disputes to mediation or a Dispute Review Board the Awarding Authority shall determine in its reasonable discretion the procedures to be followed and shall give the Contractor notice of the same in writing within 7 days of the date that the Awarding Authority receives notice of the Contractor s appeal from the decision of the chief executive officer of the Awarding Authority or his designee The cost of the services of any mediator selected by one party to this Contract shall be borne by the party making the selection The cost of the services of any mediator selected jointly by the parties to this Contract or jointly by mediators selected by the parties to this Contract shall be borne equally by the Contractor and the Awarding Authority ARTICLE VIII PAYMENT PROVISIONS 1 Schedule of Values Before the first application for payment the Contractor shall submit to the Designer and the Awarding Authority a schedule of values allocated to various portions of the Work in sufficient detail to reflect the various major components of each trade with filed Subcontractors as well as MBE WBE noted including quantities when requested aggregating the total Contract Price and divided so as to facilitate payments
294. l Conditions or the Specifications 16 Furnishings and Equipment When in the opinion of the Designer any portion of the Work is in a reasonable condition to receive fittings furniture or other property of the Owner not covered by this Contract the Contractor shall allow the Awarding Authority to bring such fittings furniture and or other property into such portions of the Work and shall provide all reasonable facilities and protection thereof No such occupancy shall be construed as interfering with the provisions relating to time of completion or as constituting an acceptance of the whole or any part of the Work Any furniture or fittings so installed shall be placed in the Work at the risk of the Awarding Authority except that the Contractor shall be liable for damages or losses to such furniture or fittings to the extent such damages or losses arise in whole or in part from the negligence or intentional misconduct of Contractor Subcontractors their agents and or employees or anyone for whose acts Contractor is responsible 17 Form for Sub contract The Contractor when subcontracting with sub bidders filed pursuant to M G L c 149 s 44F shall use the form for sub Contract in M G L c 149 s 44F 4 c The Contractor shall not interpret paragraph 3 of the statutory form of Subcontract to require such sub bidders to provide insurance with limits higher than the limits that are required by Article XIV of these General Conditions of th
295. l be in writing and shall be submitted by the party making such claim to the other party before commencement of the pertinent work or within 10 days thereafter E The Awarding Authority and the Contractor shall negotiate in good faith an agreement on an equitable adjustment in the Contract Price and or time if appropriate before commencement of the pertinent work or as soon thereafter as is possible In the absence of an agreement for an equitable adjustment the Awarding Authority shall unilaterally determine the costs attributable to the change and provide the Contractor with a written notice to that effect The Contractor may appeal the decision of the Awarding Authority within thirty days of receipt of said notice to the chief executive official of the Awarding Authority or his designee and the Contractor shall have the right to such further appeal as is provided in M G L c 30 s 39Q set forth in Section 4 D of this Article VII However if the Contractor shall exercise its rights to appeal the decision of the Awarding Authority as aforesaid the Contractor shall be required to engage in the mandatory mediation procedures set forth in Section 5 of this Article VII F During the negotiation of an equitable adjustment in the Contract Price the Contractor shall if requested provide the Awarding Authority with all cost and pricing data used by him in computing the amount of the equitable adjustment and the Contractor shall certify that the 11
296. l provide via transmittal to the UMA Resident Engineer the following closeout submittals CONTRACT CLOSEOUT 10 14 2015 017700 6 of 9 4 5 2013rev UMA 16 12 MULLINS SECURITY CAMERAS Certification from the design Registered Professional Engineer stating that the fire protection systems have been installed in accordance with the approved fire protection construction documents and meet the requirements of 780 CMR 903 1 Structural Engineer of Record SER final report as required by 780 CMR 1705 3 Certification from the design Registered Professional Engineer stating that the emergency lighting and power systems have been installed in accordance with the approved electrical construction documents Upon completion of the Work for which a permit has been issued the DPS building official shall conduct a final inspection pursuant to 780 CMR 115 5 Prerequisites for UMA Certificate of Agency Use and Occupancy UMA Certificate of Agency Use and Occupancy E 1 Form Prior to requesting a Division of Capital Asset Management UMA Certificate of Agency Use and Occupancy the UMA Resident Engineer will procure and have ready and available the following approved items referred to as Closeout Submittals 1 2 12 13 Operating and maintenance amp manuals and written operating instructions for the various systems Catalog data sheets for each item of mechanical or electrical equipment actually installed including pe
297. l will not relieve the General Contractor from responsibility for errors of any sort in the shop drawings nor for the proper coordination of any submittal with all other work If the shop drawings deviate or are intended to deviate from the Contract Documents the General Contractor shall so advise the Designer in writing at the time the shop drawings are submitted stating the difference in value between the Contract requirements and that denoted by said shop drawings 6 The General Contractor shall assume full liability for delay attributed to insufficient time for delivery and or installation of material or performance of the work when approval of pertinent shop drawing is withheld due to the failure of the General Contractor to submit revise or resubmit shop drawings in adequate time to allow the Designer and the UMA Project Manager a reasonable time not to exceed twenty one 21 calendar days for normal checking and processing of each submission or resubmission Coordinate each submittal with requirements of Contract Documents The General Contractor s responsibility for errors and omissions in submittals is not relieved by the Designer s review and approval of submittals unless Designer gives tentative written acceptance of specific deviations identified as such by the General Contractor subject to written concurrence by the UMA Project Manager Notify the Designer in writing at the time of submission of deviations in submittals from
298. le for notifying MADEP if appropriate and any necessary outside responders unless the contractor has specified their own responder Contact the appropriate outside agencies as required by law including OSHA for fatalities or injuries requiring hospitalization of three or more individuals by Contractor All regulatory notifications required for environmental events shall be made by UMA EH amp S Contractors shall report any incident involving a radiographic source to UMA EH amp S the Mass Dept of Public Health DPH and The US Nuclear Regulatory Commission NRC Ensure the UMA EHS office is contacted as well for any of these circumstances 1 19 SAFETY REGULATIONS A This project is subject to compliance with Public Law 91 596 Occupational Safety and Health Act latest edition OSHA 29 CFR 1926 with respect to all rules and regulations pertaining to construction including Volume 36 numbers 75 and 105 of the Federal Register as amended and as published by the U S Department of Labor Submit the name of the General Contractor s safety officer to the UMA Project Manager Submit copies of safety reports to the UMA Project Manager monthly SUMMARY 10 14 2015 011000 15 of 20 5 1 2015 rev UMA 16 12 MULLINS SECURITY CAMERAS Each Contractor subcontractor will be responsible to submit a written Safety Program prior to starting construction outlining measures they take to cover their operations and protect their employees Con
299. lemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 15 32 7 85 0 00 0 00 23 17 2 55 16 85 7 85 1 57 0 00 26 27 3 60 18 38 7 85 1 71 0 00 27 94 4 65 19 91 7 85 1 85 0 00 29 61 5 70 21 44 7 85 11 45 0 00 40 74 6 75 22 97 7 85 11 59 0 00 42 41 7 80 24 50 7 85 11 73 0 00 44 08 8 90 27 57 7 85 12 02 0 00 47 44 Effective Date 01 01 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 15 77 7 85 0 00 0 00 23 62 2 55 17 34 7 85 1 57 0 00 26 76 3 60 18 92 7 85 1 71 0 00 28 48 4 65 20 49 7 85 1 85 0 00 30 19 5 70 22 07 7 85 11 45 0 00 41 37 6 75 23 65 7 85 11 59 0 00 43 09 7 80 25 22 7 85 11 73 0 00 44 80 8 90 28 38 7 85 12 02 0 00 48 25 Notes Steps are 750 hrs Apprentice to Journeyworker Ratio 1 1 PAINTER TAPER BRUSH REPAINT 07 01 2015 27 95 7 85 12 30 0 00 48 10 PAINTERS LOCAL 35 ZONE 3 01 01 2016 28 85 7 85 12 30 0 00 49 00 07 01 2016 29 70 7 85 12 30 0 00 49 85 01 01 2017 30 60 7 85 12 30 0 00 50 75 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 22 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice PAINTER Local 35 Zone 3 BRUSH REPAINT Effective Date 07 01 2015 Supplemental Step X percent Apprentice Base Wage Health Pension Unemployment Total Rate
300. less than one percent of the then adjusted total Contract Price or substantially all of the Work has been completed and opened to public use except for minor incomplete or unsatisfactory work items that do not materially impair the usefulness of the Work Superintendent The licensed construction supervisor who is an employee of the Contractor designated to be in full time attendance at the Site throughout the prosecution and progress of the Work and who shall have complete authority to act for the Contractor User Agency The department county commission board agency or other instrumentality of the Commonwealth of Massachusetts or political subdivision thereof which operates or which will operate the facility at which the Work is undertaken or which comprises the completed Work Work The Work defined in Article 1 of the Owner Contractor Agreement Article Il Section 2 of these General Conditions of the Contract and otherwise in the Contract Documents Working Hours 7 00 a m to 5 00 p m but not more than eight hours per day Monday through Friday unless otherwise specified by applicable Laws All terms that this Contract defines may be used with or without initial capital letters Other terms abbreviations and references are defined as they appear herein Words and abbreviations that are not defined in the Contract Documents but which have recognized technical or trade meanings are used in accordance with those meanings For addition
301. letic fields tennis courts and recreational areas The use of tobacco is prohibited inside any vehicle located on University grounds When any person enters the grounds of the University any smoking material shall be extinguished and disposed of in an appropriate receptacle at the perimeter of the grounds of the University The Contractor shall not allow the use of intoxicating beverages or non prescription controlled substance drugs upon or about the work site The Contractor shall provide and maintain in good serviceable condition at all times warning signs and non combustible barriers forms and fire resistive tarps or plastic each of which shall be approved by the University shall be suitable for the purpose and shall be installed adjacent to each work area for complete enclosure and or isolation of all excavations wells pits manholes shafts overhead areas etc which are associated with the work under the contract Barriers shall be a secure fence guardrail cover or similar assembly designed and erected to provide protection for concrete protection from the weather and to prevent accidental access Barrier tape and or sawhorses shall not be used as a means of such access protection 1 9 COORDINATION A l The General Contractor shall be responsible for the proper fitting of all the work and for the coordination of the operations of all Subcontractors or material and persons engaged upon the work The General Contractor
302. letter detailing the reason for disapproval to the Designer THE DESIGNER SHALL a b c d Review the Form 5 accompanying backup documentation and other relevant materials and determine whether the requested change is or is not covered under the contract If the Designer recommends approval of the Form 5 complete applicable portion of Section of Form 5 and attach its letter of recommendation which must include responses to each of the following eight 8 statements 1 If such change request involves any substitution or elimination of materials fixtures or equipment state the reasons why such components were included in the first instance and the reason for substitution or elimination and if the change request is of any other nature the reasons for such change giving justification therefore The designer shall state why all changes are necessary 2 Ifthe change involves additional work state why work was not covered by the plans and specifications Plan and specification references shall be stated 3 Review the contract documents and determine if all applicable credits due the Commonwealth University of Massachusetts Amherst are included and if salvageable 4 Astatement of concurrence that the description of the work in Section 1 h of Form 5 is accurate 5 The Designer has examined the Contractor s Proposal and finds the cost to be reasonable and mathematically correct Indicate which quantities and or costs appear
303. lified to perform the work to which the employment relates and secondly to citizens of the Commonwealth generally who have been residents of the Commonwealth for at least six months at the commencement of their employment and if they cannot be obtained in sufficient numbers then to citizens of the United States C Prevailing Wages The Contractor shall comply with M G L c 149 s 26 7H The prevailing wage schedule is found in Exhibit A to the Instructions to Bidders listing the prevailing minimum wage rates that must be paid to all workers employed in the Work The Awarding Authority is not responsible for any errors omissions or misprints in the said schedule Such Schedule shall continue to be the minimum rate wages payable to workers employed in the Work throughout the term of this Contract subject to the exceptions provided in M G L c 149 s 27 yearly review of wage rates The Contractor shall not have any claim for extra compensation from the Owner if the actual wages paid to workers employed in the Work exceeds the rates listed on the schedule or as otherwise provided by law The Contractor shall cause a copy of said Schedule to be kept in a conspicuous place at the Site during the term of the Contract If reserve police officers are employed by the Contractor they shall be paid the prevailing wage of regular police officers See M G L c 149 s 34B D Payroll Records and Statement of Compliance The Contractor shall comply and shall c
304. line interconnections between components for signal transmission and control Show cable types and sizes 3 Dimensioned plan and elevations of equipment racks control panels and consoles Show access and workspace requirements 4 UPS Sizing calculations 5 Wiring Diagrams For power signal and control wiring Equipment List Include every piece of equipment by model number manufacturer serial number location and date of original installation Add pretesting record of each piece of equipment listing name of person testing date of test set points of adjustments name and description of the view of preset positions description of alarms and description of unit output responses to an alarm INFORMATIONAL SUBMITTALS Seismic Qualification Certificates For video surveillance cameras camera supporting equipment accessories and components from manufacturer 1 Basis for Certification Indicate whether withstand certification is based on actual test of assembled components or on calculation Field quality control reports Warranty Sample of special warranty CLOSEOUT SUBMITTALS Operation and Maintenance Data For cameras power supplies infrared illuminators monitors digital video recorders video switches and control station components to include in operation and maintenance manuals QUALITY ASSURANCE Electrical Components Devices and Accessories Listed and labeled as defined in NFPA 70 by a qualified testin
305. lished by Subcontractor organizations The General Contractor shall coordinate the various Subcontractors and resolve any conflicts that may exist between Subcontractor tolerances without additional cost to UMA The General Contractor shall provide any chipping leveling shoring or surveys to ensure that the various materials align as detailed by the Designer and as necessary for smooth transitions not noticeable in the finished work 1 10 FIELD ENGINEERING A Provide field engineering services establish grades lines and levels by use of recognized engineering survey practices All field engineering surveying shall be performed by a licensed Land Surveyor registered in the Commonwealth of Massachusetts The General Contractor shall survey and submit exact dimensional layouts as required Engage and pay for the services of a Massachusetts Registered Surveyor acceptable to the UMA Project Manager to locate and protect control and reference points 1 11 REFERENCE STANDARDS A For products specified by association or trade standards comply with requirements for the standard except where more rigid requirements are specified or are required by codes Refer to Section 014200 REFERENCES Where reference is made in the Contractual Documents to Publications and Standards issued by Associations or Societies the intent shall be understood to specify the current edition of such Publications or Standards including tentative revision in effec
306. ll exceeds the raceway capacity allowed by the MEC Complete raceway installation between conductor and cable termination points according to Section 260533 Raceways and Boxes for Electrical Systems prior to pulling conductors and cables Use manufacturer approved pulling compound or lubricant where necessary compound used must not deteriorate conductor or insulation Do not exceed manufacturer s recommended maximum pulling tensions and sidewall pressure values Use pulling means including fish tape cable rope and basket weave wire cable grips that will not damage cables or raceway Install exposed cables parallel and perpendicular to surfaces of exposed structural members and follow surface contours where possible Support cables according to Section 260529 Hangers and Supports for Electrical Systems CONNECTIONS Tighten electrical connectors and terminals according to manufacturers published torque tightening values If manufacturer s torque values are not indicated use those specified in UL 486A 486B Make splices terminations and taps that are compatible with conductor material 1 Use oxide inhibitor in each splice termination and tap for aluminum conductors Wiring at Outlets Install conductor at each outlet with at least 6 inches of slack IDENTIFICATION Identify and color code conductors and cables according to Section 260553 Identification for Electrical Systems Identify each spare conductor at ea
307. ll accompany said description with a letter from the Contractor s independent certified public accountant approving or otherwise commenting on the changes D The Contractor represents that it has prior to the execution of the Contract filed a statement of management on internal accounting controls as set forth in Section 3 below E The Contractor represents that it has prior to the execution of the Contract filed an audited financial statement for the most recent completed fiscal year as set forth in section 4 below and will continue to file such statement annually during the term of the Contract 3 Statement of Management Controls A The Contractor shall file with the Awarding Authority a statement of management as to whether the system of internal accounting controls of the Contractor and its subsidiaries reasonably assures that 1 transactions are executed in accordance with management s general and specific authorization 2 transactions are recorded as necessary to a to permit preparation of financial statements in conformity with generally accepted accounting principles and b to maintain accountability for assets 3 access to assets is permitted only in accordance with management s general or specific authorization and 4 the recorded accountability for assets is compared with the existing assets at reasonable intervals and appropriate action was taken with respect to any difference B The Contractor shall file with t
308. ll be reported to EH amp S Oil is also considered to be a hazardous waste in the state of MA when it is disposed waste oil must be managed in accordance with the hazardous waste section of this document Non Destructive Testing The Contractor shall notify the U M A Project Manager and the Environmental Health and Safety Department 3 days prior to the use of a radiography or x ray equipment The Contractor shall demonstrate safety procedures acceptable to the University and also provide sufficient personnel to maintain the safety zone perimeter as SUMMARY 10 14 2015 011000 16 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS required by code UMA EHS must be contacted to review all radiography to be performed on campus property before it takes place In the event of a failed source it is the contractor s responsibility to recover a damaged radiography source moisture density gauge or other radioactive source used in the construction industry and to decontaminate any soil equipment or other university property contaminated by a failed source Any salamanders used must exhibit an approval tag from the Massachusetts State Fire Marshal and any Contractor intending to utilize a salamander shall meet the requirements of 527CMR 20 and obtain a permit from the local Fire Department All Hot Works including cutting welding brazing etc requires a permit from the UMA Environmental Health and Safety Dept EH amp S located
309. llowing RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS 10 14 2015 260533 1 of 6 2 2 I od m qu 9 6 1 2 3 UMA16 12 MULLINS SECURITY CAMERAS AFC Cable Systems Inc Allied Tube amp Conduit a Tyco International Ltd Co Thomas amp Betts Corporation Listing and Labeling Metal conduits tubing and fittings shall be listed and labeled as defined in NFPA 70 by a qualified testing agency and marked for intended location and application GRC Comply with ANSI C80 1 and UL 6 IMC Comply with ANSI C80 6 and UL 1242 EMT Comply with ANSI C80 3 and UL 797 FMC Comply with UL 1 zinc coated steel LFMC Flexible steel conduit with PVC jacket and complying with UL 360 Fittings for Metal Conduit Comply with NEMA FB 1 and UL 514B 1 Conduit Fittings for Hazardous Classified Locations Comply with UL 886 and the Massachusetts Electrical Code 25 Fittings for EMT a Material Steel b Type Compression 3 Expansion Fittings PVC or steel to match conduit type complying with UL 651 rated for environmental conditions where installed and including flexible external bonding jumper 4 Joint Compound for IMC GRC or ARC Approved as defined in NFPA 70 by authorities having jurisdiction for use in conduit assemblies and compounded for use to lubricate and protect threaded conduit joints from corrosion and to enhance their conductivity SURFACE RACEWAYS Listing and Labeling Surface raceways shall be list
310. lt of such operations Hazardous Waste Generation Any work generating Hazardous or so called Universal Wastes will comply with all requirements of 310 CMR 30 000 The proper storage use and disposal of any hazardous chemicals or substances brought on site by the Contractor are the responsibility of Contractor The University will not be responsible for any hazardous materials left on site the cost to remove these materials will be the Contractor s responsibility All hazardous wastes generated as a result of demolition and remodeling shall be contained collected segregated labeled per all applicable federal EPA Massachusetts DEP and Federal DOT regulations or other applicable local state or federal hazardous waste regulations pending the appropriate disposition Contractor shall provide for properly packaging hazardous waste preparing the proper shipping papers identifying a permitted disposal site and contacting EH amp S at least 24 hours prior to shipment of the waste EH amp S will review the hazardous waste shipment and sign the paperwork EH amp S must keep the Generator copies of the manifest on file in the EH amp S office The contractor must inform EH amp S if they intend to store any type of oil in 55 gallons or larger quantities so that such storage can be included in the UMass SPCC plan this includes oil for equipment form oil cutting oil diesel gasoline etc Spills of any oil outside to soil water or ambient air sha
311. lth Pension Total Rate Unemployment BARCO TYPE JUMPING TAMPER 06 01 2015 29 00 7 30 811 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER BATCH CEMENT PLANT ON SITE 06 01 2015 3244 8970 1147 80 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36 For apprentice rates see Apprentice OPERATING ENGINEERS BLOCK PAVER RAMMER CURB SETTER 06 01 2015 29 50 7 30 811 58 0 00 48 38 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 30 18 7 30 11 58 0 00 49 06 06 06 2016 30 87 7 30 11 58 0 00 49 75 12 05 2016 31 55 7 30 11 58 0 00 50 43 For apprentice rates see Apprentice LABORER BLOCK PAVER RAMMER CURB SETTER HEAVY amp 06 01 2015 29 24 7 30 10 18 0 00 46 72 HIGHWAY LABORERS ZONE 3 HEAVY amp HIGHWAY 12 01 2015 29 74 7 30 10 18 0 00 47 22 06 01 2016 30 24 7 30 10 18 0 00 47 72 12 01 2016 30 99 7 30 10 18 0 00 48 47 For apprentice rates see Apprentice LABORER Heavy and Highway BOILER MAKER 01 01 2015 40 32 6 97 16 21 80 00 63 50 BOILERMAKERS LOCAL 29 01 01 2016 41 62 6 97 16 21 0 00 64 80 01 01 2017 42 92 6 97 16 21 0 00 66 10 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 3 of 35 Supplemental Classification Effective Date Base
312. ly debarred from doing public construction work by any agency of the United States 65 Article 6 The Contract Documents The following documents from the Contract are incorporated by reference herein and are referred to as the Contract Documents The Instructions to Bidders The General Bid submitted by the Contractor This Owner Contractor Agreement including Exhibit A if any The General Conditions of the Contract The Supplementary General Conditions Note the term Supplementary General Conditions may also refer to Division 1 of the Specifications The Plans and Specifications including Addenda identified in Article 1 above All Approved Change Orders issued after execution of this Owner Contractor Agreement Article 7 Minority Business Enterprise and Women Business Enterprise Participation Goals and Minority Women Workforce Utilization Percentages The applicable goals if any for minority business enterprise and woman business enterprise participation established for this Contract are as follows The combined participation goal for Minority Women Business Enterprise for this Contract jg The applicable minority workforce utilization percentage if any is The applicable women workforce utilization percentage if any is The MBE WBE participation goal must include a reasonable representation of both MBE and WBE firms that meet or exceeds the combined goal MBE WBE participation plans that consist sole
313. ly of either a MBE or WBE representing 100 of the overall combined goals will not be considered reasonable or responsive Firms submitting MBE WBE participation plans which do not provide reasonable participation by both MBE WBE firms shall be provided an opportunity to revise and resubmit their plans within the time frame set by the awarding authority however no price adjustments shall be permitted as a result of the revised plan Firms failing to submit an MBE WBE participation plan deemed reasonable and accepted by the awarding authority shall not be awarded the contract Article 8 Liquidated Damages For the purposes of Article VI of the General Conditions of the Contract liquidated damages for delay shall be as follows 1 000 00 per day Article 9 Additional Insurance Provisions The insurance requirements set forth in Article XIV of the General Conditions of the Contract are supplemented by the provisions if any appearing in Exhibit A attached hereto and incorporated herein In witness whereof the parties hereto have caused this instrument to be executed in triplicate under seal as of the date set forth above 66 CONTRACTOR By Name Title Date AWARDING AUTHORITY By executing this Agreement the undersigned authorized signatory of the Awarding Authority who incurs no personal liability by reason of the execution hereof or anything herein contained hereby certifies under penalties of perjury that this Contr
314. m and wiring Install new cameras in locations shown on the drawings Wire to equipment cabinets shown in accordance to manufacturer s instructions Install data connection to UMA network Coordinate work with UMA OIT Make final connections and program as directed by UMA campus police Activate system and adjust cameras as directed by UMA Project Manager Test and provide training to end users SUPERVISION OF WORK A 1 The General Contractor shall be held directly responsible for the correct installation of all work performed under this Contract The General Contractor must make good repair without expense to the Commonwealth of any part of the new work or existing work to remain which may become inoperative on account of leaving the work unprotected or unsupervised during construction of the system or which may break or give out in any manner by reason of poor workmanship defective materials or any lack of space to allow for expansion and contraction of the work during the General Contractor s warranty period from the date of final acceptance of the work by the University of Massachusetts Amherst UMA The General Contractor shall furnish a competent Massachusetts licensed superintendent satisfactory to the UMA Project Manager and to the Designer The licensed superintendent shall supervise all work under this contract and who shall remain on duty at the site throughout the Contract period while work is in progress Submit the
