Home

Document 2-III Particular Specifications

Contents

1. 4 months Copper Sulfate 500 g 1 Bottle 6 months Eriochrome black T Indicator 100 g 1 Bottle 6 months Ethylene d amine tetra acetic acid EDTA 500 g 1 Bottle 6 months Hydrogen peroxide 0 5 L AR 30 1 Bottle 2 months Magnesium Sulfate 500 g 1 Bottle 6 months Methylene Blue 100 g 1 Bottle 6 months Methyl Orange Indicator 25 g 1 Bottle 4 months Perchloric acid 500 ml 70 1 Bottle 6 months Potassium Carbonate 500 g 1 Bottle 6 months Potassium hydroxide 500 g 1 Bottle 6 months Potassium nitrate 500 g 1 Bottle 6 months Potassium permanganate 500 g 1 Bottle 6 months Silver Nitrate or AgNO 1 N 1 Bottle 6 months Sodium bicarbonate 500 g 1 Bottle 12 months Sodium Sulfite 500 g 1 Bottle 12 months Nitrogen gas 1 Cylinder 4 months Hydrogen gas 1 Cylinder 4 months Helium gas 1 Cylinder 4 months Acetylene gas 1 Cylinder 4 months Nitrous oxide gas 1 Cylinder 4 months Liquid Nitrogen gas 35L 1 Cylinder 4 months Air cylinder 1 Cylinder 4 months Phenol 1 Kit 6 months Atomic Absorption Standard Solutions J a Aluminum Nitrate 1L 6 months Arsenous Oxide TE 6 months Boron Standard 1L 6 months Cadmium Nitrate 1L 6 months e Calcium Nitrate 1L 6 months NN Chromic Nitrate 1L 6 months Cobalt Nitrate 1L 6 months Copper Nitrate 1L 6 months Lead Nitrate 1L 6 months Mercury Nitrate
2. month 170 Phosphate Standard Solution 100 mg l 1L 12 months bid Iron Reagent Powder Pillow 50 pillow 1 packet T Iron Standard Solution 1000 mg l 1L 12 months Rover Rust Mover 1 Kg month Rust Suspension 1L month Buffer Powder Pillow Citrate Type 50 pillow packet 1packet month Dithiver Metal Reagent 50 pillow packet 1packet month Potassium Cyanide 1 Kg month Lead Standard Solution 100mg l 1L 12 months Alkaline Cyanide 1L month Ascorbic Acid Powder Pillow 50 pillow packet 1packet month Manganese Standard 1000 mg l 1L 12 months Rochelle Salt Solution 1L month Phthalate Phosphate Reagent Powder Pillow 50 pillow packet packet month Nickel Standard 1000 mg l 1L 12 months a 3 Cyanide Reagent Powder Pillow 50 pillow 1 packet E pes 4 Cyanide Reagent Powder Pillow 50 pillow 1 packet PM P 5 Cyanide Reagent Powder Pillow 50 pillow 1 packet een Buffer Solution PM 40 1L month Hexanes 1L month bM Chelating Reagent Powder Pillow 50 pillow 1 packet TES Lead Acetate Trihydrate 1 Kg month M Nitrophenol Indicator 1L month Sodium Cyanide 1L month Buffer Sulfate Type Reagent TL month Detergent Reagent Powder Pillow 50 pillow packet 1 packet month Detergent Standard Solution IS month Alkaline Solution 1L month Ca MG Indicator Solution 1L month Calcium Standard 50 mg l 1L 6 months Magnesium Standard Solution 1L 6 months COD Vials 0 1500 mg l 150 packet 1
3. 256 MB Onboard DRAM 9 Network card 100 1000Mb Half Full Duplex Auto Negotiation 10 Wireless network card 802 11G compatible with 128bit encryption 11 Communication Ports 2 Serial 1 Parallel 6 USB 2 12 Video Display 17 Inch LCD 13 Keyboard 103 Key Enhanced Programmable 14 Pointing Device Microsoft Serial USB Mouse 15 Accessories Mouse Pad 7 Rewritable DVDs 2GB USB removable drive Transparent Dust Covers Power Printer Cables B When an engineering workstation laptop is being used for drawing mark up document spread sheet creation purposes and other similar functions which may not be directly related to the PIMSS aspects of the system it shall continue to monitor display and enunciate warnings pop ups upon their occurrence Tender No SE 130 158 Document 2 III C Wide format colour scanners AO size and Engineering workstations and laptops with Windows XP Vista dual boot operating system are to be provided to the designated staff of the Engineer and the designated staff of the Engineer s Representative at convenient locations D Originals of software used in the PIMSS Engineering Workstations Laptops Website and Web camera shall be furnished to the Engineer in a Compact Disk along with operating Keys like license number and CD key E Each engineering workstation laptop shall have a clock which s
4. 600 Dosing Pump DP 610 Dosing Pump DP 620 Dosing Pump DP 630 Ventilator V400 Blower B 700 Recirculation Pump P 100 Recirculation Pump P 200 Recirculation Pump P 300 Recirculation Pump P 400 Agitator A 700 Agitator A 701 Agitator A 702 Agitator A 703 Module 2 No 1 Settling Tank Drive Unit No 2 Settling Tank Drive Unit No 3 Settling Tank Drive Unit No 4 Settling Tank Drive Unit No 5 Settling Tank Drive Unit No 6 Settling Tank Drive Unit Scum Blower No Scum Blower No Scum Blower No Scum Blower No Scum Blower No o 01 BF 0 N Scum Blower No Aerator No Aerator No Aerator No Aerator No Aerator No Aerator No Aerator No INID A 6 PO Aerator No Electric Air Compressor Diesel Air Compressor Fuel Pump Blower Rotary Lobe No 1 Blower Rotary Lobe No 2 Blower Rotary Lobe No 3 Blower Rotary Lobe No 4 Blower Rotary Lobe No 5 Blower Rotary Lobe No 6 Blower Rotary Lobe No 7 Blower Rotary Lobe No 8 Tender No SE 130 181 Document 2 III Blower Rotary Lobe No 9 Blower Rotary Lobe No 10 Blower Rotary Lobe No 11 Blower Rotary Lobe No 12 Blower Rotary Lobe No 13 Blower Rotary Lobe No 14 Blower Rotary Lobe
5. 5 The Contractor shall be responsible to clean flush and remove accumulated wastewater dry and wet sludge gravels sand debris hazardous materials and polluted soil groundwater and other contaminants cart away off the site transport and dispose to dumping area outside the site in accordance to the regulations of the authorities municipality EPA and Engineer approval The Contractor shall be responsible to provide jet flushers tankers if necessary and provide mud suckers tankers to remove wastewater and discharge off the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The Contractor shall not be allowed to divert wastewater flow to any emergency by pass gulf sea lines 6 The Contractor shall provide erect and maintain all temporary staging scaffolding rigging shuttering dewatering system and carried out with all necessary precaution needed 7 Demolish unlimited depth and distances lengths of all existing types and sizes diameters of underground gravity sewer culverts and pressure pipelines dewater cut pipes remove abandonment cart away off site transport and dispose to dumping area outside the sites to any unlimited distances locations areas in the state of Kuwait in a legal manner The extent of works shall include but not limited to trench excavation soil and groundwater investigation
6. Auxiliary panels and cable works Spare equipped panel TATOO Te e ao TD 3 3 The Contractor shall be responsible to rehabilitate modify and maintenance of MPW switchgear room at Substation No 6 SU 0641 to provide electrical power for the New Pumping Station including effluent transfer pumps new Rabya pumps new landscaping irrigation pumps new dewatering pumps flow meters guard house and all other services and utilities at zone area 2 as directed by the Engineer for the duration of the contract period 4 The Contractor shall be responsible in laying cables for this purposes of sufficient capacity in accordance with the MPW regulations and shall be selected at least 50 additional capacity The following load distribution shall be considered as per the Engineer recommendation ror Estimated Runnin EE New Dewatering Pumps 2 Nos 40 30 150 30 Back Guard House Lighting amp Power System zone area 2 150 5 Therehabilitation and renovation work shall include provision of the latest version of mosaic enunciator panel PLC based control panel electrical power and control cables instrumentation earthling system supporting brackets cable trays trenches trunking and conduits cable ladders and all other associated necessary components for the proper and modern electrical installation 6 The work shall also include replacement of entire lighting system wiring lighting fixtures vent
7. Two sewage inlet slide gates 1550 x 1000 two outlet motorized slide gates 1000 x 800 and two hand operated slide gates 1000 x 800 Eight surface turbine aerators 55 kW each Return sludge supplied by the pipeline DN 800 with one gate valve DN 600 and open distribution channel with two gate valves DN 300 Return sludge pumps sump types are located in the pumping station PS 0423 Bioreactor BR 0412 Concrete structure Tender No SE 130 170 Document 2 III One basin with two separate chambers Each chamber size 36mx12mx5 55m mixed liquor depth 4 8m Effective volume of mixed liquor in basin 3900 m Six surface turbine aerators with draft tube Return sludge supplied by open channel with weir gates One by pass slide gat Six submersible pumps Two automatic weirs electrically operated chamber One oxygen meter in each chamber in each Clarifiers ST 0421 ST 0423 Three Units Concrete structure Circular tank with circular bottom Internal diameter 37 5 m Side wall sewage depth 2 55 m Sewage depth at the hopper edge 4 7 m Hopper upper DN 4 5m hopper bottom diameter 0 7m hopper depth 3 6m Sewage surface 1100 m V notch length 117 8m Equipped with rotating bridge with sludge bottom scraper Bridge is driven by two motors and gearbox unit Mixed liguor supplied from distribution chamber equipped with slide gate 1050 x 800 and by intake pipe DN 1000 Sludge re
8. motor 22 KW Two sucking and two discharge gate valves DN 250 two check valves DN 250 and piping Electrical and instrumentation installations Sludge e Road tankers filling station near drying beds including Filling Station gate valve DN 150 raise pipe DN 150 and filling hose FI 0761 e Two electrical control boxes for operation of thickened sludge pumps in PS 0732 amp PS 0733 e Electrical installation for above boxes Sludge e Road tankers filling station beside the perimeter fence Tender No SE 130 175 Document 2 III Filling Station FI 0762 including two gate valves DN 150 two raise pipes DN 150 two filling hoses Operation by the same control boxes as for FI 0761 Sludge Digestion Complex DR0711 DR0713 Three Units Three digesters DR 0711 DR 0712 amp DR 0713 internal diameter of degritter 17 5 m effective sludge volume 2800 m each Flame arrests and vacuum releasing valve on each digester One propeller mixer in each digester with motor 7 5 kW Sludge level sensor in each digester 12 gate valves DN 250 in piping feeding one digester removing digested sludge and turbid water connecting digester with heat exchanger and for biogas piping One biogas flowmeter on each digester One spiral heat exchanger 15 m of heat transfer Two sludge circulation pumps capacity 108 m h head 6 m rotation 945 min motor 705 kW Two water boilers average heat capaci
9. 1 Bottle 3 months Ferric Sulfate 7 Hydrate AR 500 g 1 Bottle 3 months Ferric Indicator Solution 100 MI 1 Bottle 6 months Ferric Ammonium Sulfate AR 500 g 1 Bottle 6 months lodine 0 l N Ampoule 6 Box 1 Box 12 months Manganese Sulfate 4 H2O AR 500 g 1 Bottle 6 months Mixed Indicator 500 ml 1 Bottle 12 months Oxalic acid 2 Hydrate AR 2 5 L 1 Bottle 12 months Phenolphthalein solution 196 250 ml 1 Bottle 6 months Phenol Red 0 02 96 Sol 100 ml 1 Bottle 4 months Phenol Red Sodium Salt 25 g 1 Bottle 6 months Potassium Bromide AR 500 g 1 Bottle 4 months Potassium dichromate AR 500 g 1 Bottle 4 months Potassium Chloride AR 500 g 1 Bottle 6 months Sodium Carbonate Anhydrous 500g 1 Bottle 6 months Sodium Chloride 500g 1 Bottle 6 months Sodium Sulfate Anhydrous AR 500g 1 Bottle 4 months Sodium Tetra Thionate 500 g 1 Bottle 6 months 1 1 1 Trichloro Ethane 2 5 L 1 Bottle 4 months Sodium Benzoate 500 g 1 Bottle 6 months Phosphoric acid concentrated AR 2 5 L 1 Bottle 6 months Benzene 1 L 1 Bottle 6 months Bromophenol Blue 100 g 1 Bottle 6 months Calcium carbonate 500 g 1 Bottle 6 months calcium oxide 500 g 1 Bottle 6 months Tender No SE 130 122 Document 2 III Carbon Tetrachloride 0 5 L 1 Bottle
10. 3 Nos in the new pumping station of zone area 2 with all related mechanical and electrical equipments for the duration of one 1 year period after renovation works at Ardiya sewage plant are completed to pump tertiary treated effluent wastewater from the header tank to Rabya farms as approved by the Engineer 3 The Contractor shall be fully responsible for the operation of the new landscaping irrigation system in the new pumping station of zone area 2 with all related mechanical and electrical equipments for the duration of one 1 year period after renovation works at Ardiya sewage plant are completed to irrigate the existing landscaping area new landscaping zone area 1 and EAD Environmental Affair Department located outside and adjacent to Ardiya sewage plant as approved by the Engineer The water source shall be effluent treated wastewater from the header tank at Ardiya sewage plant and shall be mixed with fertilizers 4 The extent of works shall include but not limited to proper operation of other related facilities mechanical and electrical equipments instruments and shall include but not limited to new dewatering pumps 2 Nos electrical supply panel and control room equipment surge tanks compressors and compressors motors pressure vessels readings of flow meters alarm system fire protection system and all other related parts Clause2 Partial Maintenance works at Ardiya Sewage plant The price fixed for this item is lu
11. C Anyclaims brought on the grounds of lack of knowledge or misunderstanding of any of the forgoing of the contract requirements shall not be entertained Clause 5 Sites visit The sites visit is considered obligatory and part of the Contract requirements The Contractor shall be deemed fully satisfied as to the form and nature of the plant and the required works of the contract The Contractor shall visit the sites to determine the exact actual conditions and type of the equipment of the plant In particular the Contractor shall confirm that his offer covers all the obligations under the contract and all matters necessary for proper completion of the Contract requirements In no case he shall be relieved from any of his contractual obligations on the grounds that he did not or could not have foreseen any matter which may have affected the execution of the contract works It is meant that no claim for the lack of information shall be allowed later on If any other information needed it is the Contractor responsibility to inquire prior to signing the contract and no claims will be accepted in this regard during the contract period The Contractor shall be deemed to have visited the sites prior to submitting his Tender and made all necessary inspections and investigations and to have decided for himself the means of access and working space the nature of the ground and sub soil the presence of existing foundations or other hidden obstructions the
12. Kuwait NEC National Electrical Codes NEMA National Electrical Manufacturer s Association Standards NESC National Electrical Safety Codes UL Underwriters Laboratories Inc EPA Environment Public Authority State of Kuwait Clause 13 Project closeout procedures The Contractor shall complete and submit the following activities but not limited to 1 Submit clearance certificates and approval from government s authorities as necessary required 2 Submit final cleaning and works activities of the project are completed in accordance to the requirements of the Contract Documents and obtaining approval final inspection and handover certificates of sites to the Ministry without any objection letter from the Engineer 3 Submit any other works requested by the Engineer related to contract documents Tender No SE 130 12 Document 2 III Clause 14 Management 1 The Contractor shall manage to execute works in conformance with the specifications of the latest editions of the codes ordinances rules and regulations of Ministry of Public Works and other Government authorities 2 The Contractor shall take upon himself the full and entire responsibility for the sufficiency of all personnel engineers supervisors manpower and labors machineries equipments pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the c
13. Microsoft Operating System Tender No SE 130 109 Document 2 III 23 24 25 26 27 28 29 30 31 32 33 The PIMS Original Software Developer should provide 24 7 365 days remote world class global customer support for maintenance and troubleshooting The PIMS server shall be designed to acguire the PIMS based data from 10 SCADA based facilities scattered geographically in different locations in Kuwait at the following scan rates Digital signals 1 minute Flows and Pressures 1 minute Levels and Others 1 minute The PIMS shall provide 55 client software licenses Out of that twenty 20 are concurrent smart client access licenses thirty five 35 are thin Web based format client access PIMS proposal shall be based on the following 1 50 Process graphics 2 30 Excel reports 3 10 Calculated variables PIMS Vendor shall provide off site training for four 4 PIMS system Administrators PIMS Vendor shall provide on site training for twenty 20 PIMS users to enable them to create and use process graphics reports trends and Real Time Web part pages As a minimum requirement all inputs outputs Digital tags Open Close and motor run status must be aggregated The PIMS Vendor shall provide all training materials and in English PIMS responsibility during the commissioning phase shall include Ensuring that the PIMS system is installed properly Powering up the syst
14. The Contractor shall prepare drawings for the approval of the Engineer No extra will be admitted if the Engineer specifies additional requirements to achieve a system to his satisfaction The Contractor shall be responsible for obtaining MPW approval to such design prior to the start the execution of the works 2 The office management system shall be original software of latest version fast document searches easy to use program customize templates with latest window XP Professional edition window vista business edition with Office English version Arabic enable and productivity manifold and shall include but not limited to the following equipment for the sole use and disposal of the Ministry Engineer e Smart information record system SIRS or equivalent as approved of the Engineer e Network PC system Monitor SCADA Supervisory Control and Data Acquisition e Alarm implemented SCADA where Emails and text messages are sent along alarm activation e Multiple data servers connected to multiple controllers Each data server has its own configuration data base and is responsible for the handling of a sub set of the process variable acquisition alarm handling archiving etc Tender No SE 130 107 Document 2 III e A network of all Sanitary Department data being monitored including Meter Mail messaging technology internet enabled alarm feature instantly notifies personnel of potential areas of concern e SCADA server
15. accessories and DPD tablets standards etc No 1 Conductivity meter with probe and all accessories calibration kit etc No 1 Portable turbidity meter with all accessories calibration kit etc No Digital Burette No 1 2 Ultrasonic cleaner No 1 4 Hand Mask for Ammonia No Accessories for Lab equipment Gas Lighter Gun Type No 10 Door Gasket No 2 Thermostat No EE S Microscope tcceeeressssooo a a Halogen Bulb No 1 b Conversion Filter No 1 Objective A Plan 10 0 25 No 1 d Objective A Plan 40 0 65 No 1 e Objective A Plan 100 1 25 oil No 1 4 Thermostat for Incubator Memmert No 1 Thermostat for Autoclave No 1 Lo 6 __ Kjeldhal Digestion Unit MMI a Digestion tubes No 4 b Heating Element No 4 7 Electrode Probe Tender No SE 130 117 Document 2 III a Dissolved Oxygen No 1 b pH probe No 1 C Conductivity probe No 1 d Membrane Cap DO Probe No 1 8 Deionizer Barnstead Filters part No 1 8036 2 0803 3 5027 4 5021 a Water Stirrer No 1 b Heating element No 1 c Condensers No 1 m 9 Specirophotometer MMI a Halogen Lamp No 1 b Area mat No 1 c Cold Trap Flask No 1 d 9mm Pellet Cell No 2 e 12 mm Pellet cell No 2 10 Kjeldahl Distillation Unit MIA a Flasks 500 ml Capacity No 4 b Bulb Steam No 4 C Distillate Col
16. anticipated causes of delay and their estimated impact on progress together with a description of corrective measures taken or proposed One copy of the latest approved Contractors CPM Schedule with updated logic time shall be attached to the Yearly Report 9 Final Report Submit a detailed report of all works activities supported with color photos new equipment renovation works and other important information needed as directed by the Engineer Clause 18 Maintenance Manuals The Contractor shall submit to the Engineer maintenance manual s original copies in accordance to manufacturer specifications for the provision of the new equipments pumps and motors The manual s shall include but not limited to Description of each equipment laboratory devices pumps and motors in details Spare parts required including manufacturer specification and address Tables of preventive maintenance schedule required for all equipments in details including time schedule frequency and quantity Description of lubricants types Repairs and trouble shooting guidelines Clause 19 Quality Control amp Inspection 1 Inspection requests shall be developed in a format acceptable to the Engineer and shall include at least the following information Space for serial number Contract or project number Contractors name Clients name Discipline civil structural mechanical electrical Instrumental Inspection or test descripti
17. compression type joint e Joint shall be rested for 1034 kpa 150 psi working water pressure at ambient temperature 15 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new valves shall be rated for 1379 kpa 200 psi working pressure at ambient temperature Gate valves Check valves Globe valves Drain valves Ball valves Flush valves Combination pressure reducing and pressure sustaining valves 16 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new remote control valves for spray drip zones areas 17 The extent of works shall include but not limited to design renovate provide install test commission operation and maintenance new polyphone tubes and micro tubes nozzles heads sub lateral irrigation lines drip emitters with single and multi outlets rotary impact sprinklers quick couplers and vacuum breakers reducers T connection pipe union connection elbow solenoid valve screen filter valve boxes pop up spray sprinklers fertilizer injector station controllers Y strainers spare parts and other related spare parts and materials that kept the system in good condition for the duration of the contract period 18 The extent of works shall include but not limited to provide test commission new lawn mower 1 No and shall remain the p
18. i The Contractor shall disconnect remove and cart away existing fire extinguishers and provide install test commission and maintenance new double fire extinguishers to be hanged on the wall Out of the two extinguishers one shall be water type and one shall be CO type and these shall be of Minimum of 10 Kg capacity Better alternate shall be also provided as per Tender No SE 130 77 Document 2 III recommendation of KFB regulations and shall be refilled or inspected by KFB yearly Also the Contractor shall consider the approval according to KFB regulations The Contractor shall provide install test commission and maintenance new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works specifications and materials shall be subject to the Engineer approval j The Contractor shall disconnect dismantle remove the existing EPABX central telephone system completely and cart away to a tippers off the site and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them The Contractor shall renovate supply erect install test commission and maintenance one new EPABX central telephone system with capacity of handling at least 40 CO lines and a provision of 200 extension lines for the MPW Quality co
19. install commission and maintenance a local telephone line and instrument connected to the new EPBAX which is installed in the MPW Quality Control Center interior lightings new A C split unit The extent of work shall include but not limited to replacing damaged aluminum doors with lockers glazing windows with mesh screens frames louvers and vents and other required works as directed by the Engineer 16 The Contractor shall provide install test commission fire extinguishers not less than 1 No as per recommendation of KFB regulations and shall be refilled or inspected by KFB yearly The Contractor shall provide install test commission and maintenance new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval 17 The Contractor provide install test commission and maintenance sufficient smoke and heat detectors in each room as per the KFB approved procedures and shall be connected to FCAP with sufficient numbers of fire alarms bells and shall be installed to alert sound and light alarm the shift operator during any fire condition The fire alarm indication panel shall be installed at the guard house near the main entrance gate of Ardiya sewage plant to alert the guard man in case of any fire hazard 18 The extent of works shall include but not limited to all related civi
20. maintenance two 2 new isolated separatesmotorized back entrances gates for the exit entry vehicle entrance gate and new pedestrian entrance gate of zone area 2 with all required accessories within two 2 years starting from the Date of Enterprise One gate width of at least 6 0 m for vehicular entrances and height of 2 5 m from finished grade with metal lockers The other isolated separate gate shall be width of at least 2 0 m for pedestrian entrances and height of 2 5 m from finished grade with metal lockers The operation of the gates shall be controlled from the guard house completely The new main gates shall be motor operated gates which move on rail laid across the access operating to the entrance 4 The extent of works shall include but not limited to supply install test commission and maintenance new emergency high loud ring bells motor conveyor rods with lights to be controlled by safety officers at the guard house and new external lightings at least 500 W metal halide type fixtures 4 Nos for each front entrance gate and back entrance gate with all related wires and electric installations outside the guard house 5 The extent of works shall include but not limited to the following requirements and subject for the Engineer approval a The frame verticals and bracings shall be of mild steel hollow sections b Accessories and other components shall be hot dip galvanized c The finished fabricated product shall be painted us
21. operation and maintenance of a new motor control center enunciator panel control relay panel motor starters distribution boards other auxiliary equipment electrical power cables instrumentation control cables earthling and bonding batteries battery charger light fittings supporting brackets and all other associated necessary components connection to substation No 1 SU 0241 for the new loads All equipment shall be connected to the new Motor Control Center with new cables and configured on the control board The Contractor shall renovate provide erect install test commission operation and maintenance of a new house for the new MCC in a separate room The room for the MCC shall be provided with air conditioner split type in sufficient nos so that the temperature of the panel room shall be maintained to 20 C at any given time Tender No SE 130 81 Document 2 III 18 The Contractor shall be fully responsible for any civil works required for the panels foundation seal all sleeves of the cables wiring cable trays trunking conduits and conduit boxes cable trench and ducts shall be protected with waterproofing membrane All works materials and specifications shall be subjectto the Engineer approval 19 The Contractor shall disconnect dismantle remove existing A C unit and cart away off site The Contractor shall renovate rehabilitate provide install test commission and maintenance new split air conditioning u
22. staff to determine by himself the plant facilities structures substructures or underground tanks underground pipelines manholes wells pits buildings and all other works of the contract requirements during the period of tendering as directed by the Engineer The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract Lifting Location of the Stations Stations S20 COASTAL ROAD FAHAHEL AREA 521 COASTAL ROAD MANGAF AREA 1 Details of screws Speed DN Length Angle Inlet Outlet No l s rpm mm m S mm mm S20 RTZ 80 55 49 49 700 758 30 400 400 A14 LENS Ed Bd Ed 46 EB L d E ZANDE 2 Details of Grease pumps Stations Sm zl WECTGNRUP woenen EWF wer CSTE Cran rar women air EST 3 Details of Gear Boxes Tender No SE 130 186 Document 2 III Lifting Type Speed ratio Power Stations CES SCN200 200 145054 54 Lm wer poses pose po 4 Screw Conveyor Motors Lifting Qty Type IEC Vol Speed Stations Spec TS E Put PETI sry e 5 use CIE sr ven rr 5 Grease Pump Motors Es ires rn er e x Stations RPM Esport A Rn OS rre en teo T ser pr eee vesc pow s e prom v 6 Ventilators amp Exhaust Fan Lifting Stations Type of Existing Quantity Fan 820 4E ONE 24 o
23. supplies dismantle electrical and mechanical equipments break concrete structures remove abandonment cart away to a tippers off the site and transport to MPW stores off the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to lightings installations and fixtures electric panels control cables foundations underground services and utilities cables wires earthling rods electrodes MCC sensors etc mast lamps near structure facilities and all other related connections and accessories 2 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 3 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth of excess areas as approved by the EPA and the Engineer landscaping grading compacting 9
24. system One grit classifier DN 228 6 mm with vortex type DN 150 grit concentrator and separation tank capacity 4 54 m h of grit Two inlets and two outlet slide gates 1400 x 1000 Electrical panel in steel weather proof cabinet Sewage Channels Concrete gravity channels covered with FRP elements connected by FRP pipes DN 150 to the odour control system Two flow meters in the sewage channels Two pH meters Caustic Soda NaOH Storage Tank SV 0181 One storage tank volume 100 m located near odour control building inside the shallow concrete basin One peristaltic pump for feeding above storage tank Foul Air Trestle Bridge FD 0171 Steel bridge 4 m high 73 m long OCF to inlet chambers Caustic soda pipes from OCF building to inlet chambers Odour Control Building SH 0141 Concrete structure Air injection system One air compressor capacity 600 m h and pipes for transferring compressed air to inlet chambers Foul air from inlet structures transferred to scrubbers by FRP duct DN 600 mm 73 m long on trestle bridge FD 0171 Three stage scrubbing Four scrubbing towers Tender No SE 130 166 Document 2 III e Four circulation pumps located on each scrubbing tower e Three Dosing pumps to scrubbers e One exhaust fan and foul air FRP piping DN 600 mm e Storage tank 10 m capacity and storage tank 5 m capacity e Two peristaltic pumps Pumps are located a
25. works required to disconnect dismantle remove abandonment and cart away to a tippers off site surge vessels VS 0661 4 Nos with all related accessories The Contractor shall demolish Rabya pumping station PS 0632 and discharge pipelines completely disconnect electrical supplies dismantle electrical and mechanical equipments completely break concrete structure remove cart away to a tippers off the site The extent of works shall include but not limited to demolish dismantle existing hatch box and unlimited distances lengths of all existing related underground pressure pipelines completely open cut method which is connected to the header tank within the boundary area of the fence Tender No SE 130 87 Document 2 III dewater cut pipes remove abandonment and cart away to a tippers off the site as approved by the Engineer 6 The Contractor shall provide erect and maintain all temporary staging scaffolding rigging shuttering over pumping and flow diversions to carry out the works close to existing structures in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services and carried out with all necessary precaution needed 7 As the existing Irrigation pumping station serving the farms in Rabya will be canceled and abandonment the irrigation process will be transferred to another location inside the New Pumping Station at Ardiya sewage plant However Rabya p
26. 02 amp 03 e Screen SC 0102 wide 3000 mm 50mm spacing in the main channel branch leading to Modules 04 amp 05 Fine Mechanical e Concrete structure Bar Screens e Screen SF 0101 wide 3000 mm 20 mm spacing in the SF 0101 SF 0102 main channel branch leading to Modules 02 amp 03 Tender No SE 130 165 Document 2 III Screen SF 0102 wide 3000mm 20mm spacing in the main channel branch leading to Modules 04 amp 05 e Belt conveyer for screenings at each fine screen e Skip for screenings at each fine screen Degritter DG 0101 e Concrete structure e One unit with four chambers each long 44 m and wide 2 8 m e One traveling bridge equipped with two diaphragm grit pumps and tipper flushing tank e Two inlets and two outlets slide gates e Electrical panel e Collecting container Degritter DG 0102 e Concrete structure e One unit with two chambers each long 27 m wide 3 m e Equipped with one electric traveling bridge with two scrapers drive e Two air lifts and two screw classifiers DN 300 mm e Three air blowers e Two inlets and two outlet slide gates 1400 x 1000 e Electrical panel in steel weather proof cabinet e Collecting container Degritter DG 0103 e Concrete structure e One unit with two chambers each long 27m wide 3m e Equipped with one electric traveling bridge with two scrappers Drive 0 75 kW scraper 0 75 kW One grit pump in each chamber Pump has auto priming
27. 2 III b Dewatering Pumps 1 The Contractor shall disconnect electrical supplies dismantle electrical and mechanical equipments cut pipes remove abandonment and cart way to a tippers off the site dewatering pumps 2 Nos completely with all fittings suction and discharge pipes valves header pipe supports gauges and drain pipes pump foundations electrical panel cables and all other related accessories and utilities as approved by the Engineer 2 The Contractor shall renovate supply install test commission operation and maintenance effluent water Submersible Dewatering pumps 2 Nos in the ground floor of the effluent transfer pumping station to control the water leakage occurs from the main pump s packing as directed by the Engineer 3 The dewatering pumps shall be installed in a concrete Chamber constructed in a lowest level than the ground floor of the pump room 4 The dewatering pump chamber shall be constructed to include two submersible pumps connected in parallel through a common header pipe discharge pipe complete with suction and discharge valves concrete foundation float switch control switch cable and wiring connection 5 The discharge pipe shall be connected to the sewer network of the pumping station through a new pipe extended to the nearest manhole of the sewage network 6 The Contractor shall submit a full report for his design of the work required with the attached proposed drawing for t
28. 35 Utilities 1 The Contractor shall contact the service authorities to determine the extent locations and invert levels of utilities affected by the Contractors work Confirmation of the exact location of utilities will be the responsibility of the Contractor where necessary by hand digging slit trenching and trial pits Electronic detectors may be used for preliminary investigation This work shall be carried out in consultation with the various service authorities The Contractor shall make his own determination of the existence and locations of such utility facilities such as the locations depths and spacing of smaller utility branches services vaults valve boxes manholes joining boxes ducts duct banks thrust blocks and the like Existing Utilities The Contractor shall prior to commencement of the work obtain information and drawings required from service authorities whose facilities might be affected by the works Two sets of these drawings shall be submitted to the Engineer The Contractor shall uncover by hand digging and verify locations of all services where necessary in accordance with any special requirements of the service authority concerned Notice of Intent The Contractor shall file a Notice of Intent with the service authorities who have services at the site or works in progress at the site at least two 2 weeks before Tender No SE 130 26 Document 2 III he desires to carry out any work near abo
29. 59 Document 2 III 4 The Contractor shall require a second stage pressure grouting Back grouting to ensure that voids have been filled Back grouting will be required at critical locations only roadways adjacent to structures and buildings sidewalks passageways etc to ensure that mix flowable fill materials placements are completed full All the works shall be approved by the Engineer and EPA 5 The extent of works shall include but not limited to cut pressure pipeline into different segments sections and cut open heads surfaces areas suitable to install temporarily pipes for the injection points to pump mix flowable fill materials with sufficient pressure and suitable to install temporarily vent pipes discharge pipes to ensure that mix flowable fill materials are completely emerges from vent pipes discharge pipes with no voids remain unfilled 6 The extent of works shall include but not limited to clean flush remove cart away transport to any distance locations areas and dispose off site wastewater debris and other substances completely that degrade the performance of fill and accumulated in the underground pressure pipelines in accordance to the regulations of the authorities and municipality prior to start grout filling placements 7 The extent of works shall include but not limited to provide transport and commission jet flushers tankers if necessary and provide mud suckers tankers to remove wastewater debris and oth
30. BB Project Information Management Software System PIMSS Project Web site Project Web Cameras and Video Servers Local Area Network and Devices Software s Engineering Workstations Laptop computers Servers Printers Plotters Scanners and Un interruptible Power System s ADSL Internet Connectivity 1 02 REFERENCE STANDARDS A B ISO 82045 5 Document management Part 5 Application of metadata for the construction and facility management sector BS ISO 12006 2 Building construction Organization of information about construction works Framework for classification of information ISO TR 19033 Technical product documentation Metadata for construction documentation ISO IEC 24762 Information technology Security techniques Guidelines for information and communications technology disaster recovery services IEEE 1062 Recommended Practice for Software Acquisition 1 03 QUALITY ASSURANCE A Requirements of the following organisations shall be conformed to as appropriate 1 Codes ordinances rules and regulations of the State of Kuwait and its lawful enforcement agencies a Ministry of Communications Kuwait b Ministry of Electricity and Water C Ministry of Information 2 International Standards Organisation Works covered by this Section shall be executed by a PIMSS specialist engaged in the installation and maintenance of PIMSS as primary business for atleast three 3 years
31. D3740 Practice for Evaluation of Agencies Engaged in Testing and or Inspection of Soil and Rock B Laboratory Authorized to operate in the State of Kuwait C Laboratory Staff Maintain a full time registered Engineer on staff to review services D Testing Equipment Calibrated at reasonable intervals with devices of accuracy traceable to either National Bureau of Standards or accepted values of natural physical constants E Prior to start of Work submit testing laboratory name address and telephone number and names of full time registered Engineer The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 21 Equipment delivered in original packages All equipment or parts thereof instruments materials and spare parts shall be delivered to the sites in their original packages and shall be easily identified without the necessity of unpacking them All packages with their manuals shall bear the name and brand of the manufacturer The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 22 Interference and protection of streets 1 The Contractor shal
32. Document Il 1 The Sign Board shall indicate in Arabic and English but not by the way of limitation the following Name of Ministry Name of Contractor Nature of Work Date of Enterprise Date of completion of the project Contract value The Sign Board shall be supplied with 3 Nos 500 watt Halogen light fittings mounted on the top of each Sign Board and to be connected to the power source The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 31 Temporary Fire Protection A The type location and sufficiency of the fire fighting facilities and equipment shall be to the Engineer s or Engineer s Representative s satisfaction Provide all fire fighting facilities and equipment required by the Kuwait Fire Department whether or not specifically detailed herein B Take adequate safety precautions during metal welding and torch cutting operations as follows 1 Welding or torch cutting operations shall be carried out only in well ventilated spaces having little or no combustible materials in the vicinity and preferably in an area designated and used exclusively as a welding shop 2 Where welding or torch cutting operations are carried out in situ surrounding areas shall be suitably protected by the covering or screening off and suitabl
33. E ONE V Ventilator fan E Exhaust fan 7 Diesel Generator Lifting Stations 8 Odour Control Equipment and related facilities Lifting Stations Tender No SE 130 187 Document 2 III
34. MPW Quality control centre and other restoration areas of zone area 1 as directed by the Engineer within two 2 years from the Date of Enterprise in accordance with MEW standard specifications for street and external lightings 5 The system of road lighting shall be provided to illuminate all road ways and walkways with a lantern lighting fitting incorporated high pressure mercury vapor discharge lamps giving a design light output of 5000 to 6000 luminaries Tender No SE 130 71 Document 2 III The extent of works shall include but not limited to renovate provide install erect test commission operation and maintenance wherever required by the approved design a new outdoor stand alone lighting distribution boards equipped with electric photo cell for auto operation of the system for each domain as specified by the Engineer All works materials and specifications shall be subject to the Engineer approval The Contractor shall be responsible for obtaining MPW approval prior to the start the execution of the works and shall include but not limited to the following requirements All the fixtures used by the Contractor shall be of THORN make and the lighting poles shall be of a hot dip galvanized type Outdoor lightings system shall include all necessary cables fittings materials chokes capacitors holders wires lamps reflectors bulbs connectors and any other accessories required for the proper installation and ope
35. Operation works at Ardiya Sewage plant The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies fuels grease oil consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The Contractor shall be fully responsible for controlling not to interrupt the continuous flow through the header tank which received the tertiary treated effluent water from Rikka sewage treatment plant then pump treated effluent from Ardiya treatment plant to DMC Data Monitoring Center Rabya farms and irrigation network on site The Contractor must make all necessary arrangements to ensure flows are maintained in a safe manner 1 The Contractor shall provide operators 4 Nos with skill labours 4 Nos to partial operation of Ardiya sewage treatment plant in three 3 shifts per day for the duration of one 1 year period after renovation works are completed 2 The Contractor shall provide all necessary safety personnel materials and equipments lightings precaution against
36. P N 100 ml 24 hr Fecal Coli M P N 100 ml 24 hr Salmonella M P N 100ml 24hr Fecal Staptcocci M P N 100ml 48 hr Fungi M P N 100 ml 144 hr 3 Microscopic life samples Sarcondina Pytoflagellates Zoo flagellates Free swimming ciliates Stalked Ciliates Suctoria Rotifiers Worms Eggs of parasites with cultivation Filamentous growth of bacteria type and category Laboratory Reagents and Solutions The Contractor shall provide test and commission new laboratory reagents and solutions periodically as specified in below table for the duration of the contract period and shall include but not limited to the following minimum new laboratory reagents and solutions requirements The Contractor shall be obligated to fulfill other requirements of new laboratory reagents and solutions in according to design specifications and shall not have the right to claim for compensation in time or cost All new laboratory reagents and solutions shall be subject to the Engineer approval The Contractor shall be responsible for obtaining MPW approval prior to the start the execution of the works Example S diphenyl carbazone diphenyl carbazone 100gm 1 Bottle 4 months Item 1 means The Contractor shall provide test and commission one 1 Bottle of laboratory reagent and solution S diphenyl carbazone diphenyl carbazone 100gm periodically every 4 months for the duration of the contract period Tender No
37. SE 130 120 Document 2 III Item Description Unit Quantity Laboratory Reagents and Solutions 1 S diphenyl carbazone diphenyl carbazone 100gm 1 Bottle 4 months 2 Xylene Cyanol ff 100gm 1 Bottle 4 months Mercuric Nitrate 500 gm or Mercuric Nitrate solution 1 Bottle 1 N 6 Amb Box 6 months 4 Sodium Nitroprusside 100 gm 1 Bottle 6 months Tri Sodium Citrate Alkaline Citrate 500 g 1 Bottle 6 months Sulfamic acid 100 gm 1 Bottle 6 months Acetic Acid 2 5 L 1 Bottle 4 months Ethyl Alcohol 2 5 L 1 Bottle 2 months Hydrochloric acid 2 5 L 1 Bottle 4 months TTC 2 3 5 Triphenyl Tetra zolium Chloride 25 g 1 Bottle 6 months Media M Endo Agar 1 kg 1 Bottle 3 months Media MFC Agar 1 kg 1 Bottle 3 months Media Nutrient Agar 500 g 1 Bottle 3 months Media SS Agar 1 kg 1 Bottle 3 months Media Membrane Enterococuss Agar 1 kg 1 Bottle 3 months K F Agar 500 gm Fecal Staptococci 1 Pack 3 months Wort Agar 1 kg 1 Pack 3 months Di Potassium Hydrogen O Phosphate AR 500 g 1 Bottle 3 months Glycerol AR 4 L 1 Bottle 6 months Potassium lodide AR 500 g 1 Bottle 6 months Potassium Dihydrogen Orthophosphate 500 g 1 Bottle 4 months Sodium Thiosulfate 500g 1 Bottle 4 months Peptone Bacteriological 500 g 1 Bottle 3 months Xylene solu
38. STANDARD SOLUTION 1000 mg l MAGNESIUM SULPHATE 250 gm NITROGEN INHIBITOR REAGENT GRADE 2 5 gm CHLORO 6 TRICHLORO MEITRYL PYRIDINE HACH AVAILABLE FROM HACH CAT NO 2533 NITRAVER 5 NITRATE REAGENT POWDER 500 PIL PILLOWS HACH CAT NO 14034 99 NITRAVER 3 NITRATE REAGENT POWDER 500 PIL PILLOWS HACH CAT NO 14065 99 POTASSIUM DICHROMATE 500 ml POTASSIUM HYDROGEN ORTHO PHOSPHATE 1 5 kg PH BUFFER 7 1L PH BUFFER 4 300 ml PH BUFFER 10 600 ml POTASSIUM CHROMATE 250 gm PHENOLPTHELIN INDICATOR POWDER 250 gm POTASSIUM NITRITE 250 gm POTASSIUM SULFATE 250 gm POTASSIUM HYDROGEN PALTALATE COD 250 gm STD CERTIFIED A C S HOCOC H COCK POTASSIUM CHLORIDE 250 gm ROUND FILTER PAPER 18 5 CM MEDIUM 2000 Tender No SE 130 139 Document 2 III FLOW CIRCLES SILVER SULFATE 250 gm SODIUM HYDROXIDE 1 5 kg SILVER NITRATE AMPOULES 0 0282 N 22 AMPULES SULFAVER 4 SULFATE REAGENT POWDER 500 PILLOWS PILLOWS HACH CAT NO 12065 99 SULFIDE 1 REAGENT HACH CAT NO 1816 37 5 BOT SULFIDE 2REAGENT HACH CAT NO 1817 32 5 BOT SODIUM NITRITE 250 gm SODIUM SULFIDE 250 gm TOTAL CL REAGEN POWDER PILLOWS 600 PIL 1 1 1 TRICHLORO ETHANE 15L ACETIC ACID 2 5L AMMONIUM ACETATE 500 g AMMONIUM HYDROXIDE 2 5L AMMONIUM MOLYBDATE 500g HYDROCHLORIC ACID HCL 2 BO
39. The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill unlimited depth of excess areas landscaping grading compacting 9596 MDD soil and to be reinstated and restored the site to a condition match its surroundings as approved by the EPA and the Engineer The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site E Rehabilitation of soil 1 Rehabilitation of soil on site within the perimeter chain link fence 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise shall include but not limited to earthworks are required to determine the properties of the soil underlying the site by taking samples tests in different locations within the perimeter chain link fence 800 m 440 m 800 m 440 m as approved by the Engineer to test that the soil is not polluted and the strength soil load bearing capacity The Contractor shall require treatment of polluted soil and submit a certificate for laboratory testing after treatment of polluted soil and the strength soil load bearing capacity as approved by the Engineer and EPA 2 The extent of work shall include but not limited to excavate and remove of excess soil above ground surfaces areas or upper hill surfaces areas landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match it
40. and full motion interactive video applications and shall be minimum 10 Mbps PDF DWG DWF DOC DOCX XLS XLSX PPT DGN MPP JPG TIFF PNG P3 PSD TXT RTF and other Microsoft and Adobe formats Dynamic Random Access Memory Drawing Web Format which is a compressed DWG output format suitable for printing redlining and mark up and display on websites AutoCAD binary drawing format Drawing Exchange format for AutoCAD which is a human readable version of DWG Drawings Documents RFI transmittals and all other contract related information managed by PIMSS Input Output Internet Protocol version 4 State when a data on a network is available for I O Computer hardware and software combination that can be connected to the PIMSS via a wired and wireless network to I O data Project Information Management Software System Comprises all contact drawings revised and or additional design drawings all shop drawings materials and equipment listings submittals transmittals RFIs meeting minutes change orders correspondence between Stakeholders and all other standard reporting items prescribed in the contract documents Random Access Memory Portable Document Format from Adobe systems is used to view documents from many software programs without having those programs installed Starting from the Date of Enterprise till the Date of Substantial completion plus three months as certified by the Engineer Comprises Engineer and hi
41. and maintenance for the laboratory partition rooms new emergency lights fixtures sufficient within one 1 year starting from the Date of Enterprise to allow enough illuminators for the movement of MPW staff during the power failure The emergency light fixtures shall be twin bulb holder type with aluminum reflector weather proof industrial type 12 Volt with inbuilt battery 6 x 10 AH and battery charger shall be thorn make or equivalent The capacity of Bulbs shall be 2 x 35 W The layout type and the numbers of fixtures shall be approved by the Engineer 10 The Contractor design provide install test commission and maintenance for the laboratory partition rooms sufficient smoke and heat detectors in each room as per the KFB approved procedures especially the laboratory rooms within one 1 year starting from the Date of Enterprise and shall be connected to FCAP and sufficient no of fire alarms sound amp light alarms bells and shall be installed to alert the guard man and shift operator during any fire condition 11 The Contractor shall design provide install test commission and maintenance for the laboratory partition rooms sufficient numbers of fire extinguishers not less than 3 Nos as per recommendation of KFB regulations within one 1 year starting from the Date of Enterprise and shall be refilled or inspected by KFB yearly Also the Contractor shall consider the approval according to KFB regulations The Contractor shall prov
42. area of the perimeter fence shall be excluded from demolishing works However the Contractor shall dismantle remove abandonment and cart away to a tippers off site the existing internal storm water drainage system of zones areas 1 amp 2 and shall renovate provide erect install test commission and maintenance new internal storm water drainage systems of zones areas 1 amp 2 and shall be connected to main storm water drainage system as specified in the contract requirements 4 The extent of works shall include but not limited to all non usable ferrous metals within the boundary area of the perimeter fence cart away to a tippers Tender No SE 130 41 Document 2 III off the site and delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer 5 The extent of works shall include but not limited to break concrete reinforcement structures walls slabs reinforced concrete cover slab puncturing the base slabs and surrounding walls including excavating depth of 2 5 meters beyond the horizontal limits of the foundation slab and walls of substructures removing and carting away to a tippers off the site The concrete cover slabs shall be carefully broken to maintain metals covers and frames Metals and frames covers shall be cleaned and sand blast to remove any corrosion product paint with two coats of coal tar paints and deliver to MPW stores off site The Contractor shall no
43. as directed by the Engineer c Grown color yearly season flowers along both sides of new main roadways and internal roadways site parking area and buildings as directed by the Engineer 4 The Contractor shall dismantle existing storm water drainage system of zones areas 1 amp 2 dewater cut pipes break concrete structure remove abandonment and cart away to a tippers off site 5 The Contactor shall design renovate provide erect install test commission and maintenance new storm water drainage system of zone areas 1 amp 2 along new main roadways and internal strip double layers asphalt roadways and parking shelters within two 2 years starting from the Date of Enterprise and shall be connected to the main storm water drainage system within the boundary perimeter new fence area 800 m long x 440 m width on site as approved by the Engineer The extent of work shall include but not limited to trench excavation gravity pipelines and fittings coating pipes suitable bedding arrangement is essential to ensure stability of pipelines for the entire life span and under varying conditions underground and above the ground fittings Laying and jointing of pipes pipes alignment and lining concrete manholes and chambers cast iron manholes covers and gratings 6 The extent of works shall include but not limited to provide plant commission and maintenance of unlimited excess underground depth area of planting soil mix within the bou
44. asbestos pressure pipelines of Rabya DN 300 mm The extent of works shall include but not limited to flow diversion excavation backfilling trenches trench preparation handling and laying out pipes laying and jointing pipes pipes alignment and lining water stops supply and used of specified couplings or collars cutting turning and chamfering specials and fittings where required and for trimming pipes where built in disposal of wastage incurred for any reason whatsoever beds haunches and surrounds cleaning and testing of pipes and pipelines on site before during and after pipes Tender No SE 130 9 Document 2 III laying pre commissioning CCTV inspection or joint testing and other related works as approved by the EPA and the Engineer All pipelines materials and size diameters specifications shall be approved by the Engineer 5 The Contractor shall design renovate supply installation setting to the work testing and commissioning a new L T switchboard control board and MCC panels complete with the necessary upgrading and modified ratings and capacities in order to provide the proper and accurate electrical power supply and control operation to the new equipment 6 The Contractor shall be responsible for any modification or replacement of any part of the pumping station whether specified above or not related to this item and to allow such work in the total price of this item no any additional cost or claims comes to the
45. at 733 rpm 7 The Contractor shall make good the space area leftover after equipment removal and prepare it for the installation of the new equipment and accessories without any obstruction from the existing fittings and structures 8 The Contractor shall renovate supply installation setting to the work testing and commissioning a new L T switchboard control board and MCC panels complete with the necessary upgrading and modified ratings and capacities in order to provide the proper and accurate electrical power supply and control operation to the new equipment Tender No SE 130 89 Document 2 III 9 The rehabilitation and renovation work shall include provision of the latest version of mosaic enunciator panel PLC based control panel electrical power and control cables instrumentation earthling system supporting brackets and all other associated necessary components for the proper and modern electrical installation 10 The Contractor shall be responsible for any modification or replacement of any part of the pumping station whether specified above or not related to this item and to allow such work in the total price of this item no any additional cost or claims comes to the ground shall be allowed by MPW 11 The Contractor shall restrictedly follow the specifications and technical conditions of the supply and installation of L T switchboard MCCs and control panel Specified in Sanitary Engineering General Specifica
46. below ground and the nature and complexity of the work to be undertaken The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 1 Demolish Screw Conveyors Lifting Stations S20 within boundary area 900 m completely and S21 within boundary area 900 m completely disconnect the electricity supplies completely dismantle mechanical and electrical equipments and instruments completely break concrete structures completely cut pipes and abandonment all types structures facilities completely and cart away off the site All types of structures facilities shall include but not limited to ground structure tank or chamber concrete reinforcement structures substructure underground tanks or chambers superstructures small pumping stations structures culvert pipelines channels and other structures facilities The extent of work shall include the following structures and equipments but not limited to Underground screw pumps covered with metals Small pumping stations c Auxiliaries Grease oil pumps Dewatering and submersible pumps Gear boxes Screw conveyors motors Main pumps motors Grease oil pumps motors Ventilators pipelines and Exhaust fans d Existing odour control equipments tanks pipes and other related facilities op Tender No SE 130 51 Document 2 III e Diesel generator set and other relate
47. commissioning setting into the work Tender No SE 130 90 Document 2 III 2 The Engineer shall review and supply the above mentioned submittal and forward his approval or rejection within one month of the submittal date In the case of submittal rejection or not approved due to missing items or incomplete data or improper design The Contractor shall correct and resubmit his study within one month of the Engineer s letter 2 Installations of New Equipments The Contractor shall renovate supply erect install commission operate and maintain the following equipments at the effluent transfer pumping station with all required civil works fittings and accessories and as directed by the Engineer a Rabya Pumps 1 The Contractor shall design renovate supply Install test commission operation and maintenance new Irrigation centrifugal Pumps 3 Nos 90 m hr each to be mounted in the pump area adjacent to the existing remaining effluent pumps 3 Nos at the location of the of the abandonment effluent transfer pumps and supplied by the effluent water from the existing contact tank header tank complete with motor pipe works suction and discharge valves non return valves valves actuators pressure gauges drains etc and all other fitting and accessories The new irrigation centrifugal pumps shall be connected the header tank Module 06 CT0612 and the existing discharge pipelines within the boundary area of the fence a
48. connected to local network server multiple accesses points and data can be viewed from office home other plants wherever the network is available 3 The Contractor shall submit the original catalogs of the latest version available in the local market and the warranty durations from the manufacturer 4 The Contractor shall design provide install test commission operate and maintenance all elements for a Plant Information Management System PIMS in sufficient detail to enable PIMS Technology Provider Vendor to develop a detailed functional specification The Vendor is expected to propose a complete and fully operation solution regardless of any inadvertent omissions in this document within one 1 year starting from the Date of Enterprise No extra will be admitted if the Engineer specifies additional requirements to achieve a system to his satisfaction The Contractor shall be responsible for obtaining the Engineer approval to such design prior to the start the execution of the works 5 The scope of work of the PIMS Vendor shall include but not limited to procurement engineering configuration design testing out and commissioning of a state of the art PIMS system consisting of Enterprise Server as long term data historian and other MPW facilities servers Process Book and graphical and reporting client tools Real time web parts for web based visualization customized graphics and reports on site user training offsite system manage
49. cum System Administrator with at least 5 years of experience in electronic Document management in construction sites and at least 2 years experience with a recognized online Construction Project Information System shall be employed full time the Period of Operation of PIMSS to train new users design maintain operate and archive PIMSS data PIMSS training for all personnel shall include three 3 eight hour sessions encompassing all aspects of operation maintenance and trouble shooting techniques associated with the system including but not limited to 1 Common System I O functions 2 System data backup and restoration 3 Use of all peripherals like Printers Web Camera and scanners Advanced training for designated advanced users shall include five 5 additional eight hour sessions encompassing all aspects of Software programming and to undertake software customization and maintenance associated with the system including but not limited to Workflow creation and troubleshooting Customization of Forms Installation of software for new users Server setup and operation Trouble shooting and System maintenance procedures oOEO0ON Tender No SE 130 161 Document 2 III 6 Web site details and modification 3 04MAINTENANCE A Requirements of General Conditions of Contract shall be referred to and complied with as appropriate without prejudice to the requirements stated herein B Initial configuration training and
50. data online and available for at least 10 years 9 The PIMS server should the flexibility to connect to more data sources in the future located in other plants and must be upgradeable to monitor more than 150 000 data tags on a single server Tender No SE 130 108 Document 2 III 10 The PIMS client software will permit Viewing of the PIMS data in a graphical form Trending of PIMS data Generating automatically updated reports Manipulation of the stored data using a calculation engine supplied with the software 11 The security scheme for the PIMS shall include system level password protection and PIMS password scheme containing several levels of user authentication 12 The PIMS Technology for the PIMS should be able to send data via standard formats OPC OLEDB ODBC to support seamlessly best of breed applications solutions from various solution providers 13 The PIMS historian software should be capable of manually back entering data to an earlier time stamp 14 The PIMS system should include capabilities to perform on line backup and restore of the complete system 15 The PIMS should be capable to establish totals averages or any other calculation to the time ordered data entries 16 The PIMS should have user friendly tools which are installed on MS Windows based client PCs allowing MPW users to access real time and historical data residing in the PIMS server and other data sources to cre
51. drains etc and all other fitting and accessories utilities and services cables wires earthling rods MCC electrodes sensors etc lightings fixtures and networks emergency lightings doors with lockers windows with mesh screens power roof ventilation system mechanical and electrical installations fire alarm system HVAC system smoke and heat detectors fuel gas distribution system laboratory compressed air system process air and gas piping laboratory vacuum system and all related mechanical electrical and instrumental works as approved by the Engineer 2 The extent of works shall include but not limited to calibration of existing and new equipments and devices of zone area 1 facilities and shall include but not limited to laboratory equipments and devices safety equipments gas detectors devices alarms pumps in automatic modes pressure gauges fire and smoke detectors and other instruments on daily basis to get accurate data readings 3 The Contractor shall be fully responsible for the proper maintenance and repair or if required replace of the new mechanical and electrical equipments instruments air conditioning units and street and outdoor lightings poles and networks of zone area 2 facilities for the duration of one 1 year period after renovation works are completed as approved by the Engineer and shall include but not limited to substation SU 0641 effluent transfer pumping station PS 0633 remaining effluent
52. f 1000 ml cap 12 Nos g 2000 ml cap 5 Nos Tender No SE 130 134 Document 2 III 92 Buckner funnel 12 Nos Funnel polypropylene 100 mm diameter 100 mm stem 12 Nos Separator funnel 500 ml cap 12 Nos 1000 ml cap 12 Nos Pipettes ONE MARK 1 ml cap 12 Nos 2 ml cap 12 Nos 5 ml cap 12 Nos 10 ml cap 5 Nos 20 ml cap 5 Nos 25 ml cap 5 Nos 50 ml cap 5 Nos Test tubes 100 pkt 12 pkts Watch glass 75 mm diameter 5 Nos 100 mm diameter 5 Nos 150mm 5 Nos Gas washing bottle Pyrex 125 ml cap 5 Nos Quartz curette for U V spectra 2 pkt 20 pkts 100 Storage bottle polyethylene 12 pkts Tender No SE 130 135 Document 2 III 101 HDPE 50 litter cap 5 Nos 102 Filters glass fiber WHATMAN GF C 100 pkt 12 pkts 103 Grease tube silicone 50 gm 12 Nos 104 Rubber tubing 8 mm int thick wall 50 coil 12 Nos 105 Anti bumping glass beads 250 grams 5 pkts M Torque A Torque paper 60 Rolls Carts chemicals amp glass ware 12 Nos Clamps different types 24 Nos Sterile pads 50 pkt 12 pkts Glass cutting knife for Borosilicate glass 12 Nos Glass cutting knife diamond mount 12 Nos Lubricating grease 12 Nos rubber grease soft 12 Nos Rubber grease medium 12 Nos Silicone grease 12 Nos Apiezon grease for glass 12 Nos Mortar amp pe
53. from the Work in a manner approved by the Engineer s Representative and so as not to adversely affect the permanent works or adjacent areas and properties The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 39 Lines Grades and Measurements The Contractor shall employ a competent field engineer registered within the State as a Professional Engineer or Land Surveyor The Contractor shall require to establish all lines elevations references marks etc needed by the Contractor for landscaping after finishing the activities works of demolish The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Tender No SE 130 28 Document 2 III Clause 40 Information and Photography No information photographs etc shall be released by the Contractor to any person or news media without the prior authority and consent of the Engineer Clause 41 Final Cleaning 1 Remove waste debris and abandoned items or surplus materials from sites Clean grounds remove stains spills and foreign substances from paved areas and sweep clean All cleaning work shall be to the Eng
54. grid spacing of components accessories fittings hardware anchorages height elevations of the same and schedule of components 2 Submit manufacturer s installation instructions Tender No SE 130 74 Document 2 III D Renovation works of MPW Quality control center AB 1044 and other related works The Contractor shall renovate MPW Quality control center Module 10 AB 1044 with all related accessories completely and shall include but not limited to offices partition rooms telemetry partition room laboratory partition rooms kitchen toilets and all other partition rooms within three 3 months starting from the Date of Enterprise and shall include the following requirements but not limited to all related mechanical electrical instrumental and civil works as approved by the Engineer 1 Telemetry system Partition Room a The Contractor shall reinstall test commission a Telemetry system in partition room of MPW Quality control center Module 10 AB 1044 as specified in the contract requirements and shall include but not limited to all related mechanical electrical instrumentation and civil works for the operation of the telemetry system as directed by the Engineer b The extent of works shall include but not limited to provide install test commission and maintenance new lightings fixtures A C split unit 3 5 ton with compressor oil heater office desk L shape swivel leather chairs with arms wooden doors with loc
55. ground shall be allowed by MPW Submittals and Approval The Contractor shall submit to the Engineer for review and approval the following documents within 2 months from the date of enterprise 1 Full study report on the installation of the new Rabya pumps as mentioned above complete with the proper recommendation and equipment selection to achieve such work 2 Shop drawing factory test reports manufacturer certified reports and technical data for the new pump motor sets 3 Nos required in this item includes the following e Manufacturer Catalogs e Product specifications and performance e Pump materials details e Motor housing materials winding material ambient temperature and maximum elevation in which motor is designed to operate continuously insulation class design factor bearing life and dynamic balance e Dimension and weight e Provision of mounting on the pump e Pump Motor construction details e Starting methods e Speed torque curve 3 Submittals shall also contain workshop drawing documents manufacturer specification of the new switchboard MCC control panel and distribution cables and accessories and all other electrical equipment will be installed through the work including but not limited to Single line diagram showing loads and short circuit calculation Schematic diagram showing electrical arrangement of the panels Cable layout Component list Tender No SE 130 92 Document
56. have openings through which a probe may be inserted If not the lid must be removed using appropriate tools and the atmosphere tested before entry Atmospheric testing will be performed by the entry supervisor or attendant for oxygen deficiency and explosive and toxic gases Multi gas meters shall be provided by the Contractor that test for oxygen deficiency explosive gases and certain toxic gases Hydrogen Sulfide and Carbon monoxide a Oxygen concentration in the confined space is greater than 19 5 percent and less than 23 5 percent by volume b Presence of flammable gases or vapors is less than 10 percent of the lower flammable limit C Potential toxic gases or vapors are present at concentrations below OSHA permissible exposure limits e g less than 10 part per million ppm for Hydrogen Sulfide The Safety Officer shall evaluate the work place to determine if any spaces are permit required confined spaces If there are changes in the use or configuration of a non permit confined space that could increase the hazards to the entrants the Safety Officer shall re evaluate the space and reclassify it as a permit required confined space if necessary Warning Signs A plant that contains permit required confined spaces must post warning signs at the entrance of these spaces 3 Abandonment of demolished structures and cart away off site The Contractor shall require to execute all the works in accordance to the latest
57. heater and boiler and all related works The color and type of materials shall be subject to the Engineer Approval All works and materials shall be subject to the Engineer approval 11 The extent of works shall include but not limited to dismantle remove abandonment pipeline valves fittings and other connections from the main water source point to mosque cart away to a tippers off the site The Contractor shall renovate supply erect install test commission and maintenance new UPVC pipelines connected from the main water source point to mosque with all fittings and other related civil works All works specifications and materials shall be subject to the Engineer approval 12 The extent of works shall include but not limited to provide install commission and maintenance new fire extinguishers not less than 1 No as per recommendation of KFB regulations and shall be refilled or inspected by KFB yearly The Contractor shall provide install test commission and maintenance Tender No SE 130 106 Document 2 III new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval 13 The extent of works shall include but not limited to all required civil mechanical and electrical works as required for proper completion works All specifications paints equipments furniture an
58. immediately preceding years in Kuwait and approved for the purpose by relevant governmental agencies Descriptions of the software and hardware components stated in the tender documents are intended to define functional requirements of an acceptable system integral with the whole of the Contract These shall not be interpreted Tender No SE 130 152 Document 2 III 1 04 outside that context and the Contractor shall in his tender highlight and allow for alterations modifications to the system or the system components which in his opinion are necessary to accomplish the intended purpose PIMMS supplied shall have local agent s certified by manufacturer s to maintain the equipment during its Period of Operation Materials and fieldwork required to complement PIMSS are included in this Section Additional software and hardware shall be provided as appropriate subsequent to system commissioning PIMSS shall be installed by competent installers trained by software vendor and under the supervision and guidance of a PIMSS specialist as appropriate Computer equipment system components shall conform to the requirements of FCC regulation Part 15 Section 15 governing radio frequency electromagnetic interference and be so labelled Where it is intended to integrate PIMSS with external systems software and hardware used shall be compatible with such systems Alternatively compatibility shall be ensured by using appropriate adapters an
59. in galleries under express rings roads including bends fittings junctions joints jointing parts supports anchors and other related connections to be carted away to a tippers off the site as approved by the Engineer and EPA 11 The extent of works shall include but not limited to provide install and maintain all temporary staging scaffolding rigging shuttering to carry out the works in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services and carried out with all necessary precaution needed Tender No SE 130 60 Document 2 III 12 The Contractor shall be deemed to have carried out his own investigations to ascertain himself the nature of the soil conditions and the groundwater level The Contractor shall provide install and operate pumps plugs conduits dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations 13 Demolish unlimited depths of all hatch boxes among underground pressure pipelines completely dismantle mechanical equipment and other related connections break concrete structure dewater cut pipes remove abandonment and cart away to a tippers off the site a The extent of works shall include but not limited to breaking concrete reinforcement structures walls slabs cover slabs and foundations puncturing the base slab and surrounding walls including excavating dept
60. minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities 2 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations MPW and other governmental authorities to execute demolishing works of all types of structures facilities pipelines manholes etc within one 1 month starting from the Date of Enterprise 3 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities of soil and groundwater investigations rehabilitation and treatment of polluted soil within one 1 month starting from the Date of Enterprise 4 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities to remove and transport pollutants in a safety manner shall include but n
61. necessary trenches with Chaucer plate covers building of cable manholes earthling pits and fitting laying of ducts ceiling of ducts excavation of trenches backfilling and consolidation carting away of surplus spoil etc shall be executed by the Contractor and the full and entire cost of all such builder s works and materials shall be included in the total bid amount 8 The Contractor shall co operate and co ordinate with all other parties or Contractor s executing work on sites or adjacent to his sites of work in order that the minimum interference inconvenience is caused to the public 9 The extent of work shall include but not limited to underground services and utilities cables wires earthling rods electrodes MCC sensors etc and all required mechanical electrical instrument and civil works in accordance to the regulations of the authorities EPA and Engineer approval No claims will be admitted if the Engineer specifies additional requirements or any modification to achieve the system to his satisfaction such work will be executed and carried out through the same contract price without any additional cost to the ministry 10 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be rei
62. of the latest version of mosaic enunciator panel PLC based control panel electrical power and control cables instrumentation earthling system supporting brackets cable trays trenches trunking and conduits cable ladders and all other associated necessary components for the proper and modern electrical installation Tender No SE 130 84 Document 2 III 6 The work shall also include replacement of entire lighting system wiring lighting fixtures ventilation system power outlets and other related accessories 7 The Contractor shall Supply install testing commissioning and setting to work Emergency lighting independent units self contained battery of 4 hrs Back up time for the following areas as specified in the contract documents e 5 Units for substation S S 1 e 10 Units for MPW Quality Control Centre e 4units for Laboratory e 2units for Mosque e 3Units for Scada Control room e 3 Units for Telemetry Master Station e 2 Units for Guard house e 6 Nos weather proof units for the outdoor areas 8 Supply install testing and commissioning of new lighting amp Power system for zone area 1 and facilities complete with the following equipment Lighting and Power distribution boards Explosion proof and weather proof lighting fittings Lighting Switches sockets outlets junction boxes and accessories Lighting and power cables conduits fittings and accessories Earthling System 9 Supply install connection and
63. operation of PIMSS for a period of 6 months from the Date of Enterprise and at least 4 months after completion of PIMSS implementation must be done through qualified personnel from the PIMSS specialist stationed full time on site C Corrective actions modifications made on the PIMSS during Period of Operation shall be updated on user documentation and on user and manufacturer archive software media D Any updates or changes to PIMSS shall be informed and agreed to with the Engineer and Engineer s Representative in advance and supplementary training shall be provided in modified or new product functions Software updating shall be done outside of regular working hours E The hardware and software provided by the contractor remain the property of the contractor and must be maintained by the contractor and shall be in working condition during Contractor s working hours F Replacements for all hardware and software systems are to be provided on the same day of failure from spares to be kept by the contractor G If any part of the system is not able to function for longer than 24 hours the contractor shall replace the malfunctioning component or provide a temporary equivalent substitute system Failure to correct the malfunction within 48 hours from receipt of the Engineer s representative written notice shall be cause for a penalty of KD 200 per day of delay to be deducted from the Contract amount 4 The contractor has to be a
64. pipelines Machine House MH 0231 Concrete structure Fifteen process air blowers for Modules 02 amp 03 Each blower capacity 9552 Nm h at 55 C Discharge pressure 55 kPa Rotation speed 1450 min Absorbed power 177 kW Motor rated 200kW Blower equipped with pressure unloading valve solenoid control valve safety valve check and butterfly valves DN 300 and flexible connection Four pumps for module 02 each pump Four pumps for Module 03 Horizontal shaft Each pump horizontal shaft nominal capacity 900 m3 h head 11 2 m rotation speed 1450 min motor rated 55 kW One pump for Module 02 Horizontal shaft nominal capacity 180 m h head 15 m motor 18 5 kW One pump for Module 02 Horizontal shaft nominal capacity 90 m h head 4 7 m motor 3 kW Air and sludge piping with valves diameters from DN 350 up to DN 1000 Two drain pumps One ventilation fan MCC for all above equipment Control room for Module 02 amp 03 Shutter door doors upper floor windows ground floors and remove of underground pipelines other building components Electrical Substation SU 0243 MCC for aerators in bioreactors BR 0213 amp BR 0411 Module 03 Module 3 shall include but not limited to the following structures mechanical and electrical equipments Bioreactor BR 031 1 Concrete substructure One basin with 9 separate chambers Each chamber size 50x8 4x38 m Inlet channel with two slide gates Di
65. pipelines assess condition of pipelines and locate any other obstructions but not limited to dismantle cut remove and abandonment damaged pressure pipelines or parts of pipelines including bends fittings junctions joints jointing parts supports anchors and other related connections to be carted away to a tippers off the site as approved by the Engineer and EPA 14 The extent of works shall include but not limited to capping and sealing additional unknown single pipeline diameter 300 mm 1 2 300 mm and double pipelines diameters 700 mm 2 6 700 mm connected to Ardiya sewage plant outside the perimeter fence C Demolish Extraneous materials pipes etc accumulated on site cut remove abandonment and cart away to a tippers off the site 1 Demolish all extraneous materials pipes etc accumulated on site remove and abandonment within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise dismantle electrical and mechanical equipments cut remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to bushes dirt trash sand debris debris containers sand and cement
66. pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The existing odour control facility and degritter one unit with four chambers one traveling bridge equipped with two diaphragm grit pumps and tipper flushing tank two inlet and two outlet tanks electrical panel and collecting container are located outside existing boundary fence area The extension boundary fence area of theses facilities shall be included as part of the contract requirements 2 The following types of structures mechanical and electrical equipment of the following zones areas and partial of sanitary sewerage system and partial storm water drainage system shall not be included in the abandonment works Zone Area 1 Main Entrance Gate Guard House Module 10 AB 1041 MPW Quality control center Module 10 AB 1044 Mosque AB 1043 Substation SU 0241 which is located near the machine house Wastewater Pumping Station PS 0931 Zone Area 2 Substation SU 0641 which is located near effluent transfer pumping station Second stage contact tank Module
67. sand and shall include but not limited to aggregates fly ashes potable water additives and admixtures as necessary required to control of pumping mix flowable fill properly and self leveling placements without shrinkage until the volume of the underground gravity pipelines is completely full The extent of works shall include but not limited to video with closed circuit television to ensure no voids remain unfilled The Contractor shall submit a certificate of mix flowable fill materials for approval by the Engineer and EPA 3 Provide install transport and commission grouting equipments and pumps of mix flowable fill to the site in ready unlimited quantities of mix trucks to pump mix flowable fill continuously with sufficient pressure to overcome friction and prevent nesting and void formation The Contractor shall follow procedures with sufficient safety precautions and care to avoid damage to existing underground utilities structures The quantities of machineries trips are not limited to be available on demand The Contractor shall maintain safe access to adjacent property and buildings The Contractor shall provide experienced crews to perform filling operation to monitor density of mix flowable fill and to control pressure The extent of works shall include but not limited to furnishing installing and maintaining temporary traffic control devices barriers barricades cones drums warning signs fencing and lights maintenance for the prot
68. setting to work a new earthling system for all electrical equipments and switchboards as per the latest regulation of MEW and requirement of the contract specifications 10 The Contractor shall include but limited to the preparation of concrete surfaces repairs shall include but not limited to clean and dry from all contamination surface laitance and other loose materials according to approved manufacture requirements either grit or water blasting technique to be dumped out of the station building In addition the old contaminated sealant of existing joints shall be thoroughly cleaned out from all traces of previous sealant and primer using a suitable mechanical method such as grit blasting water blasting or grinding The extent of work shall include but not limited to civil maintenance and repair works of wall and ceiling plastering replacement of all doors and door frames stairs tiles false ceiling etc as directed by the Engineer 11 The Contractor shall paint internal wall and roof with emulsion paint for substation Painting shall be carefully executed with clean brushes and in the best manner and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendations Painting of interior walls shall not be carried out in wet dusty or foggy weather and interior walls and roofs shall not proceed in dusty condi
69. the Contractor responsibility to obtain the latest copies of these regulations at his own expense and there will be no consideration for any such unawareness of these requirements 4 The Contractor shall check and allow in the Contract prices for obtaining any permits licenses or paying rents and fees for any authorities necessary for starting carrying out completing setting to work and handing over in an operating and useable condition all equipment and materials called for in the Contract documents 5 The work shall include the supply manufacture installation erection delivery storage testing setting to work commissioning and handing over in perfect operating condition all materials and equipment called for in the Contract Documents as well as carefully removal of the old existing materials and equipment packing transporting them safely to MPW store 6 A complete installation shall include any sundry items or components may be necessary or as specified by the Engineer Such items whether mentioned or not shall be included at no extra cost to the contract sum 7 No claims will be admitted if the Engineer specifies additional requirements or any modification to achieve the system to his satisfaction such work will be executed and carried out through the same contract price without any additional cost to the ministry 8 All builder s works such as chasing of walls grouting of bolts foundation trenches with Chaucer pla
70. the state of Kuwait in a legal manner The quantities of machineries trips are not limited to be available on demand and shall include but not limited to tractors tippers Lorries mud suckers tankers flushers cranes tools equipment etc to execute the works completely After the termination of the contract the mobile equipment or machineries shall remain the property of the Contractor All the works shall be approved by the Engineer EPA and Ministry of Interior Traffic Department 7 The extent of works shall include but not limited to provide install and commission suitable plug or cap and sealing pipe ends surfaces completely connecting to the inlet and outlet gravity pipelines ends and manholes either by filling pipe ends surfaces with dry pack grout mixture or installing manufactured cap to form water Tender No SE 130 65 Document 2 III tight seal The extent of works shall include but not limited to plug other open surfaces areas with dry pack grout mixture to form water tight seal 8 Demolish unlimited depths of all manholes among underground gravity pipelines completely dewater break concrete structure remove abandonment and cart away to tippers off the site a The extent of works shall include but not limited to breaking concrete reinforcement structures walls slabs cover slabs and foundations puncturing the base slab and surrounding walls including excavating depth of 2 5 meters beyond the horizontal li
71. to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 29 Handling and Distribution The Contractor shall handle haul and distribute all materials and all surplus materials on the different portions of the Work as necessary or required shall provide suitable and adequate storage room for materials and equipment during the progress of the Work and be responsible for the protection loss of or damage to materials and equipment furnished by him until the final completion and acceptance of the Work The Contractor shall be solely responsible for any damage to public or private utilities or installations that may result from any negligence or default on his part or the part of his agents employees or labor Any such damage shall be repaired Tender No SE 130 23 Document 2 III at his own expense and according to invoices sent by the authorities and parties concerned The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 30 Sign Board The Contractor shall provide and erect where directed by the Engineer a Sign Board of the standard dimensions not less than 3x4 meters Materials and method of installation as given by the MPW General Conditions
72. to plumbing system pipes plumping specialties sanitary sewer system and manholes connected to the nearest new sewer manhole plumbing system plumping specialties sinks with faucets hot and cold boiler exhaust fan plumbing chrome fittings connections and other services UPVC pipelines fittings and other connections which linked to the main water source water proofing insulation aluminum doors with hang louvers and lockers glazing windows with mesh screens frames louvers and vents interior lights and fittings equipment and wiring installations PVC false ceiling sheets in aluminum framing and sealed with silicon and should be non toxic chemical resistance and water repellent cables and connection to existing substation No 1 SU 0241 and other related civil mechanical electrical and instrumentation works The extent of works shall include but not limited to provide all required laboratory consumables detergents soap paper tissues cotton cleaning solution and sponge big roll tissue papers etc per month for the duration of the contract period 6 The Contractor shall be responsible to design supply install test commission and maintenance for the laboratory partition rooms lightings fixtures and network Tender No SE 130 112 Document 2 III fire alarm system telephone instrument wall hanged for each room connection extension line shall be provided from the new EPBAX which is installed in the MPW Quality Control
73. transfer pumps 3 Nos and remaining surge vessels 4 Nos irrigation pumps Rabya Pumps 3 Nos landscaping irrigation Pumps 2 Nos dewatering Pumps 2 Nos electrical supply Panel and control room equipment surge tanks compressors and compressors motors pressure vessels flow meters alarm system fire protection system fire detection telephone extension lines HVAC system smoke and heat detectors lightings and power system emergency lightings back entrance gate utilities and services safety equipments motors pipe works suction and discharge valves non return valves valves actuators pressure gauges drains etc and all other fitting and accessories 4 The extent of works shall include but not limited to calibration of new equipments and devices of zone area 2 and shall include but not limited to flow meters safety equipments gas detectors devices alarms pumps in automatic modes pressure gauges fire and smoke detectors and other instruments on daily basis to get accurate data readings 5 The Contractor shall provide install test commission new original spare parts for the prompt repair and maintenance of the mechanical and electrical equipments instruments air conditioning units and lightings fixtures and networks instruments air conditioning units and other related required spare parts All replacement spare parts shall be original parts from the original equipment supplier or manufacturer 6 The Contrac
74. treatment of polluted soil on site termite control groundwater pressure investigation soil rehabilitation backfill excavated area after treatment of polluted soil and all required mechanical electrical and civil works in accordance to the regulations of the authorities municipality EPA and Engineer approval All non salvage ferrous metals surfaces shall be delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer The Contractor shall not be allowed to divert wastewater flow to any Tender No SE 130 52 Document 2 III emergency by pass gulf sea line and shall use tankers mud suckers to remove wastewater off sites to any unlimited distances locations areas in the state of Kuwait in a legal manner 8 Demolish unlimited depth dry and wet manholes transition chambers TC hatch boxes wells pits channels distribution chambers and other underground chambers completely dismantle dewater break remove abandonment cart away off site transport and dispose to dumping area outside the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of work shall include but not limited to all existing step irons ladders fences concrete passing slabs concrete surfaces walls slabs and columns passing slabs covers air release valves chambe
75. 06 CT0612 or header tank which received the treated effluent from Rikka sewage treatment plant Inlet and outlet channels of second stage contact tank or header tank Module 06 CT0612 By pass channel to sea which is connected to outlet channel of second stage contact tank or header tank Module 06 CT0612 Effluent transfer pumping station Module 06 PS 0633 Effluent transfer pumps 3 Nos only with discharge pipe Inlet and outlet channels of effluent transfer pumping station Module 06 PS 0633 Surge vessels tanks Module 06 VS 0661 4 Nos only related to effluent transfer pumping station Module 06 PS 0633 Partial of Sanitary sewerage system Wastewater Pumping Station PS 0931 Main Sewer pipeline and manholes connected to Wastewater Pumping Station PS 0931 and internal sewer pipelines and manholes of zones areas 1 amp 2 connected to main sewer pipeline or wastewater pumping station PS 0931 Main storm water drainage system within the boundary area of the perimeter fence Tender No SE 130 32 Document 2 III 3 The Contractor shall co operate co ordinate and not interfere his operations with all other parties or Contractor s executing works on sites or adjacent to his sites 4 The Contractor is required to provide more than one of required machineries on site in order to work concurrently in different locations to finish all the works of the contract requirements on time for the duration of the contra
76. 1L 6 months Magnesium Nitrate 1L 6 months Manganese Nitrate 1L 6 months Nickel Nitrate 1L 6 months Tender No SE 130 123 Document 2 III 1L 6 months 102 Sodium Nitrate 1L 6 months Zinc Nitrate 1L 6 months Electrode chemicals a Sulfideantioxidantbuffer A DK TREE 4 months 105 pH electrode chemicals EaR REDE UE DE 6 months pH buffer 10 01 1L 6 months Electrode filling sol 1L 6 months Electrode storage sol 475 ml 1 No 6 months Bismuth Sulphite Agar 500 g 1 Bottle 6 months Aluminum Standard Solution 100 mg l 1L 12 months ECR Reagent Powder 50 pillow packet 1packet 2 months Hexa Methlene Powder 50 pillow packet 1packet 2 months ECR Masking Reagent 1L 2 months Arsenic Standard Solution 1000 mg l 1L 12 months Lead Acetate 20 Solution 1L 4 months Pyridine 1L 4 months Silver Di ethyl Dithio Carbomate 1 kg 4 months Stannous Chloride 1L 4 months Zinc Mesh 1 Kg month Borover 3 Powder Pillow 50 pillow packet 1packet month Boron Standard 1000 mg l 1L 12 months Buffer Pillow Citrate Type 50 pillow packet 1packet month Di thiver Metal Reagent 50 pillow packet 1packet month Potassium Cyanide 100 g packet 1packet month Cadmium Standard Solution 1000 mg l 1L 12 months Chloride Standard Solution 1000 mg l 1L 12 months Ferric
77. 596 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 4 The extent of works shall include but not limited to demolish concrete structures break remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval Tender No SE 130 46 Document 2 III G Disconnect remove shift transport on site reinstall test and commission existing Telemetry system from Administration Building AB 1042 to MPW Quality Control Centre AB 1044 1 Disconnect the electricity supplies dismantle electrical equipments and instruments remove shifting all Telemetry systems from the Administration Building AB 1042 transport on site reinstall test and commission existing Telemetry system to MPW Quality Control Center AB 1044 prior to demolish the Administration Building AB 1042 within three 3 months starting from the Date of Enterprise The location of new Telemetry system partition room shall be approved by the Engineer All works materials and specifications shall be subject to the Engineer approval The Contractor shall be responsible for obtaining MPW approval to such design prior to the start the execution of the works 2 The Contract
78. 6 SU 0641 and other related works within two 2 years starting from the Date of Enterprise Renovation works of Mosque Building and other related works within one 1 month starting from the Date of Enterprise J Provision of new Management System and other related accessories within one 1 year starting from the Date of Enterprise Tender No SE 130 7 Document 2 III K Renovation works of Laboratory Partition Rooms furniture equipments and devices reagents and solutions miscellaneous glasses and plastic wares chemical supplies and other related accessories within one 1 year starting from the Date of Enterprise Section D Partial Operation and Maintenance works at Ardiya Sewage plant 1 Partial Operation works at Ardiya Sewage plant for the duration of one 1 year period after renovation works are completed Partial Maintenance works at Ardiya Sewage plant Maintenance works of existing and new mechanical and electrical equipments Instrumentation air conditioning units office equipments laboratory equipments street and outdoor lightings poles and networks furniture utilities services and other related works of zone area 1 facilities starting from the Date of Enterprise for the duration of the contract period Maintenance works of the new mechanical and electrical equipments instruments air conditioning units and street and outdoor lightings poles and networks of zone area 2 facilities for the durati
79. Acid Reagent Powder Pillow 50 pillow packet 1packet month Citric Acid Powder Pillow 50 pillow packet 1packet month Molybdate Reagent Powder Pillow 50 pillow packet 1packet month Silica Standard 1000 mg l 1L 12 months Sulfaver 4 reagent Powder Pillow 50 pillow packet 1packet month Sulphate Standard Solution 1L 12 months Sulfide I Reagent 100 ml 1packet month Sulfide II Reagent 100 ml 1packet month Formaline Stock Solution 4000 mg l 1L month Cyclohexane 1L month Zincover 5 Reagent Powder Pillow 50 pillow packet 1packet month Zinc Standard Solution 1000 mg l 1L 12 months Nitraver 3 Nitrite Reagent Powder Pillow 50 pillow packet 1 packet month Nitraver 5 Nitrite Reagent Powder Pillow 50 pillow packet 1 packet month Buffer Solution Hardness Type 1L month Phenol Reagent 1 Powder Pillow 50 pillow packet 1 packet month Phenol Reagent 2 Powder Pillow 50 pillow packet 1 packet month Copper Sulfate Powder Pillow 50 pillow packet 1 packet month Sulfide Inhibitor Reagent Powder Pillow 50 pillow 1 packet packet P month Potassium Per Sulfate Powder Pillow 50 pillow i odeket packet P month PhosVer 3 Phosphate Reagent pillows 50 pillow d packet 1 packet month Tender No SE 130 125 Document 2 III 169 Molybdovanadate Reagent 1L
80. Automatic Burettes 50 ml capacity with 1000 ml reservoir amber bottle 2 Nos 50 ml capacity with 1000 ml reservoir bottle clear glass 2 Nos 50 ml capacity with 2000 ml reservoir amber bottle 1 No 50 ml capacity with 2000 ml reservoir bottle clear glass 1 No 25 ml capacity with 2000 ml reservoir bottle clear glass 1 No Graduated Cylinders with spout glass BS 604 CHE E pamitan EMS 50 ml cap 6 Nos 100 ml cap 6 Nos 500 ml cap 12 Nos Membrane filter holder to hold 47 mm diameter filter membrane 4 Nos Flasks conical wide mouth Borosilicate glass Ka s 250micap 12Noes 500 ml cap 5 Nos 1000 ml cap 4 Nos 2000 ml cap 4 Nos 11 Funnels glass Pyrex E a 30 mm diameter 30 mm stem 5Nos Tender No SE 130 129 Document 2 III 50 mm diameter 50 mm stem 5 Nos 100 mm diameter 100 mm stem 5 Nos ECCE Pipettes graduated MMM 1 ml cap 12 Nos 2 ml cap 12 Nos 5 ml cap 12 Nos 20 ml cap 5 Nos 10 ml cap 5 Nos 25 ml cap 2 Nos Pipettes container 2 Packs Diluting screw glass caps 12 Packs Small plastic pumps 12 Packs Tissue for microscopic lances Roth 21x21 cm 12 Packs Wash bottles polyethylene Lu 250mlcap i 5Nos 500 ml cap 5 Nos 1 000 ml cap 5 Nos Flasks culture media Auto cleavable with screw caps graduated marking area a T 100mlcap 20Nos 250 ml cap 20 Nos Bottles for media 100 ml auto
81. Center within one 1 year starting from the date of enterprise Each partition lab room shall have separate extension telephone internal line 7 The Contractor shall renovate supply erect install test commission and maintenance new HVAC system unit not less than 25 tons with compressor for all laboratory partition rooms only and its related ducting system completely The HVAC package units shall have a cooling capacity not less than 1 5 times the existing systems The Contractor shall renovate supply erect install test commission and maintenance the ducting system according to the system capacity for the cooling and the ventilation requirements The new HVAC system unit for the laboratory partition rooms shall be isolated completely from new HVAC system units 2 Nos x 25 tons with two 2 Nos compressors for MPW Quality control center Module 10 AB 1044 and its related ducting system completely All works specifications and materials shall be subject to the Engineer approval 8 The Contractor shall study design supply install test commission and maintenance for the laboratory partition rooms power supply for new laboratory building from existing modified substation No 1 SU 0241 within one 1 year starting from the Date of Enterprise and shall include but not limited to utilities and services cables wires earthling rods MCC electrodes sensors etc 9 The Contractor shall design provide install test commission
82. DN 800 Sludge removed by under bottom draw off pipe DN 500 controlled by telescopic weir valve and drain valve in overflow chamber Scum removal facility consists of scum skimming board fixed to the bridge Return Sludge Lifting Station PS 0531 Concrete structure Two screw pumps helix diameter 1400 with supporting pipe shaft DN 711 helix length 10 460 Helix rotation speed 44 4 min Inclination 30 deg Two excess sludge pumps to thickeners at Module 08 Two gates and two check valves DN 100 One magnetic flow meter DN 125 One monorail with electrical driven hoist fixed to the ceiling Sewage Channels and Pipeline Mixed Liquor amp Effluent Channels Concrete structure Raw sewage gravity channel brand 1050 wide with one slide gate 150 x 800 Mixed liquor channel from bioreactor BR 0511 and BR 0412 to clarifiers ST 0501 ST 0503 Three slide gates 1050 x 800 to above clarifiers Effluent channels from clarifiers to effluent channel from Module 03 Electrical and Control Cables Power and control cables for process facilities and lighting network in Module 04 Module 06 Module 6 shall include but not limited to the following structures mechanical and electrical equipments Screw Lifting Station PS 0631 Three screw pumps Provided with bypass to sea Overhead crane First Stage Contact Tank CT 0611 Concrete structure Three tanks 20x13x5 2 m deep with total vol