315. m the site periodically and dispose of at legal disposal dump site DEP approved Handle material in a controlled manner with as few handlings as possible Do not drop or throw materials from heights Schedule cleaning operations so that dust and other contaminants resulting from cleaning process will not damage surrounding surfaces PARKING Parking Parking spaces on Campus are very limited and the University will not provide designated parking lot spaces near the construction site for the Contractor s use The Contractor shall contact Parking Services 545 0065 to determine the location of the nearest available parking spaces The Contractor will be required to pay all fees for parking The Contractor shall state his her parking and staging area requirements during the Pre construction Meeting The area s for materials storage will then be agreed to between the Contractor and the UMA Project Manager The limits of material storage will be delineated by the Contractor with construction fencing and enforced throughout the Contract DEBRIS CONTROL AND REMOVAL Debris shall not be permitted to accumulate or migrate and the work shall at all times be kept satisfactorily clean Facility trash receptors shall not be used for the disposal of debris Dumpster shall be provided by the General Contractor for removal of debris for all Subcontractors TEMPORARY FACILITIES AND CONTROLS 10 14 2015 015000 3 of 4 16 12 12 4 2012 rev MULLINS
316. materials ordered which shall not impede or otherwise interfere with construction progress The General Contractor shall present a list and written proof of all materials and equipment ordered through purchase orders Such list shall be presented at the meetings and shall be continuously updated Scheduling shall be discussed with all concerned parties and methods shall be presented by the General Contractor which shall reflect construction completion not being deferred or foreshortened Identify critical long lead items and other special scheduling requirements The project schedule is to include time for submission of shop drawing submittals time for review and allowance for resubmittal and review Project meetings shall be chaired by the Designer Minutes of the project meetings shall be prepared by the Designer and shall be distributed to all present The Designer s meeting minutes shall be the only official meeting record Minutes shall enumerate each topic item and each topic shall be updated at each progress meeting Actions to be taken for each topic shall be recorded along with identification of the party responsible for each action item Items shall not be removed from the Minutes until all issues with each item have been resolved 1 14 PERMITS INSPECTION AND TESTING REQUIRED BY GOVERNING AUTHORITIES A If the Contract Documents laws ordinances rules regulations or orders of any public authority having any jurisdiction
317. mination Remember this information was not available to the Division of Capital Asset Management at the time of certification bidder s performance on the projected listed in Parts 1 and 2 must be part of your review Contact the project references e AWARDING AUTHORITIES ARE STRONGLY ENCOURAGED TO REVIEW THE LOW BIDDER S ENTIRE CERTIFICATION FILE AT THE DIVISION OF CAPITAL ASSET MANAGEMENT Telephone 617 727 9320 for an appointment Bidding Limits Single Project Limit The total amount of the bid including all alternates may not exceed the bidder s Single Project Limit Aggregate Work Limit The annual value of the work to be performed on the contract for which the bid is submitted when added to the annual cost to complete the bidder s other currently held contracts may not exceed the bidder s Aggregate Work Limit Use the following procedure to Division of Capital Asset Management Prime General Contractor Update Statement Effective March 30 2010 Page 2 of 12 28 determine whether the low bidder is within its Aggregate Work Limit Step 1 Review Update Statement Question 42 to make sure that all requested information is provided and that the bidder has accurately calculated and totaled the annualized value of all incomplete work on its currently held contracts column 9 Step 2 Determine the annual dollar value of the work to be performed on your project This is done as follows i If the project i
318. misphere Hispanics Native Americans and Cape Verdeans Commission refers to the Massachusetts Commission Against Discrimination During the performance of this Contract the Contractor and all of its Subcontractors hereinafter collectively referred to as the Contractor shall comply with all applicable equal employment opportunity non discrimination and affirmative action requirements including but not limited to the following 2 Non Discrimination and Affirmative Action A The Contractor shall not discriminate against any employee or applicant for employment because of race color religious creed national origin age handicap sexual orientation or sex The aforesaid provision shall include but not be limited to the following employment upgrading demotion or transfer recruitment advertising recruitment layoff termination rates of pay or other forms of compensation conditions or privileges of employment and selection for apprenticeship The Contractor shall comply with the provisions of M G L c 151B and all other applicable anti discrimination and equal opportunity laws B The Contractor shall comply with the provisions of Executive Order 478 entitled Order Regarding Nondiscrimination Diversity Equal Opportunity and Affirmative Action which prohibits unlawful discrimination based on race color age gender ethnicity sexual orientation religion creed ancestry national origin disability veteran s status including Vi
319. mply with the requirements of the MEC the Massachusetts Building Code and University of Massachusetts Standards in addition to other references required by contract Job site safety and worker safety is the responsibility of the contractor ELECTRICAL WORK 10 14 2015 260001 4 of 5 2 13 2012rev UMA 16 12 MULLINS SECURITY CAMERAS C Electrical work shall be accomplished with all affected circuits or equipment de energized When an electrical outage cannot be accomplished in this manner for the required work the following requirements are mandatory 1 Electricians must use full protective equipment i e certified and tested insulating material to cover exposed energized electrical components certified and tested insulated tools etc while working on energized systems in accordance with NFPA 70E 2 Work on energized circuits or equipment cannot begin until prior written approval is obtained from the University Project Manager D For work on existing equipment arrange phase and perform work to assure electrical service for other buildings at all times E New work shall be installed and connected to existing work neatly and carefully Disturbed or damaged work shall be replaced or repaired to its prior Code compliant conditions as required by GENERAL REQUIREMENTS Coordinate location of equipment and conduit with other trades to minimize interferences 1 9 EQUIPMENT INSTALLATION AND REQUIREMENTS A Equipment locat
320. mponents required to aim and adjust cameras Initial setup shall be completed by a manufacturer s field service representative All required software shall be loaded and the system shall be configured per UMA requirements Any tools equipment computers etc required to setup and configure the complete camera system shall be by the manufacturer s representative FIELD QUALITY CONTROL Manufacturer s Field Service Engage a factory authorized service representative to inspect test and adjust components assemblies and equipment installations including connections Perform tests and inspections VIDEO SURVEILLANCE 10 14 2015 265700 7 of 9 3 5 G UMA16 12 MULLINS SECURITY CAMERAS Manufacturer s Field Service Engage a factory authorized service representative to inspect components assemblies and equipment installations including connections and to assist in testing Tests and Inspections 1 2 Inspection Verify that units and controls are properly installed connected and labeled and that interconnecting wires and terminals are identified Pretesting Align and adjust system and pretest components wiring and functions to verify that they comply with specified requirements Conduct tests at varying lighting levels including day and night scenes as applicable Prepare video surveillance equipment for acceptance and operational testing as follows a Prepare equipment list described in Informational Submittal
321. ms or equipment is required by the Contract Documents such certification must be stamped by a registered Massachusetts professional in the discipline required The Designer shall be entitled to rely upon the accuracy and completeness of such calculations and certifications K Materials furnished or used or employed under the Contract must be equal in quality to the samples furnished and be satisfactory to the Designer 3 Tests A Any material to be used in the Work may be tested or inspected at any time by the Designer with the prior Approval of the Awarding Authority and may be rejected if it fails to comply with specified tests The Awarding Authority shall pay for all testing of specified material If the Contractor requests permission to use a material that was not specified then the Contractor shall pay for such testing The cost of testing of materials that fail the testing criteria shall be borne by the Contractor B The Contractor shall notify the Designer and the Awarding Authority of the proposed sources of materials in time to permit all required testing and inspection before the material is needed for incorporation into the Work The Contractor shall have no claim arising from Contractor s failure to designate the proposed source or to order the material in time for adequate testing and inspection Necessary arrangements shall be made to permit the Designer to make factory shop or other inspection of materials or equipment ordered for
322. n Attachment B to these Instructions to Bidders 5 2 All entries on the Bid form shall be typewritten or in ink 5 3 Where so indicated on the Bid form sums shall be expressed in both words and numerals Where there is a discrepancy between the Bid sum expressed in words and the Bid sum expressed in figures the Bid sum expressed in words shall control unless the intention of the Bidder clearly is otherwise as determined by the Awarding Authority in its sole discretion 5 4 Each general Bidder shall acknowledge all required alternates in Section C on the Form for General Bid by entering the dollar amount of addition or subtraction necessitated by the alternate General Bidders shall enter on the Form for General Bid a single amount for each alternate that shall consist of the sub Bidders amounts and the amount for work performed by the general Bidder 5 5 If an alternate includes work within the Bidder s scope of work and does not involve a change in the cost of the Bid the Bidder shall so indicate by writing No Change or N C 0 in the space provided for that alternate Sub Bidders shall enter on the Form for Sub Bid the amount of addition or subtraction necessitated only for those alternates expressly identified in the Bid Documents as part of the sub Bidder s category of work If the alternate is not identified in the Bid Documents as affecting the sub Bidder s category of work then the sub Bidder shall so indicate by writing N A and
323. n Massachusetts G L Chapter 30 section 39 39 39N 39P 39Q Refer to Article of the General Conditions of the Contract All parties must keep themselves informed of any amendments affecting said statutes NO CHANGES ADDITIONS SUBSTITUTIONS OR ELIMINATIONS IN THE PLANS SPECIFICATIONS OR CONTRACT SHALL BE COMMENCED UNTIL RECEIPT BY THE CONTRACTOR OF a AN APPROVED BY THE UNIVERSITY OF MASSACHUSETTS AMHERST PURCHASE ORDER All requests for changes increasing the contract price must be submitted on the UMA Form 5 prior to the final acceptance of the project The Contractor waives all rights against the University of Massachusetts Amherst if it fails to comply with this requirement The University of Massachusetts Amherst shall be under no obligation to process a request for change after final acceptance of the project The term request for change is used throughout these procedures and applies to every request to revise the contract requirements The request for change must be made in writing and in accordance with the provisions of the Contract the General laws rules regulations and other procedures of the University of Massachusetts Amherst 171 1 02 GENERAL PURPOSE The purpose of these procedures is to properly authorize necessary changes provide satisfactory documentation supporting the nature and cost of each change and all the change order work to be accomplished in a timely and efficient manner It is the
324. n accordance with Approved submittals submitting Shop Drawings Product Data Samples and similar submittals the Contractor represents that the Contractor has determined and verified materials field measurements and field construction criteria related thereto and has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents The Contractor shall not be relieved of responsibility for deviations from requirements of the Contract Documents by the Designer s approval of Shop Drawings Product Data Samples or similar submittals unless the Contractor has specifically informed the Designer in writing of such deviation at the time of submittal and the Awarding Authority has given explicit written approval to the specific deviation The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings Product Data Samples or similar submittals by the Designer s or the Awarding Authority s actions 109 H The Contractor shall direct specific attention in writing or on resubmitted Shop Drawings Product Data Samples or similar submittals to revisions other than those requested by the Designer on previous submittals I Informational submittals upon which the Designer is not expected to take responsive action may be so identified in the Contract Documents J When professional certification of performance criteria of materials syste
325. n listed above provide the Awarding Authority with new performance and payment bonds as described in Paragraph A above Such bonds shall be provided solely at the Contractor s expense 2 Subcontractor Bonds A Ifthe Contractor provided in its General Bid that any or all filed subcontractors shall provide the Contractor with payment and performance bonds for the full amount of their respective Subcontracts then the costs for said bonds shall be the responsibility of the Contractor B Ifthe Contractor provided in its General Bid that filed Subcontractors shall provide bonds and subsequently waives the requirement the Contractor shall give the Awarding Authority a written certification that the Contractor understands that if the filed Subcontractor defaults or is terminated the Contractor shall have full responsibility for all costs and expenses related to said default or termination but shall be entitled to a credit adjustment to the Contract Price in an amount equal to the bond premium Contractor would have paid had Contractor required the filed Subcontractor to provide such bonds ARTICLE XVII TERMINATION OF CONTRACT 1 Termination for Cause A The Awarding Authority may without prejudice to any other right or remedy deem this Contract terminated for cause if any of the following defaults shall occur and not be cured within three 3 days after the giving of notice thereof by the Awarding Authority to the Contractor and any surety that
326. nager will attach the monetized punch list to the UMA Certificate of Agency Use and Occupancy indicate the official date of Use and Occupancy establish the date upon which all remaining punch list items must be completed normally 30 45 calendar days and procure appropriate signatures on the original and seven 7 copies 15 After receipt of signatures the UMA Project Manager will distribute the signed copies 16 Project schedules in Primavera format unless otherwise authorized baseline and all updates 17 Notification to Operating Agency and Or User Agency of Proposed Use and Occupancy Date The UMA Project Manager is to notify the Operating Agency and or User Agency of the project Use and Occupancy date at least seven 7 calendar days in advance Prerequisites for UMA Certificate of Final Inspection Release and Acceptance UMA Final Certificate of Final Inspection Release and Acceptance E 2 Form Upon receipt of the UMA Certificate of Agency Use and Occupancy and its adjunct monetized punch list the General Contractor shall cause the completion of all of the other punch list items within timeframe required by said certificate but not more than 45 calendars days if the timeframe is not indicated on the said certificate 1 If the General Contractor fails to pursue completion of the remaining monetized punch list work on a continual basis within the timeframe required by the certificate UMA may after seven 7 calendar days
327. name and resume of the superintendent for approval to the UMA Project Manager Include experience with projects of equal size and complexity SUMMARY 10 14 2015 011000 3 of 20 16 12 5 1 2015 rev MULLINS SECURITY CAMERAS 1 8 GENERAL CONTRACTOR S USE OF PREMISES A Use of the Site Confine operations to areas within contract limits indicated Do not disturb portions of the site beyond the areas in which the Work is indicated 1 Owner Occupancy Allow for Owner occupancy and use by the public if applicable Driveways and Entrances Keep driveways and entrances serving the premises clear and available to the Owner the Owner s employees and emergency vehicles at all times Do not use these areas for parking or storage of materials Schedule deliveries to minimize space and time requirements for storage of materials and equipment on site 3 Areas outside the Immediate Work Area The Contractor is responsible for clean up of all debris dirt and sediment resulting from the construction work B Schedule and perform work to afford minimum of interruption to normal and continuous operation of utility systems The General Contractor shall submit to UMA and the Designer for approval proposed schedule for performing work including construction of new utilities re routing of existing utilities and final connection of new work to existing work Schedule shall indicate shutdown time required for each operation 1 Work includes chec
328. ncy for violations of any laws or regulations related to occupational health or safety Note this information may be obtained from OSHA s Web Site at www osha gov Has your firm been sanctioned for failure to achieve DBE MBE WBE goals workforce goals or failure to file certified payrolls on any public projects Other than previously reported in the above paragraphs of this Section have any administrative proceedings or investigations involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled by any local state or federal agency relating to the procurement or performance of any construction contract Are there any other issues that you are aware which may affect your firm s responsibility and integrity as a building contractor Division of Capital Asset Management Sub bidder Update Statement Effective March 30 2010 Page 9 of 10 48 PART 5 SUPERVISORY PERSONNEL List all supervisory personnel who will be assigned to the project if your firm is awarded the contract Attach the resume of each person listed below NAME TITLE OR FUNCTION PART 6 CHANGES IN BUSINESS ORGANIZATION OR FINANCIAL CONDITION Have there been any changes in your firm s business organization financial condition or bonding capacity since the date your current Certificate of Eligibility was issued Yes If YES attach a separate page providing complete details
329. nd signed showing a quantities and costs utilizing unit pricing b the classification and hours of labor fringe benefits and the complete breakdown showing unit cost of material and equipment and c any other allowable costs as set forth in Article See also Section 5 below Upon completion of the work changes initially authorized by the NOI on a c Time and Materials basis must be adjusted by the University of Massachusetts Daily Time and Material Report Forms d If additional is requested furnish an explanation with breakdown Extensions of time shall not be granted on a retroactive basis because of changes e Each change must be all inclusive as to all costs and all time extensions f The General Contractor shall review all cost breakdowns being submitted by its suppliers and subcontractors and check them to insure the information being submitted is accurate and mathematically correct g Deliver one 1 Form 5 complete in accordance with these procedures to the University of Massachusetts Project Manager THE RESIDENT ENGINEER UNIVERSITY OF MASSACHUSETTS PM IF NO RESIDENT ENGINEER a Note the receipt of Form 5 in the record of NOIs Change Orders diary and daily report b Inform the Designer the University of Massachusetts Project Manager if applicable and the Project Engineer of the receipt of Form 5 c Review the From 5 accompanying backup documentation and other relevant materials and determine whether th
330. nder this contract and except for costs due to a suspension order the awarding authority shall not approve any costs in the claim incurred more than twenty days before the general contractor notified the awarding authority in writing of the act or failure to act involved in the claim 4 Use and Occupancy Prior to Final Acceptance A The Contractor agrees to the use and occupancy of the Project or any portion thereof before Final Acceptance of the Work by the Awarding Authority B The Awarding Authority and the User Agency will cooperate with the Contractor with respect to the completion of the Work by taking such reasonable steps as may be possible to avoid interference with the Contractor s Work provided that they do not interfere with the proper functioning of the facility C The Contractor shall not be responsible for wear and tear or damage resulting solely from temporary occupancy D Useand occupancy of any part of the Work prior to Final Acceptance by the Awarding Authority shall not relieve the Contractor from maintaining the required payment and performance bonds and insurance to the extent that insurance is required to be maintained after Substantial Completion required by this Contract 5 Certificate of Agency Use and Occupancy A When the Work or portion thereof which the Awarding Authority agrees to accept separately has reached the state of Substantial Completion as shown on Approved payment request the Contractor shall
331. nder which Bidder does business Business Address If selected Bidder is an individual doing business under a different name then Bidder must furnish evidence of any required DBA filing University of Massachusetts Amherst Facilities Planning Physical Plant Building 360 Campus Center Way Amherst MA 01003 9248 Telephone 413 545 1383 57 UNIVERSITY OF MASSACHUSETTS AMHERST FORM FOR SUB BID M G L c 149 s 44F as amended The following must be attached to or inserted into this Sub Bid or Trade Bid 1 Current Sub Bidder Certificate of Eligibility issued by the Division of Capital Asset Management and Maintenance showing the Sub Bidder or Trade Contractor is certified in the category of work for which this Sub Bid is submitted 2 Completed Sub Bidder Update Statement NOTE All information and the documents called for in the update statement must be supplied All information provided must be complete and accurate A defect or omission in the Update Statement may result in the rejection of the Bid Part 5 MUST list the NAMES of all supervisory personnel for this project 3 Bid deposit meeting the requirements of Section 5 13 and 5 14 of the Instructions to Bidders 58 To all General Bidders except those excluded A The undersigned proposes to furnish all labor and materials required for completing in accordance with the hereinafter described Plans Specifications and addenda all the work specified in Section No of
332. ne and anyone on campus inside buildings and throughout the grounds This policy applies to everyone and anyone including students staff faculty contractors and visitors For the purpose of this policy tobacco refers to any and all tobacco products whether inhaled or ingested as well as electronic cigarettes 1 The use of tobacco will be prohibited in all buildings and vehicles owned or leased by UMASS Amherst regardless of location 2 The use of tobacco will also be prohibited on all University grounds and in any outdoor area controlled by the University This includes all University land parking lots and parking ramps athletic fields tennis courts and recreational areas 3 The use of tobacco will be prohibited inside any vehicle located on University grounds 4 When any person enters the grounds of the University any smoking material shall be extinguished and disposed of in an appropriate receptacle at the perimeter of the grounds of the University Attention Contractors Effective July rs 2012 The University of Massachusetts Amherst will be posting all addenda to the procurement website http www umass edu procurement constructionprojects htm Effective July 1st 2012 the university will not be sending out hard copies of the addenda Notification will be sent via e mail to all plan holders of record once an addendum has been posted to the website t is the sole responsibility of the Bidder to ascertain
333. ner and UMA s Resident Engineer of such inspections at least three 3 business days in advance longer if so required in the various Sections of the Specifications so they may arrange to observe The General Contractor shall comply with all conditions and provide all notices required by all permits The General Contractor shall perform and or arrange for and pay all testing and inspections required by the Governing Codes and Authorities other than those provided by UMA and shall notify the Designer and UMA s Resident Engineer of such inspections at least three 3 business days in advance of all such testing or inspection so they may arrange to observe Where Inspecting Authorities require corrective work for conformance with applicable Codes and Authorities the General Contractor shall promptly comply with such requirements except in cases where such requirements clearly exceed the requirements of the Contract Documents in which case the General Contractor shall proceed in accordance with the procedures for modifications or changes in the work established in the Contract Documents as amended Prior to the start of construction the General Contractor shall complete applicable applications permits and notifications to the MADEP such as the Demolition Construction form BWP AQ 06 and the asbestos notification form ANF 001 and pay the required fees These forms must be submitted at least 10 working days in advance of any regulated acti
334. ng Other communications shall be similarly confirmed upon written request in each case The Superintendent shall attend each job meeting The Superintendent shall be responsible for coordinating all of the Work of the Contractor and the Subcontractors B The Superintendent shall be a competent employee regularly employed by the Contractor The Superintendent shall be licensed in accordance with the Building Code and shall have satisfactorily performed similar duties on previous construction projects similar in type complexity and scale to the Project The Superintendent s resume shall be submitted to the Awarding Authority prior to commencement of construction together with such other information as the Awarding Authority may reasonably require in order to determine whether or not to Approve of his or her appointment Any change in the Superintendent shall require the prior consent of the Awarding Authority The Contractor shall establish an emergency telephone line by which the Awarding Authority the Designer or their respective agents may contact the Superintendent during non working hours 4 Labor A The Contractor shall employ only competent workers The Contractor shall enforce strict discipline and good order among the Contractor s employees and other persons carrying out the Work The Contractor shall certify and insure that all employees to be employed at the worksite will have successfully completed a course in construction safety and he
335. ng Authority s Right to Waive Provision of this Article in Whole or in Part p 160 I Ae ON XM XH a do E e APPENDIX C COMMONLY USED FORMS p 161 Procedure for Payment to Contractors Payment Voucher Input Form Requisition for Payment Monthly Requisition Breakdown DCAM Form 55 Instructions Regarding Change Orders and Contract Modifications DCAM Form 13 Daily Time and Material Report for Change Orders Request and Agreement for a Change in the Plans Specifications and or Contract DCAM Form 5 Notice of Intent Contractor s Weekly Workforce Report Minorities Women in Contractor s Weekly Workforce Report 90 Weekly Payroll Report Form and Statement of Compliance Quarterly Projected Workforce Table Certification of Payment by Contractor to MBE WBE and Instructions Certificate of Completion by Minority Women Business Enterprise Form for Transfer of Title Work Not Incorporated DCAM Form 16 Certificate of Agency Use and Occupancy E 1 Certificate of Final Inspection Release and Acceptance E 2 91 ARTICLE I DEFINITION OF TERMS The following words shall have the following meanings as used in this Contract Advertisement The Advertisement or Notice Inviting Bids or Proposals for the Work identified in Article 6 of the Owner Contractor Agreement Approval or Approved An approval in writing signed by the authorized signatory of the Awarding Authority Architect The architect identified as the Designer in Article 1 o
336. ngineers ASME ASME International The American Society of Mechanical Engineers International ASTM ASTM International American Society for Testing and Materials International AWI Architectural Woodwork Institute REFERENCES 10 14 2015 014200 2 of 4 12 4 2012 rev AWPA AWS BHMA BIA CDA CISCA CRI CSI DHI EPA FM FMRC FSC GA GANA GS HPVA ICRI IESNA ILI ISO ISSFA ITS LEED MFMA NAAMM NAIMA NBGQA NCMA NeLMA NEMA NFPA NFRC NOFMA NRCA NSF NTMA NWWDA SDI SDI SGCC SJI SMACNA SSINA SSPC TCA UMA 16 12 MULLINS SECURITY CAMERAS American Wood Preservers Association American Welding Society Builders Hardware Manufacturers Association Brick Industry Association The Copper Development Association Ceilings amp Interior Systems Construction Association Carpet amp Rug Institute The Construction Specifications Institute The Door and Hardware Institute Environmental Protection Agency United States Factory Mutual Factory Mutual Research Now FM Global Forest Stewardship Council Gypsum Association Glass Association of North America Green Seal Hardwood Plywood amp Veneer Association International Concrete Repair Institute Inc Illuminating Engineering Society of North America Indiana Limestone Institute of America Inc International Organization for Standardization International Solid Surface Fabricators Association Intertek Testing Service NA Leadership in