83. Document 2 III Particular Specifications Tender No SE 130 1 Document 2 III Index Document 2 III Particular Specifications Page No Part A General Requirements 3 29 Part B Particular Requirements 30 162 Part C Appendixes Note Attach Drawings 163 187 Tender No SE 130 2 Document 2 III Document 2 III Part A General Requirements Tender No SE 130 3 Document 2 III Index Document 2 III Part A General Requirements Clause 1 Summary of works Clause 2 Definitions Clause 3 Government Bodies Clause 4 Study the sites by the Contractor Clause 5 Sites visit Clause 6 Contractor use of sites Clause 7 Electricity Clause 8 Water Clause 9 Language of correspondence and reports Clause 10 Clause 11 Clause 12 Clause 13 Clause 14 Clause 15 Clause 16 Clause 17 Clause 18 Clause 19 Clause 20 Clause 21 Clause 22 Clause 23 Clause 24 Clause 25 Clause 26 Clause 27 Clause 28 Clause 29 Clause 30 Clause 31 Clause 32 Clause 33 Clause 34 Site Meetings Co operation and Co ordination with other Contractors Reference Standards Project closeout procedures Management Submittals Manufacturers specifications Correspondence Site memos Request of inspections Reports etc Maintenance Manuals Quality Control amp Inspection Quality Assurance Equipment delivered in original packages Interference and protection of streets Reference Sta
84. E 130 80 Document 2 III 12 13 14 15 16 17 thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with steel trowel Primer for concrete shall be suitable for use with the waterproofing membrane All works materials and specifications shall be subject to the Engineer approval The Contractor shall renovate provide install maintenance and commission with the following new equipments and furniture and shall include but not limited to gas electric cooker with oven and gas cylinder to be filled continuously office desk L shape cabinet with triple drawers telephone instrument with multi memories connection and one extension line shall be provided from the new EPBAX swivel leather chair with arms single bed length 2 m x width 1 m x thickness at least 15 cm with base mattress pillow and blanket sofa bed three seats size 140 x 200 cm with cover closet double doors and shelves laundry washer dryer vacuum cleaner and carpeting all interior rooms with other fittings and connections coffee table sofa two seats interior lightings large insect killer lights twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure aluminum doors with lockers glazing windows with mesh screens frames louvers and vents carpet curtain and other required furniture as directed by the Engineer All works materials and specifications shall be subject to the Engineer approval Th
85. Iron Solution 1L month Mercuric Thiocyanate Solution 1L month DPD Free Chlorine Reagent Powder Pillow 50 pillow 1 packet packet 2 6 months Chlorine Standard Solution PENA month Color Standard 500 pt Co Unit 1L 12 months Acid Reagent Powder Pillow 50 pillow packet 1packet month Chromaver 3 Chromium Reagent 50 pillow packet 1packet month Chromium 1 Reagent 50 pillow packet 1packet month 134 Chromium 2 Reagent 50 pillow packet 1packet month Tender No SE 130 124 Document 2 III 135 Chromium Trivalent Standard Solution 1L 12 months 136 EDTA Reagent 50 pillow packet 1packet month Phthalate Phosphate Reagent 50 pillow packet 1 packet month PAN Indicator Solution 0 3 96 1L month Cobalt Standard Solution 1000 mg l 1L 12 months Cuver 1 Copper reagent Powder Pillow 50 pillow 1 Pillow packet month Copper Standard Solution 100 mg l 1L 12 months Free Copper Reagent Powder pillow 50 pillow Tooaokdi packet P month Hydro Sulphite Reagent Powder Pillow 50 pillow 1 backet packet P month Potassium Reagent Powder Pillow 50 pillow naciai packet P month Potassium II Reagent Powder Pillow 50 pillow mack packet P month Potassium III Reagent Powder Pillow 50 pillow Pf packet packet P month Potassium Standard Solution 100 mg l 1L 12 months
86. MSS 4 Video server capable of High Speed Recording and Playback of all web cameras 30fps per camera 5 Can be operated and viewed remotely over the Internet from designated Workstations and Laptops provided to the Engineer Engineer s Representative D The network setup must be based on a domain model with appropriate security access to users based on the requirements of the Engineer and Engineer s Representative Any change in any user s system security access must be approved by the Engineer and or Engineer s Representative Tender No SE 130 156 Document 2 III E Licensed software to edit view and print all Project Information Items and all Electronic Document Formats are to be provided for the workstations supplied to the Engineer and Engineer s Representative F A Broadband internet data link with redundancy with 24 hour and 7 days connectivity and a guaranteed uptime of 9996 must be provided exclusively for the Engineer and Engineer s Representative and other PIMSS designated users at the site offices of the Engineer and Engineer s representative and MPW and GC offices 1 00 GLOSSARY OF TERMS USED Broadband Electronic Document Formats eeeeeeene Project Information Items Period of Operation Stakeholders High data capacity two way link between an end user and access network suppliers capable of supporting voice data
87. No SE 130 176 Document 2 III Flare ignition panel Gas gate valves DN 40 amp DN 150 for pilot burners and main gas burner duty pressure 100 kPa Air Compressor Station AB 0722 Air compressor for supplying air to flare ignition system at WG 0761 Control box for compressor and power cabling Piping DN 25 from compressor to the ignition panel Sludge Dewatering Building DH 0708 Six belt filter presses thickened sludge intermediate tank Twelve positive displacement sludge pumps for feeding presses including valves Polymer storage Polymer dissolving mixing and dosing tanks and pumps including valves and posing pipes to presses Dried sludge shed DZ 0742 with dewatered sludge cake belt conveyor Washing water pumps Belt cleaning air compressor Electrical instrumentation panel Electrical installation Pipes DN 150 connecting thickened sludge pumps with feeding pumps Ventilation fans Service water plumbing Sludge Drying Kilns DK 0744 Two horizontal rotary ovens for drying dewatered sludge System of feeding and unloading belt conveyors Electrical driving units Electrical panel Sludge Drying Bed Complex DB 0711 Concrete structure Twelve beds 30 x 0 6 m each with filtration sand grain 0 6 mm on supporting gravel Under bed drainage DN 150 One drainage manhole at each bed Sludge feeding gate valve DN 150 at each bed Filtrate pipeline between above man
88. No 15 Return Sludge Pump No 1 Return Sludge Pump No 2 Return Sludge Pump No 3 Return Sludge Pump No 4 Return Sludge Pump No 5 Return Sludge Pump No 6 Return Sludge Pump No 7 Return Sludge Pump No 8 Scum Pump Surplus Sludge Pump Dewatering Pump No 1 Dewatering Pump No 2 Excess Sludge Pump No 1 Excess Sludge Pump No 2 Overhead Crane Module 3 No 1 Settling Tank Drive Unit No 2 Settling Tank Drive Unit No 3 Settling Tank Drive Unit No 4 Settling Tank Drive Unit No 5 Settling Tank Drive Unit No 6 Settling Tank Drive Unit Scum Skimming Pump No 1 Scum Skimming Pump No 2 Scum Skimming Pump No 3 Scum Skimming Pump No 4 Scum Skimming Pump No 5 Scum Skimming Pump No 6 Module 4 No 1 Settling Tank Drive Unit No 2 Settling Tank Drive Unit No 3 Settling Tank Drive Unit Aerator No 9 Aerator No 10 Aerator No 11 Aerator No 12 Aerator No 13 Aerator No 14 Aerator No 15 Aerator No 16 Sludge Recirculation Pump No 1 Sludge Recirculation Pump No 2 Sludge Recirculation Pump No 3 Sum Pump No 3 Scum Pump No 4 Tender No SE 130 182 Document 2 III Over Head Chain Block 1 Over Head Chain Block 2 Return Sludge Screw Pump No 1 Return Sludge Screw Pump No 2 Retu
89. TION The system shall be designed in compliance with relevant ISO guidelines in respect of system protocol It shall generally include and perform but not limited to the following A Project Information Management Software System PIMSS shall be Internet enabled based Related hardware shall be microprocessor based complete in all respects and capable of executing functions called for in respect of the various systems listed in this specification 1 Capable of ensuring that all Project Information Items see Glossary 1 06 is mediated through centrally organized stored tracked and is accessible online electronically 24 hours a day and 7 days a week with a 9996 uptime 2 Collaboration and document movement between Stakeholders made possible by configurable routing of all Project Information Items Once an agreed upon workflow for a particular document type like RFls is configured PIMSS shall automate the routing of these and other related construction documents and drawings 3 The exact workflows for each of the standard construction documents shall be decided in consultation with the Engineer and Engineer s Representative and approved workflows are to be available online Changes to approved document routing workflow can only be made on approval of Engineer and Engineer s Representative 4 Summary status of all project information items in any of the document routing workflows shall also be available online for example the nu
90. TTLE ETHYL ALCOHOL 2 5L SODIUM SULFITE Na SO 1 BOTTLE NITRIC ACID 2 BOTTLE SODIUM HYDROXIDE 1000 g SODIUM THIOSULFATE 500 g POTASSIUM SULFATE 1 BOTTLE Copper Il Sulfate 1 BOTTLE BARIUM CHLORIDE 500 g SULFURIC ACID STANDARD SOLUTION 19 2N 2 BOTTLES CAT ERIOCHROM BLACK 100g POTASSIUM IODIDE 500g CHLOREX 1 BOTTLE MAGNESIUM CHLORIDE HEXA HYDRATE 500 g SODIUM ETHANOATE 1 BOTTLE MAGNESIUM CHLORIDE 1 BOTTLE TRICHLORO FLUORO ETHANE 2 5L N HEXANE 1L ETHANOL 2 BOTTLE NUTRIENT AGAR 1 0 kg S S AGAR 1 0 kg M F C BROTH 1 0 kg WORT AGAR 1 0 kg BRAIN HEART INFUSION AGAR 1 0 kg ENDO AGAR 1 0 kg KF STREPTOCOCCUS AGAR 1 0 kg COVER SLIPS 2000 NOS SLIDES 2000 PCS MEMBRANE FILTER PAPER 600 PCS PETRIDISHES 600 PCS S P DISCARDING BAGS 25 PCS ALUMINIUM FOIL 1 PKT LENSE PAPER 1 PKT COTTON 12 ROLLS Tender No SE 130 140 Document 2 III Index Document 2 III Part C Particular Requirements Section D Partial Operation and Maintenance works at Ardiya Sewage plant Clause 1 Partial Operation works at Ardiya Sewage plant Clause 2 Partial Maintenance works at Ardiya Sewage plant A Maintenance works of mechanical and electrical equipments Instrumentation air conditioning units office equipments laboratory equipments exterior and outdoor lightings poles and networks furniture utilities services and other related works B Civil Maintenance works C Landscaping Plantation and Irrigation works Clause 1 Partial
91. accessories b Replace all defective instruments pressure gauges and pressure monitors in effluent transfer pumping station and the surge vessel system c The Contractor shall overhaul completely all the main pumps motors blowers ventilation fans compressors and all aux equipment of the New Pumping station including replacement of bearings seals damaged parts etc d The Contractor shall be responsible for rehabilitation and modification of the electrical power system telephone network and electrical lighting system but not limited to the following e Replace the entire lighting fixtures 4 x 20 W fluorescent luminaries with mirror optical reflectors and electronic power saving ballast in the building with new ones having a minimum illumination level of 500 Lux in all the areas e Dismantle remove and cart away existing indoor lightings fittings The Contractor shall provide install test commission and maintenance new indoors lighting system inside the new pumping station and outdoors lightings at least 500 W metal halide type fixtures 4 Nos with all related wires and electric installations outside the new pumping station e Supply install test commission and maintenance new twin bulb indoor weather proof emergency lighting units 20 Nos with all related wires inside the new pumping station The emergency light fixtures shall be holder type with aluminum reflector industrial type 12 Volt with 6 x 10 AH and batter
92. action of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 10 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth of excess areas as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 11 Dismantle existing extraneous materials pumps equipments woods debris metals pipes non usable parts etc completely accumulated on site within the boundary area of the fence perimeter remove cart away off the site transport and dispose all to dumping area outside the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval All non salvage ferrous metals surfaces shall be delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer Tender No SE 130 53 Document 2 III 12 The Contractor is obligated to execute all preliminary works and coordinate with MEW to disconnect remove abandonment and deliver transformers with all other related electrical accessories and connections off sites for all substations required to be
93. actor shall be fully responsible to protect his staff from escaped wild animals especially dogs The Contractor shall provide safety officer to be available in the plant for 24 hours for the duration of the contract period The extent of work shall include but not limited to interior and exterior telephone line and other related works 23 The extent of work shall include but not limited to all required civil mechanical electrical and instrumental works as approved by the Engineer F Renovation works of MPW Switchgear room of substation S S 1 SU 241 and other related works 1 The work assigned by this item shall be carried out with a full co ordination and supervision of MEW It is the Contractor responsibility to obtain MEW approval of his design criteria and installation ideas on the shop drawings prior to start of any Electrical Works and for the connection of the Electrical supply or part of it to the work of MPW if required 2 Upon completion of the Electrical Work the Contractor shall be responsible for obtaining MEW approval for the whole installation or modification or any part thereof including supervision of MEW representative on the final testing and energizing the panels and setting to work Tender No SE 130 82 Document 2 III 3 The Contractor shall acquaint himself with the latest issue of the rules and regulations of Electrical installation work of the Ministry of Electricity and water MEW in Kuwait It is
94. age inlet channel with one slide gate 1050x800 Fine pore membrane duplex air diffusers 328 units formed in four grids Process air piping with four butterfly valves DN 250 Air from blowers located in machine house Return sludge supplied by gravity pipeline DN 600 from two screw pumps located in PS 0531 pumps common for BR 0512 Guard rails around the basin Bioreactor BR 0512 Concrete structure One basin with two separate chambers Each chamber size 42x14x8 m Mixed liquor depth 7 2 m Effective volume of mixed liquor in basin 8180 m Six surface turbine aerators with draft tube 55 kW each Return sludge supplied by open channel with weir gates One by pass slide gate Six submersible pumps air pumping 80 Nm h Two automatic weirs electrically operated in each chamber One oxygen meter in each chamber Clarifiers ST 0521 ST 0523 Three Units Concrete structure Circular tank with circular bottom Internal diameter 37 5 m Side wall sewage depth 2 55 m Sewage depth at the hopper edge 5 33 m Hopper upper diameter 4 5 m Tender No SE 130 172 Document 2 III hopper bottom DN 0 7 m hopper depth 3 6 m Sewage surface 1100 m V notch length 3 15 m Equipped with rotating bridge with sludge bottom scraper Bridge is driven by two motors and gearbox unit Mixed liquor supplied from distribution chambers controlled by slide gate 1050 x 800 and by intake pipe
95. al halide type fixtures with all related wires and electric installations outside the new guard house 10 The Contractor shall renovate provide paint test commission and maintenance interior and exterior walls and roof with emulsion paint Painting shall be carefully executed with clean brushes and in the best manner and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendations Painting of exterior walls shall not be carried out in wet dusty or foggy weather Painting interior walls and roofs shall not proceed in dusty conditions The extent of works shall include but not limited to scraping and sand blasting to remove dust out of exterior walls prior to painting works All works materials and specifications shall be subject to the Engineer approval 11 The Contractor shall renovate provide install commission and maintenance new water proofing roof insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum Tender No S
96. all include but not limited to debris metals pipes non usable parts etc completely to dumping area outside the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to provide install and operate pumps plugs conduits dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations The extent of works shall include but not limited to provide erect and maintain all temporary staging scaffolding rigging shuttering to carry out the works in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services and carried out with all necessary precaution needed Tender No SE 130 66 Document 2 III Index Document 2 III Part B Particular Requirements Section C Renovation works at Ardiya Sewage plant Clause 1 Renovation works at Ardiya Sewage plant A Renovation works of new double layers asphalt roadways and storm water drainage system of zones areas 1 amp 2 and other related works Renovation works of street lightings poles outdoor lightings poles of zones areas 1 amp 2 and other related works Renovation works of chain link boundary fence within the perimeter 800 m 440 m 800 m 440 m with Barbe
97. all be subject to the Engineer approval Oil content analyzer for grease and oil experiment BUCHI Scrubber for Organic Nitrogen experiment 4 scrubbers c Washing face shower as safety precaution including all related fittings and other accessories 2 Nos d Eye protection glasses 12 glasses e Class A of burettes and pipettes and all required glass wares each 1 Dozen Analytical Balance must come with calibration unit and especial table for accurate weight g Fuel Gas Distribution System h Laboratory Compressed Air System i J k Oo m Process Air and Gas Piping Power Roof Ventilation Laboratory Vacuum System 3 The Contractor shall be responsible to arrange and conduct complete professional training programs of three 3 months to train MPW staff Microbiologist 5 persons and Chemist 5 persons concerning operation and maintenance of new laboratory equipments and devices in accordance to manufacturers and shall include but limited to tests experiments safety precaution first aid reports sampling and procedures of all lab experiments and analysis and use of laboratory devices and equipments as approved by the Engineer a The extent of works shall include but not limited to provide Chemist and Microbiologist to monitor and supervise on MPW staff either microbiologist or chemists for the duration of the contract period MPW staff will run the lab experiments test after training course is complet
98. all include but limited to the preparation of concrete surfaces repairs shall include but not limited to clean and dry from all contamination surface laitance and other loose materials according to approved manufacture requirements either grit or water blasting technique to be dumped out of the station building In addition the old contaminated sealant of existing joints shall be thoroughly cleaned out from all traces of previous sealant and primer using a suitable mechanical method such as grit blasting water blasting or grinding 13 The Contractor shall disconnect dismantle remove and cart away existing interior lightings off the site The Contractor shall provide install test commission and maintenance new interior lightings fixtures accessories and switching devices power outlets indoor and outdoor lighting telephone extension points etc 14 The Contractor shall provide install test commission and maintenance new external lighting fitting 4 Nos 500 Watt each halogen type fixtures with all related wires and accessories outside substation 15 The Contractor shall provide install test commission and maintenance new emergency lights fixtures not less than 4 Nos allowing enough illuminators for the movement of operators during the power failure The emergency light fixtures shall be twin bulb holder type with aluminum reflector weather proof industrial type 12 Volt with inbuilt battery 6 x 10 AH and battery charger shall
99. and Modification works of Effluent Transfer Pumping Station PS 0633 and other related works The Contractor shall be responsible to carry out the modification works required for the existing effluent water transfer pumping station PS 0633 within two 2 years starting from the Date of Enterprise to reduce the number of the existing pumps to 3 Nos only and allow installation of additional equipment as a combined New Pumping Station includes the following e Effluent water transfer pumps 3 Nos e New Rabya pumps 3 Nos New landscaping irrigation Pumps 2 Nos New Dewatering Pumps 2 Nos New Electrical supply Panel and control room equipment Before the modification works above to be conducted The Contractor shall disconnect dismantle remove abandonment and cart away to a tippers off site effluent transfer pumps 3 Nos with discharge pipe and all related accessories completely to make an adequate area for the installation of the new above mentioned equipment The Remaining effluent Pumps 3 Nos with discharge pipe and all related accessories shall be completely overhauled within the entire renovation work of all mechanical and electrical equipment of the station as detailed later The extent of works shall include but not limited to study and investigate thoroughly surge vessels VS 0661 in surge protection system and the Contractor shall be responsible to carry out the modification and renovation
100. and for electricity loading required to execute the works without any interruption for the works 11 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of the works Demolish Screw Conveyors Lifting Stations S20 and S21 completely within two 2 years starting from the Date of Enterprise disconnect the electricity supplies completely dismantle mechanical and electrical equipments and instruments completely break concrete structures completely cut pipes remove abandonment all types of the structures facilities underground services and utilities cables wires earthling rods electrodes MCC sensors etc within the boundary area of the fence perimeter completely except the fence cart away to a tippers off the site Screw Conveyors Lifting Stations S20 and S21 in Appendix 2 and attached drawings are considered as guidance only to the Contractor and do not cover all require works and does not show all the actual equipment and structures on sites Therefore it is obligated that the Contractor to visit all the sites during the period of tendering to determine by himself the actual conditions of the site and all the components of works The Contractor shall be deemed to be fully conversant with the prevailing conditions above ground and
101. and soap holders color ceramic tiles for the ground floor and interior walls exhaust fans large insect killer lights with twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure interior lightings fixtures ceramic tiles and walls power outlets electric installations and other accessories and services as approved by the Engineer The color of ceramic tiles and walls type of materials shall be subject to the Engineer Approval All works and materials shall be subject to the Engineer approval 10 The Contractor shall dismantle remove abandonment and cart away off site main entrance door inner doors and windows completely of toilet bath room The extent of works shall include but not limited to provide install test commission and maintenance new aluminum doors with hang louver and lockers for main entrance door and inner toilets doors 2 Nos double glazed rolling windows with mesh screen plates installation of neon lightings chrome fittings ceramic tiles for walls and ground floor angle valves hose bibs traps and drainage fixtures to be connected to the nearest sewerage manhole UPVC pipes ferrous accessories used for the installation of sanitary fixtures shall be anti rust given at the factory chrome plated brass escutcheon plates on chrome fittings fixed on the wall hand dryer secure mirrors to walls in concealed with plywood packing holders of toilet papers and rolling tissues large exhaust fans water
102. and vacuum pressure releasing valve on the gas holder One gas inlet gate valve and drain valve in the underground manhole near the tank One gas flow meter on the inlet pipe to the tank Tank dome level control sensor and indicators Gas flow control valve DN 150 to waste gas burner Waste Gas Burner WG 0862 Tower stack 4 m high made of bricks 10 nozzles gas burner with temperature sensors Control valve DN 150 Control panel for automatic ignition of gas Sludge Drying Beds Complex DB 0812 Concrete structure Eleven beds 30 x 12 x 0 6 m each with filtration sand top layer grain 0 6 mm on layers of supporting gravel Under beds drainage DN 150 One drainage manhole at each bed Sludge feeding butterfly valve DN 150 at each bed Filtrate pipeline between above manholes connected to turbid water PS 0731 Pipeline DN 200 supplying 11 drying beds with sludge by digested sludge pumps Tender No SE 130 179 Document 2 III Sludge Drying Beds Complex DB 0813 Concrete structure Nine beds same like in complex DB 0812 Manhole pipelines valves etc similar to one in complex DB 0813 Electrical Substation SU 0841 Transformers for Module 08 MCC for Module 08 Module 09 Module 9 shall include but not limited to the following structures mechanical and electrical equipments Hydrogen Sulfide Monitoring System MM 0901 Fifteen H2S sensors located around t
103. anitary fixtures and fittings ventilation system toilets fixtures ceiling roof roof insulation drainage system and other related works of zones areas 1 amp 2 11 The extent of works shall include but not limited to painting of all buildings of zones areas 1 amp 2 including parking areas to be carefully executed with clean Tender No SE 130 149 Document 2 III brushes and in the best manner and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendations Painting of exterior work shall not be carried out in wet dusty or foggy weather and interior work shall not proceed in dusty conditions The paint finish to internal walls shall be emulsion paint The Contractor shall paint buildings inside and if applicable outside once in a year during the Contract period and repaint all equipment and piping once during the Contract All woodwork and gypsum board assemblies shall be prepared to a fine clean finish by scraping or sanding all made dust free immediately before painting and coating Plaster shall be clean dry and free from loose to materials All fixed ironmonger except hinges shall be removed before painting fixed on completion Holes and cracks shall be cut back and solidly filled allowed to dry and rubbed down smooth 12 The extent of work shall include but not limited to repair or if requi
104. any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The Contractor shall renovate supply erect install test commission and maintenance new water proofing roof insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum Tender No SE 130 75 Document 2 III thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with steel trowel Primer for concrete shall be suitable for use with the waterproofing membrane All works specifications and materials shall be subject to the Engineer approval c The Contractor shall disconnect remove abandonment of the existing electrical power supply system installations and connections cart away to a tippers off the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The Contractor shall renovate supply erect install test commission an
105. ap 12 Nos 500 ml cap 5 Nos 1000 ml cap 12 Nos Bottles amber glass Borosilicate reagent bottle with Polystop stopper 250 ml cap 5 Nos 500 ml cap 5 Nos 1000 ml cap 5 Nos Bottles dispensing with top dispensers mounted on bottle with screw necks amber glass Range of dispenser up to 10 ml with 500 ml cap Bottle 5 Nos Range of dispenser up to 50 ml with 1000 ml cap Bottle 3 Nos Bottles for BOD s 300 ml 20 Nos Bottles dropping with polypropylene bulb 30 ml cap 5 Nos Bottle carrier to carry 300 ml bottles for 8 bottles 5 Nos Buckets plastic 10 litter capacity 5 Nos Clamps three prong 5 Nos 5 Nos Condenser coil type 85 Crucible Tender No SE 130 133 Document 2 III a Glass can withstand up to 1200 deg C 20 ml cap 12 Nos Porcelain 12 ml cap 12 Nos Cylinder with spout Polypropylene 50 ml cap 5 Nos 100 ml Cap 5 Nos 250 ml Cap 5 Nos Evaporating dishes 150 MI capacity pyrex 12 Nos Evaporating dishes 320 ml capacity 5 Nos Filter flask with side arm 500 ml cap 5 Nos 1000 ml cap 12 Nos 2000 ml cap 5 Nos Flasks conical with ground neck neck size 24 29 250 ml cap 12 Nos Flasks volumetric class A glass 25 ml cap Trapezoidal shape 12 Nos 50 ml cap Trapezoidal shape 12 Nos 100 ml cap 12 Nos 250 ml cap 12 Nos 500 ml cap 5 Nos
106. ass double doors curtains interior plant and telephone instrument with multi memories A C split unit 3 5 Tons with compressor and all related civil mechanical and electrical works All specifications of new furniture and equipment subject to the Engineer approval 7 The extent of works shall include but not limited to all required civil works for the concrete reinforcement for the foundation base of the pumps 8 The extent of work shall include painting all exposed piping valves gates joints penstock surge vessels tanks and other metal surfaces shall be painted but not limited to the following e All other ferrous metal piping iron exposed to view metal surfaces shall be thoroughly cleaned to remove grease and dirt and wire brushed and scraped to remove scale and rust and coating should be according to international standard e All exposed galvanized piping and fitting shall be cleaned thoroughly by swabbing with thinner or solvents and any rust removed as for ferrous metal above Two casts of primer which provide a bond for the paint shall then be brushed on Undercoating and finishing shall be as above ferrous metal e Allcastiron pipe and fittings exposed to view shall be thoroughly cleaned of all dirt rust and grease given a coast of a composition of coal tar or black paint finish over factory applied coat H Renovation works of MPW Switchgear room of substation S S 6 SU 0641 and other related works 1 The work a
107. ate interactive graphical displays and reports that can be saved and shared 17 The PIMS should make available graphics in web based format via an integral web server and based on Microsoft Share Point Portal server MPW users should be able to create and save their personalized graphic web pages without the requirement of programming All historical and real time information shall be accessible 18 The data collection sampling rate shall be configurable on point to point or group of point s basis allowing scan rates as fast as at least 1 second interval 19 The PIMS Vendor shall provide a detailed PIMS architecture drawing including all networking and PIMS hardware 20 The PIMS technology must have accumulated minimum 5 years online experience in Waste Water Treatment Plants WWTP and Irrigation Systems Environment Field proven experience references shall support the claim of PIMS technology supplier The Vendor must present a reference list with minimum 5 clients with core business in WWTP and Irrigation 21 The PIMS Enterprise server should have the flexibility to connect to more data sources in the future and must be upgradeable to monitor more than 1 000 000 tags on a single server PIMS Vendor must represent references with 1 000 000 tags in one server in minimum 10 sites 22 The PIMS Vendor shall provide all necessary system and application software The acceptable operating system software is latest industry standard latest
108. ate mobile diesel generators to be available on demand for electricity loading required execute the works without any interruption for the works 16 In the case the Contractor may find unforeseen old structures equipments or underground pipelines need to be demolished he should take the action to include such equipment in the demolishing works and shall be allowed in the total sum of the contract 17 The Contractor shall be responsible to clean and remove sewage sludge debris and other contaminants cart away off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 18 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of the works Demolish all types of structures facilities disconnect the electricity supplies dismantle mechanical and electrical equipments cut pipes remove abandonment cart away to a tippers off the site earth filling excess areas with new imported borrow soil landscaping grading compacting 9596 MDD soil and to be reinstated and restored the site to a condition match its surroundings for all types of the structures facili
109. ate mobile diesel generators to be available on demand for electricity loading required to execute the works without any interruption for the works 9 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of the works The Contractor is obligated to grout filling unlimited depths and full volumes of the underground gravity pipelines completely within three 3 years starting from the Date of Enterprise from the inlets of gravity pipelines ends to the outlets of gravity pipelines ends until the volumes of the underground gravity pipelines are completely full with mix flowable fill materials with no voids remain unfilled The extent of works shall include but not limited to demolish dismantle dewater break remove abandonment cart away to a tippers off the site unlimited depths of manholes completely earth filling excess areas with new imported borrow soil as approved by the EPA and the Engineer landscaping grading soil compacting 9596 MDD and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall be deemed to be fully conversant with the prevailing conditions above ground and below ground and the nature and complexity of the work to be under
110. ate of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 4 The extent of works shall include but not limited to cut remove replant and commission of the existing grown trees within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m into different locations as approved by the Engineer and shall include but not limited to watering gardening mowing and trimming grass pruning trees paving cultivating seeding etc 5 The extent of works shall include but not limited to preventive and maintenance of new irrigation network system for the duration of one 1 year period after renovation works are completed and shall include repair or if required replace all required defective spare parts and pumps but not limited to PVC main irrigation pressure pipelines and fitting for water distribution polyphone tubes and micro tubes nozzles heads sub lateral irrigation lines drip emitters with single and multi outlets rotary impact sprinklers gate valves quick couplers and vacuum breakers reducers T connection pipe union connection elbow solenoid valve screen filter valve boxes pop up spray sprinklers fertilizer injector station controllers Y strainers and other related spare parts and materials that kept the system in good condition Tender No SE 130 151 Document 2 III PART 1 SPECIAL SYSTEMS GENERAL 1 01 WORK INCLUDED G TUM O
111. ation Rehabilitation Modification and Maintenance works including all earthworks the provision and installation of metal beam guardrails barriers adequate drainage lighting traffic signals signs barricades and other traffic control devices on proposals submitted by the Contractor and approved by the Engineer or as directed by the Engineer Where required temporary protection of existing services in accordance with the requirements of the concerned Service Authority or Company shall form part of the Detours Works Restoration of the Detour sites to their original condition or such other condition as directed or approved by the Engineer will be required on completion of use of the Detours Flagmen Persons acting as flagmen shall be identified with appropriate and distinctive apparel approved by the Engineer and shall be equipped with a STOP GO sign conforming to these Specifications Reflective apparel is required for flagging during darkness The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 23 Reference Standards 1 2 3 4 General Specifications for Kuwait Motorway Expressway System State of Kuwait Ministry of Public Works Roads Administrations Kuwait Traffic Signs Manual Institute of Transportation Engineers The Con
112. ation and maintenance manuals of all laboratory equipments and devices 4 The Contractor shall design provide erect install furnish commission and maintenance the following new laboratory partition rooms furniture equipments and devices reagents and solutions miscellaneous glasses and plastic wares chemical supplies and other related accessories within one 1 year starting from the Date of Enterprise and shall include but not limited to all related mechanical electrical instrumental and civil works as approved by the Engineer 5 The laboratory partition rooms are located in MPW Quality control center AB 1044 6 The cost of Management System shall be born by the Contractor and shall be allowed to include in the total price of this contract Tender No SE 130 111 Document 2 III b Description of the works 1 Laboratory Partition Rooms Furniture and other accessories 1 The Contractor shall dismantle mechanical and electrical equipments and instruments and furniture of all laboratory partitions rooms completely of the MPW Quality control center remove abandonment cart away to a tippers off the site and transport to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to furniture devices plumbing system pipes plumping specialties sanitary sewer s
113. atment of polluted soil prior to backfill on site 9 The extent of works shall include but not limited to demolish unlimited distances lengths and unlimited depths of all existing types and sizes diameters of underground pressure pipelines Dimensions of pipelines 7 x DN 1000 2 x DN 700 2 x DN 300 1 x DN 150 of the inlets chambers IS 0151 IS 0152 completely within the boundary area of the perimeter fence dewater cut pipes remove abandonment and cart away to a tippers off the site The extent of works shall include but not limited to provide install and commission suitable plug or cap pipelines ends surfaces of pressure pipelines completely within the boundary area of the perimeter fence either by filling pipelines ends surfaces with dry pack grout mixture or install manufactured cap to form water tight seal However the Contractor shall require to sharp edges after cutting pipes and smoothen by means of grinding with suitable disc All the works shall be approved by the Engineer and EPA 10 The Contractor shall be deemed to have carried out his own investigations to ascertain himself the nature of the soil conditions and the groundwater level The Contractor shall provide install and operate pumps plugs conduits Tender No SE 130 42 Document 2 III dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations 11 The extent of works shall inclu
114. bags grits gravels stones precast concrete blocks polluted soil corroded pipes tanks concrete blocks rubbers woods tires chains oil grease dry sludge wet sludge wastewater sand and gravels of drying beds sand and gravels of sand filters dry trees plastics non usable office equipments non usable office and laboratory furniture not valid chemicals and solutions oil and grease barrels sand and gravels of drying beds sand Tender No SE 130 43 Document 2 III and gravels of sand filters fence pipes screens fence barbed wires shelters and other non usable parts and other contaminants accumulated on site 2 The extent of works shall include but not limited to clean paint re usable extraneous mechanical and electrical equipments instruments and devices tools pumps valves hoses etc accumulated on site within the boundary area of the perimeter fence cart away to a tippers off the site and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them 3 The extent of work shall include but not limited to clean remove all extraneous non usable ferrous metals equipments pumps motors etc accumulated on site within the boundary area of the perimeter fence cart away to a tippers off the site and delivered to MPW stores without packing but shall be covered with large plastic shee
115. be thorn make or equivalent The capacity of Bulbs shall be 2 x 35 W The layout type and the numbers of fixtures shall be approved by the Engineer 16 The Contractor shall paint internal wall and roof with emulsion paint for substation Painting shall be carefully executed with clean brushes and in the best manner Tender No SE 130 103 Document 2 III and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendations Painting of interior walls shall not be carried out in wet dusty or foggy weather and interior walls and roofs shall not proceed in dusty conditions The extent of work shall include maintenance and painting metal door for each substation and provide new lockers 17 The Contractor shall provide install test commission and maintenance new water proofing roof insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with stee
116. bioreactor BR 0411 Raw sewage gravity underground pipeline DN 1000 from Tender No SE 130 171 Document 2 III Channels distribution chamber DC 0151 to open channel leading to bioreactor 0412 One slide gate 1050x800 electrically operated Mixed liquor channels from bioreactor BR 0411 and BR 0412 to clarifiers ST 401 ST 0403 Three slide gates 1050 x 800 to above clarifiers Effluent from Module 02 Two slide gates 1050x 800 electrically operated Flow meter in effluent channel Electrical Panel BR 0401 Steel cabinet panel for six submersible pumps in bioreactor BR 0412 Electrical Substation SU 0441 Concrete structure Control room with mimic panel for Modules 04 MCC S for process facilities of Modules 04 amp 05 Transformers for Modules 04 amp 05 Roof A C unit Lighting Network Mast lamps near bioreactors and clarifiers of Module 04 Electrical and Control Cables Power and control cables for process facilities and lighting network in Module 04 Module 05 Module 5 shall include but not limited to the following structures mechanical and electrical equipments Raw sewage e Concrete channel 1 05 wide 170m long one slide gate supplying channel 1050 x 800 electrically operated Leads from BR 0511 amp BR 0512 Bioreactor BR 051 1 Concrete structure One basin 48x21x4 6 m mixed liquor depth 3 8 m Effective volume of mixed liquor 3740 m Sew
117. but not limited to provide mobile containers to remove debris garbage cutting grass dust pruning trees and disposed off site to approved areas by the Municipality 8 The extent of works shall include maintenance of all buildings MPW Quality Control Center centre substations SU 0241 and SU 0641 mosque guard house new pumping station civil structures but not limited to repair of walls roofs slabs and other concrete surfaces treatment and repair of cracks and joints leakages cure of damaged concrete surfaces making good irregularities and defects including expansion and other joints corrective measures to ensure water tightness replacing defective joints and water stops 9 The extent of works shall include maintenance of all buildings MPW Quality Control Center centre laboratory partition rooms mosque guard house new pumping station waste drainage sewer system plumbing system kitchen and toilets fixture but not limited to sanitary fittings joints and other related connections valves pipes sanitary pipelines and manholes 10 The extent of works shall include but not limited to repair or if required replace wood doors lockers stoppers handles louvers frames aluminum doors single and double roller shutter doors glazed aluminum windows with mesh screens all types of floor ceramic tiles all exposed piping and other surfaces exterior brick exhaust fans boilers gas ovens curtains toilets and kitchen plumbing s
118. cleavable 20 Nos Burette stand 33x 18 cm 5 Nos Filter funnel s steel diff size 5 Nos Autoclave tape sterile 1 9 cm x 55 4 m Roll 5 Rolls Disposable Auto cleavable Bio hazard bags 14 x 19 size 100 packet 24 packets Membrane filters 47mm diameter 0 45 micron lec pore size WHATMAN Cat No 7184004 100 POM packet Petridishes disposable 100 mm sterile 100 packet 12 packet Petridishes disposable 50 mm sterile 100 packet 12 packets Gas Cylinders 2 Nos Forceps stainless steel 10 mm 5 Nos Gloves Latex S M L size 100 packet 12 packets Safety goggles 12 packets Lamp National EFT15E67C 2V 12 packets Tender No SE 130 130 Document 2 III Permanent markers black red blue 6 Nos Pipette filler bulbs 12 packets Natural gas flame burner 16 cm height 6 Nos sampling bottles polyethylene auto cleavable 20 Nos Spatula spoon flat 6 Nos Aluminum foil HEAVY DUTY 12 Nos Filter papers WHATMAN QUALITATIVE No 1 47 mm 100 packet 12 packets 90 mm 100 packet 12 packets Heavy duty wall mounted paper towel a 22 5 cm wide 50 packet Tissue paper laboratory wipers 14 x 19 50 Rolls KIMWIPES BRAND EX L 140 box 50 Boxes Liquid soaps 10 Dozen Dettol soaps 10 Dozen Roll Holder 1 Dozen Cleaning cloth M ME 7J6 xblom 2 Dozens 56 x 61 2 Dozens 51x 51 2 Dozens 54 x 46 2 Dozen
119. ct period and shall not have the right to claim for compensation in time or cost 5 The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities 6 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations MPW and other governmental authorities to execute demolishing works of all types of structures facilities gravity and pressure pipelines manholes etc within one 1 month from the Date of Enterprise 7 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities to remove and transport pollutants in a safety manner shall include but not limited to polluted soil equipments metals demolished structures wood debris pipes asbestos chemicals oil grease wastewater groundwater heavy metals etc within one 1 month starting from the Date of Enterprise 8 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regula
120. d for his employees and those of his Sub contractors and for the Ministry and Engineers staff on the sites Where required the Contractor shall furnish drinking water in suitable containers and provide dispensing units and cups The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 9 Language of correspondence and reports All correspondence on matter arising out of the contract shall be addressed by the Contractor to the Engineer and not directly to the Employer The Arabic language shall be considered the official and deserved language for all the contract documents except for those which were prepared and given in the contract in English language not limited to General Specifications Particular Specifications Bills of Quantities and attachments Appendixes etc for which the deserved and official language shall be English language All reports minutes of meetings and other correspondence shall be in both Arabic and English languages In a case of any contradiction between the Arabic and English versions the Arabic language shall supersede Clause 10 Site Meetings A To be held once each month to review both work progress and the Contractors 90 days look ahead schedule Progress and schedule reviews shall verify a Actual start and finish
121. d Wires completely height 2 m and other related works Renovation works of MPW Quality control center AB 1044 and other related works Renovation works of the main Guard House AB 1041 and other related works Renovation works of MPW Switchgear room of substation S S 1 SU 0241 and other related works Renovation Rehabilitation and Modification of Effluent Transfer Pumping Station PS 0633 and other related works Renovation works of MPW Switchgear room of substation S S 6 SU 0641 and other related works Renovation works of Mosque Building and other related works Provision of new Management System and other related accessories Renovation works of Laboratory partitions rooms furniture equipments and devices reagents and solutions miscellaneous glasses and plastic wares chemical supplies and other related accessories Tender No SE 130 67 Document 2 III Clause 1 Renovation works at Ardiya Sewage plant The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work i
122. d connections f Manholes transition chambers TC and underground pipelines g Discharge pipelines and manhole outside the boundary area of the fence 2 Clean paint re usable parts shall include but not limited to all existing mechanical and electrical equipments instruments pumps valves hoses etc within the boundary area of the perimeter fence then cart away off the sites and delivered to MPW stores off site in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them 3 The extent of works shall include but not limited to demolish concrete structures asphalt roadways concrete roadways foot pathways interlock tiles concrete tiles curbstones and sites paving areas break remove abandonment cart away to a tippers off the sites transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 4 The Contractor shall be deemed to have carried out his own investigations to ascertain himself the nature of the soil conditions and the groundwater level The Contractor shall provide install and operate pumps plugs conduits dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations
123. d maintenance new combined electrical power supply system installations and connections for the renovation of MPW Quality control Center The power supply and telephone network of the MPW Quality Control Center shall be taken from substation No 1 SUO241 The panel shall be housed in a separate room which shall house the telephone exchange fire alarm control panel and electrical power supply panel All works specifications and materials shall be subject to the Engineer approval d The Contractor shall provide install test commission operation and maintenance of a new motor control center enunciator panel control relay panel motor starters distribution boards other auxiliary equipment electrical power cables instrumentation control cables earthling and bonding batteries battery charger light fittings supporting brackets and all other associated necessary components connection to existing substation No 1 SUO241 for the new loads The extent of works shall include but not limited to 1 All equipment shall be connected to the new Motor Control Center with new cables and configured on the control board 2 The Contractor shall provide install test commission operation and maintenance of a new motor control center enunciator panel control relay panel motor starters distribution boards and other auxiliary equipment The Contractor shall be responsible to house the new MCC in a separate room erected in the building The ne
124. d other materials shall be subject to the Engineer approval The Contractor shall provide all other required consumables for ablution detergents soaps paper rolling tissues toilet tissues big roll tissue holder etc per month for the duration of the contract period as directed by the Engineer The color of ceramic tiles and type of materials shall be subject to the Engineer approval 14 The Contractor shall dismantle remove concrete tiles around the mosque building area and cart away off the site The extent of works shall include but not limited to renovate modify provide erect install commission and maintenance new color painting precast curbstones site paving concrete tiles interlocking of different colors bricks street furniture foot pathways for pedestrians and colour decorative tiles 15 The extent of works shall include but not limited to provide install commission and maintenance new irrigation system landscaping planting ground covers grown vines grown shrubs and grown color yearly season flowers around the mosque building area as approved by the Engineer J Provision of new Management System and other related accessories 1 The Contractor shall design provide install test commission operate and maintenance all elements of the office management system the works shall be started within one 1 year starting from the Date of Enterprise and commissioned before the end of the first year of the contract duration