337. ngs the Awarding Authority and Designer written acknowledgements from appropriate User and documents and framed data in the forms required by the Contract Documents 7 Complete all items required to be completed by the Department of Public Safety and obtain a Certificate of Occupancy from the Department of Public Safety or if the Awarding Authority is a municipality the building department having jurisdiction and similar releases which permit the User Agency and the Awarding Authority full and unrestricted use of the areas claimed to be ready for occupancy 8 Deliver specified maintenance stocks of materials required spare parts and all special tools furnished by manufacturers to persons designated by the Awarding Authority and obtain written receipts for same 9 Make final changes of lock cylinders or cores and advise the Awarding Authority of the change of project security responsibility 10 Complete start up of systems and instruct User Agency personnel on proper operation and routine maintenance of all systems and equipment obtain and submit to Agency personnel that start up and instruction have been completed 11 Remove all remaining temporary facilities that are no longer needed surplus materials and debris the Contractor shall not remove construction offices and trailers without the prior Approval of the Awarding Authority 12 Submit final utility meter readings and similar information and advise the User Agency and the
338. not pass tests and inspections END OF SECTION 260519 LOW VOLTAGE ELECTRICAL CONDUCTORS AND CABLES 10 14 2015 260519 4 of 4 16 12 MULLINS SECURITY CAMERAS SECTION 260526 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 A 1 2 A 1 3 A 1 4 A B RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY Section includes grounding and bonding systems and equipment ACTION SUBMITTALS Product Data For each type of product indicated QUALITY ASSURANCE Electrical Components Devices and Accessories Listed and labeled as defined in the Massachusetts Electrical Code by a qualified testing agency and marked for intended location and application Comply with UL 467 for grounding and bonding materials and equipment PART 2 PRODUCTS 2 1 A MANUFACTURERS Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the following 1 Burndy Part of Hubbell Electrical Systems Thomas amp Betts Corporation 3 O Z Gedney A Brand of the EGS Electrical Group GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 10 14 2015 260526 1 of 4 2 2 2 3 2 4
339. ns of the Work subject to the UMA Project Manager s approval The Schedule of Shop Drawings Product Data and Samples shall correspond with the construction schedule so that the submissions relate to the time when the products and or systems will be required on the site Neither the Designer nor the UMA Project Manager will approve a schedule that calls for out of sequence submittals B Shop Drawings 1 Original drawings shall be prepared by General Contractor Subcontractor Supplier or Distributor which illustrate some portion of the Work showing fabrication layout setting or erection of details a Shop drawings shall be prepared by a qualified detailer b Details shall be identified by reference to sheet and detail numbers indicated on Contract Drawings Maximum sheet size shall be 24 inch by 36 inch SUBMITTAL REQUIREMENTS 10 14 2015 013300 1 of 8 12 4 2012 16 12 MULLINS SECURITY CAMERAS d Submit with the required number of opaque prints specified and electronic media herein C Product Data 1 3 4 Manufacturers catalog sheets brochures diagrams schedules performance charts illustrations and other standard descriptive data Provide manufacturer s catalogue sheet specification for each product and other pertinent data as required under the individual specification a Modify product data submittals to delete information which is not applicable to the project b Supplemen
340. nt Committee of the Joint Venture described in Section of the Joint Venture Agreement continues to consist of who together have the power to bind the Joint Venture and the parties thereto 4 The Management Committee of the Joint Venture hereby appoints as an authorized representative of the Joint Venture who shall have the power individually to execute any and all documents in connection with the Contract and whose signature shall be binding upon the Joint Venture The Management Committee may modify or revoke such appointment and may appoint additional authorized representative s only with the consent of the Director of Facilities Planning University of Massachusetts Amherst and only by a written document executed by the members of the Management Committee 78 5 Nochanges in the Management Committee of the Joint Venture shall be effective without the written consent of the Director of Facilities Planning University of Massachusetts Amherst 6 No amendments to the Joint Venture Agreement shall be effective without the written consent of the Director of Facilities Planning University of Massachusetts Amherst 7 Byexecuting this certificate acknowledge that they are jointly and severally liable to the University of Massachusetts Amherst for all obligations of the Joint Venture This certificate is executed under seal as of the dates set forth opposite the last signature below a Massachusetts joint venture By a Massachuse
341. nto the University of Massachusetts Amherst in the sum of in lawful money of the United States of America to be paid to the University of Massachusetts Amherst for which payments well and truly to be made we bind ourselves our respective heirs executors administrators successors and assigns jointly and severally firmly by these presents Whereas the said principal has made a Contract with the University of Massachusetts Amherst Awarding Authority Bearing date of 20 for construction of UMA Number Project Name Now the condition of this obligation is such that if the principal shall pay for all labor performed or furnished and for all materials used or employed in said Contract and in any and all duly authorized modifications alterations extensions of time changes or additions to said Contract that may hereafter be made notice to the surety of such the foregoing to include any other purpose or items set out in and to be subject to provisions of Massachusetts General Laws Chapter 30 section 39A and Chapter 149 section29 as amended then this obligation shall become null and void otherwise it shall remain in full force and virtue In witness whereof we hereunto set our hand and seals this day of 20 Sea Print Name of General Contractor Print Name of Surety By Signature Title Signature Title Surety Address 70 PERFORMANCE BOND Know all men by these presents th
342. ntract Refer to Section 015000 Temporary Facilities and Controls for additional requirements SUMMARY 10 14 2015 011000 5 of 20 5 1 2015 rev UMA 16 12 MULLINS SECURITY CAMERAS Areas not to be used for storage include the areas under the drip line of trees planting beds and sidewalks Install temporary fencing around the drip line of trees and protect vegetation from construction damage Restoration of the delineated parking and storage area shall be as described in Section 017700 Contract Closeout Trailers or storage piles shall not be located over utility lines or their access points Radios tape players boom boxes or other audio entertainment equipment including personal entertainment devices shall not be allowed on the project site The University of Massachusetts prohibits tobacco use everywhere on campus inside buildings and throughout the grounds This policy applies to everyone and anyone on campus including students staff faculty contractors and visitors For the purpose of this policy tobacco refers to any and all tobacco products whether inhaled or ingested as well as electronic cigarettes The use of tobacco is prohibited in all buildings and vehicles owned or leased by UMass Amherst regardless of location The use of tobacco is prohibited on all University grounds and in any outdoor area controlled by the University This includes all University land parking lots and parking ramps ath
343. ntract Documents specifically require costs more than the item later approved as equal 2 the Bid Pricing Materials prove that the Contractor calculated its bid using the cost of the item later found as equal 3 any increase is reduced by any cost that the Contractor would have incurred for structural or mechanical changes necessary to accommodate the substitute item 4 the Contractor shall not be entitled to any adjustment for overhead and profit 5 any increase must exceed the aggregate amount that the Contractor saved using products or materials that the Awarding Authority approved as equal under this Contract In calculating the Contractor s aggregate saving under the preceding clause 5 the Contractor shall provide the Awarding Authority with the Bid Pricing Materials and a calculation based on the Bid Pricing Materials that compare the price stated in the Bid Pricing Materials of each item replaced with an or equal item with the cost of the approved equal item specifically describes all costs that Contractor would have incurred making structural or mechanical changes to include within the Work the item later found to have been improperly rejected and copies of all plans specifications shop Drawings and other design documents that the Awarding Authority deems necessary or desirable 5 Delivery and Storage of Materials Inspection A Materials and equipment shall be progressively delivered to the Site so that there will be neither
344. ntractor subcontractor or other person doing or contracting to do the whole or part of the Work shall be required or permitted to work more than eight hours in any one day or more than forty eight hours in any one week or more than six days in any one week except in cases of extraordinary emergency G Timely Payment of Wages The Contractor shall comply with and shall cause its Subcontractors to comply with M G L c 149 s 148 which requires the weekly or biweekly payment of employees within six days of the end of the pay period during which wages were earned if employed for five or six days of a calendar week and within other periods of time under certain circumstances as set forth therein H Lodging etc The Contractor shall comply with and shall cause its Subcontractors to comply with M G L c 149 s 25 which provides that every employee under this Contract shall lodge board and trade where and with whom he elects and neither the Contractor nor his agents or employees shall either directly or indirectly require as a condition of the employment of any person that the employee shall lodge board or trade at a particular place or with a particular person Truck Rates The use by the Contractor of trucks or other motor vehicles hired from either common or contract motor carriers in the course of performance of this Contract is subject to such minimum rates and charges and rules and regulations as may from time to time be promulgated
345. ny disputed order decision or action by the agency or its authorized representative shall be fully performed or complied with pending resolution of the dispute 122 b Within thirty days of submission of the dispute to the chief executive official of the state agency or his designee he shall issue a written decision stating the reasons therefore and shall notify the parties of their right of appeal under this section If the official or his designee is unable to issue a decision within thirty days he shall notify the parties to the dispute in writing of the reasons why a decision cannot be issued within thirty days and of the date by which the decision shall issue Failure to issue a decision within the thirty day period or within the additional time period specified in such written notice shall be deemed to constitute a denial of the claim and shall authorize resort to the appeal procedure described below The decision of the chief executive official or his her designee shall be final and conclusive unless an appeal is taken as provided below c Within twenty one calendar days of the receipt of a written decision or of the failure to issue a decision as stated in the preceding subparagraph any aggrieved party may file a notice of claim for an adjudicatory hearing with the division of hearing officers or the aggrieved party may file an action directly in a court of competent jurisdiction and shall serve copies thereof upon all other parties in
346. ny such appointment 2 Right of Access to Work The Awarding Authority the User Agency and the Designer and persons designated by them may for any purpose enter upon the Work the Site and premises used by the Contractor and the Contractor shall provide safe facilities therefore Other contractors of the Awarding Authority may also enter upon the same for the purposes which may be required by their contracts or work Any differences or conflicts which may arise between the Contractor and other contractors of the Awarding Authority with respect to their work shall be initially resolved by the Designer 3 Inspection No Waiver No inspection by the Awarding Authority or the Designer or employees or agents of either of them and no order measurement certificate approval payment order payment acceptance or any other action or inaction of any of them shall operate as a waiver by the Awarding Authority of any provision of this Contract 97 ARTICLE IV GENERAL PERFORMANCE OBLIGATIONS OF THE CONTRACTOR The Contractor shall complete for the Contract Price all of the Work in a proper thorough and workmanlike manner in accordance with the Contract Documents Without limiting the foregoing and without limiting the Contractor s obligations under any other provision of the Contract Documents the Contractor shall for the Contract Price perform the following general obligations 1 Review of Contract Documents and Field Conditions A Bef
347. o event prior to the seventieth day after substantial completion of the subcontract work the awarding authority shall make direct payment to the subcontractor of the balance due under the subcontract including any amount due for extra labor and materials furnished to the general contractor less any amount i retained by the awarding authority as the estimated cost of completing the incomplete or unsatisfactory items of work ii specified in any court proceedings barring such payment or iii disputed by the general contractor in the sworn reply provided that the awarding authority shall not deduct from a direct payment any amount as provided in part iii if the reply is not sworn to or for which the sworn reply does not contain the detailed breakdown required by subparagraph d The awarding authority shall make further direct payments to the subcontractor forthwith after the removal of the basis for deduction from direct payments made as provided in parts i and ii of this subparagraph f The awarding authority shall forthwith deposit the amount deducted from a direct payment as provided in part iii of subparagraph 5 in an interest bearing joint account in the names of the general contractor and the subcontractor in a bank in Massachusetts selected by the awarding authority or agreed upon by the general contractor and the subcontractor and shall notify the general contractor and the subcontractor of the date of the deposit and the bank re
348. of certification Division of Capital Asset Management Sub bidder Update Statement Effective March 30 2010 40 e The sub bidder s performance on the projected listed in Parts 1 and 2 must be part of your review Contact the project references e AWARDING AUTHORITIES ARE STRONGLY ENCOURAGED TO REVIEW THE SUB BIDDER S ENTIRE CERTIFICATION FILE AT THE DIVISION OF CAPITAL ASSET MANAGEMENT Telephone 617 727 9320 for an appointment Correction of Errors and Omissions in Sub bidder Update Statements Matters of Form An awarding authority shall not reject a sub bidder s bid because there are mistakes or omissions of form in the Sub bidder Update Statement submitted with the bid pursuant to M G L c 149 44D provided the sub bidder promptly corrects those mistakes or omissions upon request of the awarding authority 810 CMR 8 13 1 Correction of Other Defects An awarding authority may in its discretion give a sub bidder notice of minor defects and omissions as to form in the Sub bidder s Update Statement and provide an opportunity to correct its Sub bidder Update Statement However the sub bidder shall not be allowed to make corrections to a Sub bidder Update Statement if material information about the sub bidder was omitted from the Sub bidder Update Statement filed with the sub bidder s bid The Awarding Authority shall advise DCAM of any material omissions in a Sub bidder s Update Statement 810 CMR 8 13 2
349. of dollars The Unit Prices if any approved by the Awarding Authority are those included in the Contractor s General Bid The following Alternates have been accepted and their costs are included in the Contract Price Alternate No s Article 4 Approved Subcontractors The filed Subcontractors listed in the Contractor s General Bid submitted by the Contractor have been approved for the performance of the specified portions of the Work subject to the Commonwealth s verification that they have complied with state corporation and partnership registration laws No other filed Subcontractors and no non filed Subcontractors shall be used for these or any other portions of the Work without the prior written approval of the Awarding Authority Article 5 Certifications Pursuant to M G L c 62 c s 49A the individual signing this Contract on behalf of the Contractor hereby certifies under the penalties of perjury that to the best of his or her knowledge and belief the Contractor has complied with any and all applicable state and federal tax laws The individual signing this Contract on behalf of the Contractor further certifies under penalties of perjury that the Contractor is not presently debarred from doing public construction work in the Commonwealth under the provisions of M G L c 29 s 29F or any other applicable debarment provisions of any other chapter of the General Laws or any rule or regulation promulgated thereunder and is not present
350. of the Work Days Represents calendar days excluding weekend and holidays unless otherwise specified DCAM The Division of Capital Asset Management and Maintenance of the Commonwealth of Massachusetts Designer The architect or engineer identified as the Designer in Article 1 of the Owner Contractor Agreement subject to the provisions of Article Section 1 of these General Conditions of the Contract N A Dispute Review Board A panel of three experienced impartial reviewers organized and agreed upon by the Owner and Contractor The Board members are provided with plans and specifications become familiar with project procedures and participants and meet on the job site regularly to encourage the resolution of disputes at the job level and renders non binding recommendations on the resolution of the dispute Engineer The Designer except that the term Resident Engineer shall have the meaning otherwise specified herein Drawings The Drawings are the graphic and pictorial portions of the Contract Documents wherever located and whenever issued showing the design location and dimensions of the Work generally including Plans elevations sections details schedules and diagrams Final Acceptance The written determination by the Designer and by the Awarding Authority that the Work has been 100 completed except for the Contractor s indemnification obligations warranty obligations obligations to continue to maintain insuran
351. oject This Unilateral Change Order should not in any way be construed by the contractor to be an extension to the actual contract substantial completion date 3 Delays Statutory Provisions M G L c 30 s 390 A Notwithstanding any provision of this Contract to the contrary except as otherwise provided by law as set forth in paragraph B below the Contractor shall not be entitled to increase the Contract Price or to receive damages on account of any hindrances or delays avoidable or unavoidable but if any delay is caused in the opinion of the Designer by the Awarding Authority the Contractor shall be entitled to an extension of time The length of the extension shall be sufficient in the opinion of the Designer for the Contractor to complete the Work Although no delay shall increase the Contract Price the Awarding Authority may require that any change in the date by which the Contractor must complete all or any part of the Work be processed on a standard Change Order form B Ifa suspension delay interruption or failure to act of the Awarding Authority increases the cost of performance to any Subcontractor that Subcontractor shall have the same rights against the Contractor with respect to such increase as the Contractor shall have against the Awarding Authority by virtue of a and b of M G L c 30 s 390 set forth below but nothing in provisions a and b shall alter any other rights which the Contractor or the subcontractor may
352. om the owner or officials in charge of such landfills disposal or recycling facilities The Contractor shall bear all fees and costs in connection with such classification removal transportation disposal and storage The Contractor shall not permit any storage of debris or waste except in accordance with Laws C The Contractor shall not permit any open fire on the Site D Chemical Waste Chemical waste shall be stored in corrosion resistant containers removed from the Site and disposed of not less frequently than monthly unless more frequently required by Laws including without limitation hazardous materials laws or by the Supplementary General Conditions or Specifications Disposal of chemical waste shall be performed in accordance with requirements of the U S Environmental Protection Agency EPA and the Massachusetts Department of Environmental Protection DEP Fueling and lubricating of vehicles and equipment shall be conducted in a manner that affords the maximum protection against spills and evaporation Lubricants shall be disposed of in accordance with procedures meeting all applicable Laws The Contractor shall immediately notify the Designer of any hazardous materials release large enough to require reporting under applicable Laws The Contractor shall be responsible for immediately cleaning up in accordance with Laws any oil or hazardous materials releases resulting from its operations Any costs incurred in cleaning up any such rele
353. ompatible and UL listed for use with the University s existing Honeywell Fusion NVR system and software All workers on the security camera system shall hold valid Massachusetts S license The work will include all operations necessary to deliver the building s and ancillary on and off site amenities in a fully installed and operable condition including all utility and site work and obtaining all necessary licenses permits and certificates The scope of work without limiting the generality thereof includes all labor materials equipment and services required to perform the work described fully in the Drawings and Specifications Reference to Drawings The work to be done under this Contract is shown on the Drawings listed at the end of this Section Work will include all site removal and new construction for the Mullins Security Camera Project including electrical work as required The General Contractor will provide a schedule for completion of the project to the Owner within the required construction period 1 4 EXAMINATION OF SITE AND DOCUMENTS A A pre bid conference will be held at the job site on the date and at the time indicated in the Invitation to Bid The bidders are expected to examine and to be thoroughly familiar with all contract documents and with the conditions under which the work is to be carried out UMA will not be responsible for errors omissions and or charges for extra work arising from th
354. on shall be valid except as provided in M G L c 30 s 39F of the General Laws 4 No Personal Liability of Public Officials No public official employee or agent of the Awarding Authority or Owner shall have any personal liability for the obligations of the Awarding Authority or Owner set forth in this Contract 5 Severability The provisions of this Contract are severable and if any of these provisions shall be held unconstitutional or unenforceable by any court of competent jurisdiction the decision of such court shall not affect or impair any of the other provisions of this Contract 6 Choice of Laws This Contract shall be governed by the laws of the Commonwealth of Massachusetts for all purposes without regard to its laws on choice of law All proceedings under this Contract or related to the Project shall be brought in the courts of the Commonwealth of Massachusetts 7 Standard Forms Unless directed otherwise in writing by the Awarding Authority Contractor shall use the standard forms in use by the Awarding Authority and or Division of Capital Asset Management and Maintenance appearing in Appendix C to these General Conditions of the Contract 8 No Waiver of Subsequent Breach No waiver of any breach or obligation of this Contract shall constitute a waiver of any other or subsequent breach or obligation 9 Remedies Cumulative All remedies of the Awarding Authority provided in this Contract shall be construed as cum
355. onable for acceptance without further competition 9 8 If the Awarding Authority decides to reject all general Bids or if the Awarding Authority does not receive any general Bids the Awarding Authority may retain and use the sub Bids received for a second opening of general Bids provided however that there are no changes in the work involved for the sub trades for which the sub Bids are so retained and used and provided further that the Awarding Authority shall obtain the consent of each sub Bidder included in any award of a general Contract made pursuant to the second opening of general Bids if such award is not made within ninety days Saturdays Sundays and legal holidays excluded after the opening of such sub Bids SECTION 10 EXECUTION OF CONTRACTS 10 1 If a selected filed sub Bidder fails within five days Saturdays Sundays and legal holidays excluded after presentation of a Subcontract by the general Bidder to which the Contract was awarded to perform its agreement to execute a Subcontract in the form provided by the Awarding Authority with such general Bidder contingent upon the execution of the general Contract and if requested to do so by such general Bidder in the general Bid to furnish a performance and a payment bond as stated in its filed sub Bid such general Bidder and the Awarding Authority shall select from the other filed sub Bids duly filed with the Awarding Authority for such sub trade and not rejected the lowest re
356. one 3 Effective Date 04 01 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 55 18 22 9 80 4 48 0 00 32 50 2 65 21 53 9 80 13 36 0 00 44 69 3 75 24 85 9 80 14 18 0 00 48 83 4 85 28 16 9 80 14 99 0 00 52 95 Notes Steps are 2 000 hours Apprentice to Journeyworker Ratio 1 5 Issue Date 09 17 2015 Wage Request Number 20150917 043 Page 18 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment MORTAR MIXER 06 01 2015 29 00 7 30 811 58 0 00 47 88 LABORERS ZONE 3 BUILDING amp SITE 12 07 2015 29 68 7 30 11 58 0 00 48 56 06 06 2016 30 37 7 30 11 58 0 00 49 25 12 05 2016 31 05 7 30 11 58 0 00 49 93 For apprentice rates see Apprentice LABORER OILER 06 01 2015 28 13 9 70 11 47 80 00 49 30 OPERATING ENGINEERS LOCAL 98 12 01 2015 28 88 9 70 11 47 0 00 50 05 For apprentice rates see Apprentice OPERATING ENGINEERS OTHER POWER DRIVEN EQUIPMENT CLASS VI 06 01 2015 26 15 9 70 11 47 0 00 47 32 OPERATING ENGINEERS LOCAL 98 12 01 2015 26 90 9 70 11 47 0 00 48 07 For apprentice rates see Apprentice OPERATING ENGINEERS PAINTER BRIDGES TANKS 07 01 2015 48 56 87 85 16 10 80 00 72 51 PAINTERS LOCAL 35 ZONE 3 01 01 2016 49 51 7 85 16 10 0 00 73 46 07 01 2016 50 46 7 85 16 10 0 00 74 41 01 01 2017 51 41 7 85 16 10 0 00 75 36 Apprentice PAINTER Local 35
357. ons on the Work that must be done before Final Acceptance a If a DPS inspector including but not limited to AABA boiler elevator or any other authorized inspector requires modifications and or additions that were not included in the construction documents the Designer should review the applicable code s and provide written interpretation to the UMA Project Manager together with his her recommendations The General Contractor shall immediately correct all punch list items that affect health safety or function as determined by the Designer completion of which is required before issuance of a UMA Certificate of Agency Use and Occupancy Upon receipt of the UMA Certificate of Agency Use and Occupancy and its adjunct monetized punch list the General Contractor shall cause the completion of all of the other punch list items within the timeframe required by said certificate but not more than 45 calendar days if the timeframe is not indicated on the said certificate There is a history of specific items that are essential to the Use and Occupancy but are frequently overlooked Some things to watch for are Provide properly colored and positioned exit signs Properly located emergency lighting fixtures Complete or by agreement schedule personnel training Final cleaning Ventilating systems 1 Clean permanent filters and replace disposable filters if units were operated during construction 2 Clean ducts blowers and coils
358. ontract the Awarding Authority determines or has reason to believe that 1 there has been a change or reduction in any M WBE Work which will result in the Contractor failing to meet the M WBE participation goal s for this Contract other than a reduction in M WBE Work resulting from a change in the Contract work ordered by the Awarding Authority and 2 the Contractor has failed to comply fully with all of the terms and conditions of paragraphs 1 through 7 above the Awarding Authority may 1 suspend payment to the Contractor of an amount equal to the value of the work which was to have been performed by an M WBE pursuant to the Contractor s Schedule of M WBE Participation but which was not so performed in order to ensure that sufficient Contract funds will be available if liquidated damages are assessed pursuant to paragraph 9 and or 2 suspend the Contractor s performance of this Contract in whole or in part B The Awarding Authority shall give the Contractor prompt written notice of any action taken pursuant to paragraph A above and shall give the Contractor and any other interested party including any M WBEs an opportunity to present evidence to the Awarding Authority that the Contractor is in compliance with the requirements of this Article or that there is some justifiable reason for waiving the requirements of this Article in whole or in part The Awarding Authority may invite SOMWBA and the Massachusetts Commission Against Discrimina
359. ontractor proposes to perform the work described above in accordance with the provisions of Article VII of the contract and certifies that the attached cost data is accurate complete and current and mathematically correct Payment shall be made on the basis of a Predetermined lump sum total of add deduct b Lump Sum not to exceed add deduct 5 max price based on contract unit prices or negotiated agreed unit prices c Time and Materials Basis not to exceed add deduct Computed in accordance with Article VII of the contract Require authorization of Commissioner Place X beside selected proposal method and strike out either add or deduct whichever does not apply Attach detailed estimates and break down for above in accordance with change order instructions A claim for work performed under protest shall be submitted per c above An extension of contract time of calendar days is requested Contractor by Firm Name Authorized Signature Date Ill APPROVAL RECOMMENDED BY The Designer and the Resident Engineer must attach their respective letters of recommendation with responses to questions listed in Form 13 change order instructions Adverse or altered recommendation must be delineated on the letters Resident Engineer Date Designer Date Project Engineer Date Do Not Fill in This Block Project Manager Date Contract Award Deputy Director Date Previous Addition IV APPROVED BY THE