125. d the like at no additional cost Products are listed in specifications for the purpose of defining the requirements and shall be construed to mean or approved equal Alternatives submitted for approval shall be identical in function and performance SUBMITTALS Three 3 copies of the following shall be submitted under provisions of the General Conditions of Contract These being a critical part of the job shall be prepared in a professional manner and submitted in one or more file s book s each A4 size open flat files or hardbound volumes if single volume will limit it s use A Project Documentation Stage Preliminary to be submitted within ONE 1 month from the date of enterprise Job specific volume containing the following in separate sections with indexes Sections not submitted shall be marked with the date by which that section will be supplied One set of these documents shall be maintained at site at all times 1 Functional Description Overall system tasks and functioning Separate sheet for each PIMSS 2 Similarly overview of the Project Website and listing of the different areas on a site map and their functions 3 Web cameras specifications and descriptions of all salient features associated with the systems and how still photo and video data is interfaced with the PIMSS and or the website in an easy to understand format 4 Drawings Supplied in plastic drawing covers and clipped into the volume co
126. d treatment of polluted soil on site backfill excavated area after treatment of polluted soil Tender No SE 130 48 Document 2 III landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 3 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth of excess foundation areas as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA I Demolish Asphalt and Concrete Roadways Internal roadways and Pavements break remove abandonment cart away to a tippers off the Demolish asphalt and concrete roadways internal roadways and pavements break remove abandonment within the perimeter chain link fence 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer app
127. dates for activities completed during the updated period Tender No SE 130 10 Document 2 III b Remaining durations and percentage of completion for all activities not completed c Contractors proposed measures to recover lost time and place the project back on schedule by increasing manpower materials equipment resources and working extended hours additional shifts etc B Meetings shall be attended by Engineer and or the Engineers Representative s the Contractor and his Project Manager and other staff as necessary Subcontractors may attend when involved in the matters to be discussed or resolved but only when requested by the Ministry or the Engineer In addition to the attendees named herewith the meeting shall be attended by the representatives of regulatory agencies having jurisdiction over the Project if required and such other persons the Ministry may designate C The time and location of the progress meetings shall be as directed by the Engineer s Representative D Submit the information itemized below to the Engineer at least 3 working days prior to each progress meeting A list of completed activities A list of current activities with an estimate of time required for completion A list of activities planned to start in the next period Other information required by the Engineer s Representative AON E Additional meetings as required by the Contractor shall be submitted to the Engineer s R
128. de install and operate pumps plugs conduits dewatering Tender No SE 130 70 Document 2 III system and all other required machineries and equipments with all hoses connections mechanical and electrical installations 11 The Contractor shall provide erect and maintain all temporary staging scaffolding rigging shuttering over pumping and flow diversions to carry out the works close to existing structures in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services and carried out with all necessary precaution needed 12 All works materials and specifications shall be subject to the Engineer approval The Contractor shall be responsible for obtaining MPW approval to such design prior to the start the execution of the works B Renovation works of street lightings poles outdoor lightings poles of zones areas 1 amp 2 and other related works 1 The Contractor shall design renovate provide install erect test commission operation and maintenance new street lightings poles as minimum 15 Nos to be mounted along new main double layers asphalt roadways of zone area 1 and parking areas and shall include but not limited to main front entrance gate guard house mosque MPW Quality Control Center substations No 1 SU 0241 and wastewater pumping station PS 0931 within two 2 years starting from the Date of Enterprise in accordance with MEW standard specificatio
129. de but not limited to clean flush remove cart away to a tippers off the site accumulated wastewater sludge sand gravels debris groundwater polluted soil and other contaminants shall include but not limited to manholes hatch boxes transition chambers TC underground pipelines wells pits channels distribution chambers and other underground chambers structures The Contractor shall be responsible to provide jet flushers tankers if necessary and provide mud suckers tankers to remove wet wastewater and discharge to any areas as approved by the Engineer and EPA The Contractor shall not be allowed to divert wastewater flow to any emergency by pass gulf sea lines The quantities of machineries trips are not limited to be available on demand and shall include but not limited to tractors tippers Lorries mud suckers tankers flushers cranes tools equipment including manpower drivers and fuel to execute the works completely during the contract period 12 The Contractor shall provide erect and maintain all temporary staging scaffolding rigging shuttering over pumping and flow diversions to carry out the works close to existing structures in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services and carried out with all necessary precaution needed 13 The extent of works shall include video with closed circuit television to identify open joints and connections broken
130. demolished removed and abandonment as specified in the contract requirement The extent of work shall include but not limited to all cables overhead and underground cables as approved by MEW and the Engineer 13 Rehabilitation of soil on sites within the boundary areas of Screw Conveyors Lifting Stations S20 and S21 completely and shall include but not limited to earthworks are required to determine the properties of the soil underlying the site by taking samples tests in different locations within the boundary areas as approved by the Engineer to test that the soil is not polluted and the strength soil load bearing capacity The Contractor shall require treatment of polluted soil and submit a certificate for laboratory testing after treatment of polluted soil and the strength soil load bearing capacity as approved by the Engineer and EPA 14 Demolish street lightings poles towers lightings poles and all other types of exterior lightings poles control cables panels and lightings networks installations disconnect electrical supplies break concrete structures remove abandonment and cart away off site and transport to MPW stores to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to lightings installations and fixtures electric panels control cables foundations mast lamp
131. der No SE 130 40 Document 2 III 12 The extent of works shall include but not limited to clean and remove sewage sludge debris and other contaminants cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval B Demolish underground pipelines internal sewers pipelines internal storm water drainage pipelines manholes transition chambers hatch boxes wells pits channels culverts and other underground chambers dewater dismantle cut break remove abandonment cart away to a tippers off site earthfill landscape grading soil to be reinstated and restored the site to a condition match its surrounding as approved by the EPA and the Engineer 1 Demolish unlimited distances lengths and unlimited depths of all existing pipelines types materials and all different pipes sizes diameters of underground gravity sewer pipelines storm water drainage pipelines gravity pipelines and pressure pipelines open cut method within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise except partial of sanitary sewerage system and partial of storm water drainage system dewater cut pipes remove abandonment unlimited depth and cart away to a tippers off th
132. djusted THE SPECIAL SYSTEMS in accordance and nature of the contract and subjected to the approval of the engineer 5 COST OF THE SPECIAL SYSTEMS with size The cost of SPECIAL SYSTEMS shall be borne by the contractor and shall Be allowed to include in the total price of this contract Tender No SE 130 162 Document 2 III Document 2 III Part C Appendixes Tender No SE 130 163 Document 2 III Index Document 2 III Part C Appendixes Appendix 1 Demolish Disconnect Dismantle and Abandonment Ardiya sewage plant Modules 1 10 Appendix 2 Demolish Disconnect Dismantle and Abandonment Screw Conveyors Lifting Stations S20 and S21 completely Note Attached Drawings Tender No SE 130 164 Document 2 III Appendix 1 Demolish Disconnect Dismantle and Abandonment Ardiya Sewage Plant Modules 1 10 Demolish all types of structure facilities disconnect electrical supplies dismantle electrical and mechanical equipments cut pipes break concrete structure remove abandonment and cart away off the site are divided into 10 modules and attached drawings These modules shall include but not limited to the following structures mechanical and electrical equipments The Contractor shall include the following information of the appendix as guidance only to the Contractor and does not cover all required works Therefore it is obligated that the Contractor to visit all the sites and conduct joint survey w
133. drive 1 5 KW Three concrete circular tanks TH 0724 TH 0726 diameter 13 m side wall high 3 7 m cone depth 2 85 m Hopper diameter upper 1 6 m bottom 0 4 m hopper depth 1 1 m Effective volume 518 m Flocculate scraper 1 5 kW Piping DN 200 for raw sewage supply Thickened sludge removal turbid water removal with total 18 isolating gate valves for above six thickeners Electrical and instrumentation installations for the above thickeners including sludge level sensors in each Thickened Sludge Pumping Station PS 0732 Concrete structure Two centrifugal pumps for thickeners TH 0721 TH 0723 One magnetic flow meter DN 150 Two sucking and two discharge gate valves DN 150 two check valves DN 150 and piping Electrical and instrumentation installation connected to mimic panel in the control room at digestion boilers Thickened Sludge Pumping Station PS 0733 Concrete structure Two positive displacement pumps capacity 120 m h each head 31 m rotation speed 273 min motor 18 5 kW with 1460 min for thickeners TH 0724 TH 0726 One magnetic flow meter DN 150 Two sucking and two discharge gate valves DN 200 two check valves DN 200 and piping Electrical and instrumentation installation connected to mimic panel in the control room at digestion boilers Turbid Water Pumping Station PS 0731 Concrete structure Two centrifugal pumps capacity 252 m h each head 16 m rotation speed 1480 min
134. e portable fire extinguishers shall be kept immediately available with an attendant standing by 3 The number of gas cylinders in any working area and the storage of such cylinders full or empty shall be in accordance with the FOC leaflet Precautions to be observed in connection with the use of gas or electric welding and cutting apparatus Tender No SE 130 24 Document 2 III C Gasoline and other flammable liquids shall be stored in and dispensed from UL listed safety containers and in conformance with requirements of the local fire authority Storage shall not be within the building D Make all arrangements for periodical inspection by local Fire Authorities and Insurance Underwriters Inspectors cooperate with such Authorities and promptly carry out their recommendations E Ensure that adequate and to the extent possible unimpeded means of egress from all parts of the Works is available at all times in case fire F Atthe completion of the Work or at such times as the Engineer or Engineer s Representative may direct remove all temporary fire fighting installations and equipment and replace all worn or damaged parts of the permanent systems leaving such systems in first class condition equal to new G The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compe
135. e Contractor shall disconnect remove abandonment and cart away off site of the existing electrical power supply system telephone network installations and connections The Contractor shall renovate supply install test commission and maintenance new electrical power supply system installations and connections from the existing modified substation No 1 SU 0241 The new main power panel shall be housed in a separate room which shall house the telephone exchange fire alarm control panel and electrical power supply panel All works materials and specifications shall be subject to the Engineer approval The Contractor shall be responsible for the renovation of the electrical power system telephone network and electrical lighting system The Contractor shall disconnect dismantle remove all existing lighting system carting off the site and reinstalling the entire lighting fixtures control networks ventilation fans motor control etc and all the cables of all pump motors which are in operation The lighting fixture shall be 250 W pendent types high bay type fixtures with HPMV lamps all control devices like power outlets and switches all wiring accessories conducts wires etc All exhaust fans of identical size shall be replaced The power supply cables shall be supplied and installed by the Contractor and shall be sufficient to operate an electrical load not less than 40 KW The Contractor shall renovate provide install test commission
136. e any corrosion product and paint with two coats of coal tar paints 5 The Contractor shall be fully responsible for the proper civil maintenance works of the perimeter chain link fence 800 m 440 m 800 m 440 m with barbed wires completely and other related facilities for the duration of the contract period as approved by the Engineer 6 The Contractor shall be fully responsible to clean all buildings MPW Quality Control Center centre substations SU 0241 and SU 0641 mosque guard house new pumping station and shall include but not limited to scraping sand blasting and removal of dust out of exterior walls of buildings cleaning with detergents and power sweeper all buildings floors daily cleaning office equipment daily cleaning with detergents toilets ablution facilities and kitchens daily cleaning windows doors and furniture daily vacuum clean mosque carpet daily and all other areas on site as directed by the Engineer 7 The Contractor shall include but not limited to clean and remove sand accumulated on the roadways and internal roadways of zones areas 1 amp 2 using sand power sweeper clean and remove cutting grass dust rubbish and debris daily accumulated on site including foot pathways parking shelters interlocking tiles inner and outer sides areas accumulated nearby the perimeter fence and cart away to a tippers off the site to approved areas by legal authorities and municipality The extent of work shall include
137. e power supply cables shall be supplied and installed by the Contractor and shall be sufficient to operate an electrical load not less than 500 KW 5 The Contractor shall renovate provide install test commission operation and maintenance of a new motor control center enunciator panel control relay panel motor starters distribution boards other auxiliary equipment electrical power cables instrumentation control cables earthling and bonding batteries battery charger light fittings supporting brackets and all other associated necessary components connection to existing substation No 6 SU0641 for the new loads 6 All equipment shall be connected to the new Motor Control Center with new cables and configured on the control board 7 The Contractor shall renovate provide erect install test commission operation and maintenance of a new house for the new MCC in a separate room constructed in the building The newly constructed room for the MCC shall be provided with air conditioner split type in sufficient nos so thatthe temperature of the panel room shall be maintained to 20 C at any given time 8 The Contractor shall be fully responsible for any civil works required for the panel foundation seal all sleeves of the cables wiring cable trays trunking conduits and conduit boxes cable trench and ducts shall be protected with waterproofing membrane All works and materials shall be subject to the Engineer approval 9 T
138. e site 2 Demolish unlimited depth dry and wet manholes transition chambers TC hatch boxes wells and pits channels distribution chambers culverts and other underground chambers within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise except partial of sanitary sewerage system and partial of storm water drainage system disconnect electricity supplies dismantle mechanical and electrical equipments dewater break concrete structures cut pipes remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to all existing step irons ladders fences concrete passing slabs concrete surfaces walls slabs and columns passing slabs covers air release valves chambers valves chambers drainage valves by pass pipelines frames and all other related parts 3 The Wastewater Pumping Station PS 0931 Main Sewer pipeline and manholes connected to Wastewater Pumping Station PS 0931 Internal sewer pipelines and manholes of zones areas 1 amp 2 connected to main sewer pipeline or wastewater pumping station PS 0931 and Main Storm water drainage system within the boundary
139. ecessary safeguards to prevent personal injury and property damage 2 The Contractor shall provide and maintain all necessary safety equipment such as fences barriers signs lights walkways guards and fire prevention and fire fighting equipment and shall take such other action as is required to fulfil his obligations under this subsection 3 The Contractor shall comply with all applicable Federal State and local laws ordinances rules and regulations and lawful orders of all authorities having jurisdiction for the safety of persons and protection of property 4 The Contractor shall provide one safety supervisor for the sites whose duty shall be the prevention of accidents This responsible person shall have the authority to take immediate action to correct unsafe or hazardous conditions and to enforce safety precautions and programs This safety supervisor shall be qualified for this position and the Contractor shall submit supportive documents to prove his qualifications and experience for such position 5 The Contractor shall take all the necessary safety measures to ensure the protection of the public ministry staff his staff and sub contractor s staff bearing in mind the nature of work The Contractor shall be responsible for any accidents which may occur in the Plant during the Contract 6 All Contractor s and or subcontractor staff shall have ID cards in clear view during their attendance in the plant Each ID card shall be
140. ected to the nearest new sewer manhole within two 2 years starting from the Date of Enterprise and shall include but not limited to sanitary fixtures bidet urinals water closet sink with faucets hot and cold shower with faucets hot and cold boiler and exhaust fan for toilet including chrome fittings and connections ceramic tiles and other services The Contractor shall provide all required consumables detergents soap paper tissues toilet tissue big roll tissue papers etc per month for the duration of the contract period The color of ceramic tiles and type of materials shall be subject to the Engineer approval All works materials and specifications shall be subject to the Engineer approval 4 The extent of works shall include but not limited to renovate provide install test commission and maintenance new lightings wooden doors with lockers aluminum doors with lockers glazing windows with mesh screens frames louvers vents electric installations and other accessories and all required civil mechanical electrical instruments works All works materials and specifications shall be subject to the Engineer approval 5 The extent of works shall include but not limited to civil maintenance works of the guard house which includes repair of walls roof slab and other concrete surface treatment and repair of cracks and joints leakages cure of damaged concrete surface making good irregularities and defects including expansion a
141. ection of vehicular and pedestrian traffic After the termination of the contract the mobile equipment or machineries shall remain the property of the Contractor All the works shall be approved by the Engineer EPA and Ministry of Interior Traffic Department 4 The Contractor shall require a second stage pressure grouting Backgrouting to ensure that voids have been filled Backgrouting will be required at critical locations only roadways adjacent to structures and buildings sidewalks passageways etc to ensure that flowable fill materials placements are completed The extent of works shall include but not limited to video with closed circuit television to ensure no voids remain unfilled All the works shall be approved by the Engineer and EPA 5 The extent of works shall include but not limited to clean flush remove cart away transport to any distance locations areas and dispose off site wastewater debris and other substances that degrade the performance of fill and accumulated in the underground gravity pipelines completely in accordance to the regulations of the authorities and municipality prior to start grout filling placements 6 The extent of works shall include but not limited to provide transport and commission jet flushers tankers if necessary and provide mud suckers tankers to remove wastewater debris and other substances transport and dispose to dumping area outside the site to unlimited distances locations areas in
142. ed in the contract requirement f Pedestrian gates shall be having manually operated 1 The extent of works shall include but not limited to all related civil works for the concrete reinforcement of the foundation base for columns rods to tighten the chain link of the fence and barbed wires 2 The Contractor shall provide all necessary materials and temporary power supply for proper completion of the work References A ASTM A 120Pipe steel block and hot dipped zinc coated galvanised welded and seamless for ordinary use ASTM A 126Zinc hot galvanized coating on products fabricated from rolled pressed and forged steel shapes plates bars and strips ASTM A 143Safeguarding against embrittling of hot dip galvanized structural steel products and procedure for detecting embrittling ASTM A 153Zinc coating hot dip on iron and steel hardware ASTM A 385Providing high quality zinc coatings hot dip on assembled products ASTM A 505General requirements for steel sheet and strip ASTM A 558Welding electrodes ASTM A 559Welding electrodes ME O W rom Quality Assurance A Manufacturer Company specialized in commercial quality motorized gate with five years experience B Installation In accordance with manufacturer s installation procedure C Work to be performed to comply with specifications and to the satisfaction of the Engineer Shop Drawings 1 Submit shop drawings and product data including plan layout
143. ed civil mechanical electrical and instrumentation parts to the satisfaction of the Engineer C The extent of works shall include but not limited to cutting steel structures and beams puncturing the base slabs foundation footings and surrounding walls including excavating depth of 2 5 meters beyond the horizontal limits of the foundations footings slabs columns walls of all types of structures facilities All types of structures facilities shall include foundations columns footings slabs walls beams and concrete reinforcement structures but not limited to ground structure tank or chamber substructure tanks or underground chambers superstructures wastewater retaining structures inlet chambers coarse screens fine screens degritters bioreactors or aeration tanks clarifiers contact tanks rapid sand filters parshall measuring flume thickeners digesters drying beds holding balancing tanks potable and brackish water complex and other related facilities a The extent of work shall include disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments demolish and break concrete structures cut pipes remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site but not limited to inlet and outlet channels scum networks scum removal facilities pipes valves bridges scrapers discharge underground pipes scum liquid separators scum
144. ed under supervision of the Contract staff b The Contractor shall be responsible to provide assign a fully qualified professional staff of the Contractor as technical orientation supervisor during the orientation period c The Technical Orientation Supervision shall develop and effectively implement a well defined on the job orientation program to guide the Tender No SE 130 119 Document 2 III 3 learning process of the trainee The Technical Orientation supervisor shall allow the trainee to progressively practice what he or she has learned to the greatest possible extend and the Contractor shall assume fully responsibility for all work produced by the trainee d Chemistry and microbiological tests shall include but not to the following lab tests and subject to the Engineer approval 1 Chemical lab tests Temperature pH value Transparency Conductivity Settleable matter Total Suspended Solid Volatile suspended Solid Sludge Volume 30 min Sludge Volume Index Dissolved Oxygen Chemical Oxygen Demand Biological Oxygen Demand Residual F and T Chlorine Oil and Grease Sulfide T amp F Ammonia Nitrite N Nitrate N Organic N Total Nitrogen Total Phosphate Chloride T D S Sulphate Chlorine Demand Alkalinity and Bicarbonate Heavy Metals Heavy Metals dry solid Total Nitrogen content reduce Total Phosphate reduction 2 Bacteriological lab tests Total count M P N 100 ml 48 hr Coliform M
145. em Ensuring that the server software is working correctly Ensuring that the interface with PIMS servers is functioning properly Ensuring that all other interfaces to the PIMS are working properly Loading client software in all designated machines and verify PIMS functionality comprehensively Implementing system back up strategy and maintaining the system through successful completion of the Sustained Performance Test 9 gi dom N The extent of work shall include but not limited to all required civil mechanical electrical and instrumental works as approved by the Engineer The extent of works shall include but not limited to the following works and subject to the Engineer approval The Contractor shall design provide install test and commission colored developed model of existing Ardiya pumping station and Sulaibiya wastewater treatment amp reclamation plant layout structures 1 5 m x 1 5 m and shall include all process treatment stages facilities in details but not limited to quantities of Tender No SE 130 110 Document 2 III structures substructures wastewater retaining structures buildings blower house pipelines by pass lines manholes roads landscaping irrigation areas trees substations poles workshop screening de gritting aeration tanks clarifiers chlorine Reverse Osmosis odour control facilities sludge treatment drying beds surge vessels pumps channels etc Appendix 3 Drawings The e
146. ensation in time or cost The extent of works shall include but not limited to all related civil mechanical electrical and instrument works All new laboratory equipments and devices shall be subject to the Engineer approval Laboratory Equipments and Devices Description Unit Qty Microbiology Analytical Balance with calibration unit and special table No for accurate weight 1 Top loading balance No 1 Autoclave No 1 Oven No 1 Colony Counter No 1 Distillation unit water still No 1 Filtration unit No 1 Fume hood No 1 Hot Plate No 1 10 Incubator No 1 11 Magnetic Stirrer No 1 12 Microscope with digital camera No 1 13 Microscope Camera and Television set 1 Tender No SE 130 115 Document 2 III 14 Stirrer with hot plate No 1 Sieve Shaker No 1 Vacuum pump No 1 Gas Burner GAS PROF 1 MICRO No 1 Portable colony counter No 1 Laboratory glassware washing machine No 1 Water bath No 1 pH meter with probe and all accessories sensor No membrane calibration kit etc 1 Lab line environ shaker No 1 Chemistry Atomic Absorption Spectrophotometer No 4 Automatic sampler No 1 Air pump No 1 BOD Unit with Incubator No 1 Analytical Balance with calibration unit and special table for accurate weight NO 1 Blender No 1 COD Reactor Hatch No 1 Conductivity Meter w
147. ents spare parts and all salvage of mechanical electrical and instrumentation shall be carried in closed containers and delivered to MPW stores off site in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them The extent of work shall include but not limited to following requirements and subject to the Engineer approval a Disconnectelectricity supply permanently at source remove reusable cables from the control panels insulate the cores individually with heat shrink tube provide a heat shrink overall end cab on top of the cables cart away to a tippers off the site and transport to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them as approved by MEW and the Engineer b Disconnect reusable motor cables main and auxiliary from both ends remove the cables insulate the ends roll them into individual rolls tag them metal tags detailing type voltage number and size of cores length etc cart away to a tippers off the site and transport to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them as approved by MEW and the Engineer c Disconnect the electricity sup
148. epresentative in writing 1 Provide a proposed agenda for the meeting 2 Provide the names of all personnel who are required to attend 3 The Engineer s Representative shall chair these meetings Clause 11 Co operation and Co ordination with other Contractors The Contractor shall attend all meetings called by the Employer for the purpose of co ordination and co operation The contents of the minutes of such meeting after approval of the Employer shall be binding to the Contractor The Contractor shall co operate and co ordinate his operations with all other parties or Contractor s executing work on sites or adjacent to his sites of work in order that the minimum interference inconvenience is caused to the public The Contractor shall continue executing the contract requirements to finish the works on time for the duration of the contract period and shall not have the right to claim for compensation in time or cost Clause 12 Reference Standards 1 All manufacturing testing storage installation and maintenance shall comply with the codes standards regulations and recommendations referred to throughout the contract documents unless otherwise stated in the specifications or unless otherwise approved by the Engineer 2 All references to codes regulations specifications and standards referred to in the Contract Documents shall unless otherwise stated mean the latest edition Tender No SE 130 11 Document 2 III amend
149. er approval 3 The extent of works shall include but not limited to dismantle remove water proofing roof insulation materials and cart away off site The Contractor shall design provide install test commission and maintenance new water proofing roof and shall include but not limited to water proofing insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with steel trowel Primer for concrete shall be suitable for use with the waterproofing membrane All works and materials shall be subject to the Engineer approval 4 The extent of works shall include but not limited to provide paint test commission and maintenance interior and roof of mosque building and ablution toilet room with emulsion paint Painting shall be carefully executed with clean brushes and in the best manner and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendati
150. er substances transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner The quantities of machineries trips are not limited to be available on demand and shall include but not limited to tractors tippers Lorries mud suckers tankers flushers cranes tools equipment etc to execute the works completely After the termination of the contract the mobile equipment or machineries shall remain the property of the Contractor All the works shall be approved by the Engineer EPA and Ministry of Interior Traffic Department 8 The extent of works shall include but not limited to trench excavation groundwater pressure investigation backfill excavated area after treatment of polluted soil landscaping grading soil compacting 95 MDD and to be reinstated and restored the site to a condition match its surroundings and all required mechanical electrical and civil works as approved by the Engineer and EPA 9 The extent of works shall include but not limited to provide install and commission suitable plug or cap pipelines ends surfaces completely connecting to the inlets and outlets of pressure pipelines ends and hatch boxes either by filling pipelines ends surfaces with dry pack grout mixture or install manufactured cap to form water tight seal 10 The extent of works shall include but not limited to dismantle cut remove and abandonment pressure pipelines installed
151. eriod The Contractor shall minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The Contractor shall submit the method of grout filling unlimited depths and full volumes of the underground pressure pipelines completely start from the inlet pressure pipeline end to the outlet pressure pipeline end of different pressure pipelines lengths m diameters mm and materials type of pipes until the volumes of the underground pressure pipelines are completely full within one 1 month starting from the Date of Enterprise for approval by EPA Environment Public Authority regulations MPW and other governmental authorities and shall include but not limited to techniques of cut pressure pipeline into different segments sections to install pipes for the injection points until the mix flowable fill materials emerges from vent pipes discharge pipes to ensure no voids remain unfilled plug or cap and sealing pipes ends surfaces and other open surfaces of pipelines preparation works to clean pipelines and remove wastewater or any other blockages prior to grout fill pipelines plan activities compressive strength test report mix flowable fill materials with admixtures grout fill equipment and pumps operational procedures groundwater investigations proposed of grouting sequence grout pressure flow and other related works The extent of works shall include but not lim
152. essitates complete replacement of such item the Guarantee period in respect of the item so replaced shall be extended for a further period of one year from the date of satisfactory replacement thereof If any defect appears to be a systematic defect all equipment of the same make shall be replaced by the Contractor at his own cost 11 The Contractor shall not install any parts or materials before receiving the written approval of the Employer 12 The Contractor shall guarantee in writing to the Employer that all mechanical and electrical parts will be suitable for their intended use The Contractor shall extend warranty for all materials as per contract document 13 The Contractor shall provide oil grease and other lubricants of the specific quality required for each separate piece of equipment Follow manufacturer s recommendations regarding the selection of lubricants 14 The Contractor shall provide gas diesel and other fuels necessary for the maintenance services 15 The Contractor shall replace all filters at intervals recommended by the equipment manufacturers and shall clean filters at monthly intervals 16 The Contractor shall provide all solvents cleaning agents brushes paint and similar items as necessary for the care of equipment in accordance with the manufacturer s preventive maintenance and routine maintenance instructions 17 The Contractor shall provide and install adequate and ample storage facilities and sha
153. evel The Contractor shall provide install and operate pumps plugs conduits dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations 8 The Contractor is obligated to execute all preliminary works and coordinate with MEW to disconnect remove abandonment and deliver transformers with all other related electrical accessories and connections off sites for all substations required to be demolished removed and abandonment as specified in the contract requirements The extent of work shall include but not limited to all cables overhead and underground cables as approved by MEW and the Engineer 9 The Contractor shall be responsible to clean flush and remove accumulated wastewater dry and wet sludge gravels sand debris hazardous materials and polluted soil groundwater and other contaminants drying beds media sand filters media and any locations under any circumstances cart away off the site transport and dispose to dumping area outside the site in accordance to the regulations of the authorities municipality EPA and Engineer approval The Contractor shall be responsible to provide jet flushers tankers if necessary and provide mud suckers tankers to remove wastewater and discharge off the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Enginee
154. f For labors the Contractor may submit only a list of their names Tender No SE 130 14 Document 2 III Clause 16 Manufacturers specifications Prepare and submit manufacturers specifications and installation instructions for new equipments and spare parts specified Clause 17 Correspondence Site memos Request of inspections Reports etc 1 The Contractor shall submit all correspondence site memos request of inspections reports etc among MPW Quality control center offices rooms and the Contractor office 2 The Contract shall submit request of inspections of all required works and shall include but not limited to demolish disconnect dismantle excavate break cut dewater remove abandonment cart away dispose deliver backfill earth fill backfill and earth fill materials calibration and maintenance of laboratory equipments and devices renovation works civil mechanical HVAC and electrical maintenance works maintenance and repair works preventive maintenance etc and other related as specified in the contract requirements for the Engineer approval The Contractor shall not have the right to make any future claims or any extra cost or delay in time not to inspect the works required after working hours of MPW staff 3 All correspondence site memos request of inspection reports etc from the Contractor to the Engineer or Engineer s Representative shall clearly indicate a Contract Number b Contractors Na
155. fire excavation support and protection safety signs and temporary power supply for proper completion of the work 3 The Contractor shall be responsible for maintaining and rectification of all damaged utilities and other services affected during the works at no extra cost Tender No SE 130 141 Document 2 III 4 The Contractor shall provide all necessary material lightings safety signs and temporary power supply for proper completion of the works 5 The Contractor shall be responsible to register readings from the flow meters hourly and prepare records of operation period for all existing and new pumps 6 Thecost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of the works 1 The Contractor shall be fully responsible for the operation of remaining existing effluent transfer pumps 3 Nos and remaining existing surge vessels 4 Nos in the new pumping station of zone area 2 with all related mechanical and electrical equipments for the duration of one 1 year period after renovation works at Ardiya sewage plant are completed to pump tertiary treated effluent wastewater from the header tank to DMC Data Monitoring Center as approved by the Engineer 2 The Contractor shall be fully responsible for the operation of new Rabya Pumps
156. following components but not limited to top counter granite surface drawers and shelves of 12 mm thick hardboard or plywood 1200 mm wide stainless steel sink unit with integral embossed drain board faucets separate hot and cold exhaust fan water cooler boiler refrigerator 15 feet electrical gas oven with gas cylinder water filters calling bell system connected to each partition room curtains and other related kitchen services such as plumbing ceramic tiles fittings and all civil mechanical electrical and safety works The extent of work shall include but not limited to provide all other required glass wares gas cylinder kitchen supplies and consumables per month for the duration of the contract period as directed by the Engineer All works specifications and materials of new kitchen equipment subject to the Engineer approval The color of ceramic tiles and type of materials shall be subject to the Engineer Approval The Contractor shall provide install test commission and maintenance new external lightings at least 500 W metal halide type fixtures 8 Nos with all related wires and electric installations outside the MPW Quality control center The Contractor shall replace the entire existing power outlet and control switches with new identical or equivalent type with the approval of the Tender No SE 130 78 Document 2 III Engineer All works specifications and materials shall be subject to the Engineer approval E Ren
157. for six clarifiers of Module 03 Process air Pipeline Pipeline DN 1000 to bioreactor BR 0311 Sewage Mixed Liquor amp Effluent Pipeline amp Channels Concrete gravity open channel covered with concrete slabs Underground gravity pipeline DN 1000 from degritter DG 0101 to bioreactor BR 0311 with sluice gates and manholes Concrete gravity open channels and two distribution chambers to clarifiers Gravity open channels leading to Module 06 Two flow meters in the effluent channels Sludge Discharge amp Return Networks Gravity underground pipelines discharging to pit at the machine house common pipe at the pit DN 1000 Two force pipelines DN 500 from pumps in machine house to bioreactor Excess sludge e Concrete structure Pumping Station e Two submersible pumps in the pit at machine house PS 0331 One magnetic flow meter DN 150 Excess Sludge e One underground force pipeline DN 150 from pumping Pipeline station PS 0331 to thickeners at Module 07 Module 04 Module 4 shall include but not limited to the following structures mechanical and electrical equipments Raw Sewage e Concrete chamber with weir gate 3000 mm long Above Distribution Chamber weir gate controls flow to Modules 04 amp 05 amp indirectly to bioreactors BR 0213 amp BR 0411 Bioreactor BR 041 1 Concrete substructure One basin 64 x 32 x 2 74 m mixed liquor depth 2 2 m Effective volume of mixed liquor 4150 m
158. foundations columns footings slabs walls beams and concrete reinforcement structures but not limited to domes chemicals storage tank foul air trestle bridges concrete and steel basins gas holders steel tank valve house air compressor station waste gas flare steel stack 15 m high gas gate valves flare ignition panel and main gas burner waste gas burner tower stack 4 m high made of bricks 10 nozzles gas burner control valve and control panel steel truss structures parshall measuring flume parking shelters oil and grease shelters control rooms water display fountain effluent filling station foundation of control panels and pumps concrete and steel ladders and other related parts a The extent of work shall include disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments demolish and break concrete structures cut pipes abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site but not limited to underground services and utilities cables wires earthling rods electrodes sensors etc sewage contaminants hazardous materials and polluted soil b The extent of works shall include but not limited to cutting steel structures and beams puncturing the base slabs foundation footings and surrounding walls including excavating depth of 2 5 meters beyond the horizontal limits of the foundations footings slabs columns walls of al
159. fter renovation works are completed as approved by the Engineer However the Engineer shall have the right to revise the said preventive maintenance program works at any time during the contract period and make any changes to the program 22 The extent of works shall include but not limited to the following maintenance and repair works Tender No SE 130 146 Document 2 III a Routine and preventive maintenance of various type of electrical panels and switchboard including circuit breakers contactors switches rectifier relays motor control panel protection device batteries battery chargers lighting network and fitting and emergency lighting system etc b Overhauling calibration testing of electrical protection devices such as but not limited to over current relays under voltage relays earth fault relays flash over relays phase sequence relays combined safety switches etc c Maintenance and repair works required to HVAC package units A C split units window A C including replacement of damaged parts ducts equipment and fittings as well as charge of refrigerant gases etc and all other works deemed to be necessary to maintain the A C systems and units in good working orders as instructed by MPW Engineer The A C systems in operation the Contractor shall carry on the maintenance program but not by limitation as follows 1 Seasonal checking preparation of the equipment for operation with sufficient period before t
160. g ground must be guarded by a shoring system sloping of the ground or some other equivalent means A safe means of exit from an excavation must be provided when the excavation depth is 1 5 m or greater Exit locations must be spaced at lateral intervals of 7 m or less Daily inspections of excavations shall be performed by a competent person for evidence of a possible cave in Excavations must also be inspected by a competent person after every rainstorm or other hazard increasing occurrence and the protection against slides and cave ins shall be increased if necessary 2 Confined Space Entry A large percentage of the fatal accidents that occur in confined spaces Clearly the problem is a lack of knowledge of the dangers involved in entering and working in confined spaces and the proper procedures to follow to prevent accidents Definition of Confined Space A confined space is defined as any enclosed or semi enclosed space that has restricted means for entry or exit and is not intended for continuous occupancy Typical confined spaces in the wastewater industry are manholes metering stations valve or siphon chambers digesters silos empty tanks pits or any other area in the system that has direct contact with wastewater sludge sludge gas or conduits carrying these substances Classification of Confined Spaces Confined spaces are classified based upon existing or potential hazards The two classifications of confined spaces are
161. gress of Contract works for the approval of the Engineer 0208 3 The Program shall be revised and periodically updated as required by the Engineer and to his satisfaction 4 The Engineer shall have all the right to modify change or cancel any work or any parts of the working program at any time during the contract period or to stop the continuity of the work as per the approved program as he may see useful to the work from his point of view and the Contractor will not have any right to object or Tender No SE 130 13 Document 2 III 6 8 claim against such change and he should continue the execution of the work without any delay In addition to providing a step by step description of the work in sequential order method statements shall also clarify the following Scope of works covered References procedures or standards Subcontractors utilized Products required Tools equipment and machinery required Plan of progress works starting date of the activities and the Period activities to be completed Personnel required and designated responsibilities Safety Hazards and Precautions to be taken Quality Control Measures Procedure step by step sequence of work The CPM program shall include the following detailed plans but not limited to the following detailed plans and shall be subject to Engineer approval Detailed plan of Management progress works such as reports submittals manpower categories inspections re
162. h of 2 5 meters beyond the horizontal limits of the foundations slabs and walls of hatch boxes The reinforced concrete cover slabs shall be carefully broken to maintain metals covers and frames The extent of work shall include but not limited to dismantle remove abandonment and cart away to a tippers off the site other related parts and connections shall include but not limited to all existing step irons ladders fences concrete passing slabs covers air release valves chambers valves chambers drainage valves by pass pipelines frames and all other related parts Frames and metals covers shall be cleaned and sand blast to remove any corrosion product paint with two coats of coal tar paints and deliver to MPW stores off site The extent of works shall include but not limited to provide install and commission suitable plug or cap and sealing pipes ends surfaces completely connecting to the hatch boxes either by filling pipe ends surfaces with dry pack grout mixture or installing manufactured cap to form water tight seal The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth areas after demolishing hatch boxes as approved by the EPA and the Engineer landscaping grading soil compacting 95 MDD and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The extent of wo
163. hall not be affected by power failure and which shall be synchronised with real time clocks in other engineering workstation laptops F Server for 400 users or in accordance with the size and nature of the contract and subjected to the approval of the engineer to be provided subject to the approval of Engineer s Representative 2 08 WEB CAMERA A Wide Angle outdoor web camera with the following capability 1 Focal length of at least 30 to 250mm equivalent in 35mm camera and light sensitivity of 0 5 lux 2 At least 10x optical zoom capable of at least 6 Megapixel images 3 Capable of operating in temperatures of at least 2 to 60 degrees Celsius 4 Capable of Time lapse photography 5 Capable of General Streaming Video 6 Remote controllable with Pan Tilt and Zoom B Camera to be housed in IP 65 rated camera enclosure C 4 web linked cameras in 4 locations to be specified by Engineer s Representative Web cameras output will be of 2 types photos and live stream video D Live stream video shall be viewable via password protected web interface Capable of simultaneous viewing by 20 users or in accordance with the size and nature of the contract and subjected to the approval of the engineer Video data to be linked to Digital Video Recording Server or other mechanism to allow Engineer s and Engineer s representative designated personnel to monitor site activity and review activity on any given day E Photo output to Project web
164. he Contractor shall prepare on his own a safety place as spare parts store to keep store the new spare parts and materials which required for maintenance works during the contract period 10 Any failure of equipment or a part of it shall be replaced with new tested without any extra cost to MPW Tender No SE 130 97 Document 2 III 11 The Contractor shall be responsible for related civil mechanical electrical and instrumental works required for the proper installation and operation 12 Maintaining and rectification of all damaged utilities and other services affected during the works at no extra cost 3 Renovation Works 1 The Contractor shall be responsible to carry out complete overhauling maintenance cleaning and adjusting of the existing equipment and facilities at the New Pumping Station replacing all defective parts and materials as directed by the Engineer 2 The extent of work shall include but not limited to disconnect dismantle remove abandonment clean amp paint all the existing equipment with all related pipelines and fittings valves pressure gauges motor panel and other civil mechanical and electrical works and carted away off site 3 Thefollowing are but not limited the scope of the renovation work required to be conducted and executed in parallel with the new installation work states above a Supply and replace all the pipe works of the station including all fitting flanges bolts nuts and
165. he Contractor shall provide all necessary safety personnel materials and equipments lightings safety precaution against fire fencing signs for proper completion of the work 11 The Contractor shall co operate co ordinate and not interfere his operations with all other parties or Contractor s executing works on sites or adjacent to his sites 12 The Contractor shall be responsible to provide adequate mobile diesel generators to be available on demand for electricity loading required to execute the works without any interruption for the works 13 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost il Description of Works A Renovation works of new double layers asphalt roadways and storm water drainage system of zones areas 1 amp 2 and other related works 1 The Contractor shall design renovate provide erect test commission and maintenance of new main double layers asphalt roadways new internal strip double layers asphalt roadways of zones areas 1 amp 2 and parking areas within two 2 years starting from the Date of Enterprise as approved by the Engineer The new asphalt roadways shall withstand loading stresses of heavy duty vehicles and shall allow passing at least two 2 separate paths ways forward and backward directions where d
166. he Engineer and EPA 5 The Contractor shall be responsible to identify locate check and follow all safety precautions requirements to demolish disconnect dismantle remove abandonment dispose cart away to a tippers off the site and transport off site diesel fuel chemicals gases and hazardous materials and equipment in a safe manner to avoid any risks in accordance with KNPC EPA and other concerned authorities rules and regulations shall include but limited to closed confined structures diesel and other fuels storage tanks chemical storage tanks gas pipes gas pipelines gas cylinders gas holder steel tanks waste gas flare steel stack surge vessels and other specific facilities such as odour control building chlorine building pumping station and laboratory 6 The extent of works shall include but not limited to disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments clean grease paint and coating surface metals areas remove cart away to a tippers off the site and transport usable salvage items as directed by the Engineer to MPW stores outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval and shall include but not limited to all equipment or parts thereof instruments motors pumps control panels safety equipment laboratory devices and equipm
167. he extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new drip system for the existing and new landscaping area of zones areas 1 amp 2 and EAD zone area as approved by the Engineer 10 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new sprinkler system to irrigate existing and new lawn grass zones areas 1 amp 2 area and EAD zone area as directed by the Engineer 11 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new quick coupling valves all over the area of manual watering 12 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new flush valves in each zone as appropriate 13 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new PVC pipes and fittings shall be manufactured from virgin polyvinyl chloride compound to ASTM D 1784 type 12454 B PVC 1120 or equal approved 14 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new pipe joints Tender No SE 130 94 Document 2 III e UPVC Socket type solvent cemented joints e PE plastic inserts
168. he operation of the equipment This shall be done once before summer season 2 Preventive maintenance as per approved schedule including cleaning of filters charging gas checking belts etc 3 Starting and operation of the equipment whenever required by the Engineer during the period of the Contract However the Contractor shall check periodically the unit to ensure their operation The Contractor should ensure that the equipment after starting will continue to run without interruption from faults or defect resulting from bad maintenance 4 Maintenance and service of the equipment shall include all the necessary repairs and replacement of all the defective parts whether mechanical or electrical The Contractor shall also look after the air distribution system related to the equipment and the electrical installation components starting from and including the switch fuse controlling the unit 5 The Contractor shall supply all necessary spare parts and material he may find required to the proper maintenance procedures of the A C systems and units such material shall include but not by the way of limitation instruments tools cleaning chemical refrigerants oil greases rags and all other necessary items to carry out the work d Maintenance of street Lights works shall include but not limited to chokes capacitors holders capacity wiring lamps covers connectors distribution boards photo cell for auto operation as per existing
169. he perimeter fence Cable network connecting transmitter with computer located in administration building AB 1042 Potable amp Brackish Water Complex WS 0921 Concrete structure Two water holding underground tanks For potable water 350 m for brackish 700 m One booster set for potable water with two pumps and pneumatic surge vessel pump Two electrical panels for above e One booster set brackish water with two valves and check valves for portable and brackish water systems Module 10 Module 10 shall include but not limited to the following structures mechanical and electrical equipments Administration Building structure Building Plumping AB 1042 A C units Lighting installation Roof water tank List of Equipments Module 1 Mechanical Screen No 1 Mechanical Screen No 2 Degritter Bridge Unit Hydraulic Pump Bridge Unit Diaphragm Pump No 1 Diaphragm Pump No 2 Sand Scrapper Driving Unit 1 Sand Scrapper Driving Unit 2 Screw Conveyor No 1 Screw Conveyor No 2 Screw Conveyor No 3 Screw Conveyor No 4 Blower No 1 Blower No 2 Blower No 3 Tender No SE 130 180 Document 2 III Pista Grit Pump 1 Pista Grit Pump No 2 Dosing Pump DP 100 Dosing Pump DP 400 Dosing Pump DP 201 Dosing Pump DP 400 Dosing Pump DP
170. he pump assembly and location selected to the engineer for approval before conducting the work 7 The Technical data for the dewatering pumps shall be Discharge Size 4 inches Capacity 18 30 L S Head 12 10 m Impeller type Vortex Pump materials impeller stainless steel 9 4460 Body mehenaite cast iron GG 25 Shaft stainless steel 1 4021 07 05 Electrical motor 415 volt 3 phases 50 Hz insulation class F protection type IP 68 c Landscaping Irrigation System 1 The Contractor shall disconnect electrical supplies dismantle and demolish the existing irrigation network system completely including pumps pipes pipelines fittings and other related accessories remove cart away to a tippers off the site 2 The Contractor shall study design renovate supply install test commission operation and maintenance new two 2 complete sets of booster pumps vertical multistage centrifugal pumps UVPC piping system suction and discharge gate valves for each pump bypass relief valve and bronze water type self closing check valve at discharge of each pump as well as pressure vessel suitable for minimum 1600 kpa 232 psi working pressure with capacity suitable for limiting the number of pump starts to 15 times per hour Tender No SE 130 93 Document 2 III 3 The Contractor shall study design renovate supply install test commission operation and maintenance new irrigation network system to irriga
171. he same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Tender No SE 130 25 Document 2 III Clause 34 Barriers and Enclosures A Provide to prevent public entry and to protect existing facilities and adjacent properties from damage for the proper execution of the work and for meeting the Government Regulations Provide 2 5m high safety fence and barrier as necessary enclosing all open excavations for the duration of the Project The fence shall consist of new mild steel angle or RHS posts and rails with minimum 1 8mm thick galvanized trough section sheeting panels pre painted in two colors to the approval of the Engineer Posts shall be at maximum 2 4m centre set in concrete foundation minimum size 450 x 450 x 450mm Give all necessary notices obtain licence permits and pay any fees in connection with the work herein Remove temporary materials and equipment at Substantial Completion Repair damage caused by installation or use of barricades and enclosures Provide adequate safety barriers guardrails and handrails around any excavations as required by the requirements of the Authorities having jurisdiction The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause
172. holes connected to turbid water PS 0731 Pipeline DN 200 supplying 12 drying beds with sludge by digested sludge pumps Sludge Emergency Holding Tank HT 0721 Concrete structure One rectangular underground open tank 29 x 12 x 3 6 m One sludge supplying valve DN 150 Guard rails around the tank Electrical Substation SU 0741 Concrete structure MCC for Module 07 Supporting battery for instruments of Module 07 Switch gears for Module 07 Dried Sludge Shed DZ 0742 Fuel Fill FI 0751 Tender No SE 130 177 Document 2 III Module 08 Module 8 shall include but not limited to the following structures mechanical and electrical equipments Sludge Thickeners e Concrete structure Complex 2 Units e Two concrete circular tanks internal diameter 12 m side TH 0821 TH 0822 wall high 3 1 m side wall sludge depth 2 047 cone depth 0 55 0 40 m hopper dimensions upper DN 1 2 m bottom DN 0 5 m depth 0 65 m Effective volume of one tank 305 m rotation bridge with flocculator scraper peripheral drive One thickened sludge grinder Two thickened sludge positive displacement pumps One magnetic flow meter DN 125 for thickened sludge Raw and thickened sludge piping with 12 gate valves DN 150 e Two turbid water submersible pumps capacity 108 m h each head 10 m pump rotation speed 1450 min motor rated 5 5 kW connected to turbid water pumping sump e Two mag
173. hrough auditing and detailed tracking of document history in log files which shall be accessible to the Engineer and Engineer s Representative 12 Access to the servers workstations and laptop computers supplied for use with the PIMSS system must be secured either by fingerprint or other biometric scanning to ensure that the system is being used only by the designated user 13 Access to signature used for electronic approval must be via biometric access or digital signatures The system administrator must have no direct access to Engineers and Engineers Representative digital signature biometric fingerprint Tender No SE 130 155 Document 2 III PIMSS shall include a version control function that preserves a record of all document revisions Users can track and manage multiple document versions add comments and send notifications when new versions are created The system configuration shall be such that the user is able to work with documents and drawings without being unreasonably slow All supplies DVD CD printing cartridges toner ink paper etc and accessories required to use the equipment on the project shall be supplied by the contractor Maintenance of these in working condition is also part of the Contractors responsibility Backup of all data in PIMSS and the public website in section 1 03 must be done on a daily basis and shall be a full backup or a differential backup daily for 6 days of the week and a full backu
174. ide install test commission and maintenance new fire protection system cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval 12 The Contractor shall design provide install test commission and maintenance for the laboratory partition rooms sufficient power points in each laboratory partition room Tender No SE 130 113 Document 2 III 13 The Contractor shall design provide furnish install erect test commission and maintenance new laboratory furniture to fit chemistry laboratory partition room completely within one 1 year starting from the Date of Enterprise and shall include but not limited to base units work tops sinks units 3 Nos service fixtures laboratory chairs 6 Nos and laboratory stools as approved by the Engineer The extent of work shall include but not limited to Instruments to measure temperature and humidity High chemical and corrosion resistant epoxy benches Suspended Cabinets for glass wares Safety storage cabinets class 2 with UV light equipment Safety cabinets for acids and dangerous chemicals Safety shower and equipments Safety precaution facilities tools cloths and materials shoes gloves rechargeable torch lights white coats large First Aid Kits helmet and other safety materials Boiler Oil heater Burn kit In
175. ilation system power outlets and other related accessories Tender No SE 130 102 Document 2 III 7 Supply install testing and commissioning of new lighting amp Power system for zone area 2 and facilities complete with the following equipment Lighting and Power distribution boards Explosion proof and weather proof lighting fittings Lighting Switches sockets outlets junction boxes and accessories Lighting and power cables conduits fittings and accessories Earthling System 8 Supply install connection and settings to work the local push button station with emergency stop button red mushroom type totally enclosed with protection IP 65 for each motors and substation room 9 Supply install testing commissioning and setting to work emergency lighting system of 12 Nos independent units self contained battery of 4 hours back up time to be mounted in substation No 6 4 Units and the New Pumping Station 8 Units complete with all fitting and accessories as specified in the contract documents 10 Supply install connection and setting to work a new earthling system for all electrical equipment and switchboards as per the latest regulation of MEW and requirement of the contract specifications 11 The Contractor shall be responsible to get clearance approval from M EW at his own expense for the latest regulation and modifications required for substation No 6 Module 06 SU 0641 12 The extent of work sh
176. ilities in the Contract Documents Hard copies of all documents and drawings that have legal content import shall be made and delivered against receipt from recipients 8 PIMSS required hardware Minimum 300 users or in accordance with the size and nature of the contract and subjected to the approval of the engineer and redundant ADSL internet access shall be supplied installed maintained and training shall be given in the use of PIMSS a For all designated staff of the Engineer whether located at site or at the MPW Head Office b For all designated staff of the Engineer s Representative whether located at site or at the GC Head Office C For all project staff of the Contractor whether located at site or at their Head Office d 50 users will be reserved and assigned for item a and b for their use 9 The system must be capable of storing indexing and viewing all Electronic Document Formats Any other project information item contract related documents shall be capable of being stored transmitted backed up and managed through this system 10 Project information items and linked information entered into the PIMSS shall be updated at least once every 4 hours 11 The access security to PIMSS hardware and software must be permission based and shall be controlled by the Contractor It is his responsibility to ensure that it is secure from internal or external unauthorized access PIMSS shall also maintain accountability t
177. ine pore membrane duplex air diffusers 648 units in basin Membrane active area of one diffuser 0 472 m e Process air piping with twelve butterfly valves DN 300 Air from blowers located in machine house e Distribution chamber supplied by two pipelines DN 500 located in machine house Tender No SE 130 167 Document 2 III Distribution channel with 12 discharge gate valves DN 200 Bioreactor BR 0213 Concrete substructure One basin 64 x 32 x 2 74 m Two inlet slide gates 1500 x 1000 and two outlet motorized slide gates 1000 x 800 and two manual slide gates 400 x 800 Eight surface turbine aerators 55 kW each Pipe DN 600 with one butterfly valve DN 600 amp distribution channel with two gate valves DN 500 pumps common for all bioreactors of module 02 are located in the machine house Clarifiers ST 0221 ST 0226 six units Circular concrete substructure tanks or clarifiers ST 0221 ST 0222 ST 0223 ST 0224 ST 0225 ST 0226 with conical bottom Internal DN 37 5 m V notch length 338 6 m Equipped with rotating bridge with bottom scraper Bridge is rotated by two drive units Distribution chamber equipped with slide gate supplying pipe DN 700 Bottom pipe DN 400 controlled by weir gate in overflow chamber Discharged is directed to pumps in the machine house Reception launder fixed to the bridge air lift piping and air blower and scum sewage concentrating tank with dischargi
178. ineer s satisfaction 2 Remove unsuitable material not marked for salvage such as rotted wood rusted metals pipes gears and deteriorated masonry and concrete 3 Prepare surfaces and remove surface finishes to provide for proper installation of new work and new finishes 4 Close openings in exterior surfaces to protect existing work from weather and extremes of temperature and humidity 5 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Tender No SE 130 29 Document 2 III Document 2 III Part B Particular Requirements Tender No SE 130 30 Document 2 III Index Document 2 III Part B Particular Requirements Section A Demolish Disconnect Dismantle and Abandonment existing facilities Clause 1 Demolish Disconnect Dismantle and Abandonment Ardiya sewage plant and other related works Clause 2 Demolish Disconnect Dismantle and Abandonment Screw Conveyors Lifting Stations S20 and S21 completely and other related works Tender No SE 130 31 Document 2 III Clause 1 Demolish Disconnect Dismantle and Abandonment Ardiya sewage plant and other related works The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments
179. ing approved quality primer and enamel paint black colour d Gates must be motorized remote controlled and horizontally sliding type 1 System shall be suitable to be operated under local power supply system 240 415V 50Hz 2 The assembly shall consist of photo electric cells and the pressure switches connected together in series with contacts normally closed for remote operation 3 Heavy gauge steel frame for pad mounting 4 All weather hinged cover with provision for padlocking 5 Adjustable safety friction clutch 6 Adjustable limit switches rotary type 7 Magnetic solenoid locking brake 8 Emergency disconnect for manual operation in case of power failure 9 Magnetic reversing starter size 1 contactor type with overload and under voltage protection 10 Factory pre wired electrical system 11 Permanent lubricated heavy duty bearings and heavy duty roller chain 12 The motor shall be provided with removable hood 13 Operator shall be suitable to withstand the local weather conditions IP54 Tender No SE 130 73 Document 2 III 14 Motor shall meet the international standards IEC and shall be suitable for remote operation e Electric gates operator to consist of the following 1 Electric gates operator to be located as indicated Operator to have parallel three button illuminated control stations OPEN STOP AND CLOSE 2 Provide electrical conduit switches wiring and connections as specifi
180. ipe sides ends connecting to the inlet and outlet gravity pipelines ends and manholes pipes ends and other related works The extent of works shall include but not limited to demolish dewater dismantle break remove abandonment and earth fill of manholes completely with other related works 2 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities for the safety of manpower and site work within one 1 month starting from the Date of Enterprise 3 The Contractor is obligated to visit the locations of the gravity pipelines during the period of tendering to determine by himself the actual conditions of the site and all the components of works 4 The Contractor shall require working concurrently in different locations to finish the contract requirements on time 5 The Contract shall submit request of inspection of all required works as approved by the EPA and the Engineer Tender No SE 130 62 Document 2 III 6 The Contractor shall provide all necessary safety personnel materials and equipments lightings safety precaution against fire fencing safety signs and temporary power supply for proper completion of the work 7 The Contractor shall be responsible for maintenance and rectification of all damaged utilities and other services affected during the works at no extra cost 8 The Contractor shall be responsible to provide adequ
181. ite and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them The Contractor shall renovate supply erect install test commission and maintenance new HVAC system units not less than 2 Nos x 25 tons with two 2 Nos compressors for MPW Quality control center Module 10 AB 1044 and its related ducting system completely The HVAC package units shall have a cooling capacity not less than 1 5 times the existing systems The Contractor shall renovate supply erect install test commission and maintenance the ducting system according to the system capacity for the cooling and the ventilation requirements The extent of work shall include but not limited to provide install test commission and maintenance new split air conditioning units 3 5 tons with compressors in each partition room All works specifications and materials shall be subject to the Engineer approval f The Contractor shall disconnect dismantle remove all existing lighting system cart away to a tippers off the site The Contractor shall renovate supply erect install test commission and maintenance new lighting system and shall include but not limited to the entire lighting fixtures control networks cables motor control etc in each partition room The lightings fixtures shall be 250 W pendent types high bay type fixtures w
182. ited to demolish dewater dismantle break remove abandonment and earth fill of hatch boxes completely with other related works 2 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities for the safety of manpower and site work within one 1 month starting from the Date of Enterprise 3 The Contractor is obligated to visit the locations of the pressure pipelines during the period of tendering to determine by himself the actual conditions of the site and all the components of works 4 The Contractor shall require working concurrently in different locations to finish the contract requirements on time 5 The Contractor shall submit request of inspection of all required works as approved by the EPA and the Engineer 6 The Contractor shall provide all necessary safety personnel materials and equipments lightings safety precaution against fire fencing safety signs and temporary power supply for proper completion of the work Tender No SE 130 56 Document 2 III 7 The Contractor shall be responsible for maintenance and rectification of all damaged utilities and other services affected during the works at no extra cost 8 The Contractor shall be responsible to provide adequate mobile diesel generators to be available on demand for electricity loading required to execute the works without any interruption for the works 9 The cost
183. ith HPMV lamps all control devices like power outlets and switches all wiring accessories conducts wires etc The power supply cables shall be supplied and installed by the Contractor and shall be sufficient to operate an electrical load not less than 500 KW All works specifications and materials shall be subject to the Engineer approval g The Contractor shall provide install test commission and maintenance the following equipment but not limited to curtains insect killer lights with twin tubes oil heaters new files metal cabinet metal multi shelves and double glass rolling doors new swivel leather chairs with arms and other required accessories for each partitions rooms The extent of works shall include but not limited to provide install commission two 2 sets of first aid kit large size and two 2 sets of steel keys cabinets large size in the corridor All office equipments specifications and furniture shall be subject to the Engineer approval h The Contractor provide install test commission and maintenance with sufficient smoke and heat detectors in each partition room as per the KFB approved procedures especially the laboratory partition rooms and shall be connected to FCAP and sufficient numbers of fire alarms sound amp light alarms bells and shall be installed to alert the guard man and shift operator during any fire condition All works specifications and materials shall be subject to the Engineer approval
184. ith MPW staff to determine by himself the plant facilities structures substructures or underground tanks underground pipelines manholes wells pits buildings and all other works of the contract requirements during the period of tendering as directed by the Engineer The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract Modules Facilities Structures Mechanical and Electrical Equipments Module 01 Module 1 shall include but not limited to the following structures mechanical and electrical equipments Inlet Chambers e Concrete structure IS 0151 IS 0152 e 12 force mains from pumping stations terminating in each chamber Dimensions of pipelines 7 x DN 1000 2 x DN 700 2 x DN 300 1 x DN 150 e Air injection pipes installed in ends of force mains e Two 9 kW DN 1500 agitators mixers installed in each chamber e Dosing piping installed in each chamber Dosing pumps are located in Odour control building e Bio enchancing solution dosing FRP tanks and piping installed on inlet chambers e Foul air sucking pipes DN 450 FRP installed in each chamber Sucking fan capacity 8500 Nm hr located in odour control building e Main channel inlets Coarse Manual Bar e Concrete structure Screens e Screen SC 0101 wide 3000 mm 50 mm spacing in the SC 0101 SC 0102 main channel branch leading to Modules
185. ith salinity measurement No 1 De ionizer No 1 Desiccator s cabinet No 1 Glassware drier No 1 Heating mantles 250 ml capacity No 1 Heating mantles 500 ml capacity No 1 Safety cabinet No 1 Kjeldahl Distillation Unit Automatic Titration No 1 Kjeldahl Digestion Unit No 1 Muffle furnace No 1 Oven No 1 Spectrophotometer Hatch DR complete test kit No 1 Orbital Shaker No 1 Portable Equipment Ultra meter II instrument for temperature pH No conductivity and TDS 1 Milwaukee Turbidity Meter for Turbidity test No 1 HACH DR 1890 colorimeter Sulfur reagent set for 3 sulfates test No 1 Tender No SE 130 116 Document 2 III HACH _HS C 25378 00 Hydrogen sulfide test kit for 4 H S test No 1 HACH _DR 890 colorimeter Amber Reagent set for N 0 5 Ammonia test 1 HACH DR 890 colorimeter Reactive phosphorus No 6 reagent set for phosphorus test 1 HACH Alkalinity test kit for Alkalinity test No 1 8 HACH Chloride test kit for Chloride test No 1 HACH DR 1890 colorimeter free chlorine reagent set No 9 for free chlorine test 1 HACH DR 1890 colorimeter total chlorine reagent set for free chlorine test No 1 Reverse Osmosis System Complete with piping all accessories storage tank with level controller amp online TDS monitoring System with accessories of mounting No 1 Dissolved Oxygen meter with probe and all accessories calibration kit stand etc No 1 Residual Chlorine Photometer complete with all
186. ivity to specific gravity viscosity pressure and ability to measure a wide range of difficult to measure fluids such as corrosive slurries which differentiates this type of metering system from all other flow meters The field sensors shall be suitable to operate at temperature 60 The locations of the n ew flow meters shall measure the inlets and outlets flow of header tank and shall include measure the inlet flow from Rekka treatment plant 2 1200 mm to header tank inlet flow from DMC 1200 mm to header tank the discharge outlet over flow from the header tank to DMC pipeline 1200 mm discharge outlet flow from the header tank to Rabya pressure pipelines 2 5 300 mm and discharge outlet flow from the header tank to new irrigation system as per manufacturer 3 All specifications of new flow meters and electrical installations subject to the Engineer approval g Fire Fighting Alarm System 1 The Contractor shall renovate supply install test commission operation and maintenance Fire Fighting system with an alarm facilities and sufficient number of smoke and heat detectors in each room of the effluenttransfer pumping station as per the KFB approved procedures and shall be connected to FCAP with sufficient numbers of fire alarms bells and shall be installed to alert sound and light alarm the shift operator during any emergency fire condition 2 The Contractor shall renovate provide install test commission and maintena
187. k month Isopropyl alcohol 1 Bottle month Mn standard solution1000 mg L 1 Bottle 12 months NaC H30 1 Bottle 4 months Nickel 1 reagent powder 1 Pack month Nickel 2 reagent powder 1 Pack month NITRAVER a NitriVer 2 NITRITE REAGENT POWDER PILLOWS tpack month NitriVer 6 NITRATE REAGENT POWDER PILLOWS 1 pack month NITROGEN NITRATE REAGENT POWDER 1 pack PILLOWS month NITROGEN NITRATE STANDARD SOLUTION 1 Bottle month Tender No SE 130 127 Document 2 III 238 PERTREATMENT KIT 1 Bottle month 239 Petroleum ether 1 Bottle month Phenol ACS 1 Bottle month PHENOL SOLUTION 1 Bottle month Phosphate pre treatment powder pillows 1 Pack month Potassium Chromate K2CrO 500 g 1 Pack 6 months Potassium hydrogen phthalate KHP 1 Pack month Potassium Sulfate 1Pack month Sodium Arsenite 1Pack month Sodium Hypochlorite 1Pack month Sodium iodide 1 Pack month Sodium NITRITE ACS 1 Pack month Sodium sulfide 1 Pack month Sodium TETRABORATE Na gt B40 1 Pack month Starch indicator 1 Pack month SULFANILIC ACID 1 Pack month Drierite 8 Mesh indicating 1 Bottle month OD vials High amp Low range 1 Bottle month Cadmium Granules 1 Bottle month K2SO 1 Bottle 4 months 4 Laboratory Miscellaneous Glasses and Plastic Wares The Contractor shall provide test and commission new laboratory miscellane
188. kers or aluminum doors with lockers glazing windows with mesh screens frames and curtains louvers vents electric installations and other accessories new interior lightings fixtures accessories and switching devices power outlets PVC false roof ceiling sheets in aluminum framing and sealed with silicon gypsum board assemblies and all required civil mechanical electrical and instrumental works as approved by the Engineer All works specifications and materials shall be subject to the Engineer approval c The Contractor shall co operate and co ordinate his operations with all other parties or Contractor s executing work on sites or adjacent to his sites of work in order that the minimum interference inconvenience is caused to the public 2 New equipment utilities and services a The Contractor shall dismantle remove abandonment of the existing pipelines valves fittings and other connections cart away to a tippers off the site from the main water source point to MPW Quality control centre The Contractor shall renovate supply erect install test commission and maintenance new UPVC pipelines connected from the main water source point to MPW Quality control centre with all fittings and other related civil works All works specifications and materials shall be subject to the Engineer approval b The Contractor shall dismantle remove abandonment of the existing water proofing insulation cart away to a tippers off the site to
189. ks required in the contract 1 Grout filling unlimited depths and full volumes of the following underground pressure pipelines completely start from the inlets pressure pipelines ends to the outlets pressure pipelines ends of minimum pressure pipelines lengths m until the volumes of the underground pressure pipelines are completely full with mix flowable fill materials with no voids remain unfilled All the works shall be approved by the Engineer and EPA Tender No SE 130 57 Document 2 III Type Diameter of Nos of Length of Outlet of Inlet of of pipeline pipelines pipeline pipeline Pipeline Item pipeline mm m material Asbestos 450 2 5100 A11 A1 1 GRP 450 2 pato A11 A13 2 Asbestos 700 2 3500 A11 A2 3 Ardiya A11 4 Asbestos 1000 2 16000 sewage plant DI 1000 2 Rikka A15 5 3100 sewage Plant Note Item 1 means Grout filling unlimited depth and full volumes of underground double pressure pipelines completely each pipeline Length 5100 m Diameter 450 mm Type asbestos start from the inlets of double pressure pipelines ends connected to main pumping station A1 to the outlets of double pressure pipelines ends connected to main pumping station A11 Therefore the total length required to grout filling unlimited depth and full volumes of underground pressure pipelines is 5100 m x 2 pressure pipelines 10200 m until the volumes of the underground double press
190. l and builder works as may be required for proper completion of the above mentioned works 2 EAD Environmental Affair Department 1 The Contractor shall be responsible of electrical renovation works required to provide a powerful and protected electrical supply to the EAD Environmental Affair Department located adjacent to Ardiya sewage plant within two 2 years starting from the Date of Enterprise 2 The Contractor shall investigate and check thoroughly the actual loads at the EAD Environmental Affair Department buildings and facilities and estimate the actual supply power required for each division and service of EAD in order Tender No SE 130 86 Document 2 III to select the proper equipment and cables of the electrical panel at S S 1 Module No 02 SU 0241 The Contractor shall coordinate with the EAD Environmental Affair Department authorities to evaluate the electrical power needs for the offices laboratory equipment and facilities and their future need as may be required by the department manager as well as the connection points and proper routes of the new cables The Contractor shall replace the old existing supply cables laid between the substation SU 0241 and the main LT panel of EAD Environmental Affair Department by a new higher capacity cables and repair or replace any damaged part or component of the existing LT panel before commissioning of the works Renovation Rehabilitation
191. l be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of Works A Maintenance works of mechanical and electrical equipments Instrumentation air conditioning units office equipments laboratory equipments exterior and outdoor lightings poles and networks furniture utilities services and other related works 1 The Contractor shall be fully responsible for the proper maintenance and repair or if required replace of the existing and new mechanical and electrical equipments instruments air conditioning units and lightings fixtures and networks of zone area Tender No SE 130 143 Document 2 III 1 facilities starting from the Date of Enterprise for the duration of the contract period as approved by the Engineer and shall include but not limited to MPW Quality control centre furniture and equipments laboratory furniture equipments and devices guard house furniture and equipments substation SU 0241 mosque office equipments street lightings safety equipments outdoors lightings main entrance gate conveyor rod nearby main gate EPABX central telephone system and extension lines fire protection system fire detection alarm system lightings and power system electrical renovation works required to EAD Environmental Affair Department motors pipe works water pipelines
192. l not close or obstruct any portion of a street road or private way without obtaining permits therefore from the proper authorities If any street road or private way shall be rendered unsafe by the Contractor s operations he shall make such repairs or provide such temporary ways or guards as shall be acceptable to the proper authorities Streets roads private ways and walks not closed shall be maintained passable and safe by the Contractor who shall assume and have full responsibility for the adequacy and safety of provisions made therefore 2 The Contractor shall at least 24 hours in advance notify the Police and Fire Departments in writing with a copy to the Engineer if the closure of a street or road is necessary He shall cooperate with the Police Department in the establishment of alternate routes and shall provide adequate detour signs plainly marked and well lighted in order to minimize confusion Tender No SE 130 17 Document 2 III Maintenance and protection of vehicular and pedestrian traffic through areas and furnishing erecting and maintaining temporary traffic control devices including barriers barricades cones drums warning signs and lights No work shall be performed during the hours of darkness unless otherwise authorized in writing by the Engineer Detours Works shall comprise but not be limited to necessary field surveys the Disconnect Dismantle Demolish and Abandonment existing facilities Renov
193. l trowel Primer for concrete shall be suitable for use with the waterproofing membrane 18 The Contractor shall provide install commission and maintenance a local telephone line and instrument connected to the new EPBAX which is installed in the MPW Quality Control Center interior lightings new A C split unit The extent of work shall include but not limited to replacing damaged aluminum doors with lockers glazing windows with mesh screens frames louvers and vents and other required works as directed by the Engineer 19 The Contractor shall design provide install test commission fire extinguishers not less than 1 No as per recommendation of KFB regulations and shall be refilled or inspected by KFB yearly The Contractor shall provide install test commission and maintenance new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval 20 The Contractor provide install test commission and maintenance sufficient smoke and heat detectors in each room as per the KFB approved procedures and shall be connected to FCAP with sufficient numbers of fire alarms bells and shall be installed to alert sound and light alarm the shift operator during any fire condition The fire alarm indication panel shall be installed atthe guard house near the main entrance gate of Ardiya sewage pla
194. l types of structures facilities 2 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 9596 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 3 The extent of works shall include but not limited to demolish concrete structures asphalt roadways concrete roadways foot pathways interlock tiles curbstones and sites paving areas break remove abandonment cart away to a tippers off the sites transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval Tender No SE 130 37 Document 2 III 4 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth of excess areas as approved by the EPA and the Engineer landscaping grading compacting 9596 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of t
195. le and remove the existing water proofing roof insulation and cart away off site The Contractor shall provide install test commission and maintenance new water proofing roof insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with steel trowel Primer for concrete shall be suitable for use with the waterproofing membrane 3 The Contractor shall dismantle remove abandonment of the existing pipelines valves fittings and other connections cart away to a tippers off the site from the main water source point to effluent transfer pumping station The Contractor shall renovate supply erect install test commission and maintenance new UPVC pipelines connected from the main water source point to effluent transfer pumping station with all fittings and other related civil works All works specifications and materials shall be subject to the Engineer approval 4 The Contractor shall renovate provide paint test commission and maintenance internal exterior walls and roof
196. lecting Bulb No 4 V AAS Cathode Lamps MII x Fe Mn Ni Cr Zn Ca Hg Cd Pb Na B Cu Co Mo K and Mg No 1 Ba Be Al V As Se and Sr No 1 Regulator Pressure Gauge No 1 eee eee E Automatic Titrator Probe uu Ammonia No 1 Chloride No 1 Nitrate No 1 d Oxygen Dissolved No 1 Silver Sulfide No 1 pH No 1 Settlometer Kit Pack 1 Regular Glass Desiccators No 1 Desiccators Plate No 1 Ammonia Electrode No 1 Hydrometer No 1 Note Tender No SE 130 118 Document 2 III Complete set of Microscope Camera and Television Microbiology equipment shall include but not limited to the following requirements and subject to the Engineer approval Solid state CCTV system and color monitor 21 inch graduated mechanical illumination system provides 6 volts 20 W tungsten halogen in base illuminator in both 120 V or 240 V high quality glass optics to assure clear images and sharp resolution over entire field of view separate On Off switch Rheostat intensity control and illumination indicator light Achromatic and Panchromatic engraved serial number stable C shape stand and wide base Accessories and connections 35 mm camera and photographic accessories with a tri ocular body CCTV application a tri ocular or separate adaptor mount polarizing accessories dark field accessories and phase contrast kit 2 The Contractor shall include supply test commission and maintenance these items as minimum requirements and sh
197. level of the water table and all factors affecting the Works and shall be deemed to have allowed for these in his Tender Clause 6 Contractor use of sites The Contractor shall also ascertain from the public utility authorities and the positions of all existing underground services Tender No SE 130 9 Document 2 III Clause 7 Electricity The Contractor shall make arrangements with Ministry of Electricity and Water for temporary electricity connection required for removal of existing equipments and new installations all expenses in connection with installation and removal thereof shall be paid by the Contractor Adequate temporary standby electric generators and distribution network and connections shall be provided by the Contractor as he deems necessary until connections become available for emergency use The cost of regular electrical energy consumed for the operation of existing facilities shall be paid by the Ministry Clause 8 Water The Contractor shall furnish water of the required and as may be necessary for work or for other purposes and shall make arrangements for and pay all charges for water services installation maintenance and removal thereof and vehicles costs of water Adequate water storage facilities and vehicles for transport of water shall be provided by the Contractor as he deems to be necessary The Contractor shall provide an adequate supply of drinking water of acceptable quality satisfactorily coole
198. limited depths and full volumes of the following double underground pressure pipelines completely including demolish dewater dismantle break Tender No SE 130 6 Document 2 III remove abandonment and earth fill of hatch boxes with other related works within three 3 years starting from the Date of Enterprise a 2 450 mm Length 5100 m asbestos start from main pumping station A1 to main pumping station A11 b 2 450 mm Length 5500 m GRP start from main pumping station A13 to main pumping station A11 c 20700 mm Length 3500 m asbestos start from main pumping station A2 to main pumping station A11 d 251000 mm Length 16000 m asbestos start from main pumping station A11 to Ardiya sewage plant e 2 5 1000 mm Length 3100 m DI start from main pumping station A15 to Rikka sewage plant 3 Groutfilling unlimited depths and full volumes of the following underground gravity pipelines completely including demolish dewater dismantle break remove abandonment and earth fill of manholes completely with other related works within three 3 years starting from the Date of Enterprise a 1 1600 mm Length 3100 m asbestos start from Transition Chamber TC to main pumping station A15 b 12 450 mm Length 3240 m asbestos start from secondary lifting stations S11 S12 to main pumping station A2 c 142 700 mm Length 2400 m asbestos start from secondary lifting station S13 to main pumping s
199. limited to aggregates fly ashes potable water additives and admixtures as necessary required to control of pumping mix flowable fill materials properly and self leveling placements without shrinkage All the works shall be approved by the Engineer and EPA 3 Provide install transport and commission grouting equipments and pumps of mix flowable fill to the site in ready unlimited quantities of mix trucks to pump mix flowable fill continuously with sufficient pressure to overcome friction and prevent nesting and void formation The Contractor shall follow procedures with sufficient safety precautions and care to avoid damage to existing underground utilities structures The quantities of machineries trips are not limited to be available on demand The Contractor shall maintain safe access to adjacent property and buildings The Contractor shall provide experienced crews to perform filling operation to monitor density of mix flowable fill and to control pressure The extent of works shall include but not limited to furnishing installing and maintaining temporary traffic control devices barriers barricades cones drums warning signs fencing and lights for the protection of vehicular and pedestrian traffic After the termination of the contract the mobile equipment or machineries shall remain the property of the Contractor All the works shall be approved by the Engineer EPA and Ministry of Interior Traffic Department Tender No SE 130
200. link boundary fence with barbed wires within the perimeter chain link fence 800 m 440 m 800 m 440 m completely height 2 m and shall include but not limited to concrete foundation 0 5 m for the perimeter fence columns rods to tighten the new chain link boundary fence and barbed wires within two 2 years starting from the Date of Enterprise All works materials and specifications shall be subject to the Engineer approval The Contractor shall be responsible for obtaining MPW approval prior to the start the execution of the works Tender No SE 130 72 Document 2 III 2 The Contractor shall renovate provide install test commission operate and maintenance two 2 new isolated separatesmotorized front entrances gates for the exit entry vehicle entrance gate and new pedestrian entrance gate of zone area 1 with all required accessories within two 2 years starting from the Date of Enterprise One gate width of at least 6 0 m for vehicular entrances and height of 2 5 m from finished grade with metal lockers The other isolated separate gate shall be width of at least 2 0 m for pedestrian entrances and height of 2 5 m from finished grade with metal lockers The operation of the gates shall be controlled from the guard house completely The new main gates shall be motor operated gates which move on rail laid across the access operating to the entrance 3 The Contractor shall renovate provide install test commission operate and
201. ll safeguard all spare parts and other maintenance items 18 The Contractor shall provide all tools and equipment necessary to perform the maintenance services These shall be returned to the Employer at the end of the contract period and shall be returned in good condition In addition should the Contractor require additional or replacement tools or equipment for the performance of maintenance services he shall procure and perform the maintenance services at his own expense Tender No SE 130 145 Document 2 III The minimum list of tools test equipment and accessories to be provided by the Contractor for electrical work is as follows Relay tester for current relays 0 30 Amps Relay tester for voltage relays 0 220 volts Megger 500V 1000V Digital Avometer 0 600 1 10A Digital Clamp meter 0 600V 0 1000 Amp Multi range type Electric Blower Drier Electric Vacuum Cleaners Complete set of hand tools Battery Voltage tester Hydrometers Earth Tester Portable battery charger 12V 24V Neon Tester 6 6KV Multi gases detector H2S gas detector sese gt p sg m n cues 19 The maintenance service and repair works to be conducted and provided by the Contractor involves preventive maintenance corrective maintenance and troubleshooting works comprising of general maintenance overhaul repair and emergency maintenance and calibration of entire equipments instrumentation air Conditioning units lightings networks and other rela
202. mber of pending RFls Security of approvals given to documents shall be ensured in PIMSS by tracking and logging of documents For example when an RFI was sent through PIMSS the computer IP address and user details must be tracked and logged for review 5 Reporting of project progress parameters such as budgeted and actual costs and time change orders project resource tracking and locations and other key performance indicators in agreement with the Engineer and Engineer s Representative in an executive summary dashboard from which further details can be obtained Tender No SE 130 154 Document 2 III 6 Start of implementation of PIMSS shall be within two weeks of the Date of Enterprise and shall be completed within two months from Date of Enterprise PIMSS and related hardware such as servers minimum 400 users or in accordance with the size and nature of the contract and subjected to the approval of the engineer workstations laptops computers fiber optical networking ADSL internet service etc subject to the approval of Engineer s Representatiove shall be provided and maintained in functional condition during the period of construction operation and handing over the project site If the system be needed beyond this time instructions will be issued by the Engineer and fair recompose awarded to the Contractor 7 Implementation and use of PIMSS does not entitle the Contractor to disregard legal contractual obligations and responsib
203. me c Date and reference number of the correspondence site memos 4 Progress reports shall include but not limited to color photos described hereinafter in a form provided by the Engineer or Engineer s Representative Work activities and procurement reports should be referenced where relevant to the approved Contractor s works Schedule 5 Daily Weekly Monthly Yearly and Final Report supported with charts and color photographs described all works activities and contractor staff as specified in the contract requirements for the Engineer approval 6 Procurement Status Report Submit the Procurement Status Report shall include but notlimited to the submittal and preparation status of shop drawings materials submittals samples catalogues of equipment approval status procurement of materials and delivery dates to site 7 Monthly Report Submit a detailed report reflecting the monthly progress and status of work This report shall include a description of problem areas current or anticipated causes of delay and their estimated impact on progress together with a description of corrective measures taken or proposed One copy of the latest approved Contractors CPM Schedule with updated logic time shall be attached to the Monthly Report 8 Yearly Report Submit a detailed report reflecting the yearly progress and status of work This report shall include a description of problem areas current or Tender No SE 130 15 Document 2 III
204. mechanical equipments cut pipes remove abandonment and cart way to a tippers off the site effluent transfer pumps 3 Nos completely with all fittings suction and discharge pipes valves header pipe supports gauges and drain pipes pump foundations electrical panel cables and all other related accessories and utilities as approved by the Engineer 3 Removed equipment and fittings shall be cleaned thoroughly and overhauled by the Contractor packed and transported away to MPW store or as directed by the Engineer 4 The extent of works shall include but not limited to disconnect dismantle remove abandonment and cart away to a tippers off site surge vessels VS 0661 4 Nos completely with all fittings discharge pipes valves gauges foundations electrical panel cables and all other related accessories and utilities as approved by the Engineer 5 The Contractor shall close the open end of the remaining part of header pipe and any other pipe works by a steel gasket flange of the correct size and material reasonable to withstand the maximum pressure of the effluent water 6 The Contractor shall carry out complete overhauling and maintenance work for the remaining effluent transfer pumps 3 Nos and remaining surge vessels 4 Nos with all related pipe works pipelines and fittings valves pressure gauges motor panel and other civil mechanical and electrical The capacity of pump is 835 liter sec at 978 rpm and 600 liter sec
205. ment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The Contractor shall submit the method of grout filling unlimited depths and full volumes of the underground gravity pipelines completely start from the inlets gravity pipelines ends to the nearest manhole then pump mix flowable fill materials from manhole to manhole continuously to the outlets gravity pipelines ends of different gravity pipelines lengths m diameters mm and materials type of pipes until the volumes of the underground gravity pipelines are completely full within one 1 month starting from the Date of Enterprise for approval by EPA Environment Public Authority regulations MPW and other governmental authorities and shall include but not limited to plan activities techniques of the injection points until the mix flowable fill materials emerges from vent pipes discharge pipes to ensure no voids remain unfilled compressive strength test report mix flowable fill materials with admixtures grout fill equipment and pumps preparation works to clean pipelines and remove wastewater or any other blockages operational procedures groundwater investigations proposed of grouting sequence grout pressure flow grout plug or cap and sealing p