360. operly completed Sub Bidder Update Statement shall be enclosed in a sealed envelope with the following plainly marked on the outside Filed Sub Bid for UMA No Project No Title Sub Bid Section No Trade Sub Bidders name business address and telephone number 6 2 Each general Bid including the bid deposit DCAM Certificate of Eligibility CQ7 and properly completed Update Statement CQ3 shall be enclosed in a sealed envelope with the following plainly marked on the outside General Bid for UMA No Project No Title General Bidders name business address and telephone number 6 3 All Bids must be received by the Procurement Department at the address specified on page 8 of these Instructions to Bidders no later than the applicable date and time specified on page 8 of these Instructions to Bidders Any Bid not received by the applicable deadline will not be accepted 6 4 Bidding results will not be given out over the telephone prior to 1 00 PM of the day following the Bid opening 15 SECTION 7 WITHDRAWAL OF BIDS REJECTION OF BIDS 7 1 Any Bid may be withdrawn prior to the specified deadline for the receipt of Bids provided that the withdrawal shall be made by a written request signed by a person having the authority to bind the Bidder The written request must be hand delivered or otherwise delivered to the University of Massachusetts Amherst Attn Director of Procurement Procurement Office Room 407 Good
361. or anyone with a financial interest in your firm from public contracting Have any judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled relating to a violation of state or federal law regulating the environment 10 Has your firm been fined by OSHA or any other state or federal agency for violations of any laws or regulations related to occupational health or safety Note this information may be obtained from OSHA s Web Site at www osha gov 11 Has your firm been sanctioned for failure to achieve DBE MBE WBE goals workforce goals or failure to file certified payrolls on any public projects 12 Other than previously reported in the above paragraphs of this Section have any administrative proceedings or investigations involving your firm or a principal or officer or anyone with a financial interest in your firm been brought concluded or settled by any local state or federal agency relating to the procurement or performance of any construction contract 13 Are there any other issues that you are aware which may affect your firm s responsibility and integrity as a building contractor Division of Capital Asset Management 37 Prime General Contractor Update Statement Effective March 30 2010 Page 11 of 12 PART 5 SUPERVISORY PERSONNEL List all supervisory personnel such as project managers and superintendents
362. or each raceway size B Colors for Raceways Carrying Circuits at 600 V or Less 1 Black letters on an orange field 2 Legend Indicate voltage and system or service type Vinyl Labels for Raceways Carrying Circuits at 600 or Less Preprinted flexible label laminated with a clear weather and chemical resistant coating and matching wraparound clear adhesive tape for securing ends of legend label D Fire alarm raceways junction boxes shall be red in color 2 2 CONDUCTOR IDENTIFICATION MATERIALS Color Coding Conductor Tape Colored self adhesive vinyl tape not less than 3 mils thick by 1 to 2 inches wide B Marker Tapes Vinyl or vinyl cloth self adhesive wraparound type with circuit identification legend machine printed by thermal transfer or equivalent process 1 Marker for Tags Permanent waterproof black ink marker recommended by tag manufacturer 2 Labels Tags Self adhesive label machine printed with permanent waterproof black ink recommended by printer manufacturer sized for attachment to tag 2 3 WARNING LABELS AND SIGNS A Comply with NFPA 70 and 29 1910 145 IDENTIFICATION FOR ELECTRICAL SYSTEMS 10 14 2015 260553 2 of 4 UMA16 12 MULLINS SECURITY CAMERAS B Self Adhesive Warning Labels Factory printed multicolor pressure sensitive adhesive labels configured for display on front cover door or other access to equipment unless otherwise indicated 2 4 EQUIPMENT I
363. or in any way affecting the conduct of the Work and of all orders and decrees of bodies or tribunals having any applicable jurisdiction or authority over the Work 2 Compliance with all Laws The Contractor shall cause all persons employed in the performance of the Work to comply with all existing and future Laws including but not limited to those set forth below A Corporate Disclosures The Contractor if a foreign corporation shall comply with M G L c 181 s 3 and s 5 and M G L c 30 s 39L 135 Employment Eligibility Verification The Contractor shall comply with Federal Department of Homeland Security Requirements in hiring any and all Employees to be employed in the Project who are required to be listed in the certified payroll reports for the Project Such compliance shall include but not be limited to the faithful completion of the Federal Department of Homeland Security Form 1 9 process by the Contractor for each of its Employees The Contractor shall execute a Certificate of Compliance with Employment Eligibility Verification Requirements I 9 Certificate with the execution of its Contract The Contractor shall require each of its subcontractors and sub subcontractors to execute and provide to Contractor 1 9 Certificate with the execution of each subcontract and Contractor shall immediately provide a copy to Awarding Authority Contractor acknowledges that the weekly workforce report form contained in the contr
364. or listed above and does not constitute acknowledgement that such labor is for extra work or that additional monies are due for such work 1 Materials Used Describe fully 2 Misc Equipment Etc Describe fully Submitted by Superintendent 166 Subcontractors Resident Engineer University of Massachusetts Amherst Project Manager note any discrepancy in above Report Resident Engineer University of Massachusetts Amherst Project Manager The signature of the Resident Engineer Project Manager is for verification of materials listed above and does not constitute acknowledgement that such material is for extra work or that additional monies are due for such work Send one copy with Daily Report Each Day Other copy to accompany Green Sheets to Designer when Change Order is completed 167 NOTICE INTENT 4 University of Massachusetts Amherst Facilities Planning Contract Modification Authorization to Proceed For Change Authorization in the Contract Plans and or Specifications Date UMA Number Project Number Project Name Contractor Contract Start Date Contract Award 5 NOI Request No Change Order No Requestor Nature of Request G C PCO No Date Reason for Request Designer s CCR No Date This change in work is to be performed according to ARTICLE VII of the General Conditions of the Contract Change Orders will be in accordance wi
365. or shall provide all information and reports required by the Awarding Authority or the Commission on forms and in accordance with instructions issued by either of them and will permit access to its facilities and any books records accounts and other sources of information which may be determined by the Awarding Authority or the Commission to affect the employment of personnel This provision shall apply only to information pertinent to the Owner s supplementary affirmative action Contract requirements Where information required is in the exclusive possession of another who fails or refuses to furnish this information the Contractor shall so certify to the Awarding Authority or the Commission as appropriate and shall set forth what efforts he has made to obtain the information 4 Sanctions A Whenever the Awarding Authority the Commission or the Liaison Committee believes the Contractor or any Subcontractor may not be operating in compliance with the terms of this Article the Commission shall directly or through its designated agent conduct an appropriate investigation and may confer with the parties to determine if such Contractor is operating in compliance with the terms of this Article If the Commission or its agent finds the Contractor or any Subcontractor not in compliance it may make a preliminary report on non compliance and notify such Contractor in writing of such steps as will in the judgment of the Commission or its agent bring s
366. ore commencing the Work the Contractor shall carefully study the Contract Documents and carefully compare all Specifications Plans Drawings figures dimensions lines marks scales directions of the Designer and any other information provided by the Awarding Authority and shall at once report to the Designer any questions errors inconsistencies or omissions B Before commencing the Work the Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to the Contractor with the Contract Documents and shall at once report to the Designer any questions errors inconsistencies or omissions 2 Supervision and Construction Procedures Coordination Cutting and Patching A The Contractor shall supervise and direct the Work using the Contractor s best skill and attention The Contractor shall be solely responsible for and shall have control over construction means methods techniques sequences and procedures and shall be responsible for coordinating all portions of the Work under the Contract B The Contractor shall be responsible for the proper fitting of all Work and the coordination of the operations of all trades Subcontractors and material men engaged upon the Work The Contractor shall guarantee to each of its Subcontractors all dimensions which they may require for the fitting of their work to all surrounding work C All nec
367. ory Provisions Regarding Changes A Criminal Penalties The Contractor s attention is directed to M G L 30 s 391 which provides criminal penalties for unauthorized deviations from the Plans and Specifications and to M G L c 30 s 39 and M G L c 7 5 42 421 The Contractor s attention is also directed to M G L 266 s 67B which provides criminal penalties for false claims by Contractor under this Contract Whoever makes or presents to any employee department agency or public instrumentality of the commonwealth or of any political subdivision thereof any claim upon or against any department agency or public instrumentality of the commonwealth or any political subdivision thereof knowing such claim to be false fictitious or fraudulent shall be punished by a fine of not more than ten thousand dollars or by imprisonment in the state prison for not 121 more than five years or in the house of correction for not more than two and one half years or both B Differing Site Conditions M G L 30 s 39N If during the progress of the work the contractor or the awarding authority discovers that the actual subsurface or latent physical conditions encountered at the Site differ substantially or materially from those shown on the plans or indicated in the contract documents either the contractor or the contracting authority may request an equitable adjustment in the contract price of the contract applying to work affecte
368. paces it shall be the responsibility of the Contractor entering the space to have in place a Permit Required Confined Space Entry Program that meets OSHA 29CFR 1910 146 requirements No entry shall be made without the permit UMass requires that confined spaces encountered in construction projects be evaluated and entered in accordance with 1910 146 It is also the responsibility that any work performed under this contract in PRCS s be performed in strict compliance with the contractor s own PRCS OSHA Policy At the conclusion of any work in a PRCS the General Contractor shall debrief the Project Manager and provide copies of the documentation required under the Contractor s PRCS Policy If University personnel must enter the PRCS a separate UMass Permit will be issued 1 20 OSHA SAFETY AND HEALTH COURSE DOCUMENTATION A OSHA Safety and Health Course Documentation Records Chapter 306 of the Massachusetts Acts of 2004 requires that everyone employed at the jobsite must complete a minimum 10 hour long course in construction safety and health approved by the U S Occupational Safety and Health Administration OSHA prior to working at the jobsite Compliance is required of General Contractors and Subcontractors on site employees at all levels whether stationed in the trailer or working in the field Unless the Massachusetts Attorney General s office indicates otherwise this requirement does not apply to home office employees visit
369. payment indicates that the contractor has not paid subcontractors as provided in section thirty nine F If the awarding authority fails to make payment as herein provided there shall be added to each such payment daily interest at the rate of three percentage points above the rediscount rate than charged by the Federal Reserve Bank of Boston commencing on the first day after said payment is due and continuing until the payment is delivered or mailed to the contractor provided that no interest shall be due in any event on the amount due on a periodic estimate for final payment until fifteen days twenty four days in the case of the commonwealth after receipt of such period estimate from the contractor at the place designated by the awarding 127 authority if such a place is so designated The contractor agrees to pay to each subcontractor a portion of any such interest paid in accordance with the amount due each subcontractor The awarding authority may make changes in any periodic estimate submitted by the contractor and the payment due on said periodic estimate shall be computed in accordance with the change so made but such changes or any requirement for a corrected periodic estimate shall not affect the due date for the periodic payment or the date for the commencement of interest charges on the amount of the periodic payment computed in accordance with the changes made as provided herein provided that the awarding authority may within se
370. pigtails that are not less than 6 inches 152 mm in length 5 When there is a choice use side wiring with binding head screw terminals Wrap solid conductor tightly clockwise two thirds to three fourths of the way around terminal Screw 6 Use a torque screwdriver when a torque is recommended or required by manufacturer 7 When conductors larger than No 12 AWG are installed on 15 or 20 A circuits splice No 12 AWG pigtails for device connections WIRING DEVICES 10 14 2015 262726 4 of 5 3 2 3 3 3 4 16 21 MULLINS SECURITY CAMERAS 8 Tighten unused terminal screws on the device 9 When mounting into metal boxes remove the fiber or plastic washers used to hold device mounting screws in yokes allowing metal to metal contact Receptacle Orientation 1 Install ground pin of vertically mounted receptacles down and on horizontally mounted receptacles to the right 2 Install hospital grade receptacles in patient care areas with the ground pin or neutral blade at the top Device Plates Do not use oversized or extra deep plates Repair wall finishes and remount outlet boxes when standard device plates do not fit flush or do not cover rough wall opening GFCI RECEPTACLES Install non feed through type GFCI receptacles where protection of downstream receptacles is not required IDENTIFICATION Comply with Section 260553 Identification for Electrical Systems Identify each receptacle with panelboard identi
371. promptly and in any event no later than thirty days after the written submission for decision but if such decision requires extended investigation and study the awarding authority the official architect or engineer shall within thirty days after the receipt of the submission give the party making the submission written notice of the reasons why the decision cannot be made within the thirty day period and the date by which the decision will be made D Change Order Contract Interpretation Appeal Procedure M G L 30 5 390 The following provisions apply to every contract awarded by any state agency as defined by M G L 7 5 39A for the construction reconstruction alteration remodeling repair or demolition of any capital facility as defined by the aforesaid section 39A a Disputes regarding changes in and interpretations of the terms or scope of the contract and denials of or failures to act upon claims for payment for extra work or materials shall be resolved according to the following procedures which shall constitute the exclusive method for resolving such disputes Written notice of the matter in dispute shall be submitted promptly by the claimant to the chief executive official of the state agency which awarded the contract or his designee No person or business entity having a contract with a state agency shall delay suspend or curtail performance under that contract as a result of any dispute subject to this section A
372. r Division of Capital Asset Management Prime General Contractor Update Statement Effective March 30 2010 Page 9 of 12 PART 4 Legal or Administrative Proceedings Compliance with Laws Please answer the following questions Information is to cover all judicial and administrative proceedings involving bidder s firm which were instituted or concluded adversely or otherwise from the date your most recent annual Certificate of Eligibility was issued not extended to the date of the bid The term administrative proceeding as used in this Prime General Contractor Update Statement includes i any action taken or proceeding brought by a governmental agency department or officer to enforce any law regulation code legal or contractual requirement except for those brought in state or federal courts or ii any action taken by a governmental agency department or officer imposing penalties fines or other sanctions for failure to comply with any such legal or contractual requirement ayn The term anyone with a financial interest in your firm as used in this Section I shall mean any person and or entity with a 596 or greater ownership interest in the applicant s firm If you answer YES to any question on a separate page provide a complete explanation of each proceeding or action and any judgment decision fine or other sanction or result Include all details name of court or administrative agency title of case or proceed
373. r conductors 3 Warning labels and signs 4 Equipment identification labels SUBMITTALS Product Data For each electrical identification product indicated QUALITY ASSURANCE Comply with ANSI A13 1 Comply with NFPA 70 Comply with 29 CFR 1910 144 and 29 CFR 1910 145 Comply with ANSI Z535 4 for safety signs and labels Adhesive attached labeling materials including label stocks laminating adhesives and inks used by label printers shall comply with UL 969 COORDINATION Coordinate identification names abbreviations colors and other features with requirements in other Sections requiring identification applications Drawings Shop Drawings IDENTIFICATION FOR ELECTRICAL SYSTEMS 10 14 2015 260553 1 of 4 UMA16 12 MULLINS SECURITY CAMERAS manufacturer s wiring diagrams and the Operation and Maintenance Manual and with those required by codes standards and 29 CFR 1910 145 Use consistent designations throughout Project B Coordinate installation of identifying devices with completion of covering and painting of surfaces where devices are to be applied C Coordinate installation of identifying devices with location of access panels and doors D Install identifying devices before installing acoustical ceilings and similar concealment PART 2 PRODUCTS 2 1 POWER AND CONTROL RACEWAY IDENTIFICATION MATERIALS A Comply with ANSI A13 1 for minimum size of letters for legend and for minimum length of color field f
374. ral Conditions of the Contract 2 Contract Award Price S lt gt Adjusted Contract Price 5 lt gt Authorized Additions S lt gt Paid to Date 5 lt gt Authorized Deductions S lt gt Balance Due S lt gt 3 The undersigned further certifies that in addition to the amount set forth above there are outstanding and unsettled the following the Change Orders as submitted according to UMass Form 13 Request No lt gt Date lt gt Amount lt gt Request No lt gt Date lt gt Amount lt gt Request No lt gt Date lt gt Amount lt gt 4 Subject to satisfactory disposition of Change Orders listed in Item 3 above the undersigned releases the University of Massachusetts Amherst from all further claims for wages or payments to subcontractors or suppliers except list on attached sheet by Contractor Authorized Signature The above entitled project is accepted as of Rev 5 01 Form ST 5C Massachusetts Contractor s Sales Tax Exempt Department of Purchase Certificate Revenue ___ Part A To be completed by governmental body agency or IRC Section 501 c 3 certified exempt organization Exempt number LA ee E 043 167 352 PE ea ase RIVA mr cr it pnt it Na tr iA et en Ne a cata ar pan EE ate Date Director of Procurement a re s Part B To be completed by purchasing contractor or subcontractor claiming exemption under MGL Ch sec 60 le H or t ____
375. rds 2 promulgate safety regulations and give appropriate notices to the Awarding Authority and users of adjacent utilities and property 3 insure the adequate strength and safety of all scaffolding staging and hoisting equipment temporary shoring bracing and tying 4 protect adjoining private or public property 5 provide barricades temporary fences and covered walkways required by prudent construction practices Laws and or the Contract Documents 6 furnish approved hard hats and other personal protective equipment furnish approved first aid supplies furnish the name of the first aid attendant and maintain a posted list of emergency facilities 7 provide proper means of access to property where the existing access is cut off by the Contractor 8 maintain from the beginning of any darkness or twilight through the whole of every night sufficient lights on or near any obstruction so as to guard and protect travelers from injury from such obstruction 104 9 maintain adequate security at the Site so as not to expose the Work and surrounding property to vandalism or malicious mischief 10 provide adequate fire protection procedures during the use of cutting torches welding equipment plumbers torches and other flame and spark producing apparatus 11 take prompt action to correct any dangerous or hazardous conditions l The Contractor shall not use or store explosives in the performance of the Work unless the Con
376. re Certificate of Compliance with State Tax Laws Form for Subcontract PART III General Conditions of the Contract Appendix A Equal Employment Opportunity Non Discrimination and Affirmative Action Program Appendix B Goals for Participation by Minority Business Enterprises and Women Business Enterprises Appendix C Commonly Used Forms Procedure for Payment to Contractors Form ST 5C Daily Time and Material Report for Change Orders Notice of Intent Request and Agreement for a Change in the Plans Specifications and or Contract UMA Form 5 Instructions Regarding Change Orders and Contract Modifications UMA Form 13 Daily Time and Material Report for Change Orders Request and Agreement for a Change in the Plans Specifications and or Contract UMA Form 5 Notice of Intent Contractor s Weekly Workforce Report Minorities Women in Contractor s Weekly Workforce Report Weekly Payroll Report Form and Statement of Compliance Quarterly Projected Workforce Table Certification of Payment by Contractor to MBE WBE and Instructions Certificate of Completion by Minority Women Business Enterprise Form for Transfer of Title Work Not Incorporated DCAM Form 16 Certificate of Agency Use and Occupancy 1 Certificate of Final Inspection Release and Acceptance E 2 PART IV Supplementary General Conditions and Specifications BID PACKAGE PART INSTRUCTIONS TO BIDDERS Instructions to Bidders Attachment A M
377. rent low Bidder shall submit the following documents to the Awarding Authority s Compliance Office i a completed Schedule for Participation by Minority Women Business Enterprises Schedule for Participation in the form provided by the Awarding Authority showing M WBE participation in amounts equal to or exceeding the M WBE participation goals for this Contract ii a completed Letter of Intent in the form provided by the Awarding Authority for each M WBE listed in the Schedule for Participation and iii a current SOMWBA certification letter for each M WEBE listed in the Schedule of M WBE Participation showing that the M WBE is certified in the area of work for which it is listed on the Letter of Intent 8 5 Each Letter of Intent shall identify and describe the work to be performed by the named M WBE the M WBE Work with enough specificity to permit the Awarding Authority to identify the particular items of contract work that the M WBE will perform for M WBE participation credit The Awarding Authority reserves the right to reject any Letter of Intent if the price to be paid for the M WBE Work does not bear a reasonable relationship to the value of such work under the Contract as determined by the Awarding Authority 8 6 Within five 5 working days after receipt of the Schedule For M WBE Participation Letters of Intent and SOMWBA certification letters the Awarding Authority shall review and either approve or disapprove the apparent low Bid
378. required On demand the Contractor shall pay the Awarding Authority any amount by which the cost of completing all or any portion of the Work exceeds the amount attributable to that Work under the Contract Documents The Awarding Authority s sole goal will be to complete the Work that it elects to complete within the time limits stated in the Contract or at the earliest possible date thereafter Consequently the Awarding Authority shall have no obligation to obtain competitive bids or the lowest cost for completing the Work or any part thereof The Awarding Authority s election to complete all or part of the Work shall not release the Contractor from any liability for failure to complete the Work as the Contract Documents require and shall not entitle the Contractor to a claim for an increase in the Contract Price or an extension of the time for completing the Work If the cost that the Awarding Authority incurs in completing all or any portion of the Work is less than the amount that the Contract Documents attribute to that Work the Awarding Authority will pay or credit the difference to the Contractor less any other costs and expenses that the Awarding Authority incurs including the cost of supervision and the Designer s and attorneys fees and costs 2 Failure to Complete Work on Time Liquidated Damages A If liquidated damages are specified in the Owner Contractor Agreement the Awarding Authority has determined that its damages as a res
379. required the contractor shall be liable for all additional expenses including expenses of the University 1 6 EQUIPMENT REQUIREMENTS A Where variations from the contract requirements are requested in accordance with GENERAL CONDITIONS and Section 013300 SUBMITTAL REQUIREMENTS the connecting work and related components shall include but not be limited to additions or changes to branch circuits circuit protective devices conduits wire feeders controls panels and installation methods 1 7 EQUIPMENT PROTECTION A Equipment and materials shall be protected during shipment and storage against physical damage dirt moisture cold and rain 1 During installation enclosures equipment controls controllers circuit protective devices and other like items shall be protected against entry of foreign matter and be vacuum cleaned both inside and outside before testing and operating and repainting if required 2 Damaged equipment shall be as determined by the Project Engineer placed in first class operating condition or be returned to the source of supply for repair or replacement 3 Painted surfaces shall be protected with factory installed removable heavy kraft paper sheet vinyl or equal 4 Damaged paint on equipment and materials shall be refinished with the same quality of paint and workmanship as used by the manufacturer so repaired areas are not obvious 1 8 WORK PERFORMANCE A All electrical work must co
380. ress without delay DISPOSAL OF DEMOLISHED MATERIALS Remove debris rubbish and other materials resulting from demolition operations from building site Transport and legally dispose of materials off site 1 Burning of removed materials is not permitted on project site SELECTIVE DEMOLITION 10 14 2015 024100 2 of 3 16 12 12 4 2012 rev MULLINS SECURITY CAMERAS 2 Except as indicated below the General Contractor shall remove all demolished materials and rubbish at the end of each day It shall be taken to places of legal disposal All costs in this connection shall be paid by the General Contractor 3 04 PATCHING EXISTING MATERIAL A The work shall include careful examination of the Drawings and the existing building to determine quantities options locations sizes types and details of work described in this Section including but not limited to the following 1 Patching of all holes left from all abandoned electrical items ie conduit outlet boxes fire alarm devices ect removed by the electrical contractor and fire protection items removed finish to match the existing 2 Refinish entire surfaces as necessary to provide an even finish to match adjacent finishes 1 For continuous surfaces refinish to nearest intersection i e natural break to natural break 2 For an assembly refinish entire unit 3 Paint a Match existing finish 3 05 CORE DRILLING A Core drilling in masonry and concrete 1 All holes must
381. rformance curves rating data and parts lists Catalog sheets maintenance manuals and approved shop drawings of all mechanical and electrical equipment controls and fixtures with all details clearly indicated including size of lamps Balancing report Names addresses and telephone numbers of repair and service companies for each of the major systems installed under the construction contract Signed Department of Public Safety DPS Certificate of Occupancy per 780 CMR 120 0 Licensed Builder Final Affidavit Report Designer Affidavit of Compliance Subcontractor Affidavits that specified equipment and installed items have been seismically braced in accordance with code requirements Monetized punch list of the remaining Work that must be done before Final Acceptance As built documents should be completed both electronic files and transparencies and ready to transfer over to the UMA Project Manager As built documents shall consist of but not be limited to the following a Drawings in AutoCAD ver 2000 or later format 1 Contract drawings for all disciplines marked up to clearly indicate as built conditions 2 All clarification and or changed conditions sketches SK s b Specifications in pdf format 1 All construction specifications 2 All addenda Shop drawings submittals etc scanned format 1 All approved shop drawings submittals etc Approved documents submitted to the UMA or the Designer shall be electronic
382. rformed during regular Working Hours However if the Contractor desires to carry on the Work outside of regular Working Hours or on Saturdays Sundays or Massachusetts or federal holidays then the Contractor shall allow ample time to allow satisfactory arrangements to be made for inspecting Work in progress and shall bear the costs of such inspection The Awarding Authority shall bill the Contractor directly for such costs H Work performed outside of regular Working Hours without the consent or knowledge of the Designer and or the Awarding Authority shall be subject to additional inspection and testing as directed by the Designer The cost of this inspection and testing shall be borne by the Contractor whether the Work is found to be acceptable or not The Awarding Authority at its election shall be entitled either to issue a credit Change Order to cover such cost or to withhold such cost from any further payments due the Contractor and or to receive a payment from the Contractor of the amount of such cost 3 Superintendent A The Contractor shall employ a Superintendent whose appointment shall be subject to the Approval of the Awarding Authority The Superintendent shall be in attendance at the Site full time during the performance of the Work The Superintendent shall represent the Contractor Communications given to and from the Superintendent shall be deemed given to and from the Contractor Important communications shall be confirmed in writi
383. rials equipment tools machinery implements at or near the Site owned by the Contractor and finish the Work at the Contractor s expense by whatever means the Awarding Authority may deem expedient and the Contractor shall cooperate at its expense in the orderly transfer of the same to a new contractor or to the Awarding Authority as directed by the Awarding Authority In such case the Awarding Authority shall not make any further payments to the Contractor until the Work is completely finished The Owner shall not be liable for any depreciation loss or damage to said materials machinery implements or tools during said use and the Contractor shall be solely responsible for their removal from the Site after the Owner has no further use for them Unless so removed within fifteen days after notice to the Contractor to do so they may be sold at public auction after publication of notice thereof at least twice in any newspaper published in the county where the Work is being performed and the proceeds credited to the Contractor s account or they may at the option of the Awarding Authority be stored at the Contractor s expense subject to a lien for the storage charges C Damages and expenses incurred under paragraph B above shall include but not be limited to costs for the Designer s extra services and Project Representative services required in the opinion of the Awarding Authority to successfully inspect and administer the construction contract th
384. ric main water fitting is installed connect grounding conductor on street side of fitting Bond metal grounding conductor conduit or sleeve to conductor at each end Water Meter Piping Use braided type bonding jumpers to electrically bypass water meters Connect to pipe with a bolted connector Bond each aboveground portion of gas piping system downstream from equipment shutoff valve Grounding for Steel Building Structure Install a driven ground rod at base of each corner column and at intermediate exterior columns at distances not more than 60 feet 18 m apart FIELD QUALITY CONTROL Perform tests and inspections 1 Inspect components assemblies and equipment installations including connections and test Tests and Inspections 1 2 After installing grounding system but before permanent electrical circuits have been energized test for compliance with requirements Inspect physical and mechanical condition Verify tightness of accessible bolted electrical connections with a calibrated torque wrench according to manufacturer s written instructions Grounding system will be considered defective if it does not pass tests and inspections Prepare written test and inspection reports Submit to UMASS Project Manager upon request END OF SECTION 260526 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 10 14 2015 260526 4 of 4 16 12 MULLINS SECURITY CAMERAS SECTION 260529 HANGERS AND SUPPORTS FOR ELECTRIC
385. rmation being submitted is accurate and mathematically correct 2 04 THE RESIDENT ENGINEER UNIVERSITY OF MASSACHUSETTS PM IF NO RESIDENT ENGINEER SHALL a Note the receipt of written request for NOI in the record of NOIs Change Orders diary and daily report b Inform the Designer the Project Manger if applicable and the Project Engineer of the request for NOI c Review both quantities and prices of labor and materials and recommend corrections of changes Check to make sure the required breakdowns are attached from all subcontractors on properly identifiable letterhead d If any request is inaccurate incomplete contains insufficient credits due to the University of Massachusetts Amherst or is otherwise unacceptable the Resident Engineer shall note the return of a request for an NOI in the record of NOIs Change Orders diary daily report and return the request to the Contractor with a dated cover letter detailing the reasons for return 2 05 THE DESIGNER SHALL Immediately evaluate the requested change and the Contractor s request for an NOI and proposal and transmit the Designer s recommendation and those of the Resident Engineer by written memorandum or telephone if the situation warrants to the University of Massachusetts Project Manger or Project Engineer 2 05 1 THE UNIVERSITY OF MASSACHUSETTS AMHERST PROJECT MANAGER PM SHALL If the University of Massachusetts Amherst PM agrees with the request for change and the Contr
386. rnish to the Executive Office of Labor within fifteen days after completion of its portion of the work a statement executed by the contractor subcontractor or public body who supervises the payment of wages in the following form 183 STATEMENT OF COMPLIANCE Date 20 Name of signatory party Title do hereby state That pay or supervise the payment of the persons employed by on the Contractor subcontractor or public body Building or project and that all mechanics and apprentices teamsters chauffeurs and laborers employed on said project have been paid in accordance with wages determined under the provisions of sections twenty six and twenty seven of chapter one hundred and forty nine of the General Laws Signature Title 184 UMA Number Name of Contractor Address Telephone No Scope of Work QUARTERLY PROJECTED WORKFORCE TABLE UNIVERSITY OF MASSACHUSETTS AMHERST Project No Project Name Fax Trades Utilized Estimate of Total Hours to Complete Work of Project Estimate of Total Hours of Work Remaining on Project Total Contract Dollar Value Quarter Beginning Ending 185 Trade Categories Projected Total Hours Projected Total of all Projected Total of all By All Personnel Minority Hours Women Hours MONTH Laborers Other Trades MONTH Laborers Other Trades MONTH Laborers Other Trades Authorized Signature Ti
387. rom the date your most recent annual Sub Bidder Certificate of Eligibility was issued not extended to the date of the bid The term administrative proceeding as used in this Sub Bidder Update Statement includes i any action taken or proceeding brought by a governmental agency department or officer to enforce any law regulation code legal or contractual requirement except for those brought in state or federal courts or ii any action taken by a governmental agency department or officer imposing penalties fines or other sanctions for failure to comply with any such legal or contractual requirement up The term anyone with a financial interest in your firm as used in this Section I shall mean any person and or entity with a 596 or greater ownership interest in the applicant s firm If you answer YES to any question on a separate page provide a complete explanation of each proceeding or action and any judgment decision fine or other sanction or result Include all details name of court or administrative agency title of case or proceeding case number date action was commenced date judgment or decision was entered fines or penalties imposed etc IF YOU HAVE ANY DOUBT AS TO WHETHER TO ANSWER YES IT IS BETTER TO BE OVER INCLUSIVE AND TO PROVIDE A DETAILED EXPLANATION YES NO Have any civil judicial or administrative proceedings involving your firm or a principal or officer or anyone with a financial interest in
388. rough final completion of the Work D Expenses charged under paragraph B above may be deducted and paid by the Awarding Authority out of any money then due or to become due to the Contractor under this Contract E All sums damages and expenses incurred by the Owner to complete the Work shall be charged to the Contractor In case the damages and expenses charged are less than the sum that would have been payable under this Contract if the same had been completed by the Contractor the Contractor shall be entitled to receive the difference In case such expenses shall exceed the said sum the Contractor shall pay the amount of the excess to the Owner 148 2 Termination For Convenience A The Awarding Authority may terminate this Contract for convenience even though the Contractor is not in default by giving notice to the Contractor specifying in said notice the date of termination B Incase of such termination without cause the Contractor shall be paid 1 all sums due and owing under this Contract through the date of termination including any retainage withheld to the date of termination less any amount which the Awarding Authority determines is necessary to correct or complete the Work performed to the date of termination plus 2 areasonable sum to cover the expenses which Contractor would not have incurred but for the early termination of the Contract such as demobilization of the work force restocking charges termination fees pa
389. rsonnel to keep noise to a minimum Execute construction work by methods and by use of equipment which will reduce excess noise 1 Equip compressors with silencers and power equipment with mufflers 2 Manage vehicular traffic and scheduling to reduce noise 3 No heavy equipment may be started or idled before 7A M INDOOR AIR QUALITY MANAGEMENT Minimize exposure of building occupants indoor surfaces and ventilation air distribution systems to environmental tobacco smoke At a minimum take the following measures 1 Prohibit smoking in the building or on campus Take special care to prevent accumulation of moisture on materials and within packaging during delivery storage and handling to prevent development of mold and mildew inside packaging and on products Immediately remove from site and properly dispose of materials showing signs of mold and mildew including materials with moisture stains CLEANING DURING CONSTRUCTION Unless otherwise specified under the various Sections of the Specifications the General Contractor shall perform clean up operations during construction as herein specified Control accumulation of waste materials and rubbish periodically dispose of off site in a legal manner The General Contractor shall bear all costs including fees resulting from such disposal Clean interior areas prior to start of finish work and maintain areas free of dust and other contaminants during finish operation
390. rsons to be employed in the Work who will work in harmony with others so employed Should the Work be stopped or materially delayed in the Awarding Authority s reasonable judgment due to a labor dispute the Awarding Authority shall have the right to require the Contractor to employ substitutes acceptable to the Awarding Authority 5 Notices and Permits A The Contractor at its sole cost shall take out and pay for all approvals permits certificates and licenses required by Laws pay all charges and fees and pay for or cause the appropriate Subcontractor to pay for all utilities required for the proper execution of the Work B The Contractor shall comply with all Laws and shall give all notices required thereby C Except as otherwise specified in this Contract it is not the Contractor s responsibility to ascertain that the Contract Documents are in accordance with applicable Laws However if the Contractor observes that portions of the Contract Documents are at variance with the requirements of Laws the Contractor shall promptly notify the Designer and Awarding Authority in writing and necessary changes shall be accomplished by an appropriate Contract Modification D Ifthe Contractor performs Work knowing it to be contrary to Laws without giving such notice to the Designer and Awarding Authority the Contractor shall bear full responsibility for such Work and all costs attributable thereto including without limitation corrections to the
391. s Maintain project in accordance with all local Commonwealth of Massachusetts and Federal Regulatory Requirements Store volatile wastes in covered metal containers and remove from premises Prevent accumulation of wastes which create hazardous conditions Provide adequate ventilation during use of volatile or noxious substances TEMPORARY FACILITIES AND CONTROLS 10 14 2015 015000 2 of 4 12 4 2012 rev 1 8 1 9 H 16 12 MULLINS SECURITY CAMERAS Conduct cleaning and disposal operations to comply with local ordinances and anti pollution laws 1 Do not burn or bury rubbish and waste materials on site Do not dispose of volatile wastes such as mineral spirits oil or paint thinner in storm or sanitary drains 3 Do not dispose of wastes into streams or waterways 4 Identify potential sources of cleaning water runoff and propose abatement procedures Use only those materials which will not create hazards to health or property and which will not damage surfaces Use only those cleaning materials and methods recommended by manufacturer of surface materials to be cleaned Execute cleaning to ensure that the buildings the sites and adjacent properties are maintained free from accumulations of waste materials and rubbish and windblown debris resulting from construction operations Provide on site containers for collection of waste materials debris and rubbish Remove waste materials debris and rubbish for
392. s 5 Each of the utilities and appurtenances shall be referenced by showing a tag number area served and function on the As built Drawings At the end of each month and before payment for materials installed the General Contractor each Subcontractor and agents of the Commonwealth shall review As built Drawings for purpose of payment 1 If the changes in location of all installed elements are not shown on the As Built Drawings and verified in the field then the material shall not be considered as installed and payment will be withheld Prior to the installation of all finish materials a review of the As built Drawings shall be made to confirm that all changes have been recorded All costs to investigate such conditions shall be borne by the applicable party as determined by the Designer CONTRACT CLOSEOUT 10 14 2015 017700 2 of 9 4 5 2013rev 1 4 I UMA 16 12 MULLINS SECURITY CAMERAS At the completion of the contract each Subcontractor shall submit to the General Contractor a complete set of his respective As built Drawings indicating all changes After checking the above drawings the General Contractor shall certify in writing on the title sheet of the drawings that they are complete and correct The General Contractor shall submit to the UMA Project Manager electronic files in Autocad 2013 format with two 2 sets of prints to be used for the final inspection of the project Inaccuracies in As built Drawings as determ
393. s Article Verify operation of auto iris lenses Set back focus of fixed focal length lenses At focus set to infinity simulate nighttime lighting conditions by using a dark glass filter of a density that produces clear image Adjust until image is in focus with and without the filter d Set back focus of zoom lenses At focus set to infinity simulate nighttime lighting conditions by using a dark glass filter of a density that produces a clear image Additionally set zoom to full wide angle and aim camera at an object 50 to 75 feet away Adjust until image is in focus from full wide angle to full telephoto with the filter in place Set and all preset positions consult Owner s personnel f Connect and verify responses to alarms g Verify operation of control station equipment Test Schedule Schedule tests after pretesting has been successfully completed and system has been in normal functional operation for at least 14 days Provide a minimum of 10 days notice of test schedule Operational Tests Perform operational system tests to verify that system complies with Specifications Include all modes of system operation Test equipment for proper operation in all functional modes Video surveillance system will be considered defective if it does not pass tests and inspections Prepare test and inspection reports and submit to UMA Project Manager ADJUSTING Occupancy Adjustments When requested within 12 months of
394. s unless otherwise specified in the Supplementary General Conditions or Specifications A There shall be no fewer facilities than the number required by applicable Laws B Facilities shall be kept in a clean sanitary condition at all times and shall be adequately screened to be inaccessible to flies Note If existing sanitary facilities at the Site are to be used by the Contractor this requirement will be modified accordingly in the Supplementary General Conditions or Specifications 101 11 Contract Documents and Samples at the Site A reasonable number of sets of Contract Documents as defined by the Awarding Authority will be furnished to the Contractor by the Awarding Authority immediately after signing of the Contract one of which shall be maintained at the Site for reference by authorized representatives of the Awarding Authority The Contractor shall maintain at the Site for the use and information of the Awarding Authority one record copy of the Drawings Specifications Addenda Change Orders Approved Shop Drawings Product Data Samples updated Progress Schedule and all other submittals all in good order and marked currently to record changes and selections made during construction These shall be available to the Designer and the Awarding Authority and shall be delivered to the Designer for submittal to the Awarding Authority upon completion of the Work 12 Telephones The Contractor shall provide and maintain separate ind
395. s Section shall be determined in accordance with the provisions of Article V of the CONTRACT AND GENERAL CONDITIONS REQUIREMENTS INCLUDED Work under this Contract Examination of Site and Documents Contract Method Work Sequence Supervision of Work General Contractor s Use of Premises Coordination Field Engineering Reference Standards Preconstruction Conference Project Meetings Permits Inspection and Testing Required by Governing Authorities Cutting Coring Patching Unless Otherwise Indicated Debris Removal Field Measurements Emergency Procedures Safety Regulations OSHA Safety and Health Course Documentation Damage Responsibility Owner Furnished Products UMA Occupancy Special Requirements List of Drawings SUMMARY 10 14 2015 011000 1 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS 1 3 WORK UNDER THIS CONTRACT A The work to be done under this contract consists of executing and completing all work required for UMA16 12 MULLINS SECURITY CAMERAS MULLINS CENTER UNIVERSITY OF MASSACHUSETTS AMHERST General Information a The project consists of replacing the existing security camera system with the equipment shown on the drawings New equipment will be installed in both existing and new locations as shown on the documents b NVR and cameras specified are in accordance with UMA standards and security protocols New NVR and cameras shall be as specified or be 100 c
396. s detailed in the General Conditions at Article X of compliance with Federal Department of Homeland Security Requirements including but not limited to the Employment Eligibility Verification Form 1 9 Process Bid forms for this Contract are located in Attachment B to these Instructions to Bidders The combined participation goal for Minority Women Business Enterprise for this Contract is 0 26 The MBE WBE participation goal must include a reasonable representation of both MBE and WBE firms that meet or exceeds the combined goal MBE WBE participation plans that consist solely of either a MBE or WBE representing 100 of the overall combined goals will not be considered reasonable or responsive Firms submitting MBE WBE participation plans which do not provide reasonable participation by both MBE WBE firms shall be provided an opportunity to revise and resubmit their plans within the time frame set by the awarding authority however no price adjustments shall be permitted as a result of the revised plan Firms failing to submit an MBE WBE participation plan deemed reasonable and accepted by the awarding authority shall not be awarded the contract The time for completion of the Work is specified in Article 2 of the Owner Contractor Agreement Liquidated damages for failure to complete work on time are as stated in Article 8 of the Owner Contractor Agreement Bidding Documents may be examined at the University of Massachusetts Amherst Pro
397. s is a final report 179 Date Work Date 081 140day 2240p 10M p 997M 5 10322 3105 ON 4 9 00TO VIN 1s49qQuuy RN 9jeq 9JnjeuSis pezijouiny eM 4193108 sndwey 09 3ulp ing jeors ug 9184nooe pue and S uon euu0Jul Jageue A 312e431005 sani mneJ y 1291 Aunfuad jo senjeuad pue sured saine Aqasay pausisuapun 941 ysuaywy s yasnysesseyy Jo AysyaAlUA 01 IEN J032841u0 ON wom SJnOH 01 SJnoH SJnoH SJnoH 9240pJ140AA OL 5 91eq OL 5 9240pJ140AA 9240pJ140AA 9240pJ10AA KANIM OYM saadojdwy s ojdw3 JO CIOL Je1o1 96 pJ99M 210 Je1o1 Jo Jaquiny Jo Jaquiny MINORITIES WOMEN IN CONTRACTOR S WEEKLY WORKFORCE REPORT THE UNIVERSITY OF MASSACHUSETTS AMHERST UMA No Project No Project Name Name of General Contractor Project Location EM Name of Contractor Filing Report Address Week Ending Report No JOB CATEGORY NAME OF EMPLOYEE MINORITY GROUP GENDER In contract Article XII Minority refers to Asian Americans Blacks Western Hemisphere Hispanics Native Americans and Cape Verdeans Minorities Women in Contractor s Weekly Workforce Report Revised 10 01 181 WEEKLY PAYROLL REPORT FORM THE UNIVERS
398. s made thereunder in relation to the purchase of supplies and materials in the execution of the Work including the provisions of M G L c 7 s 22 paragraph 17 which provides that there be a preference in the purchase of supplies and materials other considerations being equal in favor first of supplies and materials manufactured and sold within the Commonwealth and second of supplies and materials manufactured and sold elsewhere within the United States 108 2 Shop Drawings Product Data and Samples A The Contractor shall furnish to the Designer all samples of the materials to be used in the execution of the Work as required by the Contract Documents The Contractor shall furnish to the Designer in a timely manner all coordination Drawings shop details Shop Drawings and setting diagrams which may be necessary for acquiring and installing materials These shall be reviewed as required by the Designer A minimum of six 6 copies shall be submitted for final approval one of which shall be returned to the Contractor one to the Resident Engineer one to the Awarding Authority and one filed with the Designer The inspection and approval by the Designer of Shop Drawings etc shall be general and shall in no way relieve the Contractor from responsibility for proper fitting coordinating construction and construction sequencing The Contractor shall furnish to the Designer such information and vouchers relative to the Work the materials
399. s necessary to ascertain whether or not an M WBE has performed its own M WBE Work At the discretion of the Awarding Authority failure to submit such documentation to the Awarding Authority shall establish conclusively for the purpose of giving M WBE participation credit under this Contract that such M WBE did not perform such work 6 Notification of Changes in M WBE Work A If at any time during the performance of the Contract the Contractor determines or has reason to believe that a scheduled M WMBE is unable or unwilling to perform its M WBE Work or that there has been or will be a change in any M WMBE Work or that the Contractor will be unable to meet the M WBE participation goal s for this Contract for any reason the 157 Contractor shall immediately notify the Awarding Authority Contract Compliance Office in writing of such circumstances B Any notice of a change in M WBE Work pursuant to subparagraph A above shall include a revised Schedule of M WBE Participation and additional or amended Letters of Intent and subcontracts as the case may be 7 Actions Required If There is a Reduction in M WBE Participation Inthe event there is a change or reduction any M WBE Work which will result in the Contractor failing to meet the M WBE participation goal s for this Contract other than a reduction in M WBE Work resulting from a Change Order initiated by the Awarding Authority then the Contractor shall immediately undertak
400. s see Apprentice LINEMAN JOURNEYMAN LINEMAN 08 30 2015 48 80 8 20 9 46 0 00 66 46 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 Apprentice LINEMAN Outside Electrical West Local 42 Effective Date 08 30 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 60 29 28 8 20 0 88 0 00 38 36 2 65 31 72 8 20 0 95 0 00 40 87 3 70 34 16 8 20 9 02 0 00 51 38 4 75 36 60 8 20 9 10 0 00 53 90 5 80 39 04 8 20 9 17 0 00 56 41 6 85 41 48 8 20 9 24 0 00 58 92 7 90 43 92 8 20 9 32 0 00 61 44 Notes Apprentice to Journeyworker Ratio 1 2 TELEDATA CABLE SPLICER 01 01 2015 28 12 4 25 3 09 0 00 35 46 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 01 01 2016 28 98 4 25 3 12 0 00 36 35 TELEDATA LINEMAN EQUIPMENT OPERATOR 01 01 2015 2649 425 3 04 0 00 33 78 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 01 01 2016 2731 4 25 3 07 0 00 34 63 TELEDATA WIREMAN INSTALLER TECHNICIAN 01 01 2015 2649 425 3 04 0 00 33 78 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 01 01 2016 2731 84 25 3 07 0 00 34 63 TRACTOR TRAILER DRIVER 08 30 2015 42 16 88 20 9 26 0 00 59 62 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 TREE TRIMMER 02 01 2015 18 05 83 55 0 00 0 00 21 60 OUTSIDE ELECTRICAL WORKERS WEST LOCAL 42 01 31 2016 18 51 83 55 0 00 0 00 22 06 This classification applies only to tree work done a for a utility company R E A cooperat
401. s to perform its agreement to execute a sub contract with the general Bidder selected as the general Contractor contingent upon the execution of the General Contract and if requested to do so in the general Bid by such general Bidder to furnish a Performance and Payment Bonds as Stated in its sub Bid in accordance with M G L c 149 44F 2 the Bid deposit of such sub Bidder shall become the property of the Commonwealth as liquidated damages provided that the amount of the Bid deposit that shall become the property of the Commonwealth shall not exceed the difference between its sub Bid price and the sub Bid price of the next lowest responsible and eligible sub Bidder 11 3 In addition to the provisions for the return of Bid deposits as provided above upon receipt of a Bid Bond in an amount not less than the amount of the required Bid deposit the Awarding Authority shall return any Bid deposit of a Bidder forthwith after the public opening of Bids 22 ATTACHMENT A PREVAILING WAGE SCHEDULE The minimum wage rates provided in the following pages have been provided by the Division of Occupational Safety of the Massachusetts Department of Labor and Workforce Development The Awarding Authority is not responsible for errors or omissions in such wage rates M G L c 149 88 26 and 27 provide as follows Payments by employers to health and welfare plans pension plans and supplementary unemployment benefit plans under collective b
402. s to be completed in less than 12 months the annual dollar value of the work is equal to the full amount of the bid ii If the project will take more than 12 months to complete calculate the number of years given to complete the project by dividing the total number of months in the project schedule by 12 calculate to 3 decimal places then divide the amount of the bid by the calculated number of years to find the annual dollar value of the work Add the annualized value of all of the bidder s incomplete contract work the total of column 9 Step 3 on page 5 to the annual dollar value of the work to be performed on your project The total may not exceed the bidder s Aggregate Work Limit Correction of Errors and Omissions in Update Statements Matters of Form An awarding authority shall not reject a contractor s bid because there are mistakes or omissions of form in the Update Statement submitted with the bid provided the contractor promptly corrects those mistakes or omissions upon request of the awarding authority 810 CMR 8 05 1 Correction of Other Defects An awarding authority may in its discretion give a contractor notice of defects other than mistakes or omissions of form in the contractor s Update Statement and an opportunity to correct such defects provided the correction of such defects is not prejudicial to fair competition An awarding authority may reject a corrected Update Statement if it contains unfa
403. s which may be required to permit full use and occupancy of the Work by its intended users which in a Subcontractor s case may include the Contractor have been delivered to the Awarding Authority 3 any applicable written warranties operating instructions and related materials have been delivered to the Awarding Authority and 4 the Work may be used for its intended purpose without substantial inconvenience or interference Change Order 1 A written order not requiring the consent of the Contractor signed by the Project Manager and designated as a Change Order directing the Contractor to make changes in the Work within the general scope of the Contract or 2 any written or oral order from the Project Manager that causes any change in the Work provided that the Contractor has given the Awarding Authority written notice stating the date circumstances and source of the order and that the Contractor regards the order as a Change Order Contract The Contract formed by the Contract Documents as defined in Article 6 of the Owner Contractor Agreement Contract Documents The documents listed in Article 6 of the Owner Contractor Agreement 92 Contract Modification Any alteration of the Contract Documents accomplished by a written agreement properly executed by the parties to this Contract Contract Price The Contract Price stated in Article 3 of the Owner Contractor Agreement which is the total sum owed to the Contractor for all