206. ment or revision of such reference standard in effect as of the date of submission of these Tender Documents by the Tenderers to the issuing authority 3 The Contractor shall obtain an original copy of the latest edition of all codes local and administrative orders regulations standards and technical literature referred to in the Contract Documents including those referenced in the Contractor s Quality plans These shall be given to the Engineer at no additional cost within 30 days of receipt of the Engineer s Notice to Proceed 4 Upon completion of the works the said codes standards etc shall be handed over to the Ministry 5 Abbreviation Standards AASHTO American Association of State Highway and Transportation Officials ACI American Concrete Institute AISC American Institute of Steel Construction AISI American Iron amp Steel Institute ANSI American National Standards Institute ASTM American Society for Testing Materials AWS American Welding Society BSS British Standard Specifications CP British Standard Code of Practice DIN Deutsche Industrial Norm FS Federal Specifications IEC International Electrical Commission IEEE Institute of Electrical and Electronics Engineers IPCEA Insulated Power Cable Engineers Association ISO International Standards Organization MBMA Metal Building Manufacturers Association MEW Ministry of Electricity and Water MOC Ministry of Communications Kuwait MPW Ministry of Public Works
207. mits of the foundations slabs and walls of manholes The reinforced concrete cover slabs shall be carefully broken to maintain metals covers and frames The extent of work shall include but not limited to dismantle remove abandonment and cart away to a tippers off the site other related parts and connections shall include but not limited to all existing step irons ladders fences concrete passing slabs covers frames and all other related parts Frames and metals covers shall be cleaned and sand blast to remove any corrosion product paint with two coats of coal tar paints and deliver to MPW stores off site The extent of works shall include but not limited to provide install and commission suitable plug or cap and sealing pipes ends surfaces completely connecting to the manholes either by filling pipe ends surfaces with dry pack grout mixture or installing manufactured cap to form water tight seal The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth areas after demolishing manholes as approved by the EPA and the Engineer landscaping grading soil compacting 95 MDD and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The extent of works shall include but not limited to clean remove cart away off the site transport and dispose all existing extraneous materials sh
208. moved by under bottom draw off pipe DN 700 controlled b telescopic weir valve and Drain valve in overflow chamber Scum removal facility consists of scum skimming board fixed to the bridge scum box fixed to the walls of effluent channel discharge underground pipe DN 200 to scum liquid separator with pumping PS 0432 Return Sludge Lifting Station PS 0431 Concrete structure Three screw pumps for returning sludge to bioreactor BR 0412 helix diameter 1400 with supporting pipe shaft DN 711 helix length 10 460 Helix rotation speed 44 4 min Inclination 30 degree Three sump pumps for returning sludge to bioreactor BR 0411 Capacity 700 m h each head 7m Three gates and three check valves DN 500 Two excess sludge pumps to thickeners at Module 08 Two gates and two check valves DN 150 One magnetic flow meter DN 125 Two monorails with electrical driven hoists fixed to the ceiling Scum Pumping Station PS 0432 Scum pumping combined with scum liquid separation Liquid is pumped to mixed liquor distribution chamber before clarifiers Scum is removed manually onto dewatering concrete pad Two submersible pumps Two gates and two check valves DN 125 Scum Network Underground pipelines DN 200 from three scum box in clarifiers to the scum liquid separator PS 0432 Sewage Channels and Pipeline Mixed Liquor amp Effluent Raw sewage gravity channel from degitters DG 0102 amp DG 0103 to
209. mp sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies fuels grease oil consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work in a safe manner but not limited to all the following works and subject to Engineer approval i General Tender No SE 130 142 Document 2 III 1 The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities 2 The Contract shall submit request of inspection of all required activities works in according to contract requirements for approval by the EPA and the Engineer 3 The Contractor shall be responsible for maintenance and rectification of all damaged utilities and other services affected during the works at no extra cost 4 The Contracto
210. mpletely within one 1 year starting from the Date of Enterprise and shall include but not limited to Instruments to measure temperature and humidity High chemical and corrosion resistant epoxy benches Suspended Cabinets for glass wares Tender No SE 130 114 Document 2 III Safety storage cabinets class 2 with UV light equipment Safety storage cabinets for acids and dangerous chemicals Steel shelves Safety precaution facilities equipments tools cloths and materials shoes gloves rechargeable torch lights white coats large First Aid Kits helmet and other safety materials Oil heater Insect killer lights with twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure A C split unit 3 5 Tons with compressor 16 The extent of works shall include but not limited to all related civil mechanical electrical and instrument works as approved by the Engineer 2 Laboratory Equipments and Devices The Contractor shall provide test and commission new laboratory equipments and devices within one 1 year starting from the Date of Enterprise and shall include but not limited to the following minimum new laboratory equipments and devices requirements The Contractor shall be obligated to submit operation and maintenance manuals in accordance to manufacturers and fulfill other requirements of new laboratory equipments and devices and shall not have the right to claim for comp
211. n a safe manner but not limited to all the following works and subject to Engineer approval i General 1 The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations MPW and other governmental authorities to execute renovation works at Ardiya sewage plant within two 2 weeks from the Date of Enterprise The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities for the safety of manpower and fire precaution on sites within two 2 weeks from the Date of Enterprise The Contract shall submit request of inspection of all required activities works in according to contract requirements for approval by the EPA and the Engineer The Contractor shall be responsible for maintenance and rectification of all damaged utilities and other services affected during the works at no extra cost The Contractor shall require w
212. n all materials and equipment called for in the Contract Documents as well as carefully removal of the existing materials and equipment packing transporting them safely to MPW store 6 A complete installation shall include any sundry items or components may be necessary or as specified by the Engineer Such items whether mentioned or not shall be included at no extra cost to the contract sum 7 No claims will be admitted if the Engineer specifies additional requirements or any modification to achieve the system to his satisfaction such work will be executed and carried out through the same contract price without any additional cost to the ministry 8 All builder s works such as chasing of walls grouting of bolts construction of foundation as necessary trenches with Chaucer plate covers building of cable manholes earthling pits and fitting laying of ducts ceiling of ducts excavation of trenches backfilling and consolidation carting away of surplus soil etc shall be executed by the Contractor and the full and entire cost of all such builder s works and materials shall be included in the total bid amount 9 The works assign to this item shall include but not limited to disconnect dismantle and remove of the existing switchboards distribution boards Motors Control Center MCC Control panels batteries and battery chargers and all other electrical equipment in MPW Switchgear room at substation S S 6 including transport all of
213. n of MEW It is the Contractor responsibility to obtain MEW approval of his design criteria and installation ideas on the shop drawings prior to start of any Electrical Works and for the connection of the Electrical supply Upon completion of the Electrical Work the Contractor shall be responsible for obtaining MEW approval for the whole installation or modification or any part thereof including supervision of MEW representative on the final testing and energizing the panels and setting to work The Contractor shall acquaint himself with the latest issue of the rules and regulations of Electrical installation work of the Ministry of Electricity and water MEW It is the Contractor responsibility to obtain the latest copies of these regulations at his own expense and there will be no consideration for any such unawareness of these requirements The Contractor shall check and allow in the Contract prices for obtaining any permits licenses or paying rents and fees for any authorities necessary for starting carrying out completing setting to work and handing over in an operating and good performance A complete installation shall Tender No SE 130 47 Document 2 III include any sundry items or components may be necessary or as specified by the Engineer Such items whether mentioned or not shall be included at no extra cost to the contract sum 7 All builder s works such as chasing of walls grouting of bolts construction of foundation as
214. nce of sufficient numbers of fire extinguishers not less than 6 Nos as per recommendation of KFB regulations and shall be refilled or inspected by KFB yearly Also the Contractor shall consider the approval according to KFB regulations 3 The Contractor shall renovate provide install test commission operation and maintenance new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval h Air Conditioning and Utilities 1 The Contractor shall disconnect electrical supplies dismantle electrical and mechanical equipments cut pipes remove abandonment and cart way to a tippers off the site old existing HVAC package units and its related ducting system completely from effluent transfer pumping station and cart away to the MPW store The Contractor shall renovate provide install test commission and maintenance new HVAC system not less than 2 Nos x 25 tons with two compressors for effluent transfer pumping station The Contractor shall renovate provide install test commission and maintenance the ducting system according to the system capacity for the cooling and the ventilation requirements Tender No SE 130 96 Document 2 III 2 The Contractor shall renovate provide install test commission and maintenance new telephone instrument multi memories with telepho
215. nd other joints corrective measures to ensure water tightness replacing defective joints and water stops All works materials and specifications shall be subject to the Engineer approval 6 The Contractor shall disconnect dismantle and remove existing fresh water pipelines and fittings from the main water source point to new guard house and cart away off the site The Contractor shall renovate provide install commission Tender No SE 130 79 Document 2 III and maintenance new UPVC pipelines connected from the main water source point to new guard house including all fittings and other related accessories All works materials and specifications shall be subject to the Engineer approval 7 The Contractor shall dismantle remove and cart away kitchen facilities from guard house off the site and renovate provide install test commission and maintenance new kitchen for guard house with other services such as plumbing fittings kitchen equipment and electrical works Also the works shall include install and assemble new quality standard fabricate cabinets doors and frames of high pressure decorative laminate finished 19 mm thick MDF board unit kitchen to be aligned and secured adjoining cabinet units and counter tops with the following components but not limited to top counter granite surface drawers and shelves 12 mm thick hardboard or plywood 1200 mm wide stainless steel sink unit with integral embossed drain board faucets separa
216. nd shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 36 Security A The Contractor shall be fully responsible not to allow any unauthorized persons or vehicle entering the sites without prior permission from the Ministry The Contractor shall be fully responsible to protect his staff from escaped wild animals especially dogs The Contractor shall provide two persons security officers to be available in the plant for 24 hours during the contract period B Restrict entrance of persons and vehicles into Project sites Allow entrance only to authorised persons with proper identification Maintain log of workmen and visitors make available to Employer or Engineer on request C Coordinate access of Employer s personnel to sites D The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 37 Temporary Controls A Dust Control Execute work by methods to minimise raising dust from the sites Provide positive means to prevent airborne dust from dispersing into atmosphere B Erosion and Sediment Control 1 Plan and execute methods to control surface drainage from cuts and fills Tender No SE 130 27 Document 2 III from borrow and
217. nd workshop civil instrumentation mechanical and electrical miscellaneous parts completely within the boundary area of the fence and all related fixtures and accessories 3 The extent of works shall include but not limited to clean paint re usable miscellaneous mechanical and electrical equipments instruments and devices tools pumps valves hoses etc cart away to a tippers off the site and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them 4 The extent of work shall include but not limited to clean remove non usable ferrous metals accumulated on site within the boundary area of the perimeter fence cart away to a tippers off the site and delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer 5 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 6
218. ndards Carting away dismantled equipments and demolished structures Safety Specific Site works Contractor s staff Specifications and Appendixes Handling and Distribution Sign Board Temporary Fire Protection Temporary stairs scaffolding ladders ramps runways Temporary material and personnel hoists Barriers and Enclosures Tender No SE 130 4 Document 2 III Clause 35 Utilities Clause 36 Security Clause 37 Temporary Controls Clause 38 Temporary Drainage Clause 39 Lines Grades and Measurements Clause 40 Information and Photography Clause 41 Final Cleaning Clause 42 Special Systems Tender No SE 130 5 Document 2 III Document 2 III Part A General Requirements Clause 1 Summary of works a General The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities b Scope of the works Section A Demolish Disconnect Dismantle and Abandonment existing facilities 1 Demolish Ardiya sewage plant except zones areas 1 amp 2 and partial of sanitary sewerage system and partial of s
219. ndary area of new fence area 800 m long x 440 m width as approved by the Engineer 7 The extent of works shall include but not limited to renovate provide erect install commission and maintenance along both sides of new double layers main roadways and internal strip double layers asphalt roadways with different new street signals and signboards e g arrows direction to reach all facilities road markings and signs safety signals signboard for each facilities names etc 8 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 9 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill unlimited depth of excess areas as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 10 The Contractor shall be deemed to have carried out his own investigations to ascertain himself the nature of the soil conditions and the groundwater level The Contractor shall provi
220. ne cards and tags numbers plates so that to be easily identified without the necessity of unpacking them f Disconnect the electricity supplies dismantle mechanical and electrical equipments clean grease cart away to a tippers off the site and transport to MPW stores reusable A C split units central A C unit and window air conditioners clean units tag them in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them g Disconnect remove clean cart away to a tippers off the site and transport to MPW stores reusable mounted panels in control rooms and substations and shall include but not limited to MCC cables control room panels and hardware sensors transmitters alarms and all other related electrical accessories and connections to be carried in closed containers cart away to a tippers off the site transport and dispose to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking the Care shall be taken to protect switches instruments etc on the front of the panels during transport to MPW stores off site h Disconnect the electricity supplies dismantle mechanical and electrical equipments remove clean grease paint re usable spare parts of different equipment sets then assemble them together
221. ne connection network of the effluent transfer pumping station and shall be taken connection extension line from the new EPBAX which is installed in MPW Quality Control Center All works and materials shall be subject to the Engineer approval 3 The Contractor shall renovate provide install test commission and maintenance new emergency lights fixtures not less than 20 Nos sufficient to allow enough illuminators for the movement of operators during the power failure The emergency light fixtures shall be twin bulb holder type with aluminum reflector weather proof industrial type 12 Volt with inbuilt battery 6 x 10 AH and battery charger shall be thorn make or equivalent The capacity of Bulbs shall be 2 x 35 W The layout type and the numbers of fixtures shall be approved by the Engineer 4 The Contractor shall be responsible for the renovation and rehabilitation of the electrical power system telephone network and electrical lighting system The Contractor shall disconnect dismantle remove all existing lighting system carting off site and reinstalling the entire lighting fixtures control networks ventilation fans motor control etc and all the cables of all pump motors which are in operation The lighting fixture shall be 250 W pendent types high bay type fixtures with HPMV lamps all control devices like power outlets and switches all wiring accessories conducts wires etc All exhaust fans of identical size shall be replaced Th
222. netic flow meters DN 150 for turbid water e Turbid water piping with 4 gate valves and 2 check valves DN 150 e Electrical control boxes for the above thickener bridges thickened sludge pumps and turbid water pumps e Transmitter boxes for above sludge and turbid water flow meters Sludge e Load tankers filling station near thickening complex TH Filling Stations 0821 TH 0864 near drying beds including one filling Fl 0861 Fl 0864 pipe and hose DN 150 each e Operation by control box for thickened sludge pumps e Concrete structure Sludge Digesters e Two digester circular DR 0811 amp DR 0812 hermetic Complex tanks internal diameter of tank 20 m effective sludge DR 0811 DR 0812 volume 4700 m glass hatch with wiper on top of tank Two units e Flame arresters and vacuum pressure releasing valves on each digester e One gas compressor on each digester e Gas filtration vessel with ceramic cartridges on compressor sucking pipe on each digester and one near boiler house with gas flow meter e Control box for compressor e Sixteen gas injectors lances in each digester e Piping system with valves connecting compressor with injectors e Gas vessel with gate valve DN 150 for gas produced leading to gas holder Boiler House e Two water boilers with diesel fuel burner pump and hot BH 0831 water pump Electrical control panel for boilers Two tube type heat exchangers Three sludge circulation pump
223. ng gate valve DN 150 on each bridge Submersible pump operates in each clarifier Scum Network Chambers underground pipelines and manholes Pits at machine house Electrical Panel EP 0201 Panel for six clarifiers of Module 02 Process air pipelines Pipeline DN 500 to bioreactor BR 0211 Pipeline DN 550 to bioreactor BR 0212 Sewage Mixed Liquor amp Effluent Channels Concrete gravity open channels for sewage terminated in distribution channels to bioreactors mixed liquor channels and two distribution chambers to clarifiers Inlet to above units is controlled by slide gates Sludge Discharge amp Return Networks Gravity underground pipelines discharging sludge four clarifiers to pit at the machine house common pipe at the pit DN 1000 Four pipelines from pumps in machine house to bioreactors To bioreactor BR 0211 one pipeline DN 400 To bioreactor BR 0212 two pipelines DN 500 each To bioreactor BR 0203 one pipe line DN 600 with 2 branches DN 600 to BR 0203 and BR 0402 Excess sludge Pipeline One force underground pipeline DN 200 from machine house to thickeners at Module 07 Sludge Flow meter Chamber FC 0254 One magnetic flow meter Tender No SE 130 168 Document 2 III Sludge Flow meter Chamber FC 0255 Two magnetic flow meters located between Machine House and grease amp oil shelter Six gate valves DN 200 for interconnections of two sludge
224. nications MOC The Kuwait Fire Brigade KFB The Kuwait Municipality KM Ministry of Public Health MPH Roads and Drainage Department of MPW NOoarwnh gt Tender No SE 130 8 Document 2 III 8 Public Authority for Agriculture and Fisheries Resources PAAFR 9 Ministry of Interior Traffic Department 10 Environment Public Authority EPA Clause 4 Study the sites by the Contractor A Notwithstanding anything contained in the contract documents the Contractor shall deemed to have visited the sites studied the contract documents and by his own observation and enquiry acquainted himself with local conditions the existence and accuracy of local records and drawings the accessibility of the sites including all works areas outside the fence for the full proper execution of the contract requirements including but not by way of limitation to the following The strict observance of stringent safety precaution regulation The supply and use of labors materials equipment laws status rules and regulations relevant there to The meaning of every item mentioned in this document or specified and or entered in the bills of quantities The conditions of equipment structures and all other relevant things necessary for the proper execution of the works required by this contract according to the technical requirements B The sum of the contract price shall be deemed to cover all obligations mentioned in this contract
225. nit 3 5 tons with compressor 2 Nos for the guard house The Contractor shall be responsible to rehabilitate and erect wall section area to close the existing opening window area 20 The Contractor shall renovate provide install test commission and maintenance sufficient numbers of fire extinguishers as minimum 2 Nos Out of the two extinguishers one shall be water type and one shall be CO type and these shall be of Minimum of 10 Kg capacity Better alternate shall be also provided as per recommendation of KFB regulations and shall be refilled or inspected by KFB yearly Also the Contractor shall consider the approval according to KFB regulations The Contractor shall renovate provide install test commission and maintenance new fire protection system and cabinet fire hoses racks and nozzles fire detection alarm system and lightning protection according to KFB regulations All works and materials shall be subject to the Engineer approval 21 The Contractor renovate provide install test commission and maintenance with sufficient smoke and heat detectors as per the KFB approved procedures and shall be connected to FCAP with sufficient numbers of fire alarms bells and shall be installed to alert sound and light alarm the shift operator during any fire condition 22 The Contractor shall be fully responsible not to allow any unauthorized persons or vehicle entering the site without prior permission from the Ministry The Contr
226. non permit Tender No SE 130 20 Document 2 III confined space and permit required confined space A non permit confined space does not contain atmospheric hazards or have the potential to contain any hazard capable of causing death or serious physical harm Examples of non permit confined spaces include vented vaults or motor control cabinets These spaces have either natural or permanent mechanical ventilation to prevent the accumulation of a hazardous atmosphere and they do not present engulfment or other serious hazards Since non permit spaces are free of atmospheric or safety hazards they do not require special entry protocols However entry into these areas must comply with applicable OSHA requirements i e illumination ladders etc A permit required confined space has one or more of the following characteristics a Contains or has the potential to contain a hazardous atmosphere b Contains a material that has the potential for engulfing a person C Has an internal configuration such that a person could be trapped by inwardly converging walls or by a floor which slopes downward and tapers to a smaller cross section d Contains any other recognized serious safety or health hazard Atmospheric Testing of Permit Required Confined Spaces All permit required confined spaces must be considered dangerous before entry until proven safe Air monitoring shall be performed before removing the cover if practicable Some covers
227. ns for street and external lightings 2 The Contractor shall design renovate provide install erect test commission operation and maintenance new street lightings poles as minimum 15 Nos to be mounted along new main double layers asphalt roadways of zone area 2 and parking areas and shall include but not limited to back entrance gate substation No 6 SU 0641 second stage contact tank Module 06 CT 0612 or header tank inlet and outlet channels of header tank by pass channel to sea which is connected to outlet channel of header tank effluent transfer pumping station Module 06 PS 0633 or new pumping station surge vessels tanks Module 06 VS 0661 4 Nos within two 2 years starting from the Date of Enterprise in accordance with MEW standard specifications for street and external lightings 3 The Contractor shall acquaint himself with the latest issue of the rules and regulations of Electrical installation work of the Ministry of Electricity and water MEW in Kuwait It is the Contractor responsibility to obtain the latest copies of these regulations at his own expense and there will be no consideration for any such unawareness of these requirements 4 The extent of works shall include but not limited to design provide renovate install erect test commission operation and maintenance as minimum 15 Nos new outdoor type bollard poles with 70 watts MLL lamps for landscape and beautification areas parking areas around
228. nsation in time or cost Clause 32 Temporary stairs scaffolding ladders ramps runways 1 Provide and maintain all equipment such as temporary stairs scaffolding ladders ramps runways chutes tower cranes and or other hoisting facilities etc as required for the proper execution of works 2 As soon as permanent stairs are erected provide temporary protective treads handrails and shaft enclosures The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 33 Temporary material and personnel hoists A Provide temporary material hoists to the Engineer s or Engineer s Representative s approval and as required to facilitate execution of the Works Such hoists shall be erected and maintained in compliance with any local regulations and in accordance with ANSI A10 5 Safety Requirements for Material Hoists and shall not be used for transporting personnel B Hoists shall be erected and maintained in compliance with any local regulations and in accordance with ANSI A10 4 Safety Requirements for Personnel Hoists C All hoists shall be constructed maintained and removed so as not to cause damage staining of the permanent work D The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for t
229. nstallations and fittings lightings networks equipments and wiring installations air conditioning units all equipment or parts thereof instruments motors pumps valves screw pumps compressors surge vessels filters vessels fans drums platform scales detectors filling points tanks inlets and outlets channels valves control panels transformers windows doors safety equipment laboratory devices and equipments sucking fans ventilation fans scrubbers storage tanks foul air pipes belt filter presses polymer storage dosing tanks belt conveyors fuel tanks lightings installations chlorinators ejectors evaporators inlets and outlets channels blowers control rooms panels underground services and utilities cables wires earthling rods electrodes MCC sensors etc and all related fixtures and accessories b The extent of work shall include disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments laboratory rooms of building AB 1042 demolish and break concrete structures cut pipes remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site but not limited to instruments equipments and devices motors ovens pumps control panels cabinets furniture safety parts plumbing system pipes plumping specialties sanitary sewer system pipelines gas pipes ovens sanitary fixtures boiler exhaust fan tiles and all relat
230. nstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 11 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth of excess areas as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA H Demolish Chain Link Fence with barbed wires 800 m 440 m 800 m 440 m completely main entrance gate and conveyor rod remove abandonment and cart away to a tippers off the site 1 Demolish chain link fence with barbed wires of perimeter 800 m 440 m 800 m 440 m main entrance gate and conveyor rod completely within two 2 years starting from the Date of Enterprise cut excavate break foundation 0 5 m concrete structure remove abandonment cart away to a tippers off the site and transport to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 2 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation an
231. nt to alert the guard man in case of any fire hazard 21 The extent of works shall include but not limited to all related civil and builder works as may be required for proper completion of the above mentioned works Renovation works of Mosque Building and other related works 1 The Contractor shall demolish dismantle mechanical and electrical equipments cut pipes remove abandonment and cart away to a tippers off the site existing roof materials toilet fixtures ablution facilities equipments plumbing system pipes sanitary fixtures lightings tiles A C units doors windows equipment and other related parts as required by the Engineer The extent of works shall include but not limited to all required civil mechanical electrical and instrumental works as approved by the Engineer Tender No SE 130 104 Document 2 III 2 The Contractor shall renovate rehabilitate and modify existing mosque building AB 1043 and ablution toilet room structures completely within one 1 month starting from the Date of Enterprise and shall include but not limited to repair of walls roof insulation and drain slab and other concrete surface treatment and repair of cracks and joints leakages cure of damaged concrete surface making good irregularities and defects including expansion and other joints corrective measures to ensure water tightness replacing defective joints and water stops All works and materials shall be subject to the Engine
232. ntaining a Schematic diagrams of the location of all hardware and system components b Network layout showing how all equipment in a is connected by wired network and specific names and IP address of all equipment in a C Backup schedule of all system data d Website sitemap 5 A customized bi lingual user manual containing all common PIMSS functions and usage procedure for the designated personnel is to be Tender No SE 130 153 Document 2 III 1 05 submitted to for Engineer s Engineer s Representative s Supervising Consultant for approval and distribution to all users PIMSS Manual Stage II Final to be submitted prior to the completion of implementation of PIMSS and the website This volume shall contain the latest revisions of sections of Stage I along with the following approval of which by the Engineer shall bea pre condition for approval of PIMSS installation 1 Workflow Charts A complete set of flow charts describing the agreed upon routing workflows for all document types 2 Protocol for deciding the routing of previously undecided Project Information Items 3 File and folder naming schema for all each Project Information Item and its revision and each Electronic Document Format shall be enumerated 4 A hardcopy of training manual for all classes of users 5 Hardcopy of the Project Web site and Web camera user manual in English Arabic 6 User list and their system access levels SYSTEM DESCRIP
233. ntrol center The exchange shall be with all modern facilities of operation as specified in particular specifications The Contractor shall renovate supply erect install test commission and maintenance telephone device with multi memories and one extension line for the guard house GH 1041 each partition room of MPW Quality control center Module 10 AB 1044 including new telemetry partition room and laboratory partition rooms substation SU 0241 substation SU 0641 and existing effluent transfer pumping station PS 0633 as approved by the Engineer The Contractor shall be responsible in laying cables for this purpose and the cables shall be with at least 100 additional capacity All works specifications and materials shall be subject to the Engineer approval k The Contractor shall disconnect dismantle remove and cart away to a tippers off the site all kitchen equipment completely The Contractor shall renovate supply erect install test commission and maintenance new kitchen room with other services such as plumbing fittings and electrical works as directed by the Engineer The extent of works shall include provide install commission and maintenance for new kitchen but not limited to assemble new quality standard fabricate cabinets doors and frames of high pressure decorative laminate finished 19 mm thick MDF board unit kitchen for the MPW building to be aligned and secured adjoining cabinet units and counter tops with the
234. numbers of poles etc 23 The Contractor shall provide all supplies which shall include all consumables perishable dispensable and miscellaneous items including office supplies spare parts lubricants fuel safety supplies cleaning supplies canteen supplies and similar items required for completion of the maintenance services on monthly basis as approved by the Engineer for the duration of the contract period The extent of works shall include but not limited to provide all required Tender No SE 130 147 Document 2 III consumables office equipments laboratory safety materials toilets and ablution kitchen cleaners etc for the duration of the contract period as directed by the Engineer The extent of works shall include but not limited to supply and store of on site the following consumables first aid medicines oil grease lubricants gas fuses diesel cotton waste cleaners refill gas for AC Freon gas gas pipes related to laboratory gas cylinders distilled water paints oil seals packing washers bolts sleeves O rings nuts dry batteries rust removals filters fans screws bolts drill bits silicones rubbers sanitary materials welding electrodes fasteners and all wearable parts such as gland packing packing pushers gaskets rubber parts bulbs safety consumables gloves gas masks etc required for the proper maintenance and repair works for the duration of the contract period 24 The Contractor shall p
235. of similar equipments to make complete equipment sets remove cart away to a tippers off the site and delivered to MPW stores off site in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them i Clean paint re usable spare parts shall include but not limited to all existing mechanical and electrical equipments instruments and devices tools pumps valves hoses etc available in stores and other storages areas within the boundary area of the perimeter fence then cart away to a tippers off the site and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them Tender No SE 130 39 Document 2 III j The Contractor shall be responsible to submit three 3 compact discs CD of detailed inventory lists of delivered reusable items to MPW stores off the site to the satisfaction of the Engineer and shall include but not limited to pumps valves hoses tools materials spare parts equipment valid chemical solutions and all other different items available in Ardiya plant stores and buildings within the boundary area of perimeter fence etc 7 The Contractor shall be deemed to have carried out his own investigations to ascertain himself the nature of the soil conditions and the groundwater l
236. of the Engineer and EPA Therefore it is obligated that the Contractor to visit the site during the period of tendering to determine by himself the actual conditions of the site and all the components of works The Contractor shall be deemed to be fully conversant with the prevailing conditions above ground and below ground and the nature and complexity of the works to be undertaken The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract A Demolish all types of structures facilities disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments break concrete structures cut pipes remove abandonment cart away to a tippers off the site earthfill landscape grading soil to be reinstated and restored the site to a condition match its surrounding as approved by the EPA and the Engineer 1 The Contractor shall be responsible to demolish all types of the structures facilities completely within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m within two 2 years starting from the Date of Enterprise except zones areas 1 amp 2 disconnectthe electricity supplies completely dismantle mechanical and electrical equipments and instruments completely break concrete structures completely cut pipes remove abandonment cart away to a tippers off the site All
237. of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost ii Description of the works The Contracted is obligated to grout filling unlimited depths and full volumes of the underground pressure pipelines completely within three 3 years starting from the Date of Enterprise from the inlets pressure pipelines ends to the outlets pressure pipelines ends until the volumes of the underground pressure pipelines are completely full with mix flowable fill materials with no voids remain unfilled The extent of works shall include but not limited to demolish dismantle dewater cut pipes break remove abandonment cart away to a tippers off the site unlimited depths of hatch boxes completely earth filling excess areas with new imported borrow soil as approved by the EPA and the Engineer landscaping grading soil compacting 9596 MDD and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall be deemed to be fully conversant with the prevailing conditions above ground and below ground and the nature and complexity of the work to be undertaken The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the wor
238. of zones areas 1 amp 2 starting from the Date of Enterprise for the duration of contract period and shall include but not limited watering gardening mowing and trimming grass pruning trees paving cultivating seeding and replanting dried trees The extent of works shall include but not limited to remove dried trees off the site and replant grown trees in different locations as approved by the Engineer 2 The extent of works shall include but not limited to provide irrigate and commission adequate irrigation water manually for trees vines shrubs flowers grass plants etc of existing zones areas 1 amp 2 using water tankers and hoses starting from the Date of Enterprise for the duration the contract period until the commissioning of the new landscape network irrigation system to provide an adequate irrigation water for the existing and new landscaping zones areas 1 amp 2 and EAD zone area after renovation works are completed and shall include but not limited to trees vines shrubs flowers grass plants etc Tender No SE 130 150 Document 2 III 3 The extent of works shall include but not limited to cut and remove dried trees off the site within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m as approved by the Engineer starting from the Date of Enterprise for the duration of the contract period transport and dispose to dumping area outside the site to unlimited distances locations areas in the st
239. on Facility and location Scheduled time and date for inspection Signature block for contractor with submission time and date Evaluation block for Engineer with date and time inspected results of inspection test Approved Approved as noted Not Approved and Engineer s signature block Area for general comments 2 The Contractor must maintain sufficient staff on sites to implement all aspects of the approved Quality Plan The Contractor shall provide all equipment instruments qualified personnel and facilities necessary to inspect the work and perform all the tests required by the contract documents or provide independent inspection agencies or laboratories to do the same 3 The Contractor shall repeat inspections after correcting non conforming work either if the inspection approved as noted or not approved until all works complies with the requirements 4 Inspections and tests conducted by persons or agencies other than the Contractor shall not in any way relieve the Contractor of his responsibility to conform to the requirements of contract documents and referenced standards Tender No SE 130 16 Document 2 III The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 20 Quality Assurance A Comply with requirements of ASTM
240. on of one 1 year period after renovation works are completed Civil Maintenance works of zone area 1 facilities starting from the Date of Enterprise for the duration of the contract period Civil Maintenance works of zone area 2 facilities for the duration of one 1 year period after renovation works are completed Landscaping Plantation and Irrigation maintenance works of zones areas 1 amp 2 starting from the Date of Enterprise for the duration of the contract period Clause 2 Definitions Wherever in the Contract Documents or on the Drawings the words as directed as ordered as requested as required as permitted or words of like import are used it shall be understood that the direction order request requirement or permission of the Engineer is intended Similarly the words approved acceptable suitable satisfactory and words of like import shall mean approved by acceptable to suitable to or satisfactory to the Engineer Clause 3 Government Bodies The Contractor shall carry out all works in strict accordance with current codes regulations local and administrative orders specifications and standards of all Government Bodies whether listed here under The Contractor shall coordinate with legal Government authorities for approval if necessary at his own expense and subject to the Engineer approval Ministry of Public Works MPW Ministry of Electricity and Water MEW Ministry of Commu
241. ons Painting interior walls and roofs shall not proceed in dusty conditions The extent of works shall include but not limited to scraping and sand blasting to remove dust out of exterior walls prior to painting works All works materials and specifications shall be subject to the Engineer approval 5 The extent of works shall include but not limited to provide plaster test commission and maintenance exterior walls of mosque building and ablution toilet room with rocks panels and cladding in accordance with manufacturer s recommendations All works materials and specifications shall be subject to the Engineer approval 6 The extent of works shall include but not limited to provide install test commission and maintenance of both mosque building and ablution toilet room new interior lightings fixtures with mirror optic reflector with power saving electronic ballast Also the Contractor shall provide install test commission and maintenance new external lightings outdoors lightings at least 500 W metal halide type fixtures 4 Nos with all related wires and electric installations outside the mosque The Contractor shall replace the entire existing power outlet and control switches with new identical or equivalent type with the approval of the Engineer All works specifications and materials shall be subject to the Engineer approval 7 The Contractor shall dismantle remove abandonment and cart away off site windows completely of mosq
242. ontract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall minimize nuisances and work in a safe manner 3 Thecost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 15 Submittals 1 The Contractor shall submit CPM programs with details plans as specified in Document 2 II within one 1 month starting from the Date of Enterprise and shall include but not limited to the following requirements Section A Demolish Disconnect Dismantle and Abandonment existing facilities Section B Grout filling unlimited depths and full volumes of underground pressure and gravity pipelines completely Section C Renovation works at Ardiya Sewage plant Section D Partial Operation and Maintenance works at Ardiya Sewage plant 2 The Program shall include the following items as a minimum and not by the way of limitation a Manpower Equipment and Machineries required for the execution of each task Quality assurance program Safety precautions for the works Safety equipment and materials shall be used in conducting the works Critical path management CPM Schedule with details in color print A1 size paper 2 originals copies and 2 compact discs CDs which illustrating pro
243. or shall visit the site location and inspect the master station at Ardiya sewage plant and study all equipment of the system in order to acquaint himself with existing equipment and all details required 3 The Contractor shall also be responsible to maintain the proper operation and calibration of the system as much as possible during the moving process and submit proposed time table for shifting the equipment to the new location for the Engineer for approval before starting the work Any damage to the equipment or malfunctioning of the software program developed due to shifting the system the Contractor should replace the software at his own cost which must be allowed in the contact sum 4 The Contractor shall conduct a radio survey process to allocate the messing signals due to shifting operation and ensure a full signal transmission of outstation equipment 5 The re installation of the system equipment shall be carried out in strict accordance with the manufacturer written instruction subject to the approval of the Engineer If for any reason the proper location of any part of the telemetry system needs to be shifted or to provide any additional items to complete the installation work it is the Contractor s responsibility to execute the necessary modification or to provide any provisional item and carry out the work at no additional charge 6 The work assigned by this item shall be carried out with a full co ordination and supervisio
244. ork concurrently in different locations to execute all contract requirements on time Renovation works of zone area 1 shall be isolated from zone area 2 such as asphalt roadways street lightings poles and other works as specified in the contract except sanitary sewerage system storm water drainage system irrigation network system services utilities and other works as specified in the contract The remaining boundary area of the perimeter fence 800 m 440 m 800 m 440 m shall be landscaped graded compacted 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall consider all information of appendices as a part of contract requirements However these appendices are considered as guidance only and do not covers all requirement of the works it is the Contractor responsibility to visit all the sites and conduct full survey during the period of tendering to determine all the components of works calls by the contract and as directed by the Engineer Tender No SE 130 68 Document 2 III The Contractor shall not have the rightto make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 9 The Contract shall submit request of inspection of all required activities works in according to contract requirements for approval by the EPA and the Engineer 10 T
245. ost Clause 27 Contractor s staff 1 The Contractor shall provide all his staff and manpower to be available on sites from the first hour of the date of enterprise for all contract duration The Contractor shall make his own determination of the required staffing for proper executing the contract requirements 2 The proposed staff shall be approved by the Engineer as specified in Document 2 Il are minimum required staff which may be increased according to the work requirements but any arising additional cost during the Contract period shall be borne the Contractor without any extra charge to the Employer 3 The Contractor staff should be vaccinated with typhoid and tetanus to be protected against injuries from the Date of Enterprise 4 The Contractor staff shall be responsible to take reasonable precautions to prevent damage to existing services and utilities If any damages which in the opinion of the Engineer could reasonably have been avoided shall be required at the Contractor expense The Contractor shall be deemed to have carried out his own investigations to ascertain for himself the nature of the soil conditions and in particular the groundwater pressure level The Contractor shall not have the right to make any future claims or any extra cost on the basis that he could not inspect the sites and other related works of other components at the time of tendering 5 The Contractor shall provide one qualified and experienced Store Kee
246. ot limited to polluted soil equipments metals demolished structures wood debris pipes asbestos chemicals oil sewage groundwater heavy metals etc within one 1 month starting from the Date of Enterprise 5 The Contractor shall submit the methods and procedures for approval by EPA Environment Public Authority regulations and other governmental authorities for the safety of manpower and fire precaution on sites within one 1 month starting from the Date of Enterprise 6 The Contract shall submit request of inspection of all required activities works in according to contract requirements for approval by the EPA and the Engineer 7 The Contractor shall provide all necessary safety personnel materials and equipments lightings precaution against fire fencing excavation support and protection safety signs and temporary power supply for proper completion of the work 8 The Contractor shall be responsible for maintenance and rectification of all damaged utilities and other services affected during the works at no extra cost Tender No SE 130 50 Document 2 III 9 In the case the Contractor may find unforeseen old structures equipments or underground pipelines need to be demolished he should take the action to include such equipment in the demolishing works and shall be allowed in the total sum of the contract 10 The Contractor shall be responsible to provide adequate mobile diesel generators to be available on dem