404. sed interior and exterior surfaces If damaged during construction repair patch and touch up marred surfaces to specified finish to match adjacent surfaces as acceptable to the UMA Project Manager Leave pipe and duct spaces plenums furred spaces and the like clean of debris and decayable materials At the end of the project General Contractor and each Subcontractor shall remove all his tools equipment machinery and surplus materials from the job site The General Contractor shall remove all waste materials and rubbish from the project at this time All temporary structures shall be removed and the project shall be left clean CONTRACT CLOSEOUT 10 14 2015 017700 1 of 9 4 5 2013rev 1 3 A UMA 16 12 MULLINS SECURITY CAMERAS AS BUILT DRAWINGS As built Drawings shall consist of all the Contract Drawings As built Drawings shall be kept up to date Information from on going Work shall be recorded on As built Drawings within 48 hours of Work being performed The General Contractor and each Subcontractor shall be required to maintain one set of As built Drawings as the work relates to their Sections of the Specifications at the site The As built Drawings shall be stored and maintained in the General Contractor s field office apart from other documents used for construction The As built Drawings shall be maintained in a clean dry and legible condition and shall not be used for construction purposes As built Drawings
405. sed or employed in the performance of the Work violations by Contractor any Subcontractor or by any person directly or indirectly employed or used by any of them in the performance of the Work or anyone for whose acts any of them may be liable Contractor subcontractor and all such persons herein collectively 145 called Contractor s Personnel of any Laws violations of any provision of this Contract by any of Contractor s Personnel injuries to any persons or damage to any property in connection with the Work any act omission or neglect of Contractor s Personnel The Contractor shall be obligated as provided above regardless of whether or not such claims damages losses and or expenses are caused in whole or in part by the actions or inactions of a party indemnified hereunder In any and all claims by Contractor s Personnel against parties indemnified hereunder the Contractor s indemnification obligation set forth above shall not be limited in any way by any limitation on the amount or type of damages compensation or benefits payable by or for the Contractor or any subcontractor under workers or workmen s compensation acts disability benefit acts or other employee benefit acts Such obligation shall not be construed to negate abridge or otherwise reduce any other right or obligation of indemnity which would otherwise exist as to any party or person described in this Article XV 2 Designer s Actions The obliga
406. setts Building Authority the University and the Commonwealth of Massachusetts 7 Umbrella Coverage The Contractor shall provide Umbrella Coverage in form at least as broad as primary coverage required by Sections 2 3 and 5 of this Article in the following amount unless a higher amount is specified in Exhibit the Owner Contractor Agreement in which case the Contractor shall provide the higher amount Contract Price Umbrella Coverage Under 1 000 000 2 000 000 1 000 000 5 000 000 5 000 000 5 000 001 10 000 000 10 000 000 10 000 001 and over 25 000 000 8 Additional types of Insurance The Contractor shall provide such other types of insurance as may be required by Exhibit A to the Owner Contractor Agreement ARTICLE XV INDEMNIFICATION 1 Generally To the fullest extent permitted by law the Contractor shall indemnify defend with counsel subject to the supervision of the Attorney General of the Commonwealth of Massachusetts as required by M G L 12 5 3 and hold harmless the Owner Awarding Authority and Designer and their officers agents divisions agencies employees representatives successors and assigns from and against all claims damages losses and expenses including but not limited to court costs and attorneys fees arising out of or resulting from the performance of the Work including but not limited to those arising or resulting from labor performed or furnished and or materials u
407. signal is detected the Alarm Monitor must notify the operator of an event The Alarm Monitor image viewer shall also allow the user to search through past events that have been recorded on the client PC The Instant Recording feature allows users to manually initiate recording on a specific camera overriding the current schedule Provide through the remote software the ability to export single images in the JPG file format and save video clips in the AVI format A digital signature must be attached to every JPG and AVI file exported by the unit for use with the bundled Digital Verifier application This function must be unique to the unit and its verification software and shall not interfere with viewing files using other applications Support the Honeywell VCL and Honeywell MAXPRO protocols Include Alarm Monitor software to stream video across a LAN to a client PC when an alarm is detected on the unit The operator shall have the ability to stop play forward and backward frame by frame or at real speed the video that streams across The program must constantly monitor for a signal from the NVR and when an alarm signal is detected the Alarm Monitor must notify the operator of an event The Alarm Monitor image viewer shall also allow the user to search through past events that have been recorded on the client PC VIDEO SURVEILLANCE 10 14 2015 265700 5 of 9 2 6 A 16 12 MULLINS SECURITY CAMERAS 1 The Instant Recording fea
408. sistence The Awarding Authority will then give Contractor an invoice for those costs and the Contractor shall submit a credit Change Order for the amount of those expenses D Stored materials either at the Site or at some other location agreed upon in writing shall be so located as to facilitate prompt inspection and even though approved before storage may again be inspected prior to their use in the Work E All storage sites shall be restored to their original condition by the Contractor at the Contractor s expense F The Contractor shall take charge of and be liable for any loss of or injury to the materials for his use delivered to or in the vicinity of the place where the Work is being done whether furnished by the Owner or otherwise the Contractor shall notify the Designer as soon as any such materials are so delivered allow them to be examined by the Designer and furnish workers to assist therewith 6 Defective Damaged or Deteriorated Materials and Rejection Thereof The Designer may reject materials if the Designer reasonably determines that such materials do not conform to the Contract Documents in any manner including but not limited to materials that have become damaged or deteriorated from improper storage whether or not such materials have previously been accepted The Contractor at its own expense shall remove rejected materials from the Work No rejected material the defects of which have been subsequently corrected sh
409. soil resulting from installation of such furniture telephones and equipment 20 Maintenance Data Subject to such additional requirements as may be provided in the Supplementary General Conditions or Specifications the Contractor shall compile 3 complete and identical binders of operating and maintenance data for the entire Work The Contractor shall submit record maintenance data to the Designer for approval shall submit approved maintenance data to the Awarding Authority and shall instruct and train the User Agency s personnel in proper inspection and maintenance procedures 107 21 Closeout Procedures The Contractor shall take all actions and submit all items required for the issuance of the Certificate of Agency Use and Occupancy and Final Acceptance as specified in the Contract Documents 22 Risk of Loss The Contractor shall bear all risk of loss to the Work during the term of the Contract except for any portion of the Work as to which the Certificate of Agency Use and Occupancy has been issued pursuant to Article VI of these General Conditions of the Contract Nothing herein shall limit the Contractor s responsibilities under Article IX or XV of these General Conditions of the Contract 23 LEED Requirements Contractor understands that pursuant to Executive Order No 484 all new construction and renovation projects over 20 000 square feet must at a minimum meet a Massachusetts LEED Plus building standard and that smaller
410. sonnel with at least fourteen 14 days advance notice Coordinate instructors including providing notification of dates times length of instruction and course content Program Structure Develop an instruction program that includes individual training modules for each system and equipment not part of a system as required by individual Specification Sections For each training module develop a learning objective and teaching outline Include instruction for the following SONS s System design and operational philosophy Review of documentation Operations Adjustments Troubleshooting Maintenance Repair CLOSEOUT REQUIREMENTS AND SUBMITTALS Procedural Requirements Prior to Use and Occupancy Punch List 1 During the finishing stages of the project the General Contractor shall make frequent inspections with Subcontractors the Designer and the UMA Resident Engineer so as to progressively check for and correct faulty work During the course of construction of the project the General Contractor shall procure and maintain test records and certificates that will be required prior to issuance of the Department of Public Safety DPS Certificate of Occupancy and the Division of Capital Asset Management UMA Certificate of Agency Use and Occupancy When the General Contractor determines that he she is Substantially Complete he she shall prepare for submission to the Designer a list of items to be completed or correcte
411. sponsible and eligible filed sub Bidder at the amount named in its filed sub Bid as so filed against whose standing and ability the general Contractor makes no objection and the Contract price shall be adjusted by the difference between the amount of such filed sub bid and the amount of the sub bid of the delinquent filed sub Bidder 10 2 Upon receipt of the Award the general Bidder awarded the Contract shall submit three 3 properly executed originals of each of the following documents prior to execution of the Contract by the Awarding Authority All such documents shall be in the form prescribed by the Awarding Authority Note The successful general Bidder must submit its Schedule For Participation of 20 Minority Women Business Enterprises and Letters of Intent as set forth in Section 8 4 above prior to Award of the Contract Owner Contractor Agreement Certificate of Corporate Vote Joint Venture Authorization if appropriate Performance and Payment Bonds with power of attorney attached Certificates of Insurance evidencing coverage in amounts required by the Contract Documents Written representation by the General Contractor to the effect that it has presented subcontracts to all selected filed sub Bidders and a statement as to whether or not each such selected filed sub Bidder has executed its subcontract such that the Awarding Authority may release the Bid deposit with respect to the same Misrepresentation of the foregoing shall r
412. ss a higher coverage is specified in Exhibit A to the Owner Contractor Agreement in which case the Contractor shall provide the additional coverage Bodily Injury amp 1 000 000 each occurrence Property Damage 2 000 000 general aggregate per project Products amp Completed Operations 1 000 000 annual aggregate Personal amp Advertising Injury 1 000 000 each occurrence Medical Expenses 10 000 B This policy shall include coverage relating to explosion collapse and underground property damage C This policy shall include contractual liability coverage D The completed operations coverage shall be maintained for a period of three 3 years after Substantial Completion E Ifthe Work includes work to be performed within 50 feet of a railroad any exclusion for liability assumed under contract for work within 50 feet of a railroad shall be deleted F This policy shall include endorsement CG2010 10 85 edition Owner as Additional Insured and CG2404 11 85 edition Waiver of Subrogation in Favor of Owner 3 Vehicle Liability A The Contractor shall provide the following minimum coverage with respect to the operations of any employee including coverage for owned non owned and hired vehicles unless a higher coverage is specified in Exhibit A to the Owner Contractor Agreement in which case the Contractor shall provide the additional coverage Combined Single Limit 1 000 000 B The policy shall include a CA9948 Pollution
413. ssession at least five 5 calendar days excluding weekend and holidays unless otherwise specified before the date set for the receipt of general Bids or if a question pertains to Item 2 filed sub Bid work at least five 5 calendar days excluding weekend and holidays unless otherwise specified before the date set for the receipt of filed sub Bids The Awarding Authority will post any addenda written interpretations that it deems necessary on the Procurement website www umass edu procurement constructionprojects htm Bidders may not rely upon oral communications or interpretations from the Awarding Authority or the Designer and the Awarding Authority shall not be bound by them 4 2 It is the sole responsibility of the Bidder to ascertain the existence of any addenda issued by the Awarding Authority as posted on the website Copies of addenda will be made available for inspection at the locations listed in the Advertisement where the Contract Documents are on file 4 3 Wherever in the Contract Documents reference is made to Massachusetts General Laws it shall be construed to include all amendments thereto effective as of the date of the issuance of the invitation to bid on the proposed work 12 SECTION 5 PREPARATION OF BIDS ALTERNATES 5 1 General Bids shall be submitted on the Form for General Bid included in Attachment B to these Instructions to Bidders Filed sub Bids shall be submitted on the Form for Sub Bid included i
414. stimated value as part security for the completion of the Work and shall pay to the Contractor while carrying on the Work the balance not retained as aforesaid subject to the Approval of the Awarding Authority after deducting therefrom all previous payments and all sums to be kept under the provisions of this Contract B Each periodic estimate shall constitute the Contractor s representation that 1 the payment then requested to be disbursed has been incurred by the Contractor on account of the Work and is justly due to Subcontractors or to the Contractor in the case of other Work performed by the Contractor on account thereof 2 the materials supplies and equipment for which Application for Payment is being submitted have been installed or incorporated into the Work or have been stored at the Site or at such off Site storage locations as the Awarding Authority shall have Approved 3 the materials supplies and equipment are insured in accordance with the provisions of this Contract 4 the materials supplies and equipment are owned by the Owner and are not subject to any liens or encumbrances 5 the Work which is the subject of such periodic estimate has been performed in accordance with the Contract Documents and 6 that all due and payable bills with respect to the Work have been paid to date or shall be paid from the proceeds of such periodic estimate The Contractor s attention is directed to the criminal penalties for false claims referenc
415. struct access to existing active utility system manholes and catch basins which continue to serve facilities other than the project construction site The General Contractor shall exercise measures as necessary to prevent the placement of impediments that limit continuous access by authorized utility company or UMA maintenance personnel and shall be required to reimburse the utility company or UMA for any expense incurred as a result of need to remove any such impediments to access SUMMARY 10 14 2015 011000 13 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS 1 16 DEBRIS REMOVAL A The General Contractor shall coordinate the removal of all demolition and construction waste by the Subcontractor from the job site on a daily basis Waste shall be segregated for recycling Debris shall be legally disposed of in a D E P approved disposal site The site to be used shall be submitted to and approved by the UMA Project Manager prior to the start of construction All required dumping permits shall be obtained prior to start of construction General Contractor shall submit receipts from the disposal site s as evidence of legal disposal The Subcontractor shall pay the cost of any charges for debris removal The General Contractor shall bear responsibility for maintaining the building and site clean and free of debris leaving all work in clean and proper condition satisfactory to UMA and the Designer The General Contractor shall ensur
416. struction Projects will also submit a Site Specific Safety Plan specific to their operations at the University and which address their plan of action for identified and potential environmental health and safety issues that may arise prior to start of construction Maintain a written hazard communication program in accordance with OSHA 29CFR 1910 1200 Keep MATERIAL SAFETY DATA SHEETS MSDS on site and upon request provide MSDS sheets for materials used in the construction All accident reports are to be transmitted to the Resident Engineer within 24 hours of occurrence The Contractor shall immediately notify UMA EH amp S if an OSHA DEP or EPA regulator visits the site UMA and EH amp S personnel shall have the authority to exercise on site compliance audits on the construction site Deficiencies discovered during site inspections and visits will be relayed to the contractor s company safety representative and the UMA Project Manager The contractor will communicate back to the UMA Project Manager and Environmental Health and Safety on the course of corrective action to be taken and the timeline for completion If during such an audit in his or her professional opinion there exists an imminent danger or serious violation of established environment health and safety standards that could lead to death or serious physical harm damage to university property or the environment the University representative has the right to request the immediate ha
417. suspend any payment or portion thereof due under the Contract until the contractor demonstrates to the satisfaction of the Awarding Authority compliance with the terms of this Article This temporary suspension of payments by the Awarding Authority is separate from the sanctions set forth in Section 4A 4C of this Article above which are determined by MCAD and recommend to the Awarding Authority Payment may be suspended only after the Contractor and any other interested party shall have been given the opportunity to present evidence in support of its position at an informal hearing held by the Awarding Authority and the Awarding Authority has concluded upon review of all the evidence that such penalty is justified Payment shall not be suspended if the Awarding Authority finds that the Contractor made its best efforts to comply with this Article or that some other justifiable reason exists for waiving the provisions of this Article in whole or in part 155 APPENDIX B to General Conditions of the Contract The following provisions form Article XIII of the General Conditions of the Contract where the University of Massachusetts Amherst is the Awarding Authority GOALS FOR PARTICIPATION BY MINORITY BUSINESS ENTERPRISES AND WOMEN BUSINESS ENTERPRISES EXECUTIVE ORDER 390 M G L c 7 s 40N 1 Goals A The goals for minority business enterprise and woman business enterprise participation established for this Contract are as set forth in the Own
418. t compound mortar cement concrete dust paint and other material that may contaminate the raceway system conductors and cables 3 Install device boxes in brick or block walls so that the cover plate does not cross a joint unless the joint is troweled flush with the face of the wall 4 Install wiring devices after all wall preparation including painting is complete Conductors l Do not strip insulation from conductors until right before they are spliced or terminated on devices 2 Strip insulation evenly around the conductor using tools designed for the purpose Avoid scoring or nicking of solid wire or cutting strands from stranded wire 3 The length of free conductors at outlets for devices shall meet provisions of NFPA 70 Article 300 without pigtails 4 Existing Conductors a Cut back and pigtail or replace all damaged conductors b Straighten conductors that remain and remove corrosion and foreign matter Pigtailing existing conductors is permitted provided the outlet box is large enough Device Installation 1 Replace devices that have been in temporary use during construction and that were installed before building finishing operations were complete 2 Keep each wiring device in its package otherwise protected until it is time to connect conductors 3 Do not remove surface protection such as plastic film and smudge covers until the last possible moment 4 Connect devices to branch circuits using
419. t include payments from previous periods or estimated future payments in this column Please note that you may be required to submit copies of cancelled checks to verify the amounts reported for firms used to meet the project s M WBE goals CUMULATIVE PAYMENTS Include the total amount you paid the M WBE subcontractor either directly or indirectly for work performed on this project for all quarters to date This amount should equal all payments made during the period covered by this Certificate of Payment as well as all payments from previous periods The University of Massachusetts Amherst Facilities Planning Project Manager will check the total amount reported this quarter against any payments previously reported To ensure accurate reporting please review the prior Certifications of Payments you submitted for this project 189 Where necessary correct any earlier mathematical or reporting errors and submit revised Certifications of Payment IF YOU HAVE ANY QUESTIONS CONTACT THE UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING PROJECT MANAGER Certification of Payment Revised 10 01 190 CERTIFICATE OF COMPLETION BY MINORITY WOMEN BUSINESS ENTERPRISE UNIVERSITY OF MASSACHUSETTS AMHERST UMA Number Project Number Project Location Project Name Name of MBE WBE Firm Address Name of General Contractor Address DESCRIPTION OF WORK AS SHOWN IN LETTER OF INTENT DESCRIPTION OF ACTIVITY Note Labor Only Ma
420. t on the date of the contract advertisement notwithstanding any reference to a particular date 1 12 PRE CONSTRUCTION CONFERENCE A In accordance with Article V of the CONTRACT AND GENERAL CONDITIONS a pre construction conference to review the work will be conducted by the UMA Project Manager SUMMARY 10 14 2015 011000 7 of 20 5 1 2015 rev Ae paris E Mo Oo x 12 13 14 15 16 12 MULLINS SECURITY CAMERAS Representatives of the following shall be required to attend this conference UMA Designer General Contractor All Subcontractors Applicable Municipal Agencies The General Contractor shall have a responsible representative at the pre construction conference to be called by the UMA Project Manager following the award of the contract as well as representatives of field or office forces and major Subcontractors All such representatives shall have authority to act for their respective firms The pre construction conference is to be held within five days of Notice to Proceed or as otherwise determined by UMA Contact List The Contractor shall provide to the Designer and UMA Project Manager a list containing the following Contractor s name address office and cell phone number fax number e mail address and after hours emergency phone number Contractor s Superintendent name email address and cell phone number Each Sub Contractor s name email address address office
421. t standard information to provide additional information applicable to the project Clearly mark each copy to identify pertinent materials products or models Show dimensions and clearances required Show performance characteristics and capacities Show wiring diagrams and controls All such data shall be specific and identification of material or equipment submitted shall be clearly made in ink Data of general nature will not be accepted Product Data shall be accompanied by transmittal notice The General Contractor s stamp of approval shall appear on the printed information itself Submit the information listed above in both hard and electronic format D Samples 1 Physical samples shall illustrate materials equipment or workmanship and shall establish standards by which work is judged After review and approval samples may be used in construction of project if not retained for comparison a Office samples of sufficient size and quantity shall clearly illustrate 1 Functional characteristics of product or material with integrally related parts and attachment devices 2 Full range of color samples including standard and premium ranges 3 After review and approval by Designer and the UMA Project Manager samples may be used in construction of project if not retained for comparison b Field Samples and Mock ups 1 Erect at project site at locations acceptable to the Designer and the UMA Project Manager
422. ten notification to M WBE economic development assistance agencies trade groups and other organizations notifying them of the Contract and the work to be subcontracted by the Bidder to M WBEs The Bidder shall also submit any other information reasonably requested by the Awarding Authority to show that the Bidder has taken all actions that could reasonably be expected to achieve the M WBE participation goals 8 3 If filed sub Bids are solicited for this Contract requests from prospective general Bidders to reduce or waive the M WBE participation goals for this Contract must be received by the Awarding Authority no later than four 4 working days after the list of filed sub Bidders is mailed by the Awarding Authority to persons who have taken out plans for the Contract If 17 there are no filed sub Bids solicited for this Contract requests to reduce or waive the W MBE participation goals for this Contract must be received by the Awarding Authority no later than fourteen 14 calendar days before the date set for the receipt of general Bids THE AWARDING AUTHORITY WILL NOT CONSIDER ANY REQUEST TO REDUCE OR WAIVE THE M WBE PARTICIPATION GOALS FOR THIS CONTRACT THAT IS RECEIVED AFTER THESE DEADLINES Any reduction or waiver of the M WBE participation goals for this Contract will be made by written addendum mailed to all persons who have taken out plans for the project 8 4 No later than five 5 working days after the opening of general Bids the appa
423. terial Only Material and Labor Complete Original Subcontract Amount _ Adjusted Subcontract Amount Change Orders etc 2 Total Payments Received to Date From Prime Contractor Total Amount Balance Due From Prime Contractor 191 If the completed activity is different from that listed on the Letter of Intent please explain If more space is needed continue on back of sheet The individuals signing below hereby certify under the pains and penalties of perjury that all work listed on the Contract Letter of Intent or approved changes thereto as explained above was completed by the MBE WBE firm on 20 andthe above amounts listed for these services are true and accurate FOR CONTRACTOR FOR MBE WBE FIRM Authorized Signature Authorized Signature Print Name Print Name Title Title Date Telephone No Date Telephone No NOTE To be submitted to the University of Massachusetts Amherst within ten 10 days after completion of work by MBE WBE Facilities Planning Physical Plant Building 360 Campus Center Way Amherst MA 01003 Certificate of Completion Revised 10 01 192 PROJECT NO UMA NO FORM FOR TRANSFER OF TITLE UMA FORM 16 Name of Contractor or Subcontractor having ownership Business Address Date KNOW ALL MEN BY THESE PRESENTS That we of City in the County of and the Commonwealth of Massachusetts in consideration of One Dollar 1 00 and other good and valu
424. th matching mounting brackets Mounting Brackets for Fixed Cameras Type matched to items supported and mounting conditions Include manual pan and tilt adjustment MONITORS Monitor shall be manufactured by Tatung or equal as shown on the drawings Color Screen Size Diagonal Dimension 42 1 2 Mounting Wall mount bracket as recommended by the manufacturer 3 Electrical 120 V ac 60 Hz VIDEO SURVEILLANCE 10 14 2015 265700 3 of 9 2 5 UMA 16 12 MULLINS SECURITY CAMERAS NETWORK VIDEO RECORDERS NVR system Manufacturer Honeywell Fusion IV Rev B NVR system Shall be compatible and 100 operable with the existing campus Honeywell Fusion video retrieval system and software Remote video software HFRVS that runs on a Microsoft Windows based personal computer PC HFRVS is used for configuring communications from PCs to NVRs administering operator accounts for the NVR setting up sequential touring of NVRs and configuring communications from NVR to Alarm Station Data about multiple NVRs must be stored in a database Features The network video recorder shall include as a minimum the following features functions specifications The network video recorder shall 1 2 10 11 Offer stability security and ease of use and allow the user to edit network settings The NVR shall be optimized and support the Windows 7 OS Support static IP and DHCP IP address and subnet mask to allow for installation in many
425. th the contract and Form 13 Predetermined LUMP SUM total 5 00 168 if checked Additional Verification Backup Data Must Be Provided with Formal Change Order See Attached Lump Sum NOT TO EXCEED 5 00 Maximum price based on contract unit prices or negotiated agreed unit prices TIME AND MATERIALS Not to Exceed 5 00 Computed in accordance with Article VII of the General conditions Resident Engineer Date Project Manager Date Director Date APPROVAL OF THIS NOTICE OF INTENT DOES NOT ADDRESS REQUESTS FOR ADDITIONAL TIME EXTENSIONS OF CONTRACT TIME WILL BE ADDRESSEDUPON SUBMITTAL OF THE OFFICAL CHANGE ORDER RECEIPT OF THIS REQUEST TO BE ACKNOWLEDGED IN WRITING TO UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING CERTIFICATION OF SUFFICIENT FUNDS BY SPEED CODE COPY Project Manager Resident Engineer 169 DIVISION OF CAPITAL ASSET MANAGEMENT DCAM CHANGE REQUEST NO THE COMMONWEALTH OF MASSACHUSETTS EXECUTIVE OFFICE FOR ADMINISTRATION amp FINANCE REQUEST AND AGREEMENT FOR A CHANGE IN THE PLANS AND OR SPECIFICATIONS AND OR CONTRACT All signatures are affixed under the penalties of perjury Project No Contract Location REQUEST a Requested by of b Requestor s description of change GENERAL CONTRACTOR S PROPOSAL REQUEST NO For all costs involved in this change including extensions of time herein requested the undersigned general c
426. the Specifications and in any Plans specified in such section prepared by for name of architect or engineer project number project name in Massachusetts for the Contract sum of city town dollars 5 For Alternate 1 Add 5 Subtract 5 For Alternate No 2 Add 5 Subtract 5 For Alternate 3 Add 5 Subtract 5 For Alternate 4 Add 5 Subtract 5 For Alternate No 5 Add 5 Subtract 5 B This sub bid includes addenda numbered list all addenda Name of Sub bidder 59 C This sub bid May be used by any general bidder except May only used by the following general bidders To exclude general bidders insert X in one box only and fill in blank following that box Do not answer C if no general bidders are excluded D The undersigned agrees that if it is selected as a sub bidder it will within five days Saturdays Sundays and legal holidays excluded after presentation of a subcontract by the general bidder selected as the general contractor execute with such general bidder a subcontract in accordance with the terms of this sub bid and contingent upon the execution of the general contract and if requested so to do in the general bid by such general bidder who shall pay the premiums therefore or if prequalification is required pursuant to section 44D3 4 furnish a performance and payment bond of a surety company qualified to do business under the laws of the Commonwealth and satisfac
427. the Work in process of manufacture or fabrication or in storage elsewhere than the Site 4 Or Equal Submissions A Where products or materials are prescribed by manufacturer name trade name or catalog reference the words or Approved equal shall be understood to follow An item shall be considered equal to the item so named or described if in the opinion of the Awarding Authority a it is at least equal in quality durability appearance strength and design b it performs at least equally the function imposed in the general design for the Work and c it conforms substantially even with deviations to the detailed requirements for the items as indicated by the Specifications Any structural or mechanical changes made necessary to accommodate products or materials substituted as an or equal shall be at the expense of the Contractor Approved equal shall mean an item with respect to which the Awarding Authority shall have issued a written statement to the Contractor to the effect that the item is in the Awarding Authority s opinion equal within the meaning of this paragraph to that prescribed in the Contract Documents B The Contractor shall be responsible for providing the Designer with any information and test results that the Designer reasonably requires to determine whether or not a material is equal to a material named or described in the Contract Documents 110 C Whenever the Contractor submits a material for approval as a
428. the awarding authority claiming a demand for direct payment is premature and such subcontractor must file the petition before the awarding authority has made a direct payment to the subcontractor and has made a deposit of the disputed portion as provided in part iii of subparagraph 5 and in subparagraph 6 5 In any petition to collect any claim for which a subcontractor has filed a demand for direct payment the court shall upon motion of the general contractor reduce by the amount of any deposit of a disputed amount by the awarding authority as provided in part iii of subparagraph 5 and in subparagraph 6 any amount held under a trustee writ or pursuant to a restraining order or injunction 7 Contracts for Public Works Governed by M G L c 30 s 396 The following statutory provision applies only to contracts for public works governed by M G L 30 5 39G Upon substantial completion of the work required by a contract with the commonwealth or any agency or political subdivision thereof for the construction reconstruction alteration remodeling repair or improvement of public ways including bridges and other highway structures sewers and water mains airports and other public works the contractor shall present in writing to the awarding authority its certification that the work has been substantially completed Within twenty one days thereafter the awarding authority shall present to the contractor either a written declar
429. the existence of any addenda issued by the Awarding Authority whether or not the same are mailed to or received by Bidder Copies of addenda will be made available for inspection at the locations listed in the Advertisement where the Contract Documents are on file ATTENTION CONTRACTORS amp SUBCONTRACTORS EFFECTIVE AUGUST 1 2006 sk sk sk ke ke o ok ok 2 ke ok ke ke o oj oj ok ok ALL CONTRACTORS AND SUBCONTRACTORS PLEASE NOTE THE NEW UNIVERSITY OF MASSACHUSETTS AMHERST CONTRACT PROVISIONS REQUIRING CONFIRMATION OF HIRING PRACTICES IN ACCORDANCE WITH FEDERAL DEPARTMENT OF HOMELAND SECURITY REQUIREMENTS THIS INCLUDES BUT IS NOT LIMITED TO THE FAITHFUL COMPLETION OF THE FORM 1 9 PROCESS FOR ALL PERSONS TO BE EMPLOYED IN THE WORK OF THE PROJECT WHO ARE REQUIRED TO BE LISTED ON THE CERTIFIED PAYROLL REPORTS THE CONTRACTOR AND ALL SUBCONTRACTORS MUST 1 EXECUTE ALONG WITH ITS CONTRACT SUBCONTRACT AND CERTIFICATE OF COMPLIANCE WITH EMPLOYMENT ELIGIBILITY VERIFICATION REQUIREMENTS AND 2 MUST CERTIFY IN EACH CERTIFIED PAYROLL REPORT SUBMITTED TO UNIVERSITY OF MASSACHUSETTS AMHERST THAT THE FORM 1 9 PROCESS WAS FAITHFULLY COMPLETED FOR ALL EMPLOYEES LISTED ON EACH CERTIFIED PAYROLL REPORT SEE NOTICE TO BIDDERS AND GENERAL CONDITIONS ATTENTION CONTRACTORS amp SUB CONTRACTORS EFFECTIVE JULY 1 2006 M G L c 30 8 39S a 2 REQUIRES THAT ALL EMPLOYEES TO BE EMPLOYED AT THE WORKSITE WILL HAVE SUCCESSFULLY COMPLETED A COURSE
430. the form and manner prescribed by the rules governing the conduct of adjudicatory proceedings of the division of hearing officers In the event an aggrieved party exercises his option to file an action directly in court as provided in the previous sentence the twenty one day period shall not apply to such filing and the period of filing such action shall be the same period otherwise applicable for filing a civil action in superior court The appeal shall be referred to a hearing officer experienced in construction law and shall be prosecuted in accordance with the formal rules of procedure for the conduct of adjudicatory hearings of the division of hearing officers except as provided below The hearing officer shall issue a final decision as expeditiously as possible but in no event more than one hundred and twenty calendar days after conclusion of the adjudicatory hearing unless the decision is delayed by a request for extension of time for filing post hearing briefs or other submissions assented to by all parties Whenever because an extension of time has been granted the hearing officer is unable to issue a decision within one hundred and twenty days s he shall notify all parties of the reasons for the delay and the date when the decision will issue Failure to issue a decision within the one hundred and twenty day period or within the additional period specified in such written notice shall give the petitioner the right to pursue any legal remedies a
431. the performance of this contract that pursuant to federal requirements the Contractor shall verify the immigration status of all workers assigned to the contract without engaging in unlawful discrimination and that the Contractor shall not knowingly or recklessly alter falsify or accept altered or falsified documents from any such worker The Contractor understands and agrees that breach of any of these terms during the period of a contract may be regarded as a material breach subjecting the Contractor to sanctions including but not limited to monetary penalties withholding of payments contract suspension or termination UMA Project Number Project Number Project Title The Company Social Security No or Federal Identification No is Signed under pains and penalties of perjury the day of 20 Signature Name and Title 81 UNIVERSITY OF MASSACHUSETTS AMHERST FORM FOR SUBCONTRACT M G L c 149 s 44F THIS AGREEMENT made this day of 20 by and between a corporation organized and existing under the law of a partnership consisting of an individual doing business as __ hereinafter called the Contractor and a corporation organized and existing under the law of a partnership consisting of an individual doing business as hereinafter called the Subcontractor WITNESSETH that the Contractor and the Subcontractor for the considerations hereafter named agree as follows 1 The Subcontractor agrees to furnish all l
432. the time an alleged delay occurs Failure to notify UMA of any delay as provided in the contract shall preclude the General Contractor from subsequently claiming any damages due to said delay For purposes of scheduling the project will be considered to be Substantially Complete when all work affecting health safety and function is totally completed and with less than one 1 percent of the base contract value remaining and ready for complete Use and Occupancy as determined by the UMA Project Manager the Operating Agencies individually or collectively and the Designer Then the User Agencies individually or collectively will take control of their building area s and be responsible for operating costs and security Final punch lists will be established and monetized at this time 1 UMA Certificate of Use and Occupancy must be issued for partial Use and Occupancy contingent upon conditions set forth by the Building Official having jurisdiction The Massachusetts Department of Public Safety Occupancy Certificate must be issued by the effective Substantial Completion date 2 The General Contractor shall have the number of calendar days stated in the contract from the date of the UMA Notice to Proceed to complete all the work before Substantial Completion is achieved If the General Contractor fails to complete the work within the contract completion time frame so stated the General Contractor shall be subject to the assessment of liqu
433. the work performed In the event of any dispute as to the formal request for periodic payment the Resident Engineer and or the Designer shall in the absence of their certification on the AIA form attach to each copy a qualified certification and a recommendation as to the dollar value of the item or items in dispute to be retained by Awarding Authority in accordance with Chapter 30 Section 39K In the signatory space write See attached Letter Neither the Resident Engineer nor the Designer shall alter the AIA Form submitted with the formal request for payment in any manner If the Division concurs with the Engineer and or Designer s recommendation adjustment s shall be made to the AIA form by the Division Attention of the General Contractor is directed to the statement to the effect that payments to all sub contractors have been made in accordance with the provision of M G L c 30 s39F which statement must be signed under penalty of perjury on each copy by the General Contractor 163 V PROCESSING FOR PERIODIC PAYMENTS It shall be the sole responsibility of the General Contractor to choose the delivery of the request for periodic payment in proper form and arithmetically correct to the Resident Engineer the designee provided in M G L c 30 s 39K In the event there is no Resident Engineer assigned to the contract the Designer shall be the designee If there be neither a Resident Engineer nor a Designer the designee shall be the University o
434. therefore and the persons employed thereon as the Designer shall from time to time request B Shop Drawings Product Data Samples and similar submittals are not Contract Documents The purpose of their submission is to demonstrate for those portions of the Work for which submittals are required the way the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents C The Contractor shall review approve and submit to the Designer Shop Drawings Product Data Samples and similar submittals required by the Contract Documents with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of the Awarding Authority or of separate contractors Submittals made by the Contractor which are not required by the Contract Documents or which do not comply with the Contract Documents may be returned without action The Contractor s attention is directed to the provisions of Section 4 of this Article V and to the Specifications D The Contractor shall prepare and keep current for the Designer s approval a schedule of submittals which is coordinated with the Progress Schedule and allows the Designer reasonable time to review submittals E The Contractor shall perform no portion of the Work requiring submittal and review of Shop Drawings Product Data Samples or similar submittals until the respective submittal has been approved by the Designer Such Work shall be i
435. this Section of the Specifications SUMMARY Section includes a video surveillance system consisting of cameras digital video recorder data transmission wiring and a control station with its associated equipment DEFINITIONS IP Internet protocol LAN Local area network MPEG Moving picture experts group PC Personal computer PTZ Pan tilt zoom RAID Redundant array of independent disks TCP Transmission control protocol connects hosts on the Internet UPS Uninterruptible power supply PERFORMANCE REQUIREMENTS Seismic Performance Video surveillance system shall withstand the effects of earthquake motions determined according to ASCE SEI 7 1 The term withstand means the unit will remain in place without separation of any parts from the device when subjected to the seismic forces specified VIDEO SURVEILLANCE 10 14 2015 265700 1 of 9 1 5 1 6 1 7 1 8 UMA 16 12 MULLINS SECURITY CAMERAS ACTION SUBMITTALS Product Data For each type of product indicated Include dimensions and data on features performance electrical characteristics ratings and finishes Shop Drawings For video surveillance Include plans elevations sections details and attachments to other work 1 Detail equipment assemblies and indicate dimensions weights loads required clearances method of field assembly components and location and size of each field connection 2 Functional Block Diagram Show single
436. tion as evidence of its qualifications to perform the work as bid upon according to all the requirements of the Plans and specification 1 Have been in business under present business name years 2 Ever failed to complete any work awarded 3 List one or more recent buildings with names of the general Contractor and Designer on which you served as a subcontractor for work of similar character as required for the above named building Building Designer General Contractor Amount of Contract a b c 4 Bank reference The undersigned hereby certifies that it is able to furnish labor that can work in harmony with all other elements of labor employed or to be employed on the work that all employees to be employed at the worksite will have successfully completed a course in construction safety and health approved by the United States Occupational Safety and Health Administration that is at least 10 hours in duration at the time the employee begins work and who shall furnish documentation of successful completion of said course with the first certified payroll report for each employee and that it will comply fully with all laws and regulations applicable to awards of subcontracts subject to section forty four F of Chapter 149 of the General Laws The undersigned further certifies under penalties of perjury that this sub bid is in all respects bona fide fair and made without collusion or fraud with any other person As used in this subs
437. tion to participate in any proceedings undertaken pursuant to this paragraph C Upon showing that the Contractor is in full compliance with the requirements of this Article or that the Contractor has met or will meet the M WBE participation goals for this Contract the Awarding Authority shall release any funds withheld pursuant to clause A 1 above and lift any suspension of the Contractor s performance under clause A 2 above 9 Liquidated Damages Termination A If payment by the Awarding Authority or performance by the Contractor is suspended by the Awarding Authority as provided in paragraph 8 above the Awarding Authority shall have the following rights and remedies if the Contractor thereafter fails to take all action necessary to bring the Contractor into full compliance with the requirements of this Article or if full compliance is no longer possible because the default of the Contractor is no longer susceptible to cure if the Contractor fails to take such other action as may be required by the Awarding Authority to meet the M WBE participation goals set forth in this Contract 1 the Awarding Authority may terminate this Contract and or 2 the Awarding Authority may retain from final payment to the Contractor as liquidated damages an amount equal to the difference between x the total of the M WBE participation goals set forth in this Contract and the amount of M WBE 159 participation credit earned by the Contractor
438. tions of the Contractor under Section 1 above shall not extend to the liability of the Designer its agents or employees arising out of i the preparation or approval of maps drawings opinions reports surveys Change Orders designs or specifications or ii the giving of or the failure to give directions or instructions by the Designer its agents to employees provided such giving or failure to give is the primary cause of the injury or damage 3 Survival The provisions of this Article XV are intended to survive Final Acceptance and or any termination of this Contract ARTICLE XVI PERFORMANCE AND PAYMENT BONDS 1 Contractor Bonds A The Contractor shall provide performance and payment labor and materials bonds in the form provided by the Awarding Authority executed by a surety licensed by the Commonwealth of Massachusetts Division of Insurance Each such bond shall be in the amount of the Contract Price B If at any time prior to final payment to the Contractor the Surety is adjudged bankrupt or has made a general assignment for the benefit of its creditors has liquidated all assets and or has made a general assignment for the benefit of its creditors 15 placed in receivership otherwise petitions a state or federal court for protection from its creditors or allows its license to do business in Massachusetts to lapse or be revoked 146 then the Contractor shall within 21 days of any such actio
439. tle Date Note revised table must be submitted if any changes on projection occur Quarterly Projected Workforce Table Revised 10 01 186 CERTIFICATE OF PAYMENT BY CONTRACTOR DESIGNER TO MINORITY amp WOMEN BUSINESS ENTERPRISES UNIVERSITY OF MASSACHUSETT AMHERST TO University of Massachusetts Amherst Reporting Facilities Planning Period Physical Plant Building 360 Campus Center Way Amherst MA 01003 Contract Date Design Contract Construction Contract RE UMA No Project No Project Name The undersigned hereby certifies under the pains and penalties of perjury that the contractor designer named below has made the following payments to the named Minority and Women Business Enterprises for work performed on the above project MBE WBE Firm Name Work Subcontract Payments Cumulative Performed Amount This Quarter Payments L MBE L WBE 5 L MBE L WBE 5 5 5 L MBE L WBE 5 5 5 L MBE L WBE 5 5 5 187 L MBE L WBE 5 5 5 L MBE L wBE L MBE L WBE Date Submitted Name of General Contractor or Design Firm Telephone No Authorized Signature Fax No Print Name and Title MBE and WBE payment reports are required for each quarter of the fiscal year for each of your University of Massachusetts Amherst projects Reports are to cover the following three month periods 1 quarter July 1st September 30th 9n quarter October 1st December 31st 3 q
440. to VGA adapter rg ho AO NVR shall be pre configured for fast and seamless integration within existing IT infrastructures The unit must offer the following network setup options a The ability to throttle the bandwidth of the NVR to ensure that images and system messages are delivered as quickly as possible within the capabilities of the network s available bandwidth b The ability to view the IP configuration of the NVR VIDEO SURVEILLANCE 10 14 2015 265700 4 of 9 12 13 14 15 16 17 18 19 20 21 22 23 24 25 UMA 16 12 MULLINS SECURITY CAMERAS Include a System Log to record and display information pertaining to alarm events NVR reboots and other related information record display hardware information pertaining to system recording successes and failures and other related information The user shall have the ability to export the log information Be pre configured for fast and seamless integration within existing IT infrastructures The unit must offer the following network setup options The ability to throttle the bandwidth of the NVR to ensure that images and system messages are delivered as quickly as possible within the capabilities of the network s available bandwidth The ability to view the IP configuration of the NVR Include a System Log to record and display information pertaining to alarm events NVR reboots and other related information record display har
441. to or affecting the Work except the claim against the Owner or the Designer for the remainder if any there be of the amounts set forth by the Contractor in the Certificate of Final Inspection Release and Acceptance Final Acceptance shall not relieve Contractor of the requirements of Articles IX XIV and XV of these General Conditions of the Contract or of other provisions of this Contract to the extent that the same are intended to survive Final Acceptance ARTICLE IX GUARANTEES AND WARRANTIES 134 1 General Warranty If at any time during the period of one 1 year from the date of the issuance of the Certificate of Agency Use and Occupancy by the Awarding Authority or the date of Final Acceptance whichever occurs first any part of such Work shall in the reasonable opinion of the Awarding Authority be defective or require replacing or repairing or damage to other property of the Owner is caused by any defect in the Work the Awarding Authority shall notify the Contractor in writing to make the required repairs or replacements and repair such damage If the Contractor shall neglect to commence such repairs or replacements to the satisfaction to the Awarding Authority within ten 10 days from the date of the giving of such notice then the Awarding Authority may employ other persons to make the same The Contractor agrees upon demand to pay to the Awarding Authority all amounts which it expends for such repairs replacements and or dam
442. tory to the awarding authority in the full sum of the subcontract price E The names of all persons firms and corporations furnishing to the undersigned labor or labor and materials for the class or classes or part thereof of work for which the provisions of the section of the Specifications for this sub trade require a listing in this paragraph including the undersigned if customarily furnished by persons on his own payroll and in the absence of a contrary provision in the Specifications the name of each such class of work or part thereto and the bid price for such class of work or part thereof are NAME CLASS OF WORK BID PRICE Do not give bid price for any class or part thereof furnished by undersigned 60 F The undersigned agrees that the above list of bids to the undersigned represents bona fide bids based on the hereinbefore described Plans Specifications and addenda and that if the undersigned is awarded the contract they will be used for the work indicated at the amounts stated if satisfactory to the awarding authority G The undersigned further agrees to be bound to the general Contractor by the terms of the hereinbefore describe Plans Specifications including all general conditions stated therein and addenda and to assume toward the general Contractor all the obligations and responsibilities that the general Contractor by those documents assumes toward the Commonwealth H The undersigned offers the following informa
443. tractor first obtains the Awarding Authority s prior written specific Approval If the Awarding Authority Approves the use or storage of explosives during the performance of the Work the Contractor shall first comply with all Laws and obtain all permits approvals and certificates required in connection with the same and shall exercise best efforts including but not limited to the employment and supervision of properly qualified personnel to prevent damage injuries and accidents involving said explosives J The Contractor shall not permit cutting or welding in or immediately adjacent to existing property of the Owner Awarding Authority or of anyone else without the Awarding Authority s prior Approval in each instance 14 Debris and Chemical Waste A The Contractor shall not permit the accumulation of interior or exterior debris The Contractor shall keep the Work area clean at all times Without limitation garbage shall be removed daily B The Contractor shall properly classify and remove debris and waste from the Site and transport and dispose of it all in accordance with Laws employing a qualified and properly licensed transporter at any landfill disposal or recycling facility licensed under applicable Laws including without limitation hazardous materials laws The Contractor shall make all arrangements and give and obtain all notices communications documentation permits certificates and approvals necessary for said disposal fr
444. tractors h Credits should always include a bond reduction GENERAL CONTRACTOR S BOND PREMIUM SHALL BE INCLUDED AT THE FOLLOWING RATES IF A CONTRACTOR S BOND RATE DIFFERS FROM THIS LIST VERIFICATION FROM THE BOND CARRIER MUST BE SUBMITTED SHOWING THE ACTUAL RATE Contract Price Rates per Thousand a Contracts up to 500 000 14 40 b 500 000 to 2 500 000 8 70 c 2 500 000 to 5 000 000 6 90 d 5 000 000 to 7 000 000 6 30 e 7 500 000 and up 5 76 177 5 07 FOR TIME AND MATERIAL CHANGE ORDER WORK DAILY TIME AND MATERIAL RECORDS SHALL BE PREPARED BY THE CONTRACTOR AND COPIES MAINTAINED BY THE RESIDENT ENGINEER FOR ALL CHANGES AUTHORIZED UNDER THE ABOVE SECTIONS UPON THE COMPLETION OF THE WORK AUTHORIZED THE CONTRACTOR SHALL SUBMIT A FORMAL CHANGE ORDER WITH ALL THE REQUIRED SUPPORTING DATA VERIFIED AND SIGNED BY THE RESIDENT ENGINEER UNIVERSITY OF MASSACHUSETTS PM IF APPLICABLE 5 08 IF A CONTRACTOR DESIRES TO BE COMPENSATED AS AUTHORIZED WORK PROGRESSES IT SHALL AFTER RECEIPT OF AN NOI IMMEDIATELY SUBMIT A UMA FORM 5 AS OUTLINED IN PARAGRAPH 3 01 178 CONTRACTOR S WEEKLY WORKFORCE REPORT UNIVERSITY OF MASSACHUSETTS AMHERST UMA No Project Number Project Name Project Location Name of General Contractor Minority Goal 96 Name of Contractor Filing Report Address Week Ending Began NOTE Min Minority Women work completed Women Goal 96 Report No Check here if thi
445. ts in which case the 20 cap does not apply SECTION 9 CONTRACT AWARD 9 1 Award means the determination selection and notification of the lowest responsible and eligible Bidder by the Awarding Authority 9 2 The Awarding Authority will award the Contract within thirty days Saturdays Sundays and legal holidays excluded after the opening of Bids in accordance with M G L c 149 8444 9 3 The Contract will be awarded to the lowest responsible and eligible Bidder as determined by the Awarding Authority except in the event of substitution as provided under M G L 149 44E and 44F in which cases the procedure as required by said sections shall govern the award of the Contract 9 4 As used herein the term lowest responsible and eligible Bidder shall mean the general Bidder whose Bid is the lowest of those Bidders who in the Awarding Authority s opinion are ready willing and able to comply with all requirements of the Contract Documents and demonstrably possess the skill ability and integrity necessary for the faithful performance of the Work based on the determination of past performance and financial soundness under i M G L c l49 844A and following sections ii the rules regulations orders guidelines and policies promulgated from time to time by the Commissioner of the Division of Capital Asset Management and Maintenance DCAM and iii any other relevant criteria that the Commissioner may prescribe If the Awarding
446. ts shall represent the manufacturer s complete standard offerings except where SUBMITTAL REQUIREMENTS 10 14 2015 013300 7 of 8 12 4 2012 1 8 16 12 MULLINS SECURITY CAMERAS Specifications limit the offerings by defining a particular series or product type which is normally limited in color and pattern availability Color and Pattern charts shall be submitted in quantities specified with two 2 additional copies submitted to the UMA Project Manager and one 1 copy to the UMA Resident Engineer SCHEDULE OF VALUES Prior to the first request for payment the General Contractor shall submit to the Designer and the UMA Project Manager a Schedule of Values of the various portions of the Work in sufficient detail to reflect various major components of each Subcontractor including quantities when requested aggregating the total contract sum and divided so as to facilitate payments for work under each Section The schedule shall be prepared in such form as specified or as the Designer or the UMA Project Manager may approve and it shall include data to substantiate its accuracy Each item in the Schedule of Values shall include its proper share of overhead and profit This schedule including breakdown and values requires the approval of the Designer and the UMA Project Manager and shall be used only as a basis for the General Contractor s request for payment PART 2 PRODUCTS Not Used PART 3 EXECUTION Not Used END OF SEC
447. tten consent of the Owner except as expressly permitted in this Contract 147 6 The Contractor has failed to comply with Laws 7 The Contractor fails to maintain or provide to the Awarding Authority evidence of the insurance or bonds required by this Contract or 8 The Contractor has failed to prosecute the Work or any portion thereof to the standards required under this Contract or has otherwise breached any material provision of this Contract B The Awarding Authority shall give the Contractor and any surety notice of such termination for cause but the giving of notice of such termination shall not be a condition precedent or subsequent to the termination s effectiveness In the event of such termination and without limiting any other available remedies the Awarding Authority may at its option 1 hold the Contractor and its sureties liable in damages for a breach of Contract 2 notify the Contractor to discontinue all work or any part thereof and the Contractor shall discontinue all work or any part thereof as the Owner may designate 3 complete the Work or any part thereof and charge the expense of completing the Work or part thereof to the Contractor 4 require the surety or sureties to complete the Work and perform all of the Contractor s obligations under this Contract If the Awarding Authority elects to complete all or any portion of the Work as specified in 3 above it may take possession of all mate
448. tts corporation having a principal place of business at its general partner By Its Hereunto duly authorized Date By a Massachusetts corporation having a principal place of business at its general partner By Its Hereunto duly authorized Date Note This certificate may have to be modified depending upon the terms of the joint venture agreement 79 CERTIFICATE OF COMPLIANCE WITH STATE LAWS AND WITH UNEMPLOYMENT COMPENSATION CONTRIBUTION REQUIREMENTS Pursuant to M G L c 62C s 49A and M G L c 151A s 19A l authorized signatory for whose principal place of business is at do herby certify under penalties of perjury that has filed all state tax returns and paid all taxes as required by law and has complied with all state laws pertaining to contributions to the unemployment compensation fund and to payments in lieu of contributions The Business Organization Social Security Number or Federal Identification Number is Signed under the penalties of perjury the day of 20 Signature Name Title 80 CERTIFICATE OF COMPLIANCE WITH EMPLOYMENT ELIGIBILITY VERIFICATION REQUIREMENTS 1 9 CERTIFICATE Applicable to all UMA Construction Projects To Be Executed by GC CMGC AII Subcontractors Company Name authorized signatory for Print Name Company whose principal place of business is at Address do hereby certify under penalties of perjury that Company shall comply with Federal Dep
449. ture allows users to manually initiate recording on a specific camera overriding the current schedule 2 Provide through the remote software the ability to export single images in JPG file format and save video clips in the AVI format A digital signature must be attached to every JPG and AVI file exported by the unit for use with the bundled Digital Verifier application This function must be unique to the unit and its verification software and shall not interfere with viewing files using other applications 3 Support the Honeywell VCL and Honeywell MAXPRO protocols IP VIDEO SYSTEMS Description 1 System shall provide high quality delivery and processing of IP based video audio and control data using standard Ethernet based networks 2 System shall have seamless integration of all video surveillance and control functions 3 Graphical user interface software shall manage all IP based video matrix switching and camera control functions two way audio communication alarm monitoring and control and recording and archive retrieval management IP system shall also be capable of integrating into larger system environments 4 System design shall include all necessary compression software for high performance dual stream MPEG 2 MPEG 4 video Unit shall provide connections for all video cameras camera PTZ control data bidirectional audio discreet sensor inputs and control system outputs 5 All camera signals shall be compressed
450. uarter January 1st March 31st quarter April 1st June 30th Reports must be submitted within 10 business days of your receipt of this form NOTICE ntentionally submitting false information in this document may subject the contractor designer to criminal prosecution and or debarment from public contracting 188 Certificate of Payment Revised 10 01 INSTRUCTIONS FOR COMPLETING CERTIFICATE OF PAYMENT BY CONTRACTOR DESIGNER TO MINORITY amp WOMEN BUSINESS ENTERPRISES As part of its effort to ensure reliable up to date information concerning the actual payments made to certified MBE and WBE subcontractors on all University of Massachusetts Amherst projects the Compliance Office has prepared these instructions to assist you in completing the enclosed form PLEASE READ THESE INSTRUCTIONS CAREFULLY UNIVERSITY OF MASSACHUSETTS AMHERST WILL RETURN ANY CERTIFICATION OF PAYMENT THAT IS INCOMPLETE OR INACCURATE PLEASE NOTE IF THIS PROJECT IS COMPLETE ON HOLD OR YOUR FIRM PREVIOUSLY SUBMITTED A FINAL CERTIFICATION OF M WBE PAYMENT FOR THIS PROJECT PLEASE SO INDICATE ON THE FORM AND RETURN IT TO UNIVERSITY OF MASSACHUSETTS AMHERST FACILITIES PLANNING PLEASE INCLUDE THE FOLLOWING INFORMATION IN THE DESIGNATED SECTIONS OF THE FORM M WBE NAME Include the MBEs and WBEs listed on the project s approved Schedule For Participation and any additional M WBEs that worked on the project Please note that any change in MBE and or WBE p
451. ublic traffic Walks paved or landscaped areas over which temporary driveways cross shall upon completion of the work be restored to their original condition Temporary roadways shall be bridged over trenched areas Filing is required for a UMA issued trench permit SUMMARY 10 14 2015 011000 4 of 20 5 1 2015 rev H re 16 12 MULLINS SECURITY CAMERAS The General Contractor can gain access to the premises during the hours specified below In addition the General Contractor and his personnel will limit themselves only within the working premises during working hours If work needs to be scheduled during times other than those listed below General Contractor shall inform the UMA Project Manager one week prior to work Deliveries 7 00 AM to 6 00 PM General Access 7 00 AM to 6 00 PM during the regular work week Confine operations at the site to areas permitted by Laws Ordinances Permits Contract Documents Owner s Regulations General Contractor shall supervise the use of the site related to construction and be responsible for correcting any damage identified by the UMA Project Manager to the UMA Project Manager s satisfaction All available existing utilities adjacent to the construction site will be available for use during construction unless indicated otherwise Temporary connections to these utilities all metering transformers removal usage and their associated costs will be the responsib
452. ubstrate by means that meet seismic restraint strength and anchorage requirements Drill holes for expansion anchors in concrete at locations and to depths that avoid reinforcing bars END OF SECTION 260529 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 10 14 2015 260529 4 of 4 UMA16 12 MULLINS SECURITY CAMERAS SECTION 260533 RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS PART 1 GENERAL PART OF SECTION 260001 ELECTRICAL WORK 1 1 A 1 2 A 1 3 A B C 1 4 A B RELATED DOCUMENTS Attention is directed to the CONTRACT AND GENERAL CONDITIONS and all Sections within DIVISION 01 GENERAL REQUIREMENTS which are hereby made a part of this Section of the Specifications SUMMARY Section Includes 1 Metal conduits tubing and fittings 2 Surface raceways 3 Boxes enclosures and cabinets DEFINITIONS ARC Aluminum rigid conduit GRC Galvanized rigid steel conduit IMC Intermediate metal conduit SUBMITTALS Product Data For surface raceways wireways and fittings floor boxes hinged cover enclosures and cabinets Shop Drawings For custom enclosures and cabinets Include plans elevations sections and attachment details PART 2 PRODUCTS 2 1 A METAL CONDUITS TUBING AND FITTINGS Manufacturers Subject to compliance with requirements available manufacturers offering products that may be incorporated into the Work include but are not limited to the fo
453. uch Contractor into compliance In the event that such Contractor fails or refuses to fully perform such steps the Commission may make a final report of non compliance and recommend to the Awarding Authority the imposition of one or more of the sanctions listed below If however the Commission believes the Contractor or any Subcontractor has taken or is taking every possible measure to achieve compliance it shall not make a final report of non compliance Within fourteen days of the receipt of the recommendations of the Commission the Awarding Authority shall move to impose one or more of the following sanctions as it may deem appropriate to attain full and effective enforcement 1 The recovery by the Awarding Authority from the Contractor of 1 100 of 1 of the Contract award price or 1 000 whichever sum is greater in the nature of liquidated damages or if a Subcontractor is in non compliance the recovery by the Awarding Authority from the Contractor to be assessed by the Contractor as a back charge against the subcontractor of 1 10 of 196 of the sub Contract Price or 400 whichever 154 sum is greater in the nature of liquidated damages for each week that such party fails or refuses to comply 2 The suspension of any payment or part thereof due under the Contract until such time as the Contractor or any subcontractor is able to demonstrate his compliance with the terms of the Contract 3 The termination or cancellation of
454. uest Number 20150917 043 Page 17 of 35 Supplemental Total Rate Classification Effective Date Base Wage Health Pension Unemployment Apprentice MARBLE TILE TERRAZZO MECH Local 3 Marble Tile Spr Pitt Effective Date 08 31 2015 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 1 50 19 18 10 18 16 73 0 00 46 09 2 60 23 02 10 18 16 73 0 00 49 93 3 70 26 85 10 18 16 73 0 00 53 76 4 80 30 69 10 18 16 73 0 00 57 60 5 90 34 52 10 18 16 73 0 00 61 43 Effective Date 02 29 2016 Supplemental Step percent Apprentice Base Wage Health Pension Unemployment Total Rate 50 19 47 10 18 16 73 0 00 46 38 2 60 23 36 10 18 16 73 0 00 50 27 3 70 27 25 10 18 16 73 0 00 54 16 4 80 31 14 10 18 16 73 0 00 58 05 5 90 35 04 10 18 16 73 0 00 61 95 Notes Apprentice to Journeyworker Ratio 1 5 MECH SWEEPER OPERATOR ON CONST SITES 06 01 2015 32 97 9 70 11 47 0 00 54 14 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 72 9 70 11 47 0 00 54 89 For apprentice rates see Apprentice OPERATING ENGINEERS MECHANIC WELDER BOOM TRUCK 06 01 2015 32 44 9 70 11 47 0 00 53 61 OPERATING ENGINEERS LOCAL 98 12 01 2015 33 19 9 70 11 47 0 00 54 36 For apprentice rates see Apprentice OPERATING ENGINEERS MILLWRIGHT Zone 3 04 01 2015 33 13 9 80 16 21 0 00 59 14 MILLWRIGHTS LOCAL 1121 Zone 3 Apprentice MILLWRIGHT Local 1121 Z
455. ulative and may be exercised simultaneously or in any order as determined by the Awarding Authority in its sole discretion The Awarding Authority shall also be entitled as of right to specific performance and equitable relief including the right to an injunction against any breach of any of the provisions of this Contract 150 10 Notices Notices to the Contractor shall be deemed given when hand delivered to the Contractor s temporary field office at or near the Site or when deposited in the U S mail addressed to the Contractor at the Contractor s address specified in the Owner Contractor Agreement or when delivered by courier to either location Unless otherwise specified in writing by the Awarding Authority notices and deliveries to the Awarding Authority shall be effective only when delivered to the Awarding Authority at the address specified in the Owner Contractor Agreement and date stamped at the reception desk or for which a receipt has been signed by the agent or employee designated by the Awarding Authority to receive official notices 151 APPENDIX A to General Conditions of the Contract The following provisions form Article XII of the General Conditions of the Contract where the University of Massachusetts Amherst is the Awarding Authority EQUAL EMPLOYMENT OPPORTUNITY NON DISCRIMINATION AND AFFIRMATIVE ACTION PROGRAM 1 Compliance Generally For purpose of this Article minority refers to Asians Blacks Western He
456. ult of Contractor s failure to complete the Work to the point at which it qualifies for the issuance of a Certificate of Agency Use and Occupancy will be difficult or impracticable to ascertain Accordingly if the Work is not completed to such a point by the date specified in this Contract the Contractor shall pay to the Awarding Authority the sum designated as liquidated damages in the Contract for each and every calendar day that the Contractor is in default in completing the Work to such point Such moneys shall be paid as liquidated damages not as a penalty to cover losses and expenses to the Awarding Authority and or the User Agency resulting solely from the fact that the Work is not completed on time B Similarly if the Contract states that by a specified date a designated portion of the Work shall be prosecuted to the point at which it qualifies for the issuance of a Certificate of Agency Use and Occupancy and if such portion has not been prosecuted to such point by said date the Contractor shall pay to the Awarding Authority the sum designated in the Contract for each calendar day that the Contractor is in default in completing such portion of the Work to such point Such moneys shall also be paid as liquidated damages not as a penalty to cover 114 losses and expenses to the Owner resulting solely from the fact that the Work is not completed on time C The Awarding Authority may recover such liquidated damages by deducting the amount
457. unless delayed by causes beyond his control the contractor shall complete all such work items within forty five days after the receipt of such list or before the then contract completion date whichever is later If the contractor fails to complete such work within such time the awarding authority may subsequent to seven days written notice to the contractor by certified mail return receipt requested terminate the contract and complete the incomplete or unsatisfactory work items and charge the cost of same to the contractor Within thirty days after receipt by the awarding authority of a notice from the contractor stating that all of the work required by the contract has been completed the awarding authority shall prepare and forthwith send to the contractor for acceptance a final estimate for the quantity and price of the work done and all retainage on that work less all payments made to date unless the awarding authority s inspection shows that work items required by the contract remain incomplete or unsatisfactory or that documentation required by the contract has not been completed If the awarding authority fails to prepare and send to the contractor the final estimate within thirty days after receipt of notice of completion the awarding authority shall pay to the contractor interest on the amount which would have been due to the contractor pursuant to such final estimate at the rate hereinabove provided from the thirtieth day after such
458. urnish labor and materials as may be required from time to time to maintain this means of access in an acceptable condition as determined by the Designer Pedestrian access shall provide adequate protection against falling debris slippage adequate lighting warning and directional signs and protection against construction activities DUST CONTROL The General Contractor shall have all Subcontractors provide adequate means for the purpose of preventing dust caused by construction operations from creating a hazard nuisance and from entering adjacent occupied areas throughout the period of the construction contract This provision does not supersede any specific requirements for methods of construction or applicable general conditions set forth in the Contract Articles with added regard to performance obligations of the General Contractor TEMPORARY FACILITIES AND CONTROLS 10 14 2015 015000 1 of 4 12 4 2012 rev 1 5 1 6 1 7 A 16 12 MULLINS SECURITY CAMERAS NOISE CONTROL Work must be scheduled and performed in such a manner as to not interfere with the operations of the Owner Construction work that is deemed by the U M A Project Manager to be excessively noisy may be required to be done during non normal working hours and at no additional expense to the University Comply with requirements of authorities having jurisdiction Develop and maintain a noise abatement program and enforce strict discipline over all pe
459. vailable to him without further delay d When the amount in dispute is less than ten thousand dollars a contractor who is party to the dispute may elect to submit the appeal to a hearing officer experienced in construction law for expedited hearing in accordance with the informal rules of practice and procedure of the division of hearing officers An expedited hearing under this subparagraph shall be available at the sole option of the contractor The hearing officer shall issue a decision no later than sixty days following the conclusion of any hearing conducted pursuant to this subparagraph The hearing officer s decision shall be final and conclusive and shall not be set aside except in cases of fraud 5 Mandatory Mediation In the case of every dispute where the dollar amount in dispute or the estimated dollar value of the extension of time in dispute is 50 000 or more and the Contractor appeals the decision of the chief executive officer of the Awarding Authority or his designee described in Section 4 B above the Awarding Authority and the Contractor shall engage in good faith in a non binding 123 mediation process which process shall be concluded within sixty days from the date that the Contractor files an appeal from said decision as provided in Section 4 B above In the case of such disputes where the dollar amount in dispute or the estimated dollar value of the extension of time in dispute is 500 000 or more the parties shal
460. ven days after receipt return to the contractor for correction any periodic estimate which is not in the required form or which contains computations not arithmetically correct and in that event the date of receipt of such periodic estimate shall be the date of receipt of the corrected periodic estimate in proper form and with arithmetically correct computations The date of receipt of a periodic estimate received on a Saturday shall be the first working day thereafter The provisions of section thirty nine G shall not apply to any contract for the construction reconstruction alteration remodeling repair or demolition of any public building to which this section applies All periodic estimates shall be submitted to the awarding authority or to its designee as set forth in writing to the contractor and the date of receipt by the awarding authority or its designee shall be marked on the estimate All periodic estimates shall contain a separate item for each filed subtrade and each sub subtrade listed in sub bid form as required by specifications and column listing the amount paid to each filed subcontractor as of the date of the periodic estimate is filed The person making payment for the awarding authority shall add the daily interest provided for herein to each payment for each day beyond the due date of receipt marked on the estimate A certificate of the architect to the effect that the contractor has fully or substantially completed the work
461. vity on the site Demolition permits must be submitted for any work involving demolition new construction and renovation The University EHS office must be provided copies of any and all notifications Building permits are required for the installation of office trailers Trailers must be securely anchored to prevent displacement due to wind Metal dumpsters of 6 cubic yard aggregate capacity or more and containing combustible materials must have a Local Fire Department Permit issued for each location If the SUMMARY 10 14 2015 011000 11 of 20 5 1 2015 rev 16 12 MULLINS SECURITY CAMERAS containers are delivered and removed on the same day no permit is required 527 CMR 34 03 Storage of more than 2500 cubic feet gross volume of combustible or flammable materials in a building will require a permit from the Local Fire Department Use and storage of more than 10 gal or 42 lbs of Liquefied Propane Gas LPG containers on site must be approved by and a permit must be secured through the local Fire Department Any work involving existing fire protection systems or related equipment fire alarm sprinkler fixed extinguishing system will require the Contractor to obtain a permit from the local Fire Department Any work that affects Fire Protection Systems shall require the Contractor to notify the U M A Environmental Health and Safety Department Any work which disables part or all of a fire protections system for more than 8
462. vorable information about the contractor that was omitted from the Update Statement filed with the contractor s bid 810 CMR 8 05 2 ZT 40 e8eq 6 OTOZ U2Je N 341729443 25 401264100 e3ide UOLS juaulaje1s 5143 Jo Hed 295 ue pue 32641002 Aue 531 01 pasnja pa IeJ seu 10 JOM at 01 pafoud seu 4INOA x 21081 21081 21081 21081 21081 21081 Qq3131dINOO 31VG 210g 11015 42103 210g 11015 42103 210g 11015 210g 11015 210g 211015 42103 210g 211015 412103 31V LYVLS 21 1204100 421u3 21 1204100 421u3 21 1204100 421u3 21 1204100 421u3 21 12041005 421u3 21 1204100 421u3 39214 LOVYLNOD 4052105 440A 42103 4052105 440A 42103 4052105 440A 412103 4052105 440A 13143 4052105 440A 42103 4052105 440A 42103 AYOM JI sjaays jeuonippe 248H 9 12 0 42103 248H 9 12 0
463. w 2 03 THE CONTRACTOR SHALL If the Contractor is the requestor or if it receives a request for change it shall a Submit a written request for a Notice of Intent NOI indicating the proposed change in the work and the proposed method of compensation as set forth in Article VII of the General Conditions of the Contract and in Section of the UMA Form 5 The written request shall include a cost breakdown with the requested change as outlined in Article of the General Conditions of the Contract The breakdown of all filed sub contractors shall be separated from the General Contractor s breakdown and both are required to be on properly identifiable letterhead stationary and signed showing a quantities and costs utilizing unit pricing b the classification and hours of labor fringe benefits and the complete breakdown showing unit cost of material and equipment and c any other allowable costs as set forth in Article VII See also Section 5 below 172 b The written request for NOI and accompanying documentation shall be addressed to the Division of Facilities Planning and sent to the Project Manager One copy shall be addressed to the Designer and one to the Resident Engineer if applicable c Each written request for an NOI must include all costs associated with the request for change d The General Contractor shall review all cost breakdowns being submitted by its suppliers and subcontractors and check them to insure the info
464. warding authority upon certification by the contractor that he is the lawful owner and that the materials are free from all encumbrances but less 1 a retention based on its estimate of the fair value of its claims against the contractor and less 2 a retention for direct payments to subcontractors based on demands for same in accordance with the provisions of section thirty nine F and less 3 a retention not exceeding five percent of the approved amount of the periodic payment After the receipt of a periodic estimate requesting final payment and within sixty five days after a the contractor fully completes the work or substantially completes the work so that the value of the work remaining to be done is in the estimate of the awarding authority less than one percent of the original contract price or b the contractor substantially completes the work and the awarding authority takes possession for occupancy whichever occurs first the awarding authority shall pay the contractor the entire balance due on the Contract less 1 a retention based on its estimate of the fair value of its claims against the contractor and of the cost of completing the incomplete and unsatisfactory items of work and less 2 a retention for direct payments to subcontractors based on demands for same in accordance with the provisions of section thirty nine F or based on the record of payments by the contractor to the subcontractors under this contract if such record of
465. written notice elect to complete the work with separate forces and charge the work against the General Contractor 2 At the end of the General Contractor s one 1 year guarantee period the General Contractor shall transfer manufacturers equipment and material warranties that are still in force to the Operating Agency GUARANTEES AND WARRANTIES Submit to the Designer all extended guarantees and warranties that have been specified in various individual Sections of the Specifications Guarantees shall be assembled by Specification No and Section in accordance with Specifications Table of Contents CONTRACT CLOSEOUT 10 14 2015 017700 8 of 9 4 5 2013rev 16 12 MULLINS SECURITY CAMERAS 1 Guarantees and warranties shall be enforceable in the Commonwealth of Massachusetts and subject to interpretation in accordance with the laws of the Commonwealth of Massachusetts 2 Guarantees and warranties shall begin at the date of Substantial Completion of the Project Guarantees and warranties which start at the date of shipment from the factory or from the completion date of an individual portion of the project are not acceptable Unless more stringent requirements are otherwise specified guarantee all work against defects of materials equipment and workmanship for one year from the date of Substantial Completion or the date of issue of Certificate of Use and Occupancy for the building or portion thereof whichever occurs first
466. y law applicable only to the Awarding Authority 2 The Contractor agrees to begin prosecute and complete the entire work specified by the Awarding Authority in an orderly manner so that the Subcontractor will be able to begin prosecute and complete the work described in this subcontract and in consideration thereof upon notice from the contractor either oral or in writing the Subcontractor agrees to begin prosecute and complete the work described in this Subcontract in an orderly manner and with due consideration to the date or time specified by the Awarding Authority for the completion of the entire work 3 The Subcontractor agrees to furnish to the contractor with a reasonable time after the execution of this subcontract evidence of workers compensation insurance as required by law and evidence of public liability and property damage insurance of the type and in limits required to be furnished to the Awarding Authority by the Contractor 4 The Contractor agrees that no claim for services rendered or materials furnished by the Contractor to the Subcontractor shall be valid unless written notice thereof is given by the Contractor to the Subcontractor during the first ten 10 days of the calendar month following that in which the claim originated 5 This agreement is contingent upon the execution of a general Contract between the Contractor and the Awarding Authority for the complete work 83 IN WITNESS WHEREOF the parties hereto have
467. y on the Designer in the absence of an explicit written assumption by the Awarding Authority of any such rights and obligations except that any Approval required to be obtained from the Awarding Authority hereunder shall not be valid without the signature of the Awarding Authority The Awarding Authority may explicitly overrule in writing any action determination or decision of the Designer should the Awarding Authority choose to do so except to the extent that the same would violate applicable law Subject to the foregoing the Designer shall be responsible for the general administration of the Contract and shall perform the duties and exercise the rights herein conferred on the Designer Except as otherwise specifically provided herein the Designer shall decide all questions which may arise as to the conduct quantity quality equality acceptability fitness and rate of progress of the several kinds of work and materials to be performed and furnished under this Contract and shall decide all questions which may arise as to the interpretation of the Plans and Specifications and as to the fulfillment of this Contract on the part of the Contractor In the case of the death resignation inability or refusal of the Designer to act or the termination of his or her or its employment the Awarding Authority may appoint another person to act as Designer for the purposes of this Contract The Awarding Authority shall give written notice to the Contractor of a
468. y the Contractor or is terminated by the University of Massachusetts Amherst under the provisions of said Contract said surety shall if requested in writing by the University of Massachusetts Amherst take such action is necessary to complete the Contract In witness whereof we hereunto set our hand and seals this day of 20 71 Sea CCS al Print Name of General Contractor Print Name of Surety By Signature Title Signature Title Surety Address Countersigned Mass Resident Agent By Agent s Address Telephone Number 72 SCHEDULE FOR PARTICIPATION BY MINORITY WOMEN BUSINESS ENTERPRISES UNIVERSITY OF MASSACHUSETTS AMHERST UMA Number idle _ Project Location Project Name This form must be submitted by the General Contractor within five 5 working days of the opening of the General Bids A Letter of Intent and SOMWBA certification letter for each M WBE must be submitted with this Schedule of M WBE participation BIDDER CERTIFICATION The undersigned General Contractor firm agrees that it will subcontract with the following listed firms for the work described and for the dollar amounts listed below For purposes of this commitment the MBE and WBE designation means that a business has been certified by SOMWBA as either a MBE WBE or M WBE The General Contractor must indicate the MBE WBE firms it intends to utilize on the project as follows attach additional sheets if necessary Company N
469. yable to Subcontractors C The payment provided in paragraph B above shall be considered to fully compensate the Contractor for all claims and expenses and those of any consultants Subcontractors and suppliers directly or indirectly attributable to the termination including any claims for lost profits 3 Contractor s Duties Upon Termination For Convenience Upon termination of this Contract for convenience as provided in Section 2 of this Article the Contractor shall 1 stop the Work 2 stop placing orders and Subcontracts in connection with this Contract 3 cancel all existing orders and Subcontracts 4 surrender the Site to the Awarding Authority in a safe condition 5 transfer to the Awarding Authority all materials supplies work in process appliances facilities equipment and machinery of this Contract and all plans Drawings specifications and other information and documents used in connection with this Contract ARTICLE XVIII MISCELLANEOUS PROVISIONS 1 No Assignment by Contractor The Contractor shall not assign by power of attorney or otherwise or sublet or subcontract the Work or any part thereof without the previous written consent of the Awarding Authority and shall not either legally or equitably assign any of the moneys payable under this Contract or Contractor s claims hereunder unless with the like consent of the Awarding Authority whether said assignment is made before at the time of or after the ex
470. zed standards or to be safe for use in a specified manner b Production of equipment or product is periodically inspected by a nationally recognized testing laboratory Bears label tag or other record of certification ELECTRICAL WORK 10 14 2015 260001 2 of 5 2 13 2012rev 1 4 1 5 UMA 16 12 MULLINS SECURITY CAMERAS 4 Nationally recognized testing laboratory laboratory which is approved in accordance with OSHA regulations by the Secretary of Labor QUALIFICATIONS PRODUCTS AND SERVICES A Manufacturers Qualifications The manufacturer shall regularly and presently produce as one of the manufacturer s principal products the equipment and material specified for this project and shall have manufactured the item for at least three years Product Qualification 1 Manufacturer s product shall have been in satisfactory operation on three installations of similar size and type as this project for approximately three years 2 The University reserves the right to require the Contractor to submit a list of installations where the products have been in operation before approval Service Qualifications There shall be a permanent service organization maintained or trained by the manufacturer which will render satisfactory service to this installation within eight hours of receipt of notification that service is needed Submit name and address of service organizations MANUFACTURED PRODUCTS A Materials an

Book - University of Massachusetts Amherst

Contents

Download Pdf Manuals

Related Search

Related Contents