247. ouble traffic lanes pathways of main roadways shall be painted clearly with traffic dash painting lines and separated with traffic solid painting line The works shall be executed in conformance with the requirements of the latest editions of the codes and regulations of Roads administration General specifications for Kuwait Motorway 2 The extent of works shall include but not limited to design renovate provide erect install test commission and maintenance color painting precast curbstones site paving concrete tiles interlocking of different colors bricks street furniture foot pathways for pedestrians and colour decorative tiles along both sides of main double layers asphalt roadways and internal strip double layers asphalt roadways of zones areas 1 amp 2 and parking areas as approved by the Engineer 3 The extent of works shall design renovate provide irrigate plant landscape commission and maintenance new lawn grass areas grown shrubs as minimum 100 Nos grown color yearly season flowers of zones areas 1 amp 2 and parking areas as approved by the Engineer The extent of works shall include but not limited to Tender No SE 130 69 Document 2 III a Grown shrubs along both sides of new main roadways and internal roadways site parking area and buildings as directed by the Engineer b Grown vines and ground covers along both sides of new main roadways and internal roadways site parking area and buildings
248. ous glasses and plastic wares within one 1 year from the date of enterprise and shall include but not limited to the following minimum new laboratory miscellaneous glasses and plastic wares requirements and specifications The Contractor shall be obligated to fulfill other requirements of new laboratory reagents and solutions in according to design specifications and shall not have the right to claim for compensation in time or cost All new laboratory miscellaneous glasses and plastic wares shall be subjectto the Engineer approval The Contractor shall be resp for obtaining MPW approval prior to the start the execution of the works onsible Item Description Quantity 1 Beakers Borosilicate glass graduated a 50mlcap 12Nos b 100 ml cap 5 Nos C 250 ml cap 5 Nos d 500 ml cap 5 Nos e 1000 ml cap 5 Nos Tender No SE 130 128 Document 2 III Bottles with cap screw neck with cap and clear glass autoclave plastic 100micap i A 12Nos 250 ml cap 5 Nos 500 ml cap 5 Nos Burettes 50 MI clear glass straight bore Class A 6 Nos Brushes for cleaning glassware s different sizes me ek Flask Brush 12Nos Burette Brush 12 Nos Graduate Brush 12 Nos Beaker Brush 12 Nos Rubber Stopper Assortment 12 Nos Latex rubber tubing 8 mm 0 x 1 5 mm wall 12 Nos Vacuum tubing 6 mm 0 x 5 mm wall 12 Nos
249. ovation works of the main Guard House AB 1041 and other related works 1 The Contractor shall demolish dismantle mechanical and electrical equipments cut pipes remove abandonment and cart away to a tippers off the site existing guard house toilet fixtures equipments plumbing system pipes sanitary fixtures lightings kitchen fixtures tiles A C units doors windows water storage tank equipment and other related parts as required by the Engineer The extent of works shall include but not limited to all required civil mechanical electrical and instrumental works as approved by the Engineer 2 The Contractor shall renovate provide erect install test commission and maintenance main guard house AB 1041 of zone area 1 within two 2 years starting from the Date of Enterprise and shall include but not limited to provide install test commission and maintenance new lightings wooden doors with lockers aluminum doors with lockers glazing windows with mesh screens frames and curtains louvers vents ceramic tiles electric installations and other accessories new interior lightings fixtures switching devices power outlets for all indoor and outdoor lightings and all required civil mechanical electrical and instrumental works as approved by the Engineer 3 The Contractor shall renovate provide install test commission and maintenance new plumbing system pipes plumping specialties sanitary sewer system and manholes conn
250. p every 7th day Two copies of the full weekly backup must be maintained One copy of the backup shall be stored in a 4 hour fire proof safe on site and the other copy of all the data must be deposited as specified by the Engineer or Engineer s Representative Training in restoring this backup must be given to the Engineer and Engineers Representative to allow for examination of contents and logs that have been stored in the backup At the end of the Period of Operation DVD s containing all the information at project closure shall be supplied This DVD shall also contain an offline viewer The system shall be password secured It shall replicate the same permissions as the PIMSS Two copies of this DVD s shall be supplied one each for the Engineer and the Engineer s Representative No further copies of this DVD s are to be given to anyone else B Web server and Database software s data programming and updating as appropriate to establish a publicly accessible web site on the internet Site will contain essential project information as decided by the Engineer C Web cameras and Digital video Server system containing at least four 4 numbers installed at designated site locations and capable of the following functions 1 Capable of monitoring the site in real time day and night 2 Location movable to allow remote inspection of all critical construction operations 3 Capable of being moved to new locations and connected to the PI
251. packet month 203 COD Vials 0 150 mg l 150 packet 1packet month 204 1 1 2 trichloro 1 2 2 trifluroethane 500 ml 1 Bottle I month Tender No SE 130 126 Document 2 III 205 Sodium bisulfite monohydrate 500 g 1 Bottle month 206 Silica Gel 500 g 1 Bottle month p Dimethyl amino benzaldehyde 100 g 1 Bottle month Alpha Naphthol 25 g 1 Bottle month Sodium BoroHydride 500 g packet 1 Bottle month Universal Indicator 100 ml 1 Bottle month 1 Naphthylamine Hydrochloride 1 Bottle month AgNO 0 0141N 1pack month Al masking reagent sol ECR 1 Bottle month Alkali sol for Ca amp Mg 1 Bottle month Aluminum chloride solution 6 N 1 Bottle month Aluminum reagent powder 1 Pack month Amino acid reagent powder pillows 1 Pack month Bleach household 1Pack month Borover 3 powder 1 Pack month Bromocresol green 1 Pack month Bromo phenol 1 Bottle month Buffer sol sulfate type 1 Bottle month Clorox 1 Bottle month Chromium acid reagent powder 1 Pack month Cobalt EDTA reagent powder 1 Pack month COD standard solution 1000 mg L 1 Bottle 12 months Copper sulfate powder CuSO 1 Pack 4 months CR III Standard solution 1 Bottle month Formaldehyde 3796 1 Bottle month Formazin stock solution 1 Bottle month Glutamic acid 1 Pac
252. pensation in time or cost Clause 28 Specifications and Appendixes 1 The Contractor shall execute all the works as specified in the contract requirements in conformance with the Sanitary Engineering General Specifications 2002 General Specifications for Buildings and Engineering Works 1990 Roads administration General specifications for Kuwait Motorway 2004 and other latest editions of the codes ordinances rules and regulations of Ministry of Public Works EPA Environment Public Authority regulations and other Governmental authorities 2 The Contractor shall include all information and drawings of appendixes as a part of the contract requirements However these appendixes are considered as guidance only to the Contractor and do not cover all require works and does not show all the actual equipment and structures on sites Therefore it is obligated that the Contractor to visit all the sites during the period of tendering to determine by himself the actual conditions of the sites and all the components of works such as all types of structures facilities instruments mechanical and electrical equipments underground pipelines roads lightings and other related works The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 3 Thecost of the above mentioned requirements will be borne by the Contractor and shall deem
253. per who shall be available on sites starting from the date of enterprise for all the Contract duration The duties of the Store Keeper shall include as a minimum preparing and updating the inventory of all remove clean paint re usable way and tag new machine cards indicating the date of inspection should be affixed The tag shall also be signed by the store keeper and stamped by the Contractor prior to deliver salvageable equipments to MPW stores off site as directed by the Engineer In addition the Tender No SE 130 22 Document 2 III store keeper shall be responsible to enter all data information of all equipment and materials prior to deliver to the MPW stores off site in a special computer program CD as directed by the Engineer The cost of the store control and inventory works mentioned requirements will be borne by the Contractor and shall be allowed for in the total prices of this Contract 6 The Contractor shall be responsible for the accommodation transport travel leave safety insurance etc for all of the staff and labors 7 The Contractor shall have standard uniform clothing for each along with their badges Style and color of the uniform clothing and badges shall be submitted to the Engineer for approval 8 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for com
254. plies dismantle mechanical and electrical equipments and instruments clean grease paint and coating motors from the drive shafts and base plate clean and grease the motors plug cable entry boxes apply a coat of rust proof sealant on the bare shaft cart away to a tippers off the site and transport to MPW stores in new fitting packages Tender No SE 130 38 Document 2 III similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them d Disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments clean grease paint and coating all types of the reusable pumps including sump pumps after applying a coat of rust proof sealant on the bare shaft and protecting it from damage cart away to a tippers off the site and transport to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them as approved by MEW and the Engineer The pumps shall be metal tagged with all the relevant information prior to delivery to MPW stores off site e Disconnect dismantle remove clean cart away to a tippers off the site and transport to MPW stores all reusable lighting fixtures switches sockets fans cable trays and all other electrical items in new fitting packages similar to original packages with new machi
255. ps are not limited to be available on demand and shall include but not limited to tractors tippers Lorries mud suckers tankers Tender No SE 130 33 Document 2 III flushers cranes tools equipment including manpower drivers and fuel to execute the works completely 12 The Contractor shall be responsible for maintaining and rectification of all damaged utilities and other services affected during the works at no extra cost 13 All trees on the site shall be protected and watered by the Contractor and provide all measures necessary to ensure safe working conditions unless the Engineer directed the Contractor to cut some trees completely The extent of works shall include but not limited to replace all trees that are destroyed regardless of size in accordance with applicable codes and regulations 14 The Contractor shall consider all information of appendices as a part of contract requirements However these appendices are considered as guidance only and do not covers all requirement of the works it is the Contractor responsibility to visit all the sites and conduct full survey during the period of tendering to determine all the components of works calls by the contract and as directed by the Engineer The Contractor shall not have the rightto make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 15 The Contractor shall be responsible to provide adequ
256. quirements forms and all other works specified in the contract requirements Detailed plan for mechanical electrical instrumental and civil works required by this Contract showing dates of start and completion equipment tools and materials needed pumps safety equipment dewatering system heavy duty mobile equipment or machinery to carry out the works techniques methods and procedures of executing works to the satisfaction of the Engineer as specified in the contract documents Detailed plan for provision installation test commissioning and maintenance of preventive maintenance program proposed by the Contractor and other related required works to the satisfaction of the Engineer as specified in the contract documents Detailed plan for maintenance and painting works of existing designated equipments pumps buildings panels substations and other related required works as specified in the contract documents Detailed plan of rehabilitation of soil and other related works as specified in the contract requirements Detailed plan of clearing the sites landscaping removal of all debris waste and surplus materials off the sites All cleaning work shall be to the Engineer s satisfaction Detailed of safety plans equipment and materials shall be used in conducting the works in accordance to specifications and standards of government regulations Detailed of staff categories experience and curriculum vitae of all contractor staf
257. r i Lighting system j A C Package unit k Ventilation system Fire Alarm System m Auxiliary panels and cable works n Spare equipped panel 3 The new L T Switchboard S S 1 Module SU 0241 shall provide electric power supply to the following facilities but not limited Other facilities may add to the actual connected load during the design period as directed by the Engineer a MPW Quality control center and shall include but not limited to offices partition rooms telemetry partition room laboratory partition rooms and other partition rooms Guard house Mosque Landscaping Lighting and Power system Zone area 1 EAD Environmental Affair Department Redundancy 10096 additional spare capacity o oooc 4 The nominal connected load to the new switchboard S S 1 may be estimated as shown in the following table the Contractor shall calculate the actual connected loads required for his design report and submit single line diagram to the Engineer for approval Running ar Estimated Load Description Load KW B 00 MPW guality control center AB 1044 office eguipments laboratory eguipments and 5 devices SCADA Telemetry master stations Wastewater Pumping Station PS 0931 etc Guard House GH 1041 Mosque AB 1043 Lighting amp Power System zone area 1 EAD Environmental Affair Department Spare equipped panels 500 5 Therehabilitation and renovation work shall include provision
258. r approval The Contractor shall not be allowed to divert wastewater flow to any emergency by pass gulf sea lines 10 The Contractor shall provide erect and maintain all temporary staging scaffolding rigging shuttering over pumping and flow diversions dewatering system and related connections excavation backfiling and earth filling of unlimited underground depth area required to carry out the works close to existing structures in order to prevent subsidence of the foundations such as building tanks or other structures without any hazard to persons or existing services and carried out with all necessary precaution needed 11 The extent of works shall include but not limited to disconnect the electricity supplies dismantle non usable mechanical and electrical equipments remove abandonment cart away to a tippers off the site and transport to MPW stores off the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval and shall include but not limited to all types of ferrous metals such as bridges valves gates supports scrapers filling stations conveyors screw pumps etc and all other non usable mechanical electrical and instrumental parts All non salvage ferrous metals surfaces shall be delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer Ten
259. r shall require work concurrently in different locations to execute all contract requirements on time 5 The Contractor shall consider all information of appendices as a part of contract requirements However these appendices are considered as guidance only and do not covers all requirement of the works it is the Contractor responsibility to visit all the sites and conduct full survey during the period of tendering to determine all the components of works calls by the contract and as directed by the Engineer The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 6 The Contract shall submit request of inspection of all required activities works in according to contract requirements for approval by the EPA and the Engineer 7 The Contractor shall provide all necessary safety personnel materials and equipments lightings safety precaution against fire fencing signs for proper completion of the work 8 The Contractor shall co operate co ordinate and not interfere his operations with all other parties or Contractor s executing works on sites or adjacent to his sites 9 The Contractor shall be responsible to provide adequate mobile diesel generators to be available on demand for electricity loading required to execute the works without any interruption for the works 10 The cost of the above mentioned requirements wil
260. r training and all associated hardware and software required to establish an integrated PIMS system Real time data to be collected from the following MPW facilities servers and historized in the Enterprise or main server at Ardiya sewage plant Umm Al Haiman sewage treatment plant Wafra sewage treatment plant Rikka sewage treatment plant Khairan sewage treatment plant Kubd sewage treatment plant and Data Monitoring Centre DMC 6 The PIMS is to be state of the art real time infrastructure which allow users to gather data from the SCADA System in MPW facilities and store it sufficiently for a very long period of time at its original resolution and distribute it to authorized users through the Ministry internet the worldwide web and phone or microwave technologies in a secure manner 7 The PIMS system should be upgradeable to interface and bring operational data from Programmable Logic Controllers PLCs Emergency shutdown system ESD Asset Management System Laboratory Information Systems LIMS future Supervisory Control and Data Acquisition systems SCADA Weather Monitoring System Manual Data entry IT Infrastructure health data relational data SQL Oracle 3 party historians etc to the Enterprise server 8 The PIMS should be able to deliver information to users all levels of the Ministry through the company LAN WAN from the plant floor to the enterprise level It should keep all historical and real time critical operating
261. ractor shall be responsible for effective control of all nuisance insects snakes escaped dogs lizards birds nests and animals He shall spray all areas of the plant subject to FLY or other insect nuisance daily for the duration of the project with appropriate insect killer spray The spray machine subcontractor spraying equipment method and materials used shall be approved by the Engineer 10 The Contractor shall erect wherever required safety signs and instructions describing any required safety precautions and procedures for emergencies as directed by the Engineer These signs may contain written instructions or warning drawings or both whichever is applicable such information and quality of the signs shall be subject to the Engineer s approval All signs shall be rendered in both Arabic and English languages 11 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 26 Specific Site works 1 Excavation Activities Prior to any excavation activity efforts must be made to determine whether underground installations i e sewers telephone water fuel electric lines etc will be encountered and if so where such underground installations are located The walls and faces of all excavation in which personnel are exposed to danger from movin
262. ration of the system replacement of all necessary spare parts during the contract period The lighting circuit shall be supplied and controlled from the L T Switchboard of S S No 1 Module 0241 for zone area 1 and substation No 6 SU 0641 for zone area 2 bath network shall be monitored on the mimic panel of the control board of substations which will indicate the proper operation and electrical faults of the lighting system The Contractor shall design and select the area of lighting zones where the estimated loads can be easily covered by the power supply available on the LT distribution board of substations The Contractor shall submit his proposal of zone selection and calculations of the lighting loads estimated for zone as required by the contract specification to the Engineer for approval before conducting the work The extent of works shall include but not limited to all related civil and builder works of the concrete reinforcement for the foundation base of the outdoor street lightings tower and poles The Contractor shall be responsible for all related civil mechanical electrical and instrumental works required for the proper installation and operation Renovation works of chain link boundary fence within the perimeter 800 m 440 m 800 m 440 m with Barbed Wires completely height 2 m and other related works The Contractor shall renovate provide install test commission and maintenance new chain
263. red replace all defective or damaged pipelines completely due to collapse deflection and failure of pipelines junction fitting among pipelines intersection joints connection among pipelines and manholes The Contractor shall be responsible to carry out a CCTV Closed Circuit Television survey to inspect all pipelines sections and identify the damaged collapse deflection and failure of pipelines 13 The extent of works shall include but not limited to maintenance of all buildings MPW Quality Control Center centre substations SU 0241 and SU 0641 laboratory partition rooms mosque guard house new pumping station smoke and heat detectors especially the laboratory partition rooms fire alarms sound amp light alarms fire protection system cabinet fire hoses racks and nozzles fire detection fire extinguishers as per recommendation of KFB regulations Fire extinguishers shall be refilled or inspected by KFB yearly 14 The Contractor shall be responsible for the maintenance of asphalt and internal roadways and other related finishing civil works of zones areas 1 amp 2 The works shall be executed in conformance with the requirements of the latest editions of the codes and regulations of Roads administration General specifications for Kuwait Motorway C Landscaping Plantation and Irrigation maintenance works 1 The Contractor shall be responsible for the preventive and maintenance of the existing and new landscaping areas
264. regulations of EPA Environment Public Authority regulations and other Governmental authorities The Contractor is obligated to submit methods and procedures for approval by EPA and shall not allow to start any such works unless approval is given to the Engineer The extent of work shall include but not limited to the following Tender No SE 130 21 Document 2 III a Odour treatment and neutralize foul odours H2S gas and other malodorous gases especially during demolish process of substructures excavation and earthwork by using any method approved by the Engineer and EPA b Traffic control with Ministry of Interior carting away breaking concrete structures and reinforcement to tippers off the site approved by the Engineer and EPA c Abandonment of demolished structures and carting away to tippers off the sites as approved by the Engineer and EPA d Assorting all types of contaminants separately pipes debris metals concrete asbestos polluted soil chemicals oil spills etc so that to get rid of them easily and safety e Fencing the site work to avoid any accidents f Follow the regulation code of EPA no 210 year 2001 regarding the dust during the demolishing and abandonment works 4 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or c
265. reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 13 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth areas landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site 14 The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Tender No SE 130 88 Document 2 III 1 Modification of Effluent Transfer Pumping Station 1 The Contractor shall study and investigate thoroughly the existing equipment and conditions of the effluent transfer pumping station including the following items Suction and discharge valves Non return valves condition Foundation and supports Coupling present conditions Casings and impellers of the pumps Present flow rate Electrical motor starters and supply cables Grease pumps and pump motors All other related equipment and utilities 2 The Contractor shall disconnect electrical supplies dismantle electrical and
266. resentative teams shall be assigned this level for auditing all actions fo the System Administrator Tender No SE 130 160 Document 2 III The system shall record logging on off activity Terminals shall automatically log off after a pre set time if no keyboard activity has occurred In addition PIMSS users shall be able to manually log off when leaving the terminal PART 3 EXECUTION 3 01 INSTALLATION A Contractor shall install a fully functional system not detailed in Contract Documents in compliance with reference standards local international codes and project electrical specifications Wiring shall be installed in such a way that minimises coupling of electromagnetic and electrostatic interference on low voltage signals and data wiring 3 02 TESTING OF SOFTWARE A PIMSS Specialist shall demonstrate the hardware and software s to the Engineer and Engineers representative by in house simulation prior to implementing software on site System demonstrations shall be conducted within one month of Date of Enterprise A minimum of one week s written notice shall be given and the Engineer s written consent obtained prior to such demonstrations 3 03 TRAINING OF ENGINEER S PERSONNEL During the Period of Operation of PIMSS the PIMSS Specialist shall instruct the Engineer s and Engineer s representative and designated personnel in all aspects of the operation of PIMSS In addition a Document Control Engineer
267. rks shall include but not limited to collect remove cart away off the site transport and dispose all existing extraneous materials and shall include but not limited to debris metals pipes non usable parts etc after completion of the works to dumping area outside the site in accordance to the regulations of the authorities and municipality The extent of works shall include but not limited to provide install and operate pumps plugs conduits dewatering system and all other required machineries and equipments with all hoses connections mechanical and electrical installations The extent of works shall include but not limited to provide erect and maintain all temporary staging scaffolding rigging shuttering to carry out the works in order to prevent subsidence of the foundations of other structures without any hazard to persons or existing services Tender No SE 130 61 Document 2 III Clause 2 Grout filling unlimited depths and full volumes of underground gravity pipelines completely including demolish dewater dismantle break remove abandonment and earth fill of manholes completely with other related works The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfill
268. rn Sludge Screw Pump No 3 Aerator No 1 Aerator No 2 Aerator No 3 Aerator No 4 Aerator No 5 Aerator No 6 Submersible Ejector Pump No 1 Submersible Ejector Pump No 2 Submersible Ejector Pump No 3 Submersible Ejector Pump No 4 Submersible Ejector Pump No 5 Submersible Ejector Pump No 6 Module 5 No 4 Settling Tank Drive Unit No 5 Settling Tank Drive Unit No 6 Settling Tank Drive Unit Aerator No 7 Aerator No 8 Aerator No 9 Aerator No 10 Aerator No 11 Aerator No 12 Return Sludge Screw Pump No 4 Return Sludge Screw Pump No 5 Module 6 Screw Pump No 1 Screw Pump No 2 Screw Pump No 3 Oil Circulation Pump No 1 Oil Circulation Pump No 2 Oil Circulation Pump No 3 Air Compressor No 1 Air Compressor No 2 Booster Compressor No 1 Booster Compressor No 2 Back Wash Return Pump No 1 Back Wash Return Pump No 2 Back Wash Return Pump No 3 Back Wash Return Pump No 4 Booster Pump No 1 Booster Pump No 2 Booster Pump No 3 Chlorine Motive Water Pump No 1 Chlorine Motive Water Pump No 2 Air Scour Blower No 1 Air Scour Blower No 2 Air Scour Blower No 3 Tender No SE 130 183 Document 2 III Dewatering Pump Backwash Pump No 1 Backwash Pump No 2 Backwash P
269. roperty of MPW d Surge Tank Compressors and Compressors motors The Contractor shall study design renovate provide install test commission operation and maintenance of a new surge tank compressors 2 Nos and a new compressor motors 2 Nos of a minimum capacity of 5095 higher than the existing equipment as per the approved design of new irrigation system e Pressure Vessels The Contractor shall study design renovate supply install test commission operation and maintenance new pressure vessel with carbon steel construction suitable internal protective coating and pressure gauges The minimum capacity shall be 4 0 m with the operating range set at 5096 of the vessel height f Flow Meters 1 The Contractor shall disconnect electrical supplies dismantle electrical and mechanical equipments cut pipes remove abandonment and cart way to a tippers off the site existing flow meters Module 06 FC 0651 as approved by the Engineer Tender No SE 130 95 Document 2 III 2 The Contractor shall study design renovate supply install test calibrate commission operation and maintenance new complete five 5 sets of magnetic flow meters and measuring equipments complete with monitor and remote display units or any other type reasonable for such applications with all other related civil mechanical and electrical installations and connections specifications and shall have a high accuracy linear analog outputs insensit
270. roval The extent of works shall include but not limited to demolish foot pathways interlock tiles concrete tiles curbstones and sites paving break remove abandonment and cart away to a tippers off site transport and dispose to dumping area outside the site to different locations as directed by the Engineer in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill unlimited depth of excess foundation areas as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA Tender No SE 130 49 Document 2 III Clause 2 Demolish Disconnect Dismantle and Abandonment Screw Conveyors Lifting Stations S20 and S21 completely and other related works The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract period The Contractor shall
271. rovide install test commission and maintenance all required spare parts and materials to maintain and repair office equipment or furniture as approved by the Engineer for the duration of the contract period 25 The Contractor shall maintain and repair all new guard house equipments and furniture mosque equipments carpet and high sound speaker system to recall prayers main gates rod conveyor and shall include but not limited to provide all necessary spare parts and materials to maintain and repair damaged and defected equipments or furniture without any delay for the contract duration B Civil Maintenance works 1 The Contractor shall be fully responsible for the proper civil maintenance works of zone area 1 facilities for the duration of the contract period and shall include but not limited to main front entrance gates main guard house AB 1041 mosque AB 1043 MPW Quality Control Center including laboratory partition rooms AB 1044 substation SU 0241 main roadways internal roadways and parking areas as approved by the Engineer 2 The Contractor shall be fully responsible for the proper civil maintenance works of zone area 2 facilities for the duration of one 1 year period after renovation works are completed and shall include but not limited to substation No 6 SU 0641 second stage contact tank Module 06 CT 0612 or header tank inlet and outlet channels of header tank by pass channel to sea which is connected to o
272. rs valves chambers drainage valves by pass pipelines frames and all other related parts within the boundary area of the fence The extent of works shall include but not limited to break concrete reinforcement structures walls slabs reinforced concrete cover slab puncturing the base slabs and surrounding walls including excavating depth of 2 5 meters beyond the horizontal limits of the foundation slab and walls of substructures removing and carting away to a tippers off the site The concrete cover slab shall be carefully broken to maintain metals covers and frames Metals and frames covers shall be cleaned and sand blast to remove any corrosion product paint with two coats of coal tar paints and deliver to MPW stores off site All non salvage ferrous metals surfaces shall be delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer The Contractor shall not be allowed to divert wastewater flow to any emergency by pass gulf sea lines and shall use tankers mud suckers to remove wastewater off site 9 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisf
273. s Three hot water circulation pumps Phosphate dosing unit volume 100 dm Control boxes for sludge and water pumps One drain submersible pump Tender No SE 130 178 Document 2 III One diesel fuel pump including pipe connection to boilers One auxiliary fuel tank Sludge piping DN 125 connecting circulation pumps with heat exchangers including 12 gate valves Hot water piping DN 80 including 8 gate valves Bathroom with W C shower three sinks and electric boiler Water tank FRP on the roof Control room for Module 08 mimic panel switches for all equipment two window A C units Secondary Digested Sludge Holding Balancing Tank DR 0813 Concrete structure One circular open tank diameter 14 m side wall high 6 58 m sludge side wall depth 5 6 m cone depth 6 8 m cone bottom DN 0 4 m effective sludge volume 1200 m Swinging overflow double pipes with floats for turbid water removal Two digested sludge centrifugal pumps Digested sludge Flow meter DN 150 Control box for sludge pumps Transmitter box for flow meter Diesel fuel tank FS 0861 Underground tank 20 m for storage of diesel fuel for digestion boilers Two pipelines DN 25 connecting fuel tank with fuel pump in boiler house Filling manhole Fire extinguisher kiosk Gas Holder GT 0863 One steel tank in concrete water basin maximum biogas volume 1000 m maximum gas pressure 3 kpa Flame arrester
274. s Cotton wool 5 kg packet 50 packets Safety Station Shower Eye Face 6 Nos Face mask disposable 100 packet 36 packets Face shield 6 Nos FIRST AID KIT 50 persons 10 Nos FIRE BLANKET 10 Nos Gloves pairS MMA Non Asbestos 30 Nos acrylonitrile 30 Nos P V C oe Insulated containers 1 L X 6 6 Nos LABELS 12 packets Self adhesive blank 600 pkt 12 pkts Tender No SE 130 131 Document 2 III Warning labels 120 pkt 12 pkts Lab coat different sizes 12 Nos Loops disposable Lu 1 mieroL anas 10 micro L 5 Nos Microscope slides D Frostedslides 100 pkt mese Hanging slides 100 pkt 12 pkts Cover slips 100 pkt 12 pkts Slide marker 10 pkt 12 pkts Automatic slide dispenser 50 Nos Optic cleaning kit 50 Nos micro slide container 50 Nos Inoculation needle with loop and holder 12 Nos Forceps 100 mm 12 Nos Pipette stand with 18 small and 10 large holes 2 Nos Stirring rode glass 2 15 pkt 12 pkts Safety eye wash bottle 500 ml 12 Nos Rubber Gloves 12 Nos Zetex Gloves 12 Nos Thermometer 5 Nos Weighing dishes 8 pkt 67 46 12 pkts Tender No SE 130 132 Document 2 III Weighing paper 76 x 76 mm 500 pkt 12 pkts Micro pipette Tips 1ml disposable 100 pk 12 pkts Bottles clear Glass Borosilicate reagent bottle with Polly stop stopper 50 ml cap 5 Nos 100 ml cap 12 Nos 250 ml c
275. s approved by the Engineer The New Pumps shall be selected in a higher capacity rate than the existing pumps adequate for a continuous operation with an aggressive effluent water supply 2 The works shall include but not limited to provide erect test commission and maintenance reinforced concrete foundation to withstand pump and replacement of all related necessary spare parts during the contract period 3 The Contractor shall maintain the proper operation of the existing irrigation pumping station Rabya Pumps not to be demolished until the commissioning of the new irrigation pumps at the New Pumping Station completed 4 The Contractor shall design renovate modify provide install pipes laying pipes alignment and lining commission and maintenance unlimited lengths and unlimited depths of new double pressure pipelines type of pipe DI or as approved by the Engineer DN 300 mm to be connected with the discharge pipes of new Irrigation centrifugal pumps the header tank which received effluent treated wastewater and the existing discharge pipelines to Rabya farms within the boundary area of the fence as approved by the Engineer The extent of works shall include but not limited to design renovate construct test commission and maintenance a new hatch box with frames and metals covers within the boundary area of the fence as approved by the Engineer for the connection between the new internal double pressure pipelines and the external
276. s near structure facilities and all other related connections and accessories 15 The Contractor shall be responsible to identify locate check and follow all safety precautions requirements to dispose of diesel fuel chemicals and release gas in a safe manner to avoid any risks shall include but limited to closed confined structures diesel and other fuels storage tanks chemical storage tanks gas pipes gas pipelines manholes wells pits and other specific facilities such as odour control facility and substructures screw conveyors lifting stations Then disconnect remove and abandon the tanks pipes pipelines and other structures in accordance with EPA and other concerned authorities rules and regulation 16 The Contractor shall execute civil maintenance works of the perimeter fences of Screw Conveyors Lifting Stations S20 and S21 completely The extent of works shall include but not limited to painting and coating ferrous metals and main gate replacing the metal chains and metal lockers repair of concrete surface treatment and repair of cracks and joints leakages cure of damaged concrete surface making good irregularities and defects including expansion and other joints corrective measures to ensure water tightness replacing defective joints and water stops and painting of interior and exterior fence to be applicable outside and shall not be carried out in wet dusty or foggy weather and interior work shall not proceed in dusty condi
277. s project personnel Engineer s Representative Supervising Consultant and his personnel and Contractor and his project personnel Tender No SE 130 157 Document 2 III Software Licence Include any form of document or agreement which may limit the client s use of the software resident in the PIMSS UBS siib nde Un interruptible Power System Uptime S Amount of time within a 24 hour period a system is active or available for servicing requests PART 2 PRODUCTS 2 01 GENERAL A Acceptable Manufacturers for PIMSS Autodesk USA Primavera Systems Inc USA Newforma USA Meridian Systems USA Approved alternatives substitutions under provisions of the General Conditions of Contract o RON B Acceptable Manufacturers for Web camera 1 Earthcam Inc USA 2 Axis Communications Sweden 3 Lumenera Corporation USA 4 Approved alternatives substitutions under provisions of the General Conditions of Contract 2 02 ENGINEERING WORKSTATION LAPTOP A Hardware This shall be the minimum configuration for a desktop tower case and Laptop computer 1 Processor Intel Core2 Duo or AMD Turion 2 RAM siue 2 GB RAM 3 Hard Drive 1 250 GB 4 Floppy Drive 3 Inch 1 44 MB 5 CD ROM DVD 48 X CDRW DVD Combos 32 Bit Sound 6 Backup Device DVD Writer 7 Sound Card 32 Bit with 25 W Speakers 8 Display Card
278. s surroundings as approved by the Engineer and EPA 3 The extent of works shall include but not limited to remove polluted soil abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Tender No SE 130 45 Document 2 III Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 4 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill unlimited depth of excess areas landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings as approved by the EPA and the Engineer The Contractor shall submit a certificate approved by the EPA after treatment of polluted soil prior to backfill on site F Demolish street lightings poles towers lightings poles and all other types of exterior lightings poles control cables and lightings networks disconnect dismantle break remove abandonment and cart away off the site 1 Demolish street lightings poles towers lightings poles and all other types of exterior lightings poles control cables panels and lightings networks installations within the perimeter chain link fence 800 m 440 m 800 m 440 m completely within two 2 years starting from the Date of Enterprise disconnect the electricity
279. sect killer lights with twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure A C split unit 3 5 Tons with compressor Burn kit 14 The Contractor shall design provide furnish install erect test commission and maintenance new laboratory furniture to fit microbiology laboratory partition room completely within one 1 year starting from the Date of Enterprise and shall include but not limited to base units work tops sinks units 3 Nos service fixtures laboratory chairs 6 Nos and laboratory stools as approved by the Engineer The extent of work shall include but not limited to Instruments to measure temperature and humidity High chemical and corrosion resistant epoxy benches Suspended Cabinets for glass wares Safety storage cabinets class 2 with UV light equipment Safety cabinets for acids and dangerous chemicals Safety shower and equipments Safety precaution facilities tools cloths and materials shoes gloves rechargeable torch lights white coats large First Aid Kits helmet and other safety materials Boiler Oil heater Burn kit Insect killer lights with twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure A C split unit 3 5 Tons with compressor 15 The Contractor shall design provide furnish install erect test commission and maintenance new laboratory furniture to fit storage laboratory partition room co
280. signed by the Engineer and shall have the following information as a minimum a Logo and name of the Company b Personal photograph passport size c Name and Nationality of the person d Work position in the plant and his grade number In case of termination of any approved person the Contractor shall return his ID card to the MPW In addition no replacement for such persons will be made unless the ID card is returned to MPW staff officially Furthermore the Contractor shall prepare special ID cards for visitors of the sites subject to the Engineer s approval No person shall be allowed to enter the plant or adjacent sites without the ID card prominently displayed 7 The Contractor shall be responsible to train an adequate number of selected personnel of his staff to cover the three shifts for emergency procedures for fire fighting and First Aid 8 The Contractor shall be responsible to provide First Aid and Medical Facilities at the project sites as required A vicinity map in English amp in Arabic indicating routing to emergency facilities shall be posted in the first aid station and on the Project bulletin board along with the list of designated emergency facilities and telephone numbers i e hospitals doctors ambulances and fire departments First Aid boxes Tender No SE 130 19 Document 2 III shall conform to SPS standard requirements Medical personnel will be approved by the Kuwait Ministry of Health 9 The Cont
281. site updated everyday 2 04 WEBSITE A Contractor is to setup a Project website for public to access via Internet and containing essential project data perspectives drawings and site photos Content on site will be subject to the approval of the Engineer B Website must have redundant hardware backup to maintain an uptime of 99 2 05 PRINTERS SCANNER and DISPLAY ACCESSORIES A Laser printer with the following characteristics 1 Capable of printing A3 size documents in colour or black and white 2 Duplex printing capable Tender No SE 130 159 Document 2 III 3 Resolution of 600 dots per inch dpi 4 Paper tray capable of holding at least 250 sheets 5 Manual paper feed with provision for feeding smaller than A4 items of stationery e g envelopes 6 Minimum printing speed of 12 full pages of text per minute Tr Cartridge toner system which shall be simple to remove and replace 8 Compatible with printer drivers supplied with the PIMSS engineering workstation laptop 9 Capable of supporting all functions available on all software installed on the PIMSS engineering workstation laptop B SCANNER Flat bed scanner with latest model selected and approved by an Engineer s Representative C PROJECTOR AND SCREEN Latest Model of Projector and its fixed screen selected and approved by an Engineer s Representative D Flat Screen TV 42 Latest Model of Flat Screen TV 42 selected and approved byan Engineer s Represen
282. skimming boards scum boxes bolts motors hoppers gear boxes diffuse airs gates air injection system belts conveyors force mains pipelines agitators screens electrical control panels collecting containers penstocks inlets and outlets discharge pipelines v notches hoppers weirs Tender No SE 130 36 Document 2 III oxygen meters drive wheels units screw classifiers air blowers mixers transmitters boxes gas filtrations injectors storage tanks guard rails fences pipelines columns and foundations of columns walls slabs blowers turbine aerators heat exchangers boilers burners fire extinguishers biogas piping diesel fuel tanks water tanks vessels platforms batteries drainage pipelines foundations of control panels and pumps wall of gates and steel ladders sewage contaminants hazardous materials sand gravels bushes debris sensors booster system polluted soil motors pumps control panels safety equipment underground services and utilities cables wires earthling rods electrodes sensors etc and all other ferrous metals b The extent of works shall include but not limited to cutting steel structures and beams puncturing the base slabs foundations footings and surrounding walls including excavating depth of 2 5 meters beyond the horizontal limits of the foundations footings slabs columns walls of all types of structures facilities All types of structures facilities shall include
283. ssigned by this item shall be carried out with a full co ordination and supervision of MEW It is the Contractor responsibility to obtain MEW approval to his design and installation ideas on the shop drawings prior to start of any Electrical Works and for the connection of the Electrical supply or part of it to the work of MPW if required 2 Upon completion of the Electrical Work the Contractor shall be responsible for obtaining MEW approval for the whole installation or modification or any part thereof including testing and energizing and setting to work Tender No SE 130 100 Document 2 III 3 The Contractor shall acquaint himself with the latest issue of the rules and regulations of Electrical installation work of the Ministry of electricity and water in Kuwait MEW It is the Contractor responsibility to obtain the latest copies of these regulations on his own expense and there will be no consideration for any such unawareness of these requirements 4 The Contractor shall check and allow in the Contract prices for obtaining any permits licenses rents and fees necessary for starting carrying out completing setting to work and handing over in an operating and useable condition all electrical works and materials called for in the Contract documents 5 The work shall include the supply manufacture installation erection delivery storage testing setting to work commissioning and handing over in perfect operating conditio
284. stle 12 Nos Stands base diff size 12 Nos Stop Clock 12 Nos Test tube stand steel 12 Nos Tongs 12 Nos 130 Tripod stand 200 mm 5 Nos Tender No SE 130 136 Document 2 III 131 Tubing diff diameter 5m pkt 12 pkts 132 Wall charts 12 Nos Erlenmeyer Flask 1 000 ml 12 Nos Graduated Cylinders Plastic 1L 5 Nos Graduated Cylinder for SVI 1L 5 Nos Stirring Bars EX immx8mm ses 25mm x 8 mm 5 Nos 50mm x 8 mm 5 Nos Funnels Top Diameter 80 mm 5 Nos Beakers Polypropylene ae ih som dg gg 1000 ml 5 Nos Carboy Polypropylene w Spigot 5 Nos 140 Erlenmeyer Flask memes as 141 Aluminum weigh dishes 5 pkts 142 Weigh bottles 12 Nos 143 Acid bottles 12 Bottles 144 Acid dispensing burette 12 Nos 145 Glass burette funnels 5 Nos 146 Glass wool 5 Nos Tender No SE 130 137 Document 2 III 147 Cadmium reduction column 12 Nos Oven Lighter 12 Nos Ice Bucket 12 Nos Eppendorf Pipette 5 Nos VWR Marco automatic adjustable pipette 0 5 ml 5 Nos VWR Marco automatic adjustable pipette tips 5 Nos T T Racks 12 Nos Tubing stretcher 12 Nos DI cartridge holder 12 Nos DI cartridge 12 Nos Apron 12 Nos Oven size baker s secret 5 Nos Blue Ice Packs 5 Nos Whirl Pac Bags 5 1 2x 9 12 Nos 5 Laboratory Chemicals Supplies The Contractor shall
285. stribution channel with 18 slide gates Internal channel in each chamber with four slide gates Fine pore membrane duplex air diffusers 1512 units in basin Membrane active area of one diffuser 0 472 m Process air piping with eighteen butterfly valves DN 300 Air from blowers located in machine house Distribution chamber supplied by two pipelines DN 500 from pumps located in machine house Distribution channel with 18 discharge gate valves DN 200 Clarifiers ST 0321 ST 0326 Six Units Circular concrete substructure tanks or clarifiers ST 0321 ST 0322 ST 0323 ST 0324 ST 0325 ST 0326 with hitched conical bottom Internal diameter 37 5 m Total V notches length at each clarifier 432 0 m Equipped with rotating bridge with bottom scraper Tender No SE 130 169 Document 2 III Bridge is driven by 2 motors and gearbox units Distribution chamber equipped with slide gate amp by intake pipe DN 700 Bottom draw off pipe DN 400 controlled by telescopic weir valve in overflow chamber Discharged is directed to the pumps in the machine house Submersible pump on floats fixed to the bridge discharge pipe and channel around clarifier connected to the drainage system Scum Network Reception chambers at clarifiers manholes Scum liquid separator tank Liquid pipeline connected to the turbid water system of Module 07 pipes and joint Electrical Panel EP 0301 Panel
286. supply test and commission the following other laboratory chemicals supplies listed below within the last six 6 months of the contract period as approved by the Engineer Description Quantity ACETONE 2 5L ALKALI SOLUTION FOR HARDNESS HACH CAT 5 BOTTLES No 22417 32 AMMONIUM CHLORIDE 1 Kg ARGON GAS CYLINDER 4 NOS AMINO ACID REAGENT FOR PHOSPHATE 5 BOTTLES HACH CAT NO 1934 32 BORIC ACID 1 Kg CALCIUM CHLORIDE 250 gm Tender No SE 130 138 Document 2 III CALCIUM AND MAGNESIUM SOLUTION FOR 5 BOTTLES HARDNESS HACH CAT NO 22418 32 DI POTASSIUM HYDROGEN ORTHO 1 5 Kg PHOSPHATE DI SODIUM HYDROGEN ORTHO 500 gm PHOSPHATE EGTA SOLUTION FOR HARDNESS HACH CAT 5 BOT NO 22297 26 EDTA SOLUTION FOR HARDNESS HACH CAT 5 BOT NO 22419 26 FERROUS AMMONIUM SULPHATE 1 5 Kg FERRION INDICATOR 1 LIT FERRIC CHLORIDE 250 gm FREE CL POWDER PILLOWS HACH CAT NO 14077 99 600 PIL GLASS MF FILTER PAPER 47 DIA MM NO 934 3500 CIR AH DPD FREE CHLORINE REAGENT FOR 10mL 36 box 50 SAMPLE ampule packet DPD TOTAL CHLORINE REAGENT FOR 10mL 20 packet SAMPLE GLUCOSE BOD 5 STD REAGENT GRADE 500 gm GRAPHITE TUBE FOR ATOMIC APSORPTION 6 NOS VARIAN PART NO 63 100011 00 ISOPROPYLE ALCHOHOL 1 5L MERCURY SULPHATE 750 gm METHYL ORANGE INDICATOR 25 gm MOLYBDATE REAGENT 5 BOT FOR PHOSPHATE HACH CAT NO 2236 32 5 BOT CHLORINE
287. t be allowed to divert wastewater flow to any emergency by pass gulf sea lines 6 The extent of works shall include but not limited to demolish concrete structures break remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 7 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 9596 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA 8 The extent of works shall include but not limited to provide earth fill test and commission new imported borrow soil to fill excess unlimited depth areas of manholes transition chambers TC hatch boxes wells pits channels culverts distribution chambers and other underground chambers as approved by the EPA and the Engineer landscaping grading compacting 95 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction of the Engineer and EPA The Contractor shall submit a certificate approved by the EPA after tre
288. t odour control building e Platform scale room e One chlorinator e One Cl injector to Cl gt tower e One fresh water softening station with one booster pump one softener container 0 2 m and two solenoid valves e Two submersible dewatering pumps for draining water transferred to two pits Four dosing pumps to inlet chambers Instruments installation control panel monitoring system Electrical and lighting installation KISR Test Area Concrete substructure Chamber with Inlet channel Electrical installation Valves Basins Gravity underground pipelines Other accessories Panels Steel Bridges Storage Tank Module 02 Module 2 shall include but not limited to the following structures mechanical and electrical equipments Bioreactor BR 021 1 Concrete substructure Inlet channel with one slide gate 1050 x 800 One basin 48 x 21 x 4 6 m Fine pore membrane duplex air diffusers 328 units formed in four grids membrane active area of one diffuser 0 472 m e Process air piping with four butterfly valves DN 250 Air blowers located in machine house e Pipe DN 400 from four pumps located in machine house Guardrails around the basin Bioreactor BR 0212 e Concrete substructure One basin with 6 separate chambers Each chamber size 35 x 8 4 x 4 39 m Inlet open channel with two slide gates Flow meter in the inlet channel Distribution channel with 12 slide gates F
289. taken The Contractor shall not have the right to make any future claims or any extra cost or delay in time on the basis for proper completion of the works required in the contract 1 Groutfilling unlimited depths and full volumes of the following underground gravity pipelines completely start from the inlets gravity pipelines ends to the outlets gravity pipelines ends of minimum lengths m until the volumes of the underground gravity pipelines are completely full with no voids remain unfilled All the works shall be approved by the Engineer and EPA Tender No SE 130 63 Document 2 III Type Diameter of No of Es M Um Outlet of Inlet of ltem of pipeline pipeline pipeline Ga pipeline Pipeline material mm Asbestos 1600 1 3100 A15 TC 1 Asbestos 450 1 3240 A2 811 812 2 Asbestos 700 1 2400 A2 13 3 Asbestos 600 1 2200 Al 15 4 Note Item 1 means Grout filling unlimited depth and full volume of underground gravity pipeline completely Length 3100 m Diameter 1600 mm Asbestos start from the inlet of gravity pipeline end connected to Transition Chamber TC to the outlet of gravity pipeline end connected to main pumping station A15 until the volume of the underground gravity pipeline is completely full with mix flowable fill materials with no voids remain unfilled Item 2 means Grout filling unlimited depth and full volume of underground gravity pipeline comple
290. tation A2 d 19600 mm Length 2200 m asbestos start from secondary lifting station S15 to main pumping station A1 Section C Renovation works at Ardiya Sewage plant A Renovation works of new double layers asphalt roadways and storm water drainage system of zones areas 1 amp 2 and other related works within two 2 years starting from the Date of Enterprise B Renovation works of street lightings poles outdoor lightings poles of zones areas 1 amp 2 and other related works within two 2 years starting from the Date of Enterprise C Renovation works of chain link boundary fence within the perimeter 800 m 440 m 800 m 440 m with Barbed Wires completely height 2 m and other related works within two 2 years starting from the Date of Enterprise D Renovation works of MPW Quality control center AB 1044 and other related works within three 3 months starting from the Date of Enterprise E Renovation works of the main Guard House AB 1041 and other related works within three 3 months starting from the Date of Enterprise F Renovation works of MPW Switchgear room of substation S S 1 SU 0241 and other related works within two 2 years starting from the Date of Enterprise G Renovation Rehabilitation and Modification works of Effluent Transfer Pumping Station PS 0633 and other related works within two 2 years starting from the Date of Enterprise H Renovation works of MPW Switchgear room of substation S S
291. tative to be located in Meeting room or Reception area decided by Engineer s representative The Engineer will select the item A B C and D for the project and contractor will make the necessary payment and carryout all work described above The total cost of these four items will not exceed KD 3 000 Kuwaiti Dinars three thousand only 2 06 UN INTERRUPTIBLE POWER SYSTEM A Packaged floor mounted type capable of maintaining the following equipment for a period of 20 minutes Supported equipment shall not power down and reboot in the event of mains power failure 1 Engineering workstations Laptops including Printers 2 Web server and other servers network switches routers B UPS shall be provided for all Engineering workstations laptop docking stations and all other devices and shall be activated automatically 2 07 PASSWORD ACCESS A PIMSS users shall gain access to the system by logging on which shall be achieved by entry of a unique PIMSS user name and password combination B Each PIMSS user shall be assigned a system access level which shall enable that PIMSS user once logged on to access only those commands monitoring and program functions which have an equal or lower access level C Only the highest access level shall enable assignment or reading of PIMSS user passwords This level access is to be assigned to the Project Specialist and System Administrator Designated staff member of the Engineer and Engineer s Rep
292. te covers building of cable manholes earthling pits and fitting laying of ducts ceiling of ducts excavation of trenches backfilling and consolidation carting away of surplus spoil etc shall be executed by the Contractor and the full and entire cost of all such builder s works and materials shall be included in the total bid amount 1 Renovation works 1 Disconnect Dismantle remove and abandonment of the existing equipment at the existing L T Switchboard at substation S S 1 Module SU 0241 includes incoming feeders main switchboard distribution board MCC Control panel batteries and battery charger power and control cables lighting fittings etc and all other electrical equipment and transport all of them safely to the ministry store 2 Renovate supply manufacture delivery installation erection testing and setting to work commissioning within two 2 years starting from the Date of Enterprise and handling over in perfect operating condition the following L T switchgears and equipment complete with all required cables wires fittings and accessories including necessary civil and builder works L T Incoming Feeder Panels Main L T switchboard Distribution boards Control board with mimic panel Motor Control Center MCC O0oOoOOoo0 Tender No SE 130 83 Document 2 III f EAD Environmental Affair Department Feeder panel g Automatic Transfer Switch h Batteries and battery charge
293. te existing and new landscaping of zones areas 1 amp 2 The water source shall be effluent treated wastewater from the header tank at Ardiya sewage plant and shall be mixed with fertilizers 4 The extent of works shall include but not limited to study design renovate supply install test commission operation and maintenance new main irrigation pipeline and new irrigation network system to provide an adequate sufficient water supply to EAD Environmental Affair Department zone area within the perimeter fence of EAD located outside the boundary fence and adjacent to Ardiya sewage plant as approved by the Engineer The water source shall be effluent treated wastewater from the header tank at Ardiya sewage plant and shall be mixed with fertilizers 5 The extent of works shall include but not limited to provide erect test commission and maintenance reinforced concrete foundation to withstand pump and replacement of all related necessary spare parts during the contract period 7 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new automatic self cleaning screen filter of 200 mesh filtration fineness 8 The extent of works shall include but not limited to design renovate supply install test commission operation and maintenance new a pilot operated diaphragm type pressure reducing sustaining valve at the discharge side of the screen filter 9 T
294. te hot and cold exhaust fan water cooler boiler large size insect killer lights twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure refrigerator 15 feet electrical gas oven with gas cylinder laundry washer dryer capacity 5 kg with other fittings and connections water filters oil heater curtains and other related kitchen services such as plumbing ceramic tiles fittings and all civil mechanical electrical and safety works All specifications of new kitchen equipment and materials subject to the Engineer approval 8 The Contractor shall disconnect dismantle remove and cart away existing interior lightings off the site The Contractor shall renovate provide install test commission and maintenance new interior lightings fixtures having a minimum illumination level of 500 Lux in all the areas accessories and control switching devices inside the new guard house The lighting fixtures shall be 4 x 20 W tube fixtures fluorescent luminaries with mirror optical reflectors and electronic power saving ballast All accessories shall include power outlets all indoor and outdoor lighting telephone extension points etc The layout type and the numbers of fixtures shall be approved by the Engineer All works materials and specifications shall be subject to the Engineer approval 9 The Contractor shall renovate provide install test commission and maintenance new external lightings at least 400 W 4 Nos met
295. ted parts All electrical materials spare parts maintenance and repairs works must comply with the latest edition of MEW regulations for installation in buildings The Contactor must submit for approval samples specifications catalogues maintenance program and technical details for repairs to Engineer 20 The extent of work shall include but not limited to lubrication calibration checking fuel and distilled water recharging gas cleaning from dust testing inspecting all fans compressors motors wiring switches controls and protection devices calibrating adjusting lubricating checking of tightness of all connections cleaning the body and casing charging cleaning filters Replace worn out drain lines replace fuses bulbs fittings and make the necessary modifications if required Maintenance of various types of electrical circuit breakers contact switches rectifiers inverters relays motor control panels electrical protection devices batteries lighting system etc 21 The Contractor shall be responsible to submit to the Engineer and execute the preventive maintenance program works that occur at continuous frequencies for the duration of the contract period according to manufacturer recommendation of the existing and new mechanical and electrical equipments of zone area 1 facilities starting from the Date of Enterprise and new mechanical and electrical equipments of zone area 2 facilities for the duration of one 1 year a
296. tely Length 3240 m Diameter 450 mm Asbestos start from the inlet of gravity pipeline end connected to secondary lifting stations S11 S12 to the outlet of gravity pipeline end connected to main pumping station A2 until the volume of the underground gravity pipeline is completely full with mix flowable fill materials with no voids remain unfilled Item 3 means Grout filling unlimited depth and full volume of underground gravity pipeline completely Length 2400 m Diameter 700 mm Asbestos start from the inlet of gravity pipeline end connected to secondary lifting station S13 to the outlet of gravity pipeline end connected to main pumping station A2 until the volume of the underground gravity pipeline is completely full with mix flowable fill materials with no voids remain unfilled Item 4 means Grout filling unlimited depth and full volume of underground gravity pipeline completely Length 2200 m Diameter 600 mm Asbestos start from the inlet of gravity pipeline end connected to secondary lifting station S15 to the outlet of gravity pipeline end connected to main pumping station A1 until the volume of the underground gravity pipeline is completely full with mix flowable fill materials with no voids remain unfilled Tender No SE 130 64 Document 2 III 2 Provide grout fill test and commission mix flowable fill materials long term hardened strength materials consist of fluid mixture of 1 10 cement
297. them safely to the new MPW store on site 10 The Contactor shall arrange for an adequate temporary power supply unit of an enough capacity for all utilities and services zone area 2 facilities and all other running loads during the rehabilitation works of the S S 6 to ensure the availability of the electric power a Description of the works 1 Disconnect Dismantle remove and abandonment of the existing equipment at the existing L T Switchboard at substation S S 6 Module SU 0641 includes incoming feeders main switchboard distribution board MCC Control panel batteries and battery charger power and control cables lighting fittings etc and all other electrical equipment and transport all of them safely to the ministry store Tender No SE 130 101 Document 2 III 2 Renovate rehabilitate supply manufacture delivery installation erection testing and setting to work commissioning within two 2 years starting from the Date of Enterprise and handling over in perfect operating condition the following L T switchgears and equipment complete with all required cables wires fittings and accessories including necessary civil and builder works L T Incoming Feeder Panels Main L T switchboard Distribution boards Control board with mimic panel Motor Control Center MCC Automatic Transfer Switch Batteries and battery charger Lighting system A C Package unit Ventilation system Fire Alarm System
298. ties completely on site within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m completely except zones areas 1 amp 2 within two 2 years starting from the Date of Enterprise All types of structures facilities are divided into ten 10 modules These modules in Appendix 1 and attached drawings as guidance only to the Contractor and do not Tender No SE 130 34 Document 2 III cover all require works and does not show all the actual equipment and structures on sites The extent of works shall include but not limited to demolish dismantle dewater break cut remove abandonment cart away to a tippers off the site unlimited depth of underground gravity sewer underground storm water drainage pipelines underground pipelines gravity and pressure pipelines all types of pipes materials all different sizes of pipes diameters dry and wet manholes transition chambers TC wells and pits channels distribution chambers culverts roads lightings buildings and all other underground chambers within the boundary area of the fence perimeter 800 m 440 m 800 m 440 m completely except partial of sanitary sewerage system and partial of storm water drainage system earth filling excess areas with new imported borrow soil as approved by the EPA and the Engineer landscaping grading compacting 9596 MDD soil and to be reinstated and restored the site to a condition match its surroundings and to the satisfaction
299. tion cleaning microscope 1 L 1 Pack 6 months Immersion oil for microscope 1 Pack 6 months Rosalic Acid 100 g 1 Bottle 3 months Chloroform 500ml 1 Bottle 3 months Acetone 4 L 1 Bottle 6 months Cotton 2 Rolls 3 months Magnesium Chloride Hexa Hydrate 500 g 1 Bottle 3 months 31 Sodium Di hydrogen phosphate monohydrate 500 g 1 Bottle 3 months E Tryptone 500 g 1 Bottle 6 months Methyl red 100 g 1 Bottle 6 months Ammonium Acetate 500 g 1 Bottle 12 months Ammonium Hydroxide 2 5 L 1 Bottle 6 months 36 Ammonium Molybdate 500 g 1 Bottle 12 months Tender No SE 130 121 Document 2 III Boric Acid 500 g 1 Bottle 2 months Calcium Chloride 500 g 1 Bottle 3 months Carmine 500 ml 1 Bottle 6 months Mercuric Sulfate 100 g 1 Bottle 4 months Nitric Acid 2 5 L 1 Bottle 4 months 1 10 Phenanthroline 5 g 1 Bottle 4 months Sodium Hydroxide 500 g 1 Bottle 4 months Sulfuric Acid 2 5 L 1 Bottle 4 months Aluminum Chloride 6 Hydrate Pure 500 g 1 Bottle 12 months Ammonium Chloride 500 g 1 Bottle 3 months Bromothymol Blue Water Soluble 5 g 1 Bottle 4 months Bromocresol green Water Soluble 5 g 1 Bottle 4 months Di Sodium Hydrogen O Phosphate AR 500 g 1 Bottle 3 months Ferric Chloride 6 Hydrate AR 500 g
300. tion chambers inlet discharge pipes out discharge pipes guard rails around basins switches drying beds filter media pipes networks scraper machine equipment for drying beds sand filters pipes networks detectors alarms lights fixtures central telephone system and other related connections concrete and steel ladders oil and grease shelters parking shelters shutter doors panels A C units concrete ladders concrete columns ferrous ladders irrigation networks pipes valves equipments control system rotary impact sprinklers PVC main irrigation pressure pipelines and fitting for water distribution polyphone tubes and micro tubes nozzles heads sub lateral irrigation lines drip emitters with single and multi outlets gates couplers vacuum breakers reducers T connections elbows screen filters valves boxes fertilizer injectors station controllers Y strainers and other related irrigation parts fountain sludge piping with valves drainage sewer submersible pumps drainage sumps pumps compressors bathroom fixtures fans pressure gauges traveling overhead cranes overhead gantry beam mimic panels electric panels steel cabinets belt filter presses diesel pumps hoses fuel tanks filters fire extinguishers garbage containers collecting containers roof FRP water tanks Tender No SE 130 44 Document 2 III boilers sanitary fittings doors windows tiles safety fences materials and equipments of stores a
301. tions August 2002 Submittals and Approval 1 The Contractor shall submit to the Engineer for review and approval the following documents within 2 months from the date of Enterprise A Full study report on the modification and development of the effluent transfer pump station as mentioned above complete with the proper recommendation and equipment selection to achieve such work B Shop drawing and technical data for the new Pumping Station shows the modification required and new arrangement of the equipment e Product specifications and performance e Pump materials details e Motor housing materials winding material ambient temperature and maximum elevation in which motor is designed to operate continuously insulation class design factor bearing life and dynamic balance Dimension and weight Provision of mounting on the pump Pump Motor construction details Starting methods Speed torque curve C Submittals shall also contain workshop drawing documents manufacturer specification of the new switchboard MCC control panel and distribution cables and accessories and all other electrical equipment will be installed through the work including e Single line diagram showing loads and short circuit calculation e Schematic diagram showing electrical arrangement of the panels e Cable lay out e Component list D Working program for executing the work includes delivery time installation time testing and
302. tions Plaster shall be clean dry and free from loose to materials Tender No SE 130 54 Document 2 III Index Document 2 III Part B Particular Requirements Section B Grout filling unlimited depths and full volumes of underground pressure and gravity pipelines completely Clause 1 Grout filling unlimited depths and full volumes of underground pressure pipelines completely including demolish dismantle break remove abandonment and earth fill of hatch boxes completely with other related works Clause 2 Grout filling unlimited depths and full volumes of underground gravity pipelines completely including demolish dewater dismantle break remove abandonment and earth fill of manholes completely with other related works Tender No SE 130 55 Document 2 III Clause 1 Grout filling unlimited depths and full volumes of underground pressure pipelines completely including demolish dismantle break remove abandonment and earth fill of hatch boxes completely with other related works The price fixed for this item is lump sum and shall include all personnel engineers supervisors drivers manpower and labors machineries equipments pumps materials supplies consumables transportation tools or implements temporary accommodations and furnishings and generally for all means used for the fulfillment of the contract requirements which he undertakes to provide on site to carry out the works completely within the contract p
303. tions The extent of work shall include maintenance and painting metal door for each substation and provide new lockers 12 The Contractor shall provide install test commission and maintenance new water proofing roof insulation 75 mm thick closed cell non absorbent rigid polystyrene insulation board The insulation boards shall be placed immediately after the membrane has been laid Flexible waterproofing membrane for roofing Tender No SE 130 85 Document 2 III shall be bitumen based to accepted standards and approved by the Engineer Surfaces to receive the membrane shall be smooth dry and free from dust Roof screed shall be laid to falls over the concrete roof slab and have a minimum thickness of 35 mm The screed shall be laid compacted and shall be leveled and finished with steel trowel Primer for concrete shall be suitable for use with the waterproofing membrane 13 The Contractor shall disconnect dismantle remove and cart away existing interior lightings off the site The Contractor shall provide install test commission and maintenance new interior lightings fixtures accessories and switching devices power outlets indoor and outdoor lighting telephone extension points etc 14 The Contractor shall provide install test commission and maintenance new external lighting fitting 4 Nos 500 Watt each halogen type fixtures with all related wires and accessories outside substation 15 The Contractor shall provide
304. tions and other governmental authorities for the safety of manpower and fire precaution on sites within one 1 month from the Date of Enterprise 9 The Contract shall submit request of inspection of all required activities works and shall include but not limited to demolish and break concrete structures disconnect the electricity supplies dismantle mechanical and electrical equipments cut pipes and abandonment all types of the structures facilities excavate dewatering remove abandonment cart away dispose and deliver backfill and earth fill and all other contract requirements for approval by the EPA and the Engineer 10 The Contractor shall provide all necessary safety personnel materials and equipments lightings precaution against fire fencing excavation support and protection safety signs and temporary power supply for proper completion of the work 11 The Contractor shall require to pre clean and flush unlimited depth of manholes sewers pits channels chambers culverts drying beds sand filters underground gravity and pressure pipelines completely remove wastewater sludge sand gravels and other contaminants completely cart away to a tippers off the site transport and dispose to dumping area outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval The quantities of machineries tri
305. tor shall make all necessary arrangements to ensure the continuous supply of spare parts and materials and the rate of supply of these materials shall be in such quantities and accounts as would ensure uninterrupted operation Tender No SE 130 144 Document 2 III 7 Where spare parts materials or equipment are manufactured under license the Contractor shall submit an assurance obtained from the Company that owns the original design principle manufacturer addressed to the Employer confirming the safety of the design At the same time the owners of such designs shall confirm that the produced equipment is in good condition and in accordance with said designs 8 All equipment or parts thereof instruments or materials shall be delivered to the site in their original packages and shall be easily identified without the necessity of unpacking them All packages shall bear the name and brand of the manufacturer 9 The Contractor shall obtain and submit to the Engineer the Guarantee Certificate or Warranty furnished by the manufacturers and suppliers and such Guarantees or Certificates shall be supplementary to and not in lieu of the Contractor s own Guarantee and shall in no way invalidate the latter If any defects or faults are not made good by the Contractor within a reasonable time the Employer may proceed to do the work at the Contractor s risk and expense 10 If any defects or faults shall appear in any items of equipment which nec
306. torm water drainage system within two 2 years starting from the Date of Enterprise Zone area 1 Main Entrance Gate Guard House AB 1041 Mosque AB 1043 MPW Quality control center AB 1044 Substation SU 0241 and Wastewater Pumping Station PS 0931 Zone area 2 Substation SU 0641 Header tank CT 0612 which received the treated effluent from Rikka sewage treatment plant Inlet and outlet channels of header tank By pass channel to sea which is connected to outlet channel of second stage contact tank header tank Effluent transfer pumping station PS 0633 effluent transfer pumps 3 Nos only with discharge pipe surge vessels VS 0661 4 Nos only related to effluent transfer pumping station and Inlet and outlet channels of effluent transfer pumping station Partial of Sanitary sewerage system Wastewater Pumping Station PS 0931 Main Sewer pipeline and manholes connected to Wastewater Pumping Station PS 0931 and internal sewer pipelines and manholes of zones areas 1 amp 2 connected to main sewer pipeline or wastewater pumping station PS 0931 Main storm water drainage system within the boundary area of the perimeter fence 2 Demolish Screw Conveyors Lifting Stations S20 and S21 completely except perimeter fences within two 2 years starting from the Date of Enterprise Section B Grout filling unlimited depths and full volumes of underground pressure and gravity pipelines completely 1 Grout filling un
307. tractor shall to the maximum extent possible prevent nuisance as a result of dust raised as a result of the works Dust Control shall be by watering by tanker trucks with spray attachments or other approved methods Traffic control devices shall conform to the requirements of the General Specifications for Kuwait Motorway Expressway System and to the Kuwait Traffic Signs Manual All traffic control devices shall be approved by the Engineer before installation on the site After initial use is complete the Contractor may reuse any approved item as the need arises Clause 24 Carting away dismantled equipments and demolished structures All excavated materials dismantled equipments break and demolished structures to be incorporated in the work shall be placed so that free access can be had at all times to all parts of the work and to all public utility installations in the vicinity of the work Materials and equipment shall be kept neatly piled and compactly stored in such locations as will cause a minimum of inconvenience to public travel and adjoining owners and occupants Tender No SE 130 18 Document 2 III The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 25 Safety 1 The Contractor shall take all necessary precautions and provide all n
308. trol equipment board One chlorination control panel with automatic dosing system 1 stage 0 15 mg dm 2 stage 0 6 mg dm Two emergency high speed fans Two injectors for 1 and 2 stages chlorination Chlorine Cylinder Storage Building 1 No Chlorinators Building 1 No Electric Control Panel Building 1 No Over head Crane Two emergency high speed fans Lighting Installation Ventilation Rabya Pumping Station PS 0632 Concrete structure Irrigation pumps 3 Nos Vertical filter 2 Nos FRP vessel with mixer 2 Nos Fertilizer injector 2 Nos Pressure tank 2 Nos 15 m Hosing amp washing pumps 3 Nos Old irrigation pumps 3 Nos Inlet and Outlet channels Effluent Pumping Station PS 0633 pumps Three pumps with 2 speed each Two dewatering pumps with discharge pipeline Surge Protection Surge vessels 4 Nos and connected installations Tender No SE 130 174 Document 2 III System Tanks VS 0661 Module 07 Module 7 shall include but not limited to the following structures mechanical and electrical equipments Sludge Thickeners Complex TH 0721 TH 0726 Six Units Concrete structure Three concrete circular tanks TH 0721 TH 0722 TH 0723 diameter 10 m side wall high 4 m side wall sludge depth 3 m cone depth 2 7 m Hopper diameters upper 1 6 m bottom 0 4 m hopper depth 1 1 m Effective vol 8 m Flocculate scrapper central
309. ts as approved by the Engineer D Demolish miscellaneous structures completely disconnect the electricity supplies dismantle miscellaneous mechanical and electrical equipments and instruments completely cut pipes break concrete structures remove abandonment cart away to a tippers off the site 1 Demolish miscellaneous structures completely within two 2 years starting from the Date of Enterprise disconnect the electricity supplies dismantle miscellaneous mechanical and electrical equipments and instruments completely cut pipes break concrete structures remove abandonment cart away to a tippers off the site transport to MPW stores outside the site to any unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 2 The extent of works shall include but not limited to gates weirs pipes steel basins chlorine residue measurement stations chlorine cylinders rolling stands chlorine pipes and pipelines air injection pipes chlorinators ejectors gas pipes gas cylinders mimic panels control rooms control room panels and hardware flow meters safety equipments valve VC 0751 composite sampler SL 0354 pH meters steel bridges storage tanks surge vessels ventilation fans FRP pipes caustic soda pipes air pipelines basins valves gates oxygen meters Hydrogen sulfide monitoring system storage tanks distribu
310. ty 1450 kW each with diesel fuel burner pump in boiler room Electrical control panel for boilers Two hot water circulation pumps DN 100 each One diesel fuel auxiliary tank in Boiler room One drain submersible pump capacity 28 8 m h head 6 m rotation 1395 min motor 4 kW Control room with mimic panel and MCC Window A C unit in control room Bath room with W C shower two sinks and boiler Water tank FRP on the boiler room roof Flame arrested vessel combined with water drain located in separate room Diesel Fuel Tank FS 0764 Underground tank 20 m for storage of diesel fuel for digestion boilers One diesel fuel pump 1 1 kW Pipeline DN 25 connecting fuel pump with auxiliary tank in boiler room Filing manhole FI 0751 Fire extinguisher kiosk Gas Holder GT 0763 One steel tank in water steel basin maximum biogas volume 500 m maxi Gas pressure 2 kPa Flame arrested and vacuum pressure releasing valve on the gas holder Valve house at gas holder with gas inlet and outlet valves DN 150 and with water supply valve Tank dome level control sensor and indicators Gas flow control valve DN 150 to flare with pneumatic actuator Air compressor Station AB 0721 Air compressor for gas flow pneumatic actuator Control box for compressor and power cabling Piping DN 15 from compressor to actuator Waste Gas Flare WG 0761 Steel stack 15 m high for biogas burring Tender
311. types of structures facilities shall include foundations columns footings slabs walls roofs beams foundations and concrete reinforcement structures but not limited to buildings facilities underground floors ground floors upper floors pumps gallery facility building workshop stores substations diesel generator houses chlorine buildings sludge pumping station dewatering building scum pumping station boiler house turbid water pumping station machine house screw conveyors lifting stations site wastewater pumping station odour control building Rabya pumping station substations including transformers buildings mosque prefabricated house laboratory building and other related facilities a The extent of work shall include disconnect the electricity supplies dismantle mechanical and electrical equipments and instruments demolish and break Tender No SE 130 35 Document 2 III concrete structures cut pipes remove abandonment cart away to a tippers off the site transport and dispose to dumping area outside the site but not limited to lighting installations plumbing system pipes plumping specialties sewage contaminants hazardous materials and polluted soil sanitary sewerage system toilets sanitary fixtures exhaust fan tiles storage tanks fittings and other connections hoses electrical control boxes ferrous materials columns foundations louvers and vents telephone central system lightings fixtures i
312. ue prayer room The extent of works shall include but not limited to provide install test commission and maintenance of mosque building new glazing windows with mesh screens frames and new curtains as Tender No SE 130 105 Document 2 III approved by the Engineer All works and materials shall be subject to the Engineer approval 8 The extent of works shall include but not limited to provide erect install furnish test commission and maintenance new thick carpet of similar type used in mosque half dozen books wood carriers cabinets consists of three 3 shelves with glass rolling doors large shoes closet large insect killer lights with twin tubes 16watts and 30 cm length with transformer housed in PVC enclosure high sound speaker system to recall prayers A C Air Conditioning split unit 3 5 ton with compressor 2 Nos oil heater portable electric fans 2 Nos and all required electrical installations All works and materials shall be subject to the Engineer approval 9 The extent of works shall include but not limited to renovate provide install test commission and maintenance new ablution facilities and toilets rooms and shall include but not limited to new plumbing system pipes plumping specialties sanitary sewer system and manholes connected to the nearest new sewer manhole new sanitary fixtures urinals water closets etc new faucets hot and cold 6 Nos with wide tub used for ablution purpose soaping
313. ume 3 x 1352 4056 m Provided with chlorine injection at influent channel Measuring Flume Automatic flow measurement recording Controls chlorine dosage Rapid sand filters Complex RD 0621 Concrete structure Chlorine residual measurements Twelve units 10 x 10 m each Beds of 5 layers of gravel and coarse sand Three pneumatic sluice gates in each filter Pneumatic butterfly valves DN 150 on scour air in each filter Pneumatic butterfly valve DN 500 on backwash water in each filter Tender No SE 130 173 Document 2 III Pneumatic butterfly valve DN 500 on filtrate in each filter Backwash pump 3 Nos Backwash return pumps 4 Nos Air scouring blower GMB 14 9 3 Nos Air control compressor 2 Nos Booster pumps 3 Nos Booster compressor 2 Nos Backwash system is provided with holding tank and balancing tank Slug chlorination operates for short duration to prevent algae growth Motive water pumps 2 Nos for chlorine injection Dewatering pump 1 No Overhead crane Control room Bath room amp two roof A C units Chlorination Buildings CH 0642 Concrete structure 64 sets x 0 65 ton drums Six sets platform scale 5000 kg capacity One set drum beam balance Three chlorine evaporators Three 1 stage chlorinators Two 2 stage chlorinators Three chlorine fume detectors with acoustical and optical alarms One chlorination con
314. ump No 3 Over Head Chain Block Effluent Transfer Pump No 1 Effluent Transfer Pump No 2 Effluent Transfer Pump No 3 Emergency Dewatering Pump No 1 Emergency Dewatering Pump No 2 Chlorine residual Pump No 1 Chlorine residual Pump No 2 Chlorine residual Pump No 3 Chlorine residual Pump No 4 Over Head Crane Over Head Crane Block Chlorinator No 1 Chlorinator No 2 Chlorinator No 3 Chlorinator No 4 Chlorinator No 5 Over Head Crane Farm Pump No 1 Farm Pump No 2 Farm Pump No 3 Air Compressor No 1 Air Compressor No 2 Irrigation Pump No 1 Irrigation Pump No 2 Irrigation Pump No 3 Washing and Hosing Pump No 1 Washing and Hosing Pump No 2 Washing and Hosing Pump No 3 Dosing Pump Drainage Pump No 1 Drainage Pump No 2 Mixer Surge Vessel Tank No 1 Surge Vessel Tank No 2 Surge Vessel Tank No 3 Surge Vessel Tank No 4 Module 7 Thickener Bridge Drive Unit No 1 Thickener Bridge Drive Unit No 2 Thickener Bridge Drive Unit No 3 Thickener Bridge Drive Unit No 4 Thickener Bridge Drive Unit No 5 Thickener Bridge Drive Unit No 6 Fresh Sludge Pump No 1 Fresh Sludge Pump No 2 Dewatering Pump Turbid Water Pump No 1 Tender No SE 130 184 Document 2 III Turbid Water Pump No 1 De
315. umping station PS 0632 shall not be demolished until the commissioning of the new irrigation pumps at the New Pumping Station completed 8 The Contractor shall be responsible for all related mechanical electrical and civil works require to the Renovation Rehabilitation and modification works for effluent transfer pumping station Module 06 PS 0633 9 The Contractor shall be responsible for the controlling not to interrupt the operation of the continuous flow of effluent tertiary treated wastewater to DMC Date Monitoring Center and to Rabya Farms 10 All usable salvage items shall be delivered to MPW stores outside the site to unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them 11 All non salvage ferrous metals surfaces shall be delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer 12 The extent of works shall include but not limited to trench excavation termite control groundwater pressure investigation soil rehabilitation and treatment of polluted soil on site backfill excavated area after treatment of polluted soil landscaping grading compacting 95 MDD soil and to be
316. ure pipelines are completely full with mix flowable fill materials with no voids remain unfilled tem 2 means Grout filling unlimited depth and full volumes of underground double pressure pipelines completely each pipeline Length 5500 m Diameter 450 mm Type GRP start from the inlets of double pressure pipelines ends connected to main pumping station A13 to the outlets of double pressure pipelines ends connected to main pumping station A11 Therefore the total length required to grout filling unlimited depth and full volumes of underground pressure pipelines is 5500 m x 2 pressure pipelines 11000 m until the volumes of the underground double pressure pipelines are completely full with mix flowable fill materials with no voids remain unfilled Tender No SE 130 58 Document 2 III Item 3 means Grout filling unlimited depth and full volumes of underground double pressure pipelines completely each pipeline Length 3500 m Diameter 700 mm Type asbestos start from the inlets of double pressure pipelines ends connected to main pumping station A2 to the outlets of double pressure pipelines ends connected to main pumping station A11 Therefore the total length required to grout filling unlimited depth and full volumes of underground pressure pipelines is 3500 m x 2 pressure pipelines 7000 m until the volumes of the underground double pressure pipelines are completely full with mix flowable fill materials with no
317. utlet channel of header tank effluent transfer pumping station Module 06 PS 0633 or new pumping station 3 The Contractor shall be fully responsible for the proper civil maintenance works of wastewater pumping station PS 0931 concrete structure valves pumps and equipments main sewer pipelines and manholes within the boundary area of the perimeter fence main storm water drainage system within the boundary area of the perimeter fence Internal sewer pipelines and manholes of zones areas 1 amp 2 connected to main sewer pipeline or wastewater pumping station PS 0931 Internal storm water drainage system of zones areas 1 amp 2 connected to main storm water drainage system and other related facilities starting from the Date of Enterprise for the duration of the contract period as approved by the Engineer 4 The extent of works shall include but not limited to clean and flush unlimited depth of manholes sewers and pipelines completely remove wastewater sludge sand gravels and other contaminants completely of zones areas 1 amp 2 cart away toa tippers off the site transport and dispose to dumping area outside the site to Tender No SE 130 148 Document 2 III unlimited distances locations areas in the state of Kuwait in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval Metals and frames covers of manholes and hatch boxes shall be cleaned and sand blast to remov
318. ve or under their services He shall submit a detailed programmed for each area in which the work shall be commenced and the anticipated date of commencement in addition to a report signed by the Engineer the service authority Engineer and the Contractor confirming the Notice of Intent 5 Protection of Existing Structures and Ultilities The Contractor shall be responsible for the care and protection of all existing utilities or other facilities and structures which may be encountered in or near the area of work Temporary support adequate protection and maintenance of all underground and surface utilities encountered in the progress of the work shall be furnished by the Contractor at his expense and under the direction of the Engineer and the service authority Any structures that have been disturbed shall be restored immediately 6 Damage to Utilities and Properties In the event of any damage to utilities or properties during the progress of the Works due to the Contractor s failure to exercise the proper precautions or the failure of the Contractor or his agents employees the Subcontractor will be held liable for the cost of repairs penalties enforced by the authorities and protection of all such utilities or property The decision of the Employer regarding responsibility for any damage or interruption of any utility or service lines shall be final 7 The cost of the above mentioned requirements will be borne by the Contractor a
319. voids remain unfilled Item 4 means completely each pipeline Length 16000 m Diameter 1000 mm Type asbestos start from the inlets of double pressure pipelines ends connected to main pumping station A11 to the outlets of double pressure pipelines ends connected to Ardiya sewage plant Therefore the total length required to grout filling unlimited depth and full volumes of underground pressure pipelines is 16000 m x 2 pressure pipelines 32000 m until the volumes of the underground double pressure pipelines are completely full with mix flowable fill materials with no voids remain unfilled Item 5 means Grout filling unlimited depth and full volumes of underground double pressure pipelines completely each pipeline Length 3100 m Diameter 1000 mm Type DI start from the inlets of double pressure pipelines ends connected to main pumping station A15 to the outlets of double pressure pipelines ends connected to Rikka sewage plant Therefore the total length required to grout filling unlimited depth and full volumes of underground pressure pipelines is 3100 m x 2 pressure pipelines 6200 m until the volumes of the underground double pressure pipelines are completely full with mix flowable fill materials completely with no voids remain unfilled 2 Provide grout fill test and commission mix flowable fill materials long term hardened strength materials consist of fluid mixture of 1 10 cement sand and shall include but not
320. waste disposal areas Prevent erosion and sedimentation 2 Minimize amount of bare soil exposed at one time 3 Provide temporary measures such as dikes and drains to prevent water overflow 4 Construct fill and waste areas by selective placement to avoid erosive surface silts or clays 5 Periodically inspect earthwork to detect evidence of erosion and sedimentation promptly apply corrective measures C Noise Control 1 Fit all generators compressors percussion tools and vehicles with effective silencers of a type recommended by manufacturers of the generators compressors tools or vehicles 2 Comply with Municipality Regulations 3 Electrical generators and other heavy equipment are to be housed in Sound proof enclosure D Pest and Rodent Control Provide proper measures to control pests in occupied temporary accommodation and storage areas E Pollution Control Provide methods means and facilities to prevent contamination of soil water and atmosphere from discharge of noxious toxic substances and pollutants F The cost of the above mentioned requirements will be borne by the Contractor and shall deem to have allowed for the same in the total price of this contract The Contractor shall not have the right to claim for compensation in time or cost Clause 38 Temporary Drainage Upon taking possession of the Sites the Contractor shall assume full responsibility for draining rainwater ground water and water arising
321. watering Pump Digested Sludge Pump No 1 Digested Sludge Pump No 2 Boiler No 1 Boiler No 2 Sludge Pump No 9 Sludge Pump No 10 Sludge Recirculation Pump No 1 Sludge Recirculation Pump No 2 Sludge Recirculation Pump No 3 Module 8 Sludge Settling Tank Driving Unit No 1 Sludge Settling Tank Driving Unit No 2 Crusher Device No 1 Crusher Device No 2 Sludge Pump No 7 Sludge Pump No 8 Digested Sludge Pump No 1 Digested Sludge Pump No 2 Turbid Water Pump No 1 Turbid Water Pump No 2 Sludge Pump No 1 Sludge Pump No 2 Module 9 Portable Water Pump No 1 Portable Water PumpNo 2 Brackish Water Pump No 1 Brackish Water Pump No 2 Waste Water Pump No 1 Waste Water Pump No 2 Tender No SE 130 185 Document 2 III Appendix 2 Demolish Disconnect Dismantle and Abandonment Screw Conveyor Stations S20 amp S21 Demolish all types of structure facilities disconnect electrical supplies dismantle electrical and mechanical equipments cut pipes break concrete structure remove abandonment and cart away off the site The Contractor shall include the following information of the appendix as guidance only to the Contractor and does not cover all required works Therefore it is obligated that the Contractor to visit all the sites and conduct joint survey with MPW
322. with emulsion paint Painting shall be carefully executed with clean brushes and in the best manner and applied strictly in accordance with the manufacture s instructions All paints stains varnishes shall be well stirred before use and thinned only in accordance with manufacturer s recommendations Painting of exterior walls shall not be carried out in wet dusty or foggy weather and interior walls and roofs shall not proceed in dusty conditions Tender No SE 130 99 Document 2 III 5 The Contractor shall dismantle the existing damaged aluminum doors single and double glazed aluminum windows with mesh screens frames lockers stoppers handles louvers wood doors exhaust fans floor tiles handrails shutter door and renovate provide install test commission and maintenance new aluminum doors single and double with lockers glazed aluminum windows with mesh screens frames lockers stoppers handles louvers wood doors with lockers exhaust fans floor tiles handrails shutter door with locker and other appurtenances The shutter door shall be control by electric switch open close buttons 6 The Contractor shall be responsible to rehabilitate and modify the existing room nearby the control panels room shall include but not limited to provide install commission and maintenance office desk L shape cabinet with triple drawers three chairs with arms two single tables with glass surface closet with triple drawers and rolling gl
323. wly room for the MCC shall be provided with air conditioner split type in sufficient nos so that the temperature of the panel room shall be maintained to 20 C at any given time 3 The Contractor shall be fully responsible for any civil works required for the panels foundation seal all sleeves of the cables wiring cable trays trunking conduits and conduit boxes cable trench and ducts shall be protected with waterproofing membrane All works specifications and materials shall be subject to the Engineer approval 4 The Contractor shall prepare on his own a safety place as spare parts store to keep store the new spare parts and materials which required for maintenance works during the contract period 5 Any failure of equipment or a part of it shall be replaced with new tested without any extra cost to MPW 6 The Contractor shall be responsible for related civil mechanical electrical and instrumental works required for the proper installation and operation 7 Maintaining and rectification of all damaged utilities and other services affected during the works at no extra cost Tender No SE 130 76 Document 2 III 8 All works specifications and materials shall be subject to the Engineer approval e The Contractor shall disconnect dismantle remove abandonment old HVAC package units with compressors and its related ducting system completely and split air conditioning units with compressors cart away to a tippers off the s
324. xtent of works shall include but not limited to frame board quality materials table stand covered with transparent glass or plastic lightings installations and other related works as approved by the Engineer b The Contractor shall provide install test and commission large colored posters 20 Nos and sizes 60 cm x 50 cm with bronze frame and transparent plastic covers or as directed by the Engineer of different views or locations of existing Ardiya pumping station and Sulaibiya wastewater treatment amp reclamation plant as directed by the Engineer c The Contractor shall provide 500 copies of new booklets with color pictures drawings tables and other related works of existing Ardiya pumping station and Sulaibiya wastewater treatment amp reclamation plant as approved by the Engineer a General 1 K Renovation works of laboratory Partition Rooms furniture equipments and devices reagents and solutions miscellaneous glasses and plastic wares chemical supplies and other related accessories 2 The Contractor shall submit and follow the approved laboratory methods in accordance to the latest new original editions of Standard Methods for the Examination of Water and Wastewater prepared and published jointly by the American Public Health Association the American Water Works Association and the Water Pollution Control Federation 3 The Contractor shall submit manufacturer instructions technical data charts catalogues oper
325. y charger shall be thorn make or equivalent The capacity of Bulbs shall be 2 x 35 W Tender No SE 130 98 Document 2 III e Replace all the existing and power distribution boards with new ones with the approval of the MEW Engineer e Replace all power outlets lighting and power switches and sockets with new ones and with identical capacities e Complete overhauling of the 3 3 KV panels and replace all protection replays and all defective relays and other accessories in the panel e Replace all the vacuum tubes of all the Vacuum circuit breakers e Replace all the power cables of the effluent transfer pumps 1200 KW 3 3 KV e Complete overhauling of the 415 V MCC of the pumping station replace all defective parts and protection relays auxiliary etc e Replace the batteries and battery charger of all panels e Complete overhauling of the instrumentation panel and replace all the gauges controllers and indicators 4 Civil Maintenance and Repair works 1 The Contractor shall be responsible of the civil maintenance works for the whole building of the New Pumping station which includes repair of walls roof slab ladder and other concrete surface treatment and repair of cracks and joints leakages cure of damaged concrete surface making good irregularities and defects including expansion and other joints corrective measures to ensure water tightness replacing defective joints and water stops 2 The Contractor shall dismant
326. ystem sanitary fixtures boiler exhaust fan electrical installations and other related utilities and services The extent of works shall include but not limited to all related civil mechanical electrical and instrumentation works to the satisfaction of the Engineer 2 The extent of works shall include but not limited to clean paint re usable laboratory mechanical and electrical equipments instruments and devices tools pumps etc cart away to a tippers off the site and delivered to MPW stores in new fitting packages similar to original packages with new machine cards and tags numbers plates so that to be easily identified without the necessity of unpacking them 3 The extent of work shall include but not limited to all clean dismantle remove laboratory non usable ferrous metals cart away to a tippers off the site and delivered to MPW stores without packing but shall be covered with large plastic sheets as approved by the Engineer 4 The extent of work shall include but not limited to clean remove all laboratory non valid chemicals and solutions abandonment cart away to a tippers off the site in a legal manner and in accordance to the regulations of the authorities municipality EPA and Engineer approval 5 The Contractor design renovate provide install erect test commission and maintenance the following accessories for the laboratory partition rooms within one 1 year starting from the Date of Enterprise but not limited

Download Pdf Manuals

Related Search

Related Contents

  Philips FWV595 User's Manual  Auto Brightness: How to Improve the Android Mobile  Sommaire - Hachette  データシート  Graco 2797 User's Manual  HÖGKLASSIG  8196165 - Frymaster  Manual de instalación, funcionamiento y mantenimiento  

Copyright © All rights reserved. Failed to retrieve